SECTION C

SPECIFICATIONS

TECHNICAL SUBMISSION SECTION C SPECIFICATION

CONTENTS

PART 1 GENERAL SPECIFICATION C1/1 – C1/3

PART 2 PROJECT SPECIFICATION C2/1 – C2/4

IA D-HC 14/15 C 086 I C/Contents August 2015 & Rayyan Sewerage Scheme Phase-II Reinstatement Project # 08/2014

SECTION C

PART 1

GENERAL SPECIFICATION

TECHNICAL SUBMISSION SECTION C – PART 1 GENERAL SPECIFICATION

GENERAL SPECIFICATION

GOVERNMENT PUBLISHED SPECIFICATIONS, REGULATIONS, NOTICES AND CIRCULARS

A. The Works shall be executed in accordance with the following latest Government Specifications, Regulations, Notices and Circulars:

(a) The General Conditions of Contract – May 2007 prepared by the Contracts & Engineering Business Affairs (CEBA) Public Works Authority, P.O. Box 22188, Doha, State of ; (b) The Qatar Construction Specifications (QCS 2014) prepared by the Qatar General Organization for Standards and Metrology (QGOSM) issued with Standard no. 210/2014 for use commencing April 5th 2015 and all subsequent revisions and amendments prior to the date of the announcement inviting Tenderers. (c) The Code of Practice and Specification for Trench Works/Road Openings in the Highway prepared by the Ministry of Industry and Public Works, January 1992 with May 2013 amendments and revisions. (d) The Guide for Civil Users of Explosives in Qatar prepared by the Ministry of Public Works. (e) The Qatar Survey Manuals prepared by the Urban Planning and Development Authority (UPDA). (f) All current Public Works Authority regulations concerning the organisation of Tenders and Public Auctions and all subsequent revisions and amendments. (g) Work Zone Traffic Management Guide (WZTMG), Revision 1.1, July 2014 and all subsequent revisions and amendments. (h) The Regulations for the Installation of Electrical Wiring, Electrical Equipment and Air Conditioning Equipment, sixth re-issue dated January 1992 as prepared by the Ministry of Electricity and Water, P O Box 41, Doha. (i) Any current and relevant regulation, notice or circular issued by the Public Works Authority (including the previous Ministry of Municipal Affairs & Agriculture, Ministry of Public Works and Ministry of Industry & Public Works) the Qatar General Electricity and Water Corporation (KAHRAMAA), Ooredoo (previously known as Qatar Telecom/Q-tel), the Qatar General Organization for Standards and Metrology, the Supreme Council for the Environment and Natural Reserves or the appropriate local Municipality prior to the date of the letter or advertisement inviting Tenderers. (j) Any and all applicable local Municipality regulations. (k) State of Qatar Law No. 6 of 1987 and all subsequent amendments concerning Materials and Equipment from Qatar or other CCASG countries, obtainable from Ministry of Justice, Doha, Qatar.

IA D-HC 14/15 C 086 I C1/1 August 2015 Doha & Rayyan Sewerage Scheme Phase-II Reinstatement Project # 08/2014

TECHNICAL SUBMISSION SECTION C – PART 1 GENERAL SPECIFICATION

(l) CESMM3, Civil Engineering Standard Method of Measurement, 3rd Edition (1991), published for the Institution of Civil Engineers by Thomas Telford Services Ltd, 1 Heron Quay, London, W14 4JD and all subsequent revisions and amendments. (m) State of Qatar Law No. 30 of 2002 and all subsequent amendments concerning “The Environment and Natural Resources Protection” – Articles 6, 17, 19 & 35, obtainable from Ministry of Justice, Doha, Qatar. (n) State of Qatar Law No. 32 of 2002 which amended Article 2 of Law No. (1) for the year 1993 concerning the regulations to issue license to level the agricultural lands or beach sands and all associated rules and regulations issued by the Supreme Council for the Environment and Natural Resources, obtainable from Ministry of Justice, Doha, Qatar. (o) State of Qatar Law No. 32 of 2005 and all subsequent amendments concerning Traffic in the State of Qatar obtainable from Ministry of Justice, Doha, Qatar. (p) The Drainage Affairs (DA), Design Manual (Qatar Sewerage and Drainage). (q) All current Water Department and Electricity Department of the Qatar General Electricity and Water Corporation (KAHRAMAA) specifications and all sequent revisions and amendments. (r) Safety Rules issued by the Department of Electricity Networks. (s) The Jointing Manual prepared by Electricity Networks Department. (t) The Qatar Traffic Manual (QTM) and Qatar Highway Design Manual (QHDM) prepared by the Ministry of Public Works. (u) Drafting Standards prepared by Public Works Authority. The successful Tenderers shall maintain a copy of the above documents (a) to (u) on site for Engineer's Reference.

B. The Contractor shall be deemed to have his own copy of the Government specifications, regulations, notices and circulars given at (a) to (u) above. C. These Government specifications, regulations, notices and circulars are amended and complemented by "Part 2 - Project Specification" as detailed hereafter. D. In the case of any ambiguity or discrepancy the provisions of the Project Specification shall prevail over the provisions of the Government published specifications. E. The Contractor shall contact the Survey Section of the Ministry of Municipal Affairs and Agriculture for prior earthwork or other works to determine if the work is likely to disturb survey marks. If Survey Section require a survey mark to be moved the Contractor will be responsible for recreating the survey mark to an approved design and specification, and for resurveying the point using survey companies approved by the Survey Section. F. The Contractor shall be responsible for the protection of the Survey marks, within the boundaries of the site, for the duration of the contract period, and shall be liable for all costs of any remedial work required of the Survey Section. G. On the practical completion of the work, the Survey Section will issue a certificate stating that all survey marks, whether disturbed or otherwise, by the Contractor have been reinstated or protected to the satisfaction of the Survey Section. IA D-HC 14/15 C 086 I C1/2 August 2015 Doha & Rayyan Sewerage Scheme Phase-II Reinstatement Project # 08/2014

TECHNICAL SUBMISSION SECTION C – PART 1 GENERAL SPECIFICATION

H. In the event of failure to comply with the requirements of the above Clause PWA, without prejudice to any other rights and privileges and method of recovery, may deduct the costs of any remedial work after the practical completion date, carried out by Survey Section from any monies due or which become due to the Contractor. I. Where any Standard Publication, Specification, Regulation, Notice, and the like or any correspondence refers to a Government Ministry, Department, Division, Section, and the like it will be deemed to be the same as any successor Ministry, Department, Division, Section, and the like which has or may subsequently be officially promulgated by the Government of the State of Qatar The Contractor shall arrange to obtain following Clearance Certificates from the appropriate authorities upon completion of the works:

1. Municipality Backfill Excavation Certificate – to certify that the site has been cleared of all debris. 2. CGIS Survey Clearance Certificate – to certify that all the survey control stations are undisturbed. 3. Land Information Centre Clearance – to certify that all street name boards and signs are in satisfactory condition.

J NOTICE TO PUBLIC ON ROAD CLOSURES

Upon approval from Engineer’s representative on any road closure for the purpose of carrying out the works of PWA, the Contractor shall place a sufficient notification to the general public in local newspapers both in and English languages at least one (1) week prior to the road closure. The contents of the notification shall be approved by the Engineer and the extent shall not be less than a quarter of the standard size page of a reputed local newspaper. In order to evident the notification the contractor shall submit to the Engineer a copy as appeared on the newspaper on the same day of the notification.

K MEDIA DOCUMENTARY (PHOTOGRAPHIC & VIDEO)

The Contractor shall obtain a photographic and video record showing the progress of the works in every month, and / or as necessary, in order to provide sufficient visual evidence of the progress and to record the specialized events features of the works or other matters of interest in connection with the works or other matters of interest in connection with the works or their surroundings of the project. Such media documentation shall be submitted to the Engineer in the form of an accepted media document as a complete package at the completion of the project.

IA D-HC 14/15 C 086 I C1/3 August 2015 Doha & Rayyan Sewerage Scheme Phase-II Reinstatement Project # 08/2014

SECTION C

PART 2

PROJECT SPECIFICATION

TECHNICAL SUBMISSION PROJECT SPECIFICATION SECTION C – PART 2 SPECIFIC REQUIREMENTS

PART 2 - PROJECT SPECIFICATION 1. GENERAL CONDITIONS AND CONTRACT REQUIREMENTS 1.1 SCOPE OF WORK TO BE CARRIED OUT (1) The following is a general outline of the scope of work, however the full scope and extent of the works forming the contract is based on the Bills of Quantities of this Tender document. Quantities entered into the Bills of Quantities are a genuine pre-estimate by the Engineer or quantities that are expected to result from the contract.

(2) Individual Work Order shall be issued for each works covered by this contract, which shall follow this BOQ and the rates and are subject to re-measurement in accordance with Clause 55.1 and 55.2 of the Conditions of Contract and no claim for adjustment to the re- measured Contract Price or Rates due to discrepancies between Billed and measured quantities will be entertained.

(3) Works shall be issued either as groups or single. each works shall have an individual start and completion date, depending on the size and complexity of work.

(4) If the contractor shall fail to complete the work within the specified period, then the contractor shall pay to PWA, 0.5% of each work order sum or part thereof per day as delay penalty for such default for everyday which shall elapse between the times specified for each Job and date of actual completion of the work order.

(5) The Works are as described in the "Brief Description of Works"

(6) The scope of works comprises Phase-2 Reinstatements at 111 Nrs House Connection/Jobs at different location of Doha & Rayyan, and to be carried out as detailed below. i. Reinstatement in Major Roads: It shall be carried out after milling the existing wearing course as per length & width shown in the construction drawings/list or as decided by the Engineer as per Site. The thickness of Phase-II shall be maximum 50mm or as per site existing thickness. The works shall be carried out in accordance with latest code of Practice. The reinstatement shall be machine laid deploying only approved Class-A Road Contractor.

ii. 2-Phase-II Reinstatement in Minor Roads: It shall be carried out after removing the existing intermediate course as per length & width shown in the construction drawings/list or as decided by the Engineer as per Site. The thickness of Phase-II shall be maximum 70mm or as per site existing thickness. The works shall be carried out in accordance with latest code of Practice. The reinstatement shall be machine laid deploying only approved Class-B Road Contractor.

 Works shall be issued as Work Orders and each work order may consist of either one or more than one house connection, depending on the scope and extent of works involved.  Every Work Order shall have a start and completion date and the contractor has to complete it within the specified period.

iii. The Reinstatement works shall be carried out in accordance with Amendment to Code of Practice and Specifications for Road Opening in the Highways (May 2013).

IA D-HC 14/15 C 086 I C2/1 August 2015 Doha & Rayyan Sewerage Scheme Phase-II Reinstatement Project # 08/2014

TECHNICAL SUBMISSION PROJECT SPECIFICATION SECTION C – PART 2 SPECIFIC REQUIREMENTS

1.2 THE SITE AND LOCATION OF THE WORKS (1) The Works are to be carried out at 111 No. House Connection/Jobs at different location of Doha & Rayyan as detailed below. Phase-2 Quantity ZONE (Sq.M) S.NO JOB NO ZONE NAME NO Major Minor Roads Roads 1 40/14 53 New Rayyan 61.5

2 43/14 55 Al Manaser 36.5

3 62/14 54 Al Soudan 93

4 75/14 53 New Rayyan 25

5 125/13 35 Al Azizia 73

6 151/13 55 Al Muhaither 134

7 152/13 53 Al Muhaither 36.5

8 219/13 53 New Rayyan 58.25

9 280/13 53 Al Muhaither 25

10 369/13 55 Al Manaser 62

11 396/13 55 Al Azizia 73

12 401/13 54 Al Soudan 93

13 to 14 405/13 & 60/14 54 233.6

15 421/13 53 New Rayyan 25

16 463/13 53 New Rayyan 184.5

17 469/13 53 New Rayyan 73

18 204/13 55 Abu Sidra 36.5

19 143/13 53 Al Muhaither 36.5

20 109/14 38 Al Saad 73

21 141/13 35 Al Kulaib 47

22 106/13 34 Madina al Khalifa South 50.5

23 181/14 34 M.K. South 177.6

24 72/14 34 M.K. South 75

25 321/13 34 M.K. South 84

26 366/13 34 M.K. South 37

27 78/14 34 M.K. South 75

28 380/13 34 M.K. South 75

29 139/13 33 Al Markiya 75

30 340/13 67 75

31 141/14 65 75

32 316/13 65 Onaiza 75

33 349/13 66 Onaiza 75

34 437/13 66 Al Kutaifiya 75

35 429/13 66 Al Kutaifiya 37.5

36 438/13 67 Hizam Al Markiya 75

37 439/13 67 Hizam Al Markiya 75

38 339/13 67 West Bay 75

IA D-HC 14/15 C 086 I C2/2 August 2015 Doha & Rayyan Sewerage Scheme Phase-II Reinstatement Project # 08/2014

TECHNICAL SUBMISSION PROJECT SPECIFICATION SECTION C – PART 2 SPECIFIC REQUIREMENTS

Phase-2 Quantity ZONE (Sq.M) S.NO JOB NO ZONE NAME NO Major Minor Roads Roads 39 362/13 67 West Bay 165 40 420/13 67 West Bay

41 173/14 68 74

42 466/13 68 Jelaiah 37

43 470/13 68 Al Tarafa 75

44 104/14 32 75

45 419/13 40 New salata 37.5

46 150/13 40 New salata 37.5

47 162/13 24 Rawadat Al Khail 30

48 195/13 45 135

49 215/13 45 Old Airport 37.5

50 402/13 47 Al Thumana 75

51 468/13 47 Al Thumana 80

52 300/13 48 International Airport 120

53 112/14 67 Hezam 130

54 122/14 67 Hezam Al Markhiya 74

55 151/14 55 Al Sudan 50

56 238/14 55 Abu sidra 74

57 157/14 52 Old Rayyan 74

58 226/14 55 Al 37

59 118/14 19 80

60 243/14 41 37

61 222/14 55 Al Ghanim Al Jadeed 284.9

62 214/14 34 M.K. South 187

63 179/12 55 Abu Sidra 40

64 356/12 52 37

65 90/12 36 Al Messeila 321.45

66 81/2013 43 Al 100

67 235/12 43 Al Nuaija 91.25

68 118/12 53 New Rayan 323.47

69 02-/2013 53 25

70 34/2013 53 Al Rayyan 60

71 65/2013 53 Al Rayyan 95

72 98/2013 53 Al Rayyan 37

73 95/12 68 Al Tafa 73

74 259/12 22 Bin Mahmoud 70

75 394/12 22 Bin Mahmoud 70

76 to 80 5 Nos of Jobs Doha & Al Rayyan 225

81 4 Nos jobs Doha & Al Rayyan 110

82 190/12 52 182

83 184/12 34 M.K. South 536

84 191/12 34 M.K. South 72.9

85 327/12 55 Muhaither 19

86 50/12 55 Muhaither 146

IA D-HC 14/15 C 086 I C2/3 August 2015 Doha & Rayyan Sewerage Scheme Phase-II Reinstatement Project # 08/2014

TECHNICAL SUBMISSION PROJECT SPECIFICATION SECTION C – PART 2 SPECIFIC REQUIREMENTS

Phase-2 Quantity ZONE (Sq.M) S.NO JOB NO ZONE NAME NO Major Major Roads Roads 86 50/12 55 Muhaither 146

87 51/2012 55 Muhaither 36.75

88 117/12 53 Muhaither 36.5

89 168/12 53 Muhaither 81.95

90 335/12 53 Muhaither 56.80

91 74/13 55 Muhaither 63.75

92 296/12 16 Old Airport 73

93 199/12 16 Old Ghanim 60

94 119/12 52 Old Rayyan 200

95 33/12 63 Onaiza 73

96 60/12 67 West Bay 146

97 125/12 67 West Bay 37

98 139/12 67 West Bay 36

For future 99 to connections phase Misc. Doha & Al Rayyan 300 300 110 2 Reinstatement 111 Job B-1168 53 New Rayyan 1268

Total Quantity Of Phase-2 Reinstatement (SQ.M) 5694.37 4481.30

IA D-HC 14/15 C 086 I C2/4 August 2015 Doha & Rayyan Sewerage Scheme Phase-II Reinstatement Project # 08/2014