board of Port Catirr# 14"1""- -Re"1117 SetnalrY
REGULAR MEETING OF THE BOARD OF PORT COMMISSIONERS
OF THE
CITY OF OAKLAND
The meeting was held on Wednesday, January 7, 1970 at the hour of 2:00 p.m. in the office of the Board, Room 376, 66
Jack London Square, President Walters presiding, due written notice having been given members of the Board.
Commissioners present: Commissioners Bilotti, Gainor,
Mortensen, Tripp and President
Walters - 5
Commissioners absent: Commissioners Berkley and Soda - 2
Also present were the Executive Director; Assistant Exe- cutive Director; Port Attorney; Chief Engineer; Director of Aviation;
Public Relations Director; Secretary of the Board; and for a portion of the meeting Deputy Port Attorney John E. Nolan; Traffic Manager and Manager, Marine Terminals Department; Port Supervising Engineer
Roy Clark; Supervising Airport Traffic Representative Fernand E. Dubois; and Semi-skilled Laborer Edward H. Dillinger.
Outgoing President Robert E. Mortensen presented the new
President, William Walters, with the gavel of his office and President
Walters presented Commissioner Mortensen with a desk set in recognition of his term as President of the Board.
The reading of the minutes of the regular meeting of December
17, and the adjourned regular meeting of December 22, 1969, were approved as written and ordered filed.
The Director of Aviation introduced Mr. Fernand E. Dubois,
Supervising Airport Traffic Representative, to the Board, and First Vice
President Tripp presented Mr. Dubois with a pin denoting 15 years ser- vice to the Port. Port Supervising Engineer Roy Clark introduced Mr.
Edward H. Dillinger, Semi-skilled Laborer, to members of the Board, and Com- missioner Mortensen presented Mr. Dillinger with a pin denoting 35 years service to the Port. Both were congratulated on their many years of devoted service to the Port.
Approval of plans and specifications for construction of dike for Runway 11-29 Extenstion at the Metropolitan Oakland International
Airport, was recommended to the Board by memo from the Chief Engineer, together with authority to advertise for bids to be received on Monday,
February 16, 1970. The recommendation was approved on passage of
Resolution No. 19580.
Building permit, Phillips Petroleum Company service station, as part of the Hilton Inn project at Doolittle Drive and Hegenberger Road, was recommended for approval by memo from the Chief Engineer, drawings of which were displayed to the Board. It was explained that these plans re- place those originally approved by the Board. The building permit was approved on passage of Resolution No. 19560.
Rejection of bids for fill improvements, north of Taxiway "C", south field, at the Airport, was recommended to the Board by memo from the Chief Engineer. It was explained to the Board that the pending merger between Air California and Pacific Southwest Airlines will preclude the need for the Air California hangar at Oakland, and that the site can be filled more economically at a later date. The bids were rejected on pas-
sage of Resolution No. 19561.
Tariff changes requested by Howard Terminal in its Terminal
Tariff No. 4, having to do with carloading and unloading charges and miscellaneous accessorial charges, as explained to the Board by memo
from the Traffic Manager and Manager, Marine Terminals Department, were
approved on motion of Commissioner Mortensen, seconded and passed unan-
imously.
Contract completion for construction of railroad tracks in
the vicinity of Freight and Ferry Streets, Outer Harbor, by the con-
tractor, M. Lummus, Incorporated, on December 16, 1969, was reported
to the Board by memo from the Chief Engineer, and Resolution No. 19562
was passed accepting work performed.
-2- Contract completion for Marshalling Yard Expansion, Phase I, on November 19, 1969 by the contractor, Able Builders Company, was re- ported to the Board by memo from the Chief Engineer, in which it was recommended that the original contract completion date be extended by 87 days to November 3, 1969, due to delays by a sub-contractor in furnishing light poles due to strike action, and that the contractor be assessed $1,600 in liquidated damages for 16 days at $100 per day for the period of November 4 through November 19, 1969. The recommenda- tion was approved on passage of Resolution No. 19563, extending time for performance of contract with Able Builders Company, and Resolution
No. 19564, accepting work performed by Able Builders Company, assessing
liquidated damages and authorizing recordation of notice of completion.
Time extension considerations for Umpqua River Navigation
Company, was the subject of a memo to the Board from the Chief Engineer, in which the Board was informed that the 180-day completion time required under the contract expired January 2, 1970, and that the contractor was delayed 36 days because of labor disputes with the Marine Engineers Bene- ficial Association, and has requested a contract extension for those 36 days. The Chief Engineer informed the Board that the contractor has also
requested an additional 24-day extension due to delay because he was not
able to obtain certain equipment locally, but that the contractor by letter
dated April 24, 1969, had informed the Port that Umpqua Navigation had
"under ownership all equipment necessary for the completion of this project."
It was recommended to the Board that the 36-day delay due to labor disputes
be granted, but that the additional 24-day extension due to lack of equipment be denied; and in this connection Resolution No. 19565 was passed, extending
time for performance of contract with Bohemia Lumber Company Incorporated,
successor to Umpqua River Navigation Company, for 36 days.
Award of contract for construction of mooring dolphin and connect-
ing catwalk off easterly end of Berth "G" Wharf, Seventh Street Marine Terminal,
was the subject of a memo to the Board from the Chief Engineer, in which it
-3- was recommended that the contract be awarded to Ben C. Lerwick Com- pany in the amount of $17,333, which was the low bid among bids received for this work on January 5, 1970, and Resolution No. 19566 was passed as recommended.
A letter entitled, In the Matter of Agreement No. T-2227
Between the San Francisco Port Authority and States Steamship Company,
Docket No. 69-5, was transmitted to the Board by the Port Attorney.
This was a report on the initial decision of the Examiner, issued
December 11, 1969, in which the Hearing Examiner finds the agreement rentals to be compensatory, and recommends approval thereof. It was
explained that the Port had opposed the approval of the agreement on
the basis of the lack of compensatory rental charges in the agreement,
and the resultant competitive disadvantage to the Port of Oakland, and
it was recommended that the Port Attorney be authorized to file exceptions
to the decision, which was approved on motion of Commissioner Mortensen,
seconded and passed unanimously.
Agreement with Woodward-Clyde Associates for Soils Engineering
Services in the Middle Harbor terminal area, was recommended to the Board
for approval by memo from the Chief Engineer, in which he advised the
Board that the cost of the additional borings will not exceed $12,000.
In this connection Resolution No. 19582 was passed authorizing execution
of agreement with Woodward-Clyde E Associates.
Approval of plans and specifications for demolition of wharves,
foot of Ferro Street in Middle Harbor Terminal, was recommended to the
Board by memo from the Chief Engineer, together with authority to ad-
vertise for bids to be received on Monday, February 2, 1970, which
recommendation was approved on passage of Resolution No. 19581.
Application to Bay Conservation and Development. Commission
for filling and dredging permit for Middle Harbor Terminal, was the
subject of a memo to the Board from the Executive Director, which ap-
plication would be for the development which includes the construction
-4- of a rock-faced dike along the water side of the property and filling approximately 12 acres behind the dike, construction of a 1600 foot marginal wharf and dredging approximately 200,000 cubic yards from the proposed berth areas. It was further explained that the proposed development would adjoin the wharf being developed by Seatrain
Lines, Inc., and will result in a four-berth marginal wharf on a
continuous straight line across the face of both parcels of property.
The filing of the permit with BCDC was approved on motion of Commissioner
Tripp, seconded and passed unanimously.
Certificate of Completion for contract with Diamond
Janitorial Service and Supply Company for furnishing labor, material
and equipment for washing the exterior windows of the Airport Terminal
Building, for the period of March 1, 1969 through December 31, 1969,
was recommended for approval by memo to the Board by the Port Purchasing
Agent, and Resolution No. 19567 was passed accordingly.
Approval of award under the Beneficial Suggestion program
to Evelyn B. Johnson, Secretary Stenographer, in the amount of $50.00
for her suggestion havin g to do with the filing of copies of the Beard
minutes in subject files, in the central file room, was recommended to
the Board by the Executive Director, and was approved on passage of
Resolution No. 19568.
Personnel matters contained in the memo to the Board from
the Director of Fiscal Affairs, were approved on passage of Resolution
No. 19569 as to appointments, Resolution No. 19570 as to leaves of
absence, and Resolution No. 19571 ratifying the granting of leave of
absence to Eugene I:: Daley from position of Engineering Aide, and ratifying
his appointment to the position of Port Construction Inspector for a
limited duration.
Authorization for the Executive Director to travel to Washing-
ton, D.C. on January 19, 1970, as a member of the Port and Cargo Systems
-5- Committee of the Maritime Transportation Research Board of the National
Research Council, was approved on passage of Resolution No. 19572.
Waiver of landlord s right to personal property - Murphy s,
Inc., was the subject of a memo to the Board from the Assistant Manager,
Properties Department, in which it was explained that Murphy s has requested such waiver in connection with the installation of certain heavy-duty retread tire machinery by the American Machine F, Foundry
Company. The waiver was approved on passage of Resolution No. 19573.
Real estate commission payment to Hamilton, Cohn, Jones and
Gerow, was recommended to the Board by memo from the Manager, Properties
Department, in the amount of $4,500 in connection with the sale of
Lot D-16 in the Industrial Park to Elwyn C. Gerow and Doris B. Gerow.
The Board inquired as to whether or not there was any interest in the
real estate firm by the purchasers of the property due to the similarity
of names, and Deputy Port Attorney John E. Nolan explained that
Richard Gerow, the son of the purchasers of the property, is a member
of the real estate firm, but that the purchasers of the property have
provided the Port with an affidavit that neither of them has any interest
in the firm of Hamilton, Cohn, Jones and Gerow, and will not participate
in any way in the distribution of the real estate commission. Following
this explanation Resolution No. 19574 was passed, approving and authorizing
payment of real estate brokers commission to Hamilton, Cohn, Jones Gerow.
A motion was made by Commissioner Mortensen that the Jack
London cabin, purchased by the Port and brought to Oakland from the Yukon
territory, be donated to the Oakland Museum, along with the artifacts which
accompany it, explaining that in this matter the cabin would be viewed by
far more people and would be a more lasting tribute to Jack London. The
motion was seconded and passed unanimously.
The following written reports were noted and ordered
filed:
-6-
Status Reports
Summary of Cash - Port Revenue and Construction Accounts as of December 30, 1969.
Summary of Claims paid from various funds from December. 10, 1969 through December 29, 1969.
The following resolutions were introduced and passed
separately by the following vote:
Ayes: Commissioners Bilotti, Gainor, Mortensen,
Tripp, and President Walters - 5
Noes: None
Absent: Commissioners Berkley and Soda - 2
"RESOLUTION NO. 19560
RESOLUTION GRANTING PHILLIPS PETROLEUM COMPANY PERMISSION TO PERFORM CERTAIN WORK AND REPEALING RESOLUTION NO. 19436."
"RESOLUTION NO. 19561
RESOLUTION REJECTING BIDS FOR CONSTRUCTION OF FILL IMPROVEMENTS, NORTH OF TAXIWAY C AT SOUTH FIELD, METROPOLITAN OAKLAND INTER- NATIONAL AIRPORT."
"RESOLUTION NO. 19562
RESOLUTION ACCEPTING WORK PERFORMED BY M. LUMMUS, INCORPORATED, AND AUTHORIZING RECORDATION OF NOTICE OF COMPLETION."
"RESOLUTION NO. 19563
RESOLUTION EXTENDING TIME FOR PERFORMANCE OF CONTRACT WITH ABLE BUILDERS COMPANY."
"RESOLUTION NO. 19564
RESOLUTION ACCEPTING WORK PERFORMED BY ABLE BUILDERS COMPANY, ASSESSING LIQUI- DATED DAMAGES AND AUTHORIZING RECORDATION OF NOTICE OF COMPLETION."
"RESOLUTION NO. 19565
RESOLUTION EXTENDING TIME FOR PERFORMANCE OF CONTRACT WITH BOHEMIA LUMBER COMPANY, INCORPORATED."
-7- "RESOLUTION NO. 19566
RESOLUTION AWARDING CONTRACT TO BEN C. GERWICK CO., A DIVISION OF SANTA FE- POMEROY, INC., FOR CONSTRUCTION OF MOORING DOLPHIN AND CONNECTING CATWALK OFF EASTERLY END BERTH G WHARF, SEVENTH STREET MARINE TERMINAL; FIXING THE AMOUNT OF BONDS TO BE PROVIDED IN CON- NECTION THEREWITH; REJECTING ALL OTHER BIDS; AND DIRECTING RETURN OF BID BONDS TO BIDDERS."
"RESOLUTION NO. 19567
RESOLUTION ACCEPTING WORK PERFORMED BY DIAMOND JANITORIAL SERVICE SUPPLY CO."
"RESOLUTION NO. 19568
RESOLUTION AWARDING THE SUM OF $50.00 TO EVELYN B. JOHNSON, SECRETARY-STENO- GRAPHER, UNDER THE PORT OF OAKLAND EMPLOYEES SUGGESTION PLAN."
"RESOLUTION NO. 19569
RESOLUTION CONCERNING CERTAIN APPOINTMENTS."
"RESOLUTION NO. 19570
RESOLUTION CONCERNING LEAVES OF ABSENCE."
"RESOLUTION NO. 19571
RESOLUTION RATIFYING GRANTING OF LEAVE OF ABSENCE TO EUGENE B. DALEY FROM POSITION OF ENGINEERING AID AND RATI- FYING HIS APPOINTMENT TO POSITION OF PORT CONSTRUCTION INSPECTOR FOR A LIMITED DURATION."
"RESOLUTION NO. 19572
RESOLUTION AUTHORIZING CERTAIN TRAVEL."
"RESOLUTION NO. 19573
RESOLUTION AUTHORIZING EXECUTION OF LANDLORD S WAIVER TO AMERICAN MACHINE FOUNDRY COMPANY."
"RESOLUTION NO. 19574
RESOLUTION APPROVING AND AUTHORIZING PAYMENT OF REAL ESTATE BROKERAGE COM- MISSION TO HAMILTON, COHN, JONES GE ROW."
-8- "RESOLUTION NO. 19575
RESOLUTION AUTHORIZING EXECUTION OF FIRST SUPPLEMENTAL AGREEMENT WITH ADMAR SAILS ."
"RESOLUTION NO. 19576
RESOLUTION AUTHORIZING EXECUTION OF LICENSE AGREEMENT WITH PUGET CATERERS, INC."
"RESOLUTION NO. 19577
RESOLUTION AUTHORIZING EXECUTION OF SECOND SUPPLEMENTAL AGREEMENT WITH MARINE BARRIERS, INC."
"RESOLUTION NO. 19578
RESOLUTION APPOINTING PHYLLIS A. HERNDON TO THE POSITION. OF SECRETARY TO THE PORT ATTORNEY AND SUPERVISING LEGAL SECRETARY."
"RESOLUTION NO. 19579
RESOLUTION APPROVING BONDS OF ROTHSQIILD BAFFIN, INC."
"RESOLUTION NO. 19580
RESOLUTION APPROVING PLANS AND SPECIFI- CATIONS FOR CONSTRUCTION OF DIKE FOR RUNWAY 11-29 EXTENSION AT METROPOLITAN OAKLAND INTERNATIONAL AIRPORT AND CALLING FOR BIDS THEREFOR."
"RESOLUTION NO. 19581
RESOLUTION APPROVING PLANS AND SPECIFI- CATIONS FOR DEMOLITION OF WHARVES AT THE FOOT OF FERRO STREET AND CALLING FOR BIDS THEREFOR."
"RESOLUTION NO. 19582
RESOLUTION AUTHORIZING EXECUTION OF AGREEMENT WITH WOODWARD-CLYDE ASSOCI- ATES ."
"RESOLUTION NO. 19533
RESOLUTION APPROVING BONDS OF BEN C. CliRWICK CO . , A DIVISION OF SANTA FE- POMEROY , INC."
-9-
"RESOLUTION NO. 19584
RESOLUTION AUTHORIZING EXECUTION OF CERTAIN SUPPLEMENTAL AGREEMENTS."
"RESOLUTION NO. 19585
RESOLUTION AUTHORIZING EXECUTION OF CER- TAIN LICENSE AND CONCESSION AGREEMENTS."
Port Ordinance No. 1623 being, "AN ORDINANCE AMENDING
SECTION 6.03 OF PORT ORDINANCE NO. 867 RELATING TO THE POSITION OF
SECRETARY TO THE PORT ATTORNEY AND SUPERVISING LEGAL SECRETARY",
and Port Ordinance No. 1624 being, "AN ORDINANCE AMENDING ITEMS
NOS. 760 AND 2655 OF PORT ORDINANCE NO. 964 RELATING TO WHARFAGE
RATES AND SPACE ASSIGNMENTS", and Port Ordinance No. 1625 being,
"AN ORDINANCE AMENDING PORT ORDINANCE NO. 1606 FORMULATING AND
ESTABLISHING CONDITIONS AND PROCEDURES FOR BIDDING, CONTRACTING
AND PURCHASING", and Port Ordinance No. 1626 being, "AN ORDINANCE
AMENDING SECTION 5.15 OF PORT ORDINANCE NO. 867, CREATING ONE
ADDITIONAL POSITION OF JANITOR", were read a second time and
finally adopted by the following vote: Ayes: Commissioners Bilotti, Gainor, Mortensen,
Tripp and President Walters - 5 Noes: None Absent: Commissioners Berkley and Soda - 2
There being no further business and on motion duly made
and seconded, the meeting was adjourned at 3:00 p.m. Board of Port CorranissionMeeting Secretary %
REGULAR MEETING OF THE BOARD OF PORT COMMISSIONERS
OF THE
CITY OF OAKLAND
The meeting was held on Wednesday, January 21, 1970, at the hour of 2:00 p.m. in the office of the Board, Room 376,
66 Jack London Square, President Walters presiding, due written notice having been given members of the Board.
Commissioners present: Commissioners Berkley,
Bilotti, Gainor, Mortensen,
Soda, Tripp, and
President Walters - 7
Commissioners absent: None
Also present were the Executive Director; Assistant
Executive Director; Port Attorney; Traffic Manager and Manager,
Marine Terminals Department; Airport Manager; Chief Engineer;
Assistant Mauagul, Properties Department; Secretary of the
Board; and for a portion of the meeting, Deputy Port Attorney
John E. Nolan.
Visitors attending the meeting included Mr. Paul Cobb,
Chairman, and Miss Julia Lightfoot, Secretary, representing the Oakland Black Caucus; Mr. Virtual Murrell, Field Representative,
Urban League; Mr. Carl Jerabek, General Manager, Oakland Hilton Inn;
Mr. Robert M. Morris, Jr. Architect, Smith-Corona Marchant Build- ing; Mr. Cecil A. Beasley, Jr., legal counsel for the Port of
Oakland in Washington, D.C.; Mr. Carl Young, Graduate Siudirt; U.C.,
Berkeley; Mr. John Keating, Jr., Vice President, Western Title
Guaranty Company; Mrs. Alexandra Close, Catholic Voice; Mr. Armond
Robinson, Student, San Francisco Theological Seminary; and Mr.
Jim Cornish. The minutes of the regular meeting of January 7, 1970, were approved as written and ordered filed.
Hilton Rent-A-Car, was the subject of a memo to the
Board from the Assistant Manager, Properties Department, advising the_Board that Hilton Hotels Corporation has requested that its lease with the Port of Oakland for the operation of a hotel on Port property at Doolittle Drive and Hegenberger Road, be amended to permit the operation of a rent-a-car service for its guests. Mr. Carl Jerabek, General Manager of Oakland Hilton
Inn, appeared before the Board in support of the request. The
Board was advised that Hilton agrees to pay as commission to the
Port, the identical amount assessed by the Port to other rent- a-car agencies such as Hertz, Avis and National at the Airport.
Amendment of the lease on this basis was approved on motion of
Commissioner Mortensen, seconded and passed unanimously.
Building permit application addition to Airweld
Building, North Airport, was the subject of a memo to the Board from the Chief Engineer, recommending approval of the addition of a 20 x 33 section to be added to the present structure to eliminate outside storage. The recommendation was approved on passage of Resolution No. 19586, granting Airweld, Inc. permission to perform certain work.
Pacific Northwest-California Investigation, Civil Aero- nautics Board Docket No. 18884, was the subject of a letter to the Board from the Port Attorney advising the Board that oral argument in this matter will be heard in Washington, D. C. on
February 4, 1970, and recommending that the Port Attorney be authorized to attend, which recommendation was approved on passage of Resolution No. 19587, which resolution also approved travel for
-2-- the following: attendance at the Airport Operators Council Inter- national, Special Legislative and Federal Policy Conference, held in Washington, D.C. on January 22 and 23, to be attended by the
Director of Aviation; attendance at the Airport Operators Council
International Seminar on Airport Financing, Property Management,
Negotiation with Airlines, Rates and Charges for Airline Tenants, etc., on February 12 and 13 in Savannah, Georgia, to be attended by those members of the Board who desire to attend, and the Chief
Engineer, who will make stops at Tampa, Florida, on February 10, returning via Houston and Dallas, Texas, on February 13 and 14; and travel to Seattle, Washington, to inspect the facilities of the Port of Seattle by members of the Board, the Executive
Director, Traffic Manager and Manager, Marine Terminals Department,
Chief Engineer and Senior Engineer Keith Quan.
Claim of Edith O. Burris, was the subject of a letter to the Board from the Port Attorney; advising the Board that on
January 9, 1970, Edith 0, Burris presented a claim for personal injuries in an as yet unascertained amount, alleging that she was injured on October 5, 1969, in a slip-and-fall accident in the
Finger Building at the Airport. The Port Attorney recommended that the claim be rejected, which recommendation was approved on passage of Resolution No. 19603.
Plans and specifications for fence around Building C-226,
Maritime Street, Outer Harbor, were recommended for approval, with authority to advertise for bids to be received on February 9, 1970, as explained to the Board in a memo from the Chief Engineer, The recommendation was approved on passage of Resolution No. 19588,
Water line relocation, Ferry Street, Outer Harbor, East
Bay Municipal Utility District Agreement, was the subject of a
-3- memo to the Board from the Chief Engineer, in which the Board was advised that an agreement has been worked with the District to perform the work at a cost of $5,260, approval of which was recommended. Such agreement was approved on passage of Resolution
No. 19589.
Agreement between the East Bay Municipal Utility District, the City of Oakland and the Port, for relocation of water main,
Seventh Street underpass, was the subject of a memo to the Board from the Chief Engineer, in which the Board was advised that under the Economic Development Administration project, for the con- struction of the Seventh Street Marine Terminal, it is necessary to relocate approximately 380 feet of 16-inch water line from the right-of-way, to an easement secured from the Southern Pacific
Company, adjacent to the right-of-way, and to relocate two exist- ing fire hydrants and two water services connected to the 16-inch main, which work is estimated to cost $22,216 but not to exceed
$25,000. The Board was further advised that a dispute has arisen as to whether the District should be paid for the cost of the relocation, and because of this dispute, the work would proceed if approved by the Board under the following conditions:
1. District will proceed immediately to relocate the water line on an easement furnished by the City.
2. Upon completion of the work, the District will determine the exact cost in accordance with sound accounting principles less value of better, ments to the District such as greater capacity than now exists, salvage value of materials removed, if any, and accrued depreciation on facilities replaced by the District. The Port shall have access to District records for audit- ing purposes. Costs shall not exceed $25,000 without prior Port approval. If actual costs exceed the estimated costs, the Port will pay the District the excess amount within 30 days. Conversely, if the actual cost is less, the District will refund the difference to the Port within 30 days.
-4- Nothing in the agreement shall be deemed an admission or waiver of existing rights and each party shall have the same rights as each would have if the District had refused to perform the work until compelled to do so by court order or judgment.
4. If litigation is commenced and the Port prevails in the action, the District shall refund to the Port the amount stated in the judgment together with interest at the legal rate from the date of entry of said judgment until paid. Each party shall bear its respective attorney s fees and costs.
Execution of the agreement under the above terms was approved on passage of Resolution No. 19590.
Agreement with East Bay Municipal Utility District for construction of water facilities on Port properties at the Seventh
Street Marine Terminal, was the subject of a memo to the Board from the Chief Engineer, recommending approval of an agreement with the District to construct a 12-inch water main facilities, fire hydrants and appurtenances within the Economic Development
Administration project, for the construction of the Seventh
Street Marine Terminal, which agreement was approved on passage of Resolution No. 19591.
Installation of water lines for fire protection, Seventh
Street Marine Terminal, was the subject of a memo to the Board from the Chief Engineer, recommending that agreement be approved with the East Bay Municipal Utility District to install fire protection connections to four of the facilities being constructed under the
Economic Development Administration program, which recommendation was approved on passage of Resolution No. 19595.
Changing of certain street designation in the Outer
Harbor Area to relieve traffic congestion, as recommended to the
Board by memo from the Traffic Manager and Manager, Marine Terminals
Department, was approved on passage of Resolution No. 19592.
-5- Contract completion by Malott Peterson Roofing Co.,
Inc., on December 9, 1969, for reroofing portions of Terminal Build- ing "F", at Seventh and Terminal Streets, was reported to the Board by memo from the Chief Engineer, in which the Board was informed that this completion was 12 days beyond the required completion time of November 27, 1969, as provided in the contract, and that the Chief Engineer has recommended the assessment of liquidated damages in the amount of $10 per day, or $120. In this connection
Resolution No. 19593 was passed accepting work performed by Malott