CENTRAL REGION (Formed Under Section 42(5) of the Electricity Act 2003) 220 Kv Substation Compound, HMT Colony P.O

Total Page:16

File Type:pdf, Size:1020Kb

CENTRAL REGION (Formed Under Section 42(5) of the Electricity Act 2003) 220 Kv Substation Compound, HMT Colony P.O 1 CONSUMER GRIEVANCE REDRESSAL FORUM CENTRAL REGION (Formed under Section 42(5) of the Electricity Act 2003) 220 kV Substation Compound, HMT Colony P.O. Kalamassery, Pin – 683 503 Phone No. 0484-2556500 Website: cgrf.kseb.in, Email: [email protected], CUG No. 9496008719 Present (1) Smt.Soudamini B Chairperson (2) Smt. S.N.Sheeba. Member (3) Sri. Jefrin Manuel Member Petitioner Sri. V.J. George, AIS Road, Schoolppady, Vadassery House, Vaduthala, Kochi – 682 023. Respondent 1) The Asst.Exe. Engineer, Electrical Sub Division, Central, Ernakulam 2) The Asst. Engineer, Electrical Section, KSEBL, Vaduthala ======================================================== No.CGRF-CR/OP No.34/2020-21/297 Date :17-11-2020 O R D E R Background of the case: The petitioner, Sri.George V.J., Vadassery (H), AIS Road, Vaduthala P.O., Kochi – 682023, is a domestic consumer under the jurisdiction of Electrical Section, Vaduthala. The petitioner had registered for solar plant on 19-03-2020 and received feasibility report from KSEBL on 29-04-2020. Thus the petitioner submitted an application to register his solar plant and received an acknowledgement on 07-05-2020. On completion of installation, the petitioner submitted an application and received its confirmation on 18-05-2020 to test and connect the plant to grid. The consumer states that on 04-06-2020, Smt.Smitha, AEE, informed him about the inspection to test the plant on 05-06-2020 and fixed time at 10 am (+ / - 15 min). Hence the petitioner arranged the technician 2 by 9:30 am. Thus the technician waited till 10:30 am and left for an urgent call a couple of minutes before the arrival of AEE. When the AEE arrived and enquired for technician, the petitioner replied that he will be back in a minute. But the AEE did not wait and returned back. Thus the petitioner called the AEE for her next convenient time; but got an arrogant reply that it could be at mid-day or evening. Thus the petitioner requested the AEE to inform before she comes to the site so that he could arrange the technician. But the AEE reached the site at 12 pm without any intimation and enquired for technician, who was not present. Thus the AEE left the site without conducting the inspection. On 03-07-2020, the petitioner again visited Electrical Section, Vaduthala, and informed through letter that the solar plant has not yet tested. Thus the Assistant Engineer informed that they are not informed about the site visit and advised the petitioner to contact the office of the AEE where she reports. On 07- 08-2020, the petitioner sent a letter with Regd. AD to Electrical Section, Vaduthala; but no reply was received from that end. The petitioner states that he received a call from Smt.Sajila, Assistant Engineer, informing about the test on 08-08-2020 at 9:30 am. In this connection, a letter was received from Electrical Section, Vaduthala, on 17-08-2020 informing that the solar plant test was over and that to execute the agreement and net meter. The petitioner states that he was keeping a track of solar testing around his premises and understood that the Assistant Executive Engineer has been testing other solar plants around his premises and thereby purposefully ignored testing his solar plant. The petitioner claims that the Assistant Executive Engineer was trying to block him so that his solar plant not to get tested causing heavy loss amounting to Rs.45,637/- to him. Thus the petitioner demands to settle his reasonable claim at the earliest. List of damage:- Delayed days from date of approval to test – 86 Bill at present tariff of Rs.5.95/- - Rs.4195/- Rate of unused units - Rs.948/- Interest @ 8.50% - Rs.5494/- Legal fee paid - Rs.10000/- Humiliation and mental torture - Rs.25000/- Total - Rs.45637/- 3 Subsequently, statement of facts was called for and the same was submitted by the respondent on 13-10-2020. The Forum afforded an opportunity to hear the Petitioner and Respondent on 20-10-2020. Both the petitioner and the respondent were present for hearing. Version of the Respondent: The electric connection with consumer number–16528 under the jurisdiction of Electrical Section, Vaduthala, was given to Sri.George V.J., Vadassery House, Vaduthala, under LT 1A tariff with a connected load of 4500 Watts. The petitioner submitted an application on 19-03-2020 for feasibility certificate in order to install a 3 kWp solar plant in his premise. The feasibility certificate was issued to the petitioner on 30-03-2020. The petitioner then submitted an application for registration of solar plant in Electrical Section, Vaduthala on 07-05-2020. He also remitted a registration fee of Rs. 3,000/- on the same day. After the installation of the solar plant, the petitioner submitted an application at Electrical Section, Vaduthala, for testing the solar plant on 18- 05-2020. As per the KSEB Circular No.C.E. (E.R.S)/Projects/AEE-6/Solar- General/16-17/766(1)/dated 09-09-2016, the testing is to be completed within ten days from the date of application from the consumer. As per the directions in this circular, the application for the testing was submitted to Electrical Division, Ernakulam on 19-05-2020 for arranging the testing. The details of the consumers for solar plant testing are intimated to the Meter Testing Sub Division, Kalamassery from the Electrical Division. The schedule for the testing is decided by the testing team of Meter Testing Sub Division, Kalamassery and is intimated to the concerned Assistant Engineers of the respective Sections and the consumers in advance. In the present case, the details of the consumer was sent to Meter testing Sub Division, Kalamassery on 27-05-2020 from Electrical Division, Ernakulam. As per the information received from the AEE, Meter Testing Sub Division, Kalamassery, the testing of this consumer was arranged on 05-06- 2020. Out of the 15 nos. of testing arranged on that day, this was the second test. The testing team reached the site at around 10:15 am but the Solar Technician was not present in the site. Without the help of the Technician, it was not possible to check the safety settings of the plant. As there were many other solar plant testing pending for the day, the testing team went to other sites 4 for testing. The testing team again returned to the site at around 12:30 pm but the Technician was still not present in the site. As all the testing was to be completed before the sunset, the testing team went to other sites. So the testing could not be completed as scheduled. The petitioner then gave a written complaint to the Assistant Engineer, Electrical Section, Vaduthala on 03-07-2020 for testing the solar plant. The same was submitted to Electrical Division, Ernakulam. The Executive Engineer of that Division directed to arrange the testing after properly intimating the consumer in advance. The Assistant Executive Engineer, Meter Testing Sub Division, Kalamassery has submitted an explanation letter to the Executive Engineer for the pendency of testing. But due to the hectic schedule of the testing team, the testing could not be scheduled. On 11-08-2020, the AEE, Meter Testing Sub Division, Kalamssery informed that they have scheduled testing of solar plants under Electrical Section, Vaduthala, the very next day on 12-08-2020. The same was intimated to the consumer and solar technician in advance. The solar testing was completed on 12-08-2020. The net meter was installed and solar plant was commissioned on 15-08-2020. The respondent states that the testing team had reached the site two times on 05-06-2020 for testing the solar plant. But on both these occasions, the Technician was not present on the location. The presence of the Technician was very essential in checking the safety settings of the plant. Due to the increasing numbers of new solar plant installations, the schedule of the testing team is very tight. It may please be noted that there were 15 nos. of testing arranged on 05- 06-2020 itself. Considering the fact that the testing hours are limited by the availability of sunlight, the testing team can not waste much time in a single premises. The respondent has stated that as per Section 57 of the Electricity Act 2003, the power to fix the rate of compensation to be paid to a consumer rests with the Kerala State Electricity Regulatory Commission. The rates of compensation to be paid are as per Schedule-1 of the Kerala State Electricity Regulatory Commission (Standard of Performance of Distribution Licenses) 5 Regulations, 2015. But this Schedule-1 does not have the rate of compensation in case of failure to test the solar plant in the stipulated time frame. Thus the calculation of damages by the petitioner is without legal basis and KSEBL is not liable to pay this damages as demanded by the petitioner. Analysis and findings: Having examined the petition in detail, and the statement of facts of the respondent, considering all the facts and circumstances in detail, and perusing all the documents of both sides, the Forum comes to the following observations, conclusions and decisions thereof The petitioner has a complaint with OP No. 21/2020-21 filed before this Forum and the complaint pertain to the delay and subsequent compensation for this subject case referred in OP No.34/2020-21. The petitioner had submitted a request before the respondent for testing the solar plant installed in the premises, vide letter dated 18-05-2020.
Recommended publications
  • Accused Persons Arrested in Eranakulam City District from 05.08.2018 to 11.08.2018
    Accused Persons arrested in Eranakulam City district from 05.08.2018 to 11.08.2018 Name of Name of the Name of the Place at Date & Arresting Court at Sl. Name of the Age & Cr. No & Sec Police father of Address of Accused which Time of Officer, which No. Accused Sex of Law Station Accused Arrested Arrest Rank & accused Designation produced 1 2 3 4 5 6 7 8 9 10 11 Nakkeram Street, 1311/18 U/s 57/18, Biju.KR, SI of 1 Sridevan Sinnathampy Mogapair, Thiruvallur, Railway station 06.08.18 22(C) & 29 of Hillpalace Male Police JFCM Tamilnadu NDPS Act Tripunithira 2/4 Jawahar Hussain 1311/18 U/s Shahul 43/18,M Biju.KR, SI of 2 Abdul Shukur, Khan 1st, Royapettah, Railway station 06.08.18 22(C) & 29 of Hillpalace Hameed ale Police JFCM Chennai NDPS Act Tripunithira Edampadath House, 1283/18, U/s 23/18, Nr Chinmaya Biju.KR, SI of 3 Vishal Hari Hari Nr Market Rd, 08.08.2018 20(b) II A of Hillpalace JFCM Male School Police Thripunithura NDPS Act Tripunithira Chamaparambil 800/18 U/s 06.08.18 at Joby K J, SI of 4 Shaji Majeed 23, M House, Glass Factory Eloor P S 143,147,332, Eloor 16.35 hrs Police,Eloor JFCMC Colony, Kalamassery r/w 149 IPC Kalamassery Theroth House, Glass 800/18 U/s Joby K J, SI of 5 Rahul Manoharan 20, M Factory Colony, Eloor p S 143,147,332, Eloor Police,Eloor JFCMC Kalamassery r/w 149 IPC Kalamassery Palliparambu House, 800/18 U/s Joby K J, SI of 6 Vivek Biju 18, M Glass Factory Colony, Eloor P S 143,147,332, Eloor Police,Eloor JFCMC Kalamassery r/w 149 IPC Kalamassery Chamaparambil 800/18 U/s Joby K J, SI of 7 Minoob Biju 21, M
    [Show full text]
  • Ztsxrile"Nk REGIONAL OFFICE: ERNAKULAM
    THE SOUTH INDIAN BANK LTD Ztsxrile"nk REGIONAL OFFICE: ERNAKULAM TENDER CL}I AT'CTIO\ SALE \OTICE WHEREAS the Authorised Officer of the Bank had issued Demand Notice dated 05.06.201 7 to ( I ) M/s. Nortech Infonet Plt Ltd, Nortech House, Arakkakadavu Road, Edappally. Kochi-682024. the borrower and (2) Mr. Benly Noronha, S/o Mr. Broono Noronha. Managing Director- M/s Nortech lnfonet Pr.t. Ltd, Graceland.Samajam Road. Vaduthala, Kochi, Emakulam -682023, (3) Mrs. Ann Noronha, W/o Mr. Benly Noronha, Graceland, Samajam Road, Vaduthala, Kochi, Emakulam- 682023, (4) Mr. Jerry T. Karuvelithara, S/o Mr. Thomas, Director- M/s Nortech lnfonet Prt. Ltd, Sanmaria, Plackat Colony, Elamtulam. Cochin-682020, (5) Mr. Deepak P R, S/o Mr. V Ravi, Director- M/s. Nortech Infonet Pr.t. Ltd. Devadaru, Copper Villa, Chembumukku, Kakkanad P O, Emakulam-682030. (6) Mrs. Bindhu Deepak W/o Mr. Deepak P. R, Devadaru, Copper Villa. Chembumukku, Kakkanad P O. Emakulam-682030, (7) Mr. Dunston Noronha. S/o Mr.Augustine Noronha, Colton House. Bank Road, Kaloor, Kochi-682017 and (8) Mr. Antony Linus, S/o Mr. C. P Xavier. Director- M/s Nortech Infonet Pr.t. Ltd. Pidiancheril House, Chakkalakkal Road, Perumanoor, Cochin-682015. Guarantors under section l3(2) of the Securitisation and Reconstruction of Financial Assets and Enforcement of Security Interest Act, 2002 (hereinafter referred to as 'The Act') and has taken possession of the immovable properties. more fully described in rhe schedule hereunder under Section l3(4) of the Act read with Rule 8 of the Security Interest (Enforcement) Rules, 2002 on 27.01.2020 and 26.02.2020.
    [Show full text]
  • Kerala Sustainable Urban Development Project
    Government of Kerala Local Self Government Department Kerala Sustainable Urban Development Project (PPTA 4106 – IND) FINAL REPORT VOLUME 2 - CITY REPORT KOCHI MAY 2005 COPYRIGHT: The concepts and information contained in this document are the property of ADB & Government of Kerala. Use or copying of this document in whole or in part without the written permission of either ADB or Government of Kerala constitutes an infringement of copyright. TA 4106 –IND: Kerala Sustainable Urban Development Project Project Preparation FINAL REPORT VOLUME 2 – CITY REPORT KOCHI Contents 1. BACKGROUND AND SCOPE 1 1.1 Introduction 1 1.2 Project Goal and Objectives 1 1.3 Study Outputs 1 1.4 Scope of the Report 1 2. CITY CONTEXT 2 2.1 Geography and Climate 2 2.2 Population Trends and Urbanization 2 2.3 Economic Development 2 2.3.1 Sectoral Growth 2 2.3.2 Industrial Development 6 2.3.3 Tourism Growth and Potential 6 2.3.4 Growth Trends and Projections 7 3. SOCIO-ECONOMIC PROFILE 8 3.1 Introduction 8 3.2 Household Profile 8 3.2.1 Employment 9 3.2.2 Income and Expenditure 9 3.2.3 Land and Housing 10 3.2.4 Social Capital 10 3.2.5 Health 10 3.2.6 Education 11 3.3 Access to Services 11 3.3.1 Water Supply 11 3.3.2 Sanitation 11 3.3.3 Urban Drainage 12 3.3.4 Solid Waste Disposal 12 3.3.5 Roads, Street Lighting & Access to Public Transport 12 4. POVERTY AND VULNERABILITY 13 4.1 Overview 13 4.1.1 Employment 14 4.1.2 Financial Capital 14 4.1.3 Poverty Alleviation in Kochi 14 5.
    [Show full text]
  • Bes T-In-Cla S S Amenities
    DISCOVER THE COLOURS OF FINE LIVING BEST-IN-CLASS AMENITIES BEST-IN-CLASS BEING THE FINEST SINCE 1989, Skyline Builders has been obsessed about all things finesse. With every apartment and location, Skyline has always spent time and resources on the finest of details, making sure their customers got exactly what they wanted, the home of their dreams. And that virtue has helped them create 136 projects across 10 cities in Kerala and receive the honour of being the highest rated builder in Kerala with CRISIL DA2+, apart from the trust of over 6250 happy families. EXPERIENCE. EXPERTISE. EXCELLENCE. 25 years. 136 projects across Kerala. Over 6250 satisfied home owners Over 1.3 crore sq. ft. built-up area. NEW 136 PROJECTS LAUNCHES FRAGRANCE 24 CARAT CAMBRIDGE ACROSS Pallikunnu, Kannur Elamakkara, Cochin Mukkolakkal, Trivandrum 10 CITIES SPECTRA ZENITH PEARL SYNERGY EXOTICA Mavelipuram, Kochi Near Jubilee Mission Hospital, Kanjikuzhy, Kottayam Cheranalloor, Cochin Devalokam, Kottayam Thrissur NEW 136 PROJECTS LAUNCHES FRAGRANCE 24 CARAT CAMBRIDGE ACROSS Pallikunnu, Kannur Elamakkara, Cochin Mukkolakkal, Trivandrum 10 CITIES SPECTRA ZENITH PEARL SYNERGY EXOTICA Mavelipuram, Kochi Near Jubilee Mission Hospital, Kanjikuzhy, Kottayam Cheranalloor, Cochin Devalokam, Kottayam Thrissur NEW NEW LAUNCHES LAUNCHES 24 CARAT SYNERGY EXOTICA CAMBRIDGE PEARL ZENITH FRAGRANCE Elamakkara, Cochin Cheranalloor, Cochin Devalokam, Kottayam Mukkolakkal, Trivandrum Kanjikuzhy, Kottayam Nellikunnu, Thrissur Pallikunnu, Kannur COCHIN TRICHUR MANSION HABITAT SPRING FIELD ELYSIUM GARDEN RIVER SCAPE DUKES PALMTOP TOPAZ ROSE MOUNT HOMES KINGSMEAD BLOSSOM APARTMENTS IRIS-GARDEN VILLAS HARMONY VILLAS AXIS GLENWOODS BLOOMDALE WILLOW HEIGHTS-2 HERITAGE VILLAS Gandhi Nagar Kakkanad Padivattom Kaloor Aluva Kaloor Kakkanad Kadavanthra Cochin Peringavu Sakthan Thampuran Nagar Avenue Road Sakthan Thampuran Nagar Paravattani Nr.
    [Show full text]
  • Sr. No. Outlet Name Address Discount Offer Start Date End
    Sr. No. Outlet Name Address Discount offer Start Date End date Apparels & Textiles 1 1947 Mens Clothing Vaduthala Jn,naduvath nagar PO,Arookkutty 30% 21 December 2020 20 December 2021 2 1947 Mens Clothing Iyyatil Jn,MG Road 30% 19 December 2020 18 December 2021 3 Abaya World And top shop Near olimughal Masjid,kakkanad,cochin-30 5% 09 December 2020 08 December 2021 4 Action Textiles DH road,Ernakulam 10% 11 December 2020 10 December 2021 5 Club India designer Jawahar nagar,near Bread world,Subhash Chandra bose road,Kadavantra 10% 01 May 2021 01 April 2022 6 Cocoon RJ Group 7/449DF/ Veeky tower,mavelipuram,Kakkanad,cochin-30 5% 11 December 2020 10 December 2021 7 Fab De Moda Convent Road,Erakulam 10% 11 December 2020 10 December 2021 8 Gees fashion boutique Building No:55/1564 C1,Rosjo building,chambakkara,Poonithura,cochin -38 5% 29 December 2020 28 December 2021 9 Globers Update Your Fashion Door No:34/1392,opposite Oberon Mall,By Pass,Edapally 6% 17 December 2020 16 December 2021 10 Jean Shack Jos Junction, D.H Road, M.G Road, Ernakulam 10% 09 December 2020 08 December 2021 11 K.N.R. Sons Club Junction, D.H Road, Ernakulam 10% 09 December 2020 08 December 2021 12 Kahkashan's lucknow chikan palace Ambady building ,Opposite shenoys Theatre,Pillar No:682,MG road 5% 08 December 2020 07 December 2021 13 Kalpana Dresses DH Road,MG road,Ernakulam ,Cochin-16 5% 11 December 2020 10 December 2021 14 Kalpana Dresses Woodland Building,DH road,cochin-16 10% 17 December 2020 16 December 2021 15 L3 Design Studio Covent Road,Shenoys Jn,M.G Road 10% 24
    [Show full text]
  • Candidates Appeared in the Technician (T 1)Examination – 2016 Held on 04.09.2016 Who Are Eligible for Re-Examination
    Candidates appeared in the Technician (T_1)Examination – 2016 held on 04.09.2016 who are eligible for re-examination S. Name of the Candidate No. (Shri/Smt./Ms.) Correspondence Address 1. Roll No.280110004 Varadi Karthik Door No:2-4-15 M.V.P Colony Sector-9 VSP-530 017 2. Roll No.280110007 Akhil Krishnan S Kannamkaraveedu Odanavattom P.O Odanavattom Veliyam-691 512 3. Roll No.280110008 Alfred A.S Irattappadavil (H) Vannappuram P.O Thodupuzha Idukki-685 607 4. Roll No.280110011 Prasanth P Prakash Sadanam Karikkal (H) Karimpinpuzha P.O Pin-691 507 5. Roll No.280110015 R.Saravanan 15 C South Throwpathi Amman Kovil Street Puthur, Trichy Tamil Nadu-620 017 6. Roll No.280110018 R.Siva Sakthi 1/1, East Street 15-B, Mettupatti Alanganallur (Post) Madurai (Dist) Tamil Nadu-625 502 7. Roll No.280110026 Adarsh P.P Puthanthara P.O Vayalar P.O Cherthala Alapuzha Pin-688 536 8. Roll No.280110027 Arjun Dev P.L Sudha Nivas Indira Nagar Road Peroorkada Trivandrum Pin-695 005 9. Roll No.280110040 S.Vijaysrinivas 9/83A, Padannaparambil, Pozhikkara, Mulavukad post , Bolghatty Island, Kochi-682504 10. Roll No.280110056 Mariserla Jagadeesh D.No:12-38-20, Srinivas lodge backside New gajuwaka , Visakhapatnam 11. Roll No.280110063 Dwarapureddy Seetamahalakshmi B.C. Road , New Gajuwaka, D. No.:12-38-20, Back Side Srinivas Lodge, VSKP-530026 12. Roll No.280110068 Jagarapu Anitha D.No: 21-44-1, Neellimukku, Chakalipeta, Peddaagantyada, Visakhapatnam-44 13. Roll No.280110084 Marayya Uppada Bhavanipuram (vill) Romapalli (post) Salur (m.d), Vizianagaram (Dist)-535579 14.
    [Show full text]
  • Kochi Metro Which Is Being Formulated by DMRC Also Should Be Taken Up
    CITY MOBILITY PLAN - KOCHI 1. INTRODUCTION 1.1 GENERAL Kochi, the largest agglomeration in the state of Kerala is the nerve centre of all commercial activities in Kerala. One of the major ports in the country Kochi is blessed with connection with other parts of the country through all modes of transport like road, rail, air and water. NH 17, NH 47, and NH 49 pass through Kochi. Kochi port is located on strategic International route. Broad gauge railway lines link up Kochi to all major cities of the country. Kochi has got one of the three international airports in the state. In addition to all these the regional road linkages are supplemented by an extensive network of navigation routes through the lagoon system, serving the movement of passenger and cargo. Insufficient carrying capacity of the intra-urban and sub urban routes, unhindered development of vast areas as urban extensions due to urbanization, unscientific planning in urban infrastructure development , absence of proper linkage of various forms of transportation etc. have resulted in an inadequate mobility system in the city and suburbs. As part of the comprehensive development of the city an efficient mobility plan has to be formulated. 1.2 STUDY AREA It was only in the beginning of the 19th century that Kochi , which was situated with in the narrow strip of land sandwiched between backwaters and sea outgrew to Ernakulam in the eastern side of the back waters. The narrow streets of Fort Kochi and Mattancherry were not sufficient to take up the travel demand even at that time.
    [Show full text]
  • DP ANGAMALY Name and Address of the Present Sl
    DETAILS of UNITS in DA/DP - ERNAKULAM DISTRICT DP ANGAMALY Name and Address of the Present Sl. No Plot No Name of the unit present Occupant activity/product Fr. Jose Madan, Chief 1 DPA 1 St. Reethas Charitable Trust Cement Bricks Promoter,St.Ritas Charitable Trust A.T.Jose 2 DPA 2 Rajani Industries Arackal House Plastic Sanitary items Angamaly - 688 572 K.K.Jose 3 DPA 3 K.K.Industries Kachapilly House General Engineering Angamaly South Rev. Msgr. Abraham Karedan President, Welfare Services Ekm., 4 DPA 4 Welfare Services Ernakulam Food & Meat Processing Renewal Centre , Azad Road, Kochi-17 Rev. Msgr. Abraham Karedan President, Welfare Services Ekm. 5 DPA 5 Welfare Services Ernakulam Reeled Silk and Silk Clothes Renewal Centre , Azad Road, Kochi-18 0484-2453962 Jameela Alikunju 6 DPA 6 Silver star Plastics Ltd. Thalakkattu (H) Plastic Packing Materials Marampilly P.O. Muhammed Ashraf Moolamaparambil (H) 7 DPA 7 EMME Exporters Resumption order issued Pulinchode, Perinjanam Binu V.M. Vadakkedath (H). TELK Qrtrs 8 DPA 8 Surya Metals Fabrication Angamaly South Babu Cheriyan Curry Powder and Food 9 DPA 9 Southern Cables Pvt. Ltd Maliakkal (H) Products Ayyampilly P.O Pin -682501 Chacko Neroth, House No.X/141, Baby 10 DPA 10 Neroth Agro Foods Packaged Drinking Water Land,Asokapuram , Aluva Korapaul(MD)9895016060 K.M.Shanavas Aluminium Powder 11 DPA 11 A One Industries Kunnumpurath (H) Diffusers Grills , Dampers Thaikattukara P.O. Aluva used in Air Conditioners M.V.Devassy 12 DPA 12 Nino Brothers Moolan House Curry Powder Angamaly P.K. Giri 13 DPA 13 Malabar Hills Giri Bhavan , Oorupoika P.O Banana Chips, Potato Chips Chirayankizh, TVPM K.K.Jose Best Bond Adhesive & Starch 14 DPA 14 Kodiyan House, Private Ltd.
    [Show full text]
  • KSEB Electrical Section Codes
    SMS Format -> KSEB <Space> Section Code<Space> Consumer No -> 537252 KSEB Electrical Section Codes Section Code Electrical Section Name 5617 Adimali 4609 Adoor 6516 Agali 6648 Alakode 6521 Alanellur 5501 Alappuzha ( North) 5502 Alappuzha (Town) 5503 Alappuzha(South) 6574 Alathiyoor 6509 Alathur 5568 Aluva North 5567 Aluva Town 5569 Aluva West 6534 Ambalappara 5505 Ambalappuzha 6762 Ambalavayal 4656 Amboori 5670 Ammadam 6756 Anakkayam 4597 Anchal 4669 Anchal (West) 6748 Angadipuram 5579 Angamaly. 5648 Annamanada 5553 Arakkunnam 5535 Aranmula 6789 Areekkad 6767 Areekkulam 6549 Areekode 5679 Arimboor 5705 Arookutty 5515 Aroor 5518 Arthinkal 4652 Aryanad 5572 Athani 4664 Athirampuzha 6615 Atholy 4531 Attingal. 4532 Avanavanchery. 4632 Ayarkunnam 4565 Ayathil. 6624 Ayenchery 4629 Aymanam 4591 Ayoor 4608 Ayroor 5678 Ayyanthole 6662 Azhikode 6743 Azhiyoor 6690 Badiadkka 6773 Balamthode 4542 Balaramapuram 6613 Balussery 6603 Beach 5699 Beach, Guruvayoor Page 1 of 13 SMS Format -> KSEB <Space> Section Code<Space> Consumer No -> 537252 4513 Beach, Trivandrum 6635 Beypore 5627 Bharananganam 6697 Bheemanady 5702 Big Bazar 6518 Bigbazar 6655 Burnassery 4558 Cantonment, Kollam 4506 Cantonment. 6602 Central, Kozhikode 4672 Chadayamangalam 6660 Chakkarakkal 6716 Chakkittapara 5651 Chalakudy 6538 Chalissery 6661 Chalode 5508 Champakulam 4636 Changanacherry 6585 Changaramkulam 6745 Chapparappadavu 5527 Charummood 4575 Chathannoor. 6772 Chattanchal 6708 Chattiparamba 5698 Chavakkad 4571 Chavara. 5691 Chelakkara 6744 Chelannur 6577 Chelari 6721 Chemperi 4644
    [Show full text]
  • Vaduthala Over Bridge Draft Report English
    Social Impact Assessment Draft Report Land Acquisition for Construction of Perandoor-Vaduthala Bridge, Ernakulam Requiring Body SIA Unit Kerala Public Works Department Rajagiri College of Social Sciences (Autonomous) Roads Division Rajagiri P.O Kalamassery Thrikkakara, Ernakulam Kochi- 683104 CONTENTS List of Tables and Figures List of Abbreviations Chapter 1 Executive Summary 1.1 Project and public purpose 1.2 Location 1.3 Size and attributes of land acquisition 1.4 Alternatives considered 1.5 Social impacts 1.6 Mitigation measures Chapter 2 Detailed Project Description 2.1 Background of the project, including developer’s background and governance/ management structure 2.2 Rationale for project including how the project fits the public purpose criteria listed in the act 2.3 Details of project size, location, capacity, outputs, production targets, costs and risks 2.4 Examination of alternatives 2.5 Phases of the project construction 2.6 Core design features and size and type of facilities 2.7 Need for ancillary infrastructural facilities 2.8 Work force requirements (temporary and permanent) 2.9 Details of social impact assessment/ environment impact assessment if already conducted and any technical feasibility reports 2.10 Applicable legislations and policies Chapter 3 Team Composition Approach, Methodology and Schedule of the Social Impact Assessment 3.1 List of all team members with qualification 3.2 Description and rationale for the methodology and tools used to collect information for the social impact assessment 3.3 Sampling methodology
    [Show full text]
  • Economic and Social Issues of Biodiversity Loss in Cochin Backwaters
    Economic and Social Issues of Biodiversity Loss In Cochin Backwaters BY DR.K T THOMSON READER SCHOOL OF INDUSTRIAL FISHERIES COCHIN UNIVERSITY OF SCIENCE AND TECHNOLOGY COCHIN 680 016 [email protected] To 1 The Kerala research Programme on local level development Centre for development studies, Trivandrum This study was carried out at the School of Industrial Fisheries, Cochin University of Science and Technology, Cochin during the period 19991999--2001 with financial support from the Kerala Research Programme on Local Level Development, Centre for Development Studies, Trivandrum. Principal investigator: Dr. K. T. Thomson Research fellows: Ms Deepa Joy Mrs. Susan Abraham 2 Chapter 1 Introduction 1.1 Introduction 1.2 The specific objectives of our study are 1.3 Conceptual framework and analytical methods 1.4 Scope of the study 1.5 Sources of data and modes of data collection 1.6 Limitations of the study Annexure 1.1 List of major estuaries in Kerala Annexure 1.2 Stakeholders in the Cochin backwaters Chapter 2 Species Diversity And Ecosystem Functions Of Cochin Backwaters 2.1 Factors influencing productivity of backwaters 2.1.1 Physical conditions of water 2.1.2 Chemical conditions of water 2.2 Major phytoplankton species available in Cochin backwaters 2.2.1 Distribution of benthic fauna in Cochin backwaters 2.2.2 Diversity of mangroves in Cochin backwaters 2.2.3 Fish and shellfish diversity 2.3 Diversity of ecological services and functions of Cochin backwaters 2.4 Summary and conclusions Chapter 3 Resource users of Cochin backwaters 3.1 Ecosystem communities of Kochi kayal 3.2 Distribution of population 3.1.1 Cultivators and agricultural labourers.
    [Show full text]
  • Accused Persons Arrested in Ernakulam City District from 24.05.2020To30.05.2020
    Accused Persons arrested in Ernakulam City district from 24.05.2020to30.05.2020 Name of Name of the Name of the Place at Date & Arresting Court at Name of the Age & Address of Cr. No & Sec Police Sl. No. father of which Time of Officer, which Accused Sex Accused of Law Station Accused Arrested Arrest Rank & accused Designation produced 1 2 3 4 5 6 7 8 9 10 11 Cr No - 241 , S/o Kadavil 188,269 IPC & Age House,CSEZ PO, Prasad A 1 Anees K A Muhammed 25/20, Chittethukara 25.05.20 118 e Kp Act ,4 Infopark Station Bail Chittethukara, IoP Male (2) (j ) r/w 5 Kakkanad of KEDO 2020 Cr No - 242 Pulikkal House, 188,269 IPC & Age Radhakrishnan Ratheesh P Peringala PO, 118 e Kp Act ,4 2 Ravi P K, 31/20, Kakkanad 26.05.20 Infopark P A Station Bail R, Adhikarimoola, (2) (d ) (f) r/w Male SI of Police Kakkanad 5 of KEDO 2020 Padikkattu Cr No - 243 Age Puthenpurayil 188,269 IPC & Radhakrishnan Joyce Joseph, 26/20, Station Bail 3 Joseph, House, Kakkanad 26.05.20 118 e Kp Act ,4 Infopark P A Male Veliyannoor PO, (2) (d ) r/w 5 SI of Police Kottayam of KEDO 2020 Cr No - 244 Aravind Bhavan, 188,269 IPC & Radhakrishnan Age Pambanar PO, 4 Ajith D, Dhiraviyan, 25/20, Kakkanad 26.05.20 118 e Kp Act ,4 Infopark P A Station Bail Peerumedu Male (2) (d ) r/w 5 SI of Police Village, Idukki of KEDO 2020 Cr No - 245 Kalapurakkal 188,269 IPC & Age House, Thrikkakara Radhakrishnan Muhammed 118 e Kp Act ,4 5 Hamsa, 22/20, PO, Vazhakkala Kakkanad 26.05.20 Infopark P A Station Bail Rafi, (2) (d ) (f) r/w Male Village, SI of Police 5 of KEDO Kanayannoor 2020 Cr No - 246 188,269
    [Show full text]