Annual Procurement Review

ANNUAL PROCUREMENT REVIEW

2013

Prepared by The Procurement Department April 2013

ab0cd

Executive summary

This report, prepared by the Procurement Department (PD), reviews public sector procurement contracts signed in 2013, funded and/or administered by the Bank and procured by the Bank’s clients. A separate section (2.10) covers the procurement activities of the Nuclear Safety Department (NSD).

A total of 269 (excluding NSD contracts) contracts were signed by the Bank’s clients in 2013. The total value of these contracts amounted to €1.270 billion for which EBRD’s own financing totalled €878 million. In comparison with 2012, this represented a substantial increase in terms of the number of signed contracts (by 30 per cent) whilst maintaining the same level of the total contract value.

Co-financed contracts in EU member countries represented 36 per cent of the total number of co-financed contracts and 45 per cent of the total value of all co-financed contracts. Out of the 56 contracts signed in EU countries 45 were co-financed with EU cohesion funds.

Public sector contracts awarded through open tendering represent 98 per cent of the number of contracts and 99 per cent of the total contract value when consultancy services contracts and alternative procurement procedures are excluded for which the Bank’s open tender procedures do not apply.

In 2013, the average contract value was €4.7 million and the average EBRD financing was €3.3 million per contract.

The largest contract was the “Supply of electric multiple units for Serbian Railways”. This goods contract was signed with a value of €99 million (fully financed by EBRD).

On average, 3.9 tenders were submitted when open tendering procedures were applied.

Entities from the following five countries were most successful in terms of highest total contract value, regardless of procurement method: Romania (€189 million), Germany (€155 million), Morocco (€122 million), Spain (€121 million) and Poland (€109 million), which together won a total of €696 million or 55 per cent of the total contract value.

Out of the overall 880 tenders that were submitted, which is a significant increase compared with 2012 (615), 77 per cent were submitted by tenderers from countries of operations. Entities from EBRD’s countries of operations won 225 contracts (84 per cent of all contracts) with a total value of €738 million (58 per cent of the total contract value).

The data shows that cross-border tendering is at a very high level (36 per cent) and 30 per cent of all contracts were won by firms competing in another country.

As expected there is a slight increase in the number of contracts procured using alternative procurement procedures. This is predominantly due to increased procurement activities under the RC2F project in Romania co-financed with the EU cohesion funds.

The number of procurement complaints received by the Bank decreased significantly from 23 to 13.

Abbreviations

CRA Contract Review and Awards System FIDIC International Federation of Consulting Engineers HOP Heads of Procurement IFI International Financial Institutions. LTT Legal Transition Team MDB Multilateral Development Bank MEI Municipal and Environnemental Infrastructure NSD Nuclear Safety Department OCE Office of the Chief Economist OCCO Office of the Chief Compliance Officer OGC Office of the General Counsel PD Procurement Department PCC Procurement Complaints Committee PP&R Procurement Policies and Rules SPS Senior Procurement Specialist TC Technical Cooperation TC Team Technical Cooperation Team WB World Bank

Table of Contents 1. Introduction ...... 4 2. Analysis of public sector procurement data ...... 2 2.1 Volume and nature of contracts ...... 2 2.2 Analysis by sector ...... 4 2.4 Analysis by type of contract ...... 9 2.5 Listing of contracts by country of operation ...... 9 2.6 Analysis of contract award by country of origin of the tenderers ...... 9 2.7 Contract award process ...... 10 2.8 Level of participation ...... 11 2.9 Public sector procurement under sub-sovereign projects ...... 15 2.10 Nuclear Safety Department ...... 15 2.11 Alternative Procurement ...... 17 3. Compliance and integrity ...... 18 3.2 Prohibited practices ...... 28 3.3 Independent procurement reviews ...... 28

Annexes: 1) Listing of Contracts by Country of Operations (Value in €) 1a) Listing of signed Contracts by Country of Operation (€ Value) – Level of Bank Financing 1b) Listing of signed Contracts by Country of Operation (€ Value) Bank administered grants 2) Awards by Country of Origin of the Tenderers (Value in €) 3) Awards by Country of Origin of the Tenderers (Number) 4) Awards by Country of Origin of the Tenderers (Value in € by Contract Type) 5) Awards by Country of Origin of the Tenderers (Value in € by Procurement Method) 6) Contracts Awarded by Country of Origin of the Tenderers 7) Distribution of Tenders Submitted by Country of Operations and by Business Sector 8) Distribution of Tenders Submitted by Country of Origin of the Tenderers and by Country of Operations 9) Distribution of Tenders Submitted by Country of Origin of the Tenderers and by Business Sector 10) Contracts for Nuclear Safety Managed Funds 11) Contracts entered after the freeze date of 31 January 2014

Annual Procurement Review 2013

1. Introduction This report, prepared by the Procurement Department (PD), reviews public sector procurement contracts signed in 2013, funded and/or administered by the Bank and procured by the Bank’s clients and entered in the CRA in 2013. A separate section (2.10) covers the procurement activities of the Nuclear Safety Department (NSD). This report covers goods, works and consultancy contracts financed under public sector financing. It does not cover consultancy contracts for the Bank’s own needs, those financed through Technical Cooperation (TC) funds, those awarded by the Office of the General Counsel (OGC), or contracts for goods and services for the Bank’s own needs. Information on these contracts are provided in the reports on Engagement of Consultants by the EBRD issued by the Technical Cooperation Team (formerly the Consultancy Services Unit), and in the Annual Corporate Procurement Review, issued by the Corporate Procurement Unit (CPU). It should be noted that consultancy contracts in this report are also reported in the Engagement of Consultants by the EBRD report.

Annexes 1 to 11 of the Annual Procurement Review 2013 contain the statistical data for these public sector procurement contracts during 2013. The analysis of this data, as well as the main procurement activities of the PD (section 4), can be found in the main body of this report (with the exception of Annex 11). Sections 1-3 of this report (not section 4) as well as the annexes will be published on the Bank’s website.

Notes on Annex 11 Not included in the analysis of this report are contracts signed in 2013 which were entered into the CRA system after the data was frozen for the purposes of the production of this Annual Procurement Review.

2. Analysis of public sector procurement data

2.1 Volume and nature of contracts A total of 269 contracts (excluding NSD contracts) were signed by the Bank’s clients in 2013. The total value of these contracts amounted to €1.270 billion for which EBRD’s own financing totalled €878 million (see Annex 1 for the listing of contracts by country of operations). In comparison with 2012, this represented an increase in terms of the number of signed contracts (by 30 per cent) and a decrease of the total signed contract value (of 0.5 per cent).

Table 2.1.1a illustrates the number of public sector contracts signed between 2009 and 2013.

Table 2.1.1b demonstrates the overall contract value as well as the portion financed by the EBRD between 2009-2013. Over the past five years, a total of 884 contracts have been signed with a total value of €6.225 billion of which the EBRD financed €3.963 billion.

Co-Financing

The EBRD financed €878 million of the total contract value €1.270 billion in 2013. The balance of €392 million was provided by other sources, such as other financial institutions (IFIs, EU Agencies, bilateral donors etc.) or by the borrowers themselves. In comparison with 2012, a 31 per cent decrease of the total value provided by other sources can be noted. In 2013, 156 of the 269 contracts (58 per cent) were co-financed in comparison with 128 out of the 207 contracts (62 per cent) in 2012. The value of the 156 co-financed contracts amounted to €602 million and the EBRD’s portion of those contracts represented €210 million.

Table 2.1.2a and table 2.1.2b presents the distribution of the 156 co-financed contracts in EU member countries and non-EU member countries by number and by value. Co-financed contracts in EU member countries represented 36 per cent of the total number of co-financed contracts and 45 per cent of the total value of all co-financed contracts. The sector with the highest co-financed contractual activity in terms of number of contracts was the MEI sector with 124 contracts, i.e. 79 per cent of all co-financed contracts, representing €370 million. In the MEI sector, 69 out of 124 co-financed contracts were signed in non-EU member countries. Out of the 56 contracts signed in EU countries 45 are co-financed with EU cohesion funds. The highest overall co-financed contract value was in the MEI sector (€370 million, representing 61 per cent of the total co-financed contract value).

Table 2.1.2 Distribution of co-financed public sector contracts during 2013

2.1.2a

100

50 55 4 69 0 1 27

Number of Contracts 0 MEI Transport Power Business Sector

EU Member Countries Non-EU Member Countries

2.1.2b

600 370 409 400 264 146 200 0 8 0 MEI Transport Power

Business Sector

Values of Contracts in € in Contracts of Million Values EU Member Countries

Overall analysis

In 2013, the average contract value was €4.7 million and the average EBRD financing was €3.3 million per contract. The latter represented a decrease of 11 per cent compared to the average EBRD financing reported in 2012, where the EBRD financing averaged €3.7 million per contract. There were 24 contracts in which the total signed contract value was greater than €10 million, 14 of which had a total signed contract value of more than €20 million. In 2013, there were 18 contracts in which EBRD financing was greater than €10 million, 17 of which had EBRD financing of more than €13 million. The largest contract was the “Supply of electric multiple units for Serbian Railways”. This goods contract was signed with a value of €99 million (fully financed by EBRD).

In total 19, investment grant financed contracts were administered by the Bank following the Bank’s PP&R (in some cases with eligibility restrictions in accordance with funding agreements), representing a value of €20 million. Out of these contracts 10 were co-financed with EBRD. Also included in this report are three contracts worth €12.3 million, which were 100 per cent financed by sources other than EBRD loans or EBRD administered grants. These awards followed the application of the Bank’s PP&R and were administered by the EBRD in line with the respective implementation agreements.

2.2 Analysis by sector

In 2013, the sector with the highest public sector contractual activity was the MEI sector, with 56 per cent of the total number of contracts and 39% of the overall total contract value.

Cumulative 2009-2013 data overview

Tables 2.2.1a and 2.2.1b illustrate the overall contract value and the number of public sector contracts signed between 2009 and 2013 by business sector. With a total number of 489 contracts worth €1.828 billion, the MEI sector had the highest contractual activity in terms of number and the Transport team in terms of value (€2.944 billion) over the past five years.

Table 2.2.1 Annual number and value of public sector contract awards by business sector (2009-2013)

2.3 Analysis by country of operations

2013 analysis

Public sector contracting activities were spread across 20 countries of operation. The five countries with the highest contractual activity in terms of number of contracts signed were Romania (46), the Russian Federation (31), Moldova (27), Albania (24) and Serbia (22). These 150 contracts represent 56 per cent of all contracts signed.

The five countries with the highest contractual activity in terms of value were Serbia (€285 million), Romania (€206 million), Ukraine (€134 million), Morocco (€122 million) and Kazakhstan (€108 million). With a total signed value of €855 million, these contracts represent 67 per cent of the total signed contract value in 2013.

Cumulative 2009-2013 data overview

Table 2.3.1 illustrates the distribution of contracts signed between 2009 and 2013 in the countries of operation by contract value. During the past five years, the countries with the highest total value of contracts were, in descending order: Ukraine (€1.051 billion), Kazakhstan (€719 million), Romania (€694 million), the Russian Federation (€517 million) and Bosnia and Herzegovina (€467 million). The contracts in these five countries totalled €3.448 billion which represented 58 per cent of the overall total contract value of the past five years (€5.967 billion). In the period 2009 to 2013, no public sector contracts were reported in Belarus, Egypt, Estonia, Hungary, Jordan, Kosovo, Mongolia, Slovak Republic, Tunisia, Turkmenistan and Uzbekistan.

Table 2.3.1 Public sector contract awards in the countries of operation by value in € (2009-2013)

2.4 Analysis by type of contract Table 2.4.1 gives the distribution of contracts by size and type. The 155 works contracts represented the largest total value by contract type (57 per cent of the overall contract value) as well as the largest proportion in value financed by EBRD and EBRD administered grants (€451 million out of €888 million).

Table 2.4.1 Distribution of contracts by size and type (2013) Contract Size (€M) Works Supply & Installation Goods Consultant Services Total 0~0.3 5 18 30 6 59 0.3~7.5 127 12 27 7 173 >7.5 23 7 7 0 37 Total 155 37 64 13 269 Total Value (€) 725,648,126 249,854,484 285,821,404 8,346,501 1,269,670,515 Average Value (€) 4,681,601 6,752,824 4,465,959 642,039 4,719,965 Fund Portion* (€) 451,168,353 178,862,478 251,499,990 6,807,924 888,338,745 *Loan and grant funded

2.5 Listing of contracts by country of operation Annex 1 provides a breakdown by country of operation of all contracts signed during 2013 (excluding NSD funded contracts) showing the winning tenderer and participating tenderers.

Annex 1a provides a list of contracts and the level of Bank financing (as per percentage shown).

Annex 1b provides a list of contracts financed by Bank administered Grants (percentage shows the grant funded portion).

2.6 Analysis of contract award by country of origin of the tenderers Annex 2 provides a distribution by country of origin of the successful tenderers1 and the value of contracts signed for the period 2009-2013. Tenderers from Turkey have been the most successful over the last five years as they have won a total of €608 million or 10 per cent of the overall contract value. During the past five years the countries with the highest total amount of contract value were, in descending order: Turkey (€608 million), Romania (€550 million), the Russian Federation (€539 million), Kazakhstan (€360 million) and India (€343 million). The contracts won by firms from these five countries amount to €2.4 billion which represented 39 per cent of the overall total contract value for the past five years.

Annex 3 provides the same breakdown but on the basis of the total number of public sector contracts won and signed in the period 2009-2013 according to the country of origin of the tenderers. Out of the 883 contracts administered by EBRD in the period 2009-2013, the highest numbers of contracts were awarded to entities from Romania (142), the Russian Federation (107),

Bosnia & Herzegovina (67), Germany (42), and Croatia and Tajikistan (38 each)

Annex 4 provides the total value of contracts signed in 2013, distributed by type and by country of origin of the tenderers. This annex illustrates that in 2013 entities from Romania were the most successful overall in terms of winning Bank administered contracts (15 per cent of the total value

1 The successful tenderer nationality is recorded as being only the lead entity in the case of joint ventures. 9 of contracts). Entities from Italy were the most successful in winning loan funded consultancy services contracts at 23 per cent of the overall consultancy services contract value. Entities from Switzerland have been most successful for goods contracts, winning (35 per cent) of all goods contracts in terms of value. Entities from Germany have been the most successful at 42 per cent in winning supply and installation contracts. Lastly, entities from Romania were most successful for works contracts with 25 per cent of the value of all works contracts signed during 2013.

2.7 Contract award process

Table 2.7.1 summarises data concerning the public procurement opportunities posted on the Bank’s Internet site. It should be noted that the procurement notices were also sent to the United Nations Development Business for posting in the MDB business opportunity section as well as to the EU for publishing in the Official Journal of the European Union.

Table 2.7.1 Public procurement postings on web site (2009-2013)

General Invitations for Invitations to Invitations for Year Procurement Total Expressions of Interest Prequalify Tenders Notices

2009 79 18 16 97 210

2010 88 29 16 94 227 2011 103 23 12 163 301 2012 113 27 26 183 349 2013 84 21 14 147 266

In 2013, the Bank published a total of 266 procurement notices on its internet site. Out of 84 General Procurement Notices published in 2013, 22 were for new projects.

Table 2.7.2 Distribution of contracts by award method (2013)

Contract Size (€M) Open Short list Direct Competitive Alternative * Total selection Selection 0~0.3 50 1 3 1 4 59 0.3~7.5 131 0 3 6 33 173 >7.5 23 0 0 0 14 37 Total 204 1 6 7 51 269 Total Value (€) 989,469,382 250,000 14,296,245 6,594,655 259,060,233 1,269,670,515 Average Value (€) 4,850,340 250,000 2,051,464 942,094 5,079,612 13,173,510 Fund Portion (€) * 8,368,796,420 250,000 10,389,068 6,104,707 35,381,730 8,420,921,925

*Loan and grant funded

Table 2.7.22 illustrates that the majority (204) of the public sector contracts were awarded through open tender. This represented a 76 per cent of the total number of contracts awarded and 78 per cent of the total contract value. As open tendering only applies to goods, works and supply and installation contracts procured in accordance with the Bank’s PP&R (which in 2013 was a total of 256 contracts), the public sector contracts awarded through open tendering represent 98 per cent of the number of these contracts and 99 per cent of the total contract value when consultancy services

2 Please refer to Procurement Policies Rules edition May 2010, for explanation of different tender processes. 10 contracts and alternative procurement procedures are excluded.

Annex 5 provides the total value of contracts signed in 2013, distributed by method of procurement and by country of origin of the tenderers to whom the contracts were awarded. Entities from Germany were the most successful at winning open tendered contracts with a total value of €155 million, followed by Morocco (€122 million), Spain (€106 million), Switzerland (€100 million) and Poland (€92 million). Overall, entities from these five countries won 58 per cent of all open tendered contracts.

Annex 6 provides details of the public sector contracts awarded in 2013, by country of origin of the tenderers.

2.8 Level of participation

Table 2.8.1 provides data on the rate of participation in public sector tenders by country of origin of the tenderers for contracts signed in 2013.

A total of 880 tenders from 48 countries were received during 2013, which is an increase in participation (43 per cent) compared with the 615 tenders received in 2012. On average, 3.9 tenders were submitted when open tendering procedures were applied (compared with and average of 3.5 tenders in 2012) using open tendering procedures.

The seven most successful tendering countries in terms of number of contracts were: Romania (53), the Russian Federation (34), Morocco (21), Albania (17) and Armenia, FYR Macedonia and Tajikistan (12 each). Entities from these seven countries won a total of 161 contracts (60 per cent of the total number of contracts) worth €445 million, which represented 35 per cent of the total contract value.

Entities from the seven most successful countries in terms of number of contracts won, submitted 56 per cent of all tenders received by the Bank’s clients.

The column “Rate of Success” seen in Table 2.8.1 provides an indication of the ratio of the award of contracts and the number of tenders submitted by entities from each country.

Table 2.8.1 Distribution of contracts by country of origin of the tenderers (2013) Tenderer Country Signed Contract % of Total Number % of Number of Total % Rate of % of Total Value (EUR) Value Won of Total Unsuccessful Number of Success Tenders Contracts Contracts Tenders Tenders Submitted Won Won

ALBANIA 36,695,351 2.89% 17 6.32% 67 84 20.24% 9.55% ARMENIA 18,527,691 1.46% 12 4.46% 28 40 30.00% 4.50% AUSTRIA 26,496,640 2.09% 4 1.49% 20 24 16.67% 2.81% AZERBAIJAN 1,978,873 0.16% 6 2.23% 7 13 46.15% 1.46% BELGIUM 0 0.00% 0 0.00% 2 2 0.00% 0.22% BOSNIA AND 43,493,866 3.43% 7 2.60% 14 21 33.33% 2.36% HERZEGOVINA BULGARIA 29,546,780 2.33% 3 1.12% 7 10 30.00% 1.24% CHINA 24,686,055 1.94% 4 1.49% 7 11 36.36% 1.24% CROATIA 32,574,762 2.57% 9 3.35% 10 19 47.37% 2.25% CZECH REPUBLIC 23,607,006 1.86% 2 0.74% 10 12 16.67% 1.35% DENMARK 0 0.00% 0 0.00% 2 2 0.00% 0.22% FINLAND 1,364,277 0.11% 1 0.37% 0 1 100.00% 0.11% FRANCE 6,013,449 0.47% 6 2.23% 12 18 33.33% 2.25% FYR MACEDONIA 25,961,853 2.04% 12 4.46% 11 23 52.17% 2.59% GEORGIA 2,439,150 0.19% 1 0.37% 2 3 33.33% 0.34% GERMANY 155,491,307 12.25% 7 2.60% 25 32 21.88% 3.60% GREECE 3,939,500 0.31% 2 0.74% 9 11 18.18% 1.35% HUNGARY 0 0.00% 0 0.00% 1 1 0.00% 0.11% INDIA 8,892,320 0.70% 1 0.37% 5 6 16.67% 0.67% IRAN 0 0.00% 0 0.00% 6 6 0.00% 0.67% ITALY 56,511,651 4.45% 6 2.23% 26 32 18.75% 3.71% KAZAKHSTAN 0 0.00% 0 0.00% 1 1 0.00% 0.11% KOREA 0 0.00% 0 0.00% 1 1 0.00% 0.11% KOSOVO 5,190,962 0.41% 2 0.74% 2 4 50.00% 0.45% KUWAIT 1,352,113 0.11% 1 0.37% 6 7 14.29% 0.79% KYRGYZ REPUBLIC 1,884,211 0.15% 5 1.86% 20 25 20.00% 2.81% MAURITIUS 0 0.00% 0 0.00% 2 2 0.00% 0.22% MOLDOVA 8,666,718 0.68% 8 2.97% 38 46 17.39% 5.17% MONTENEGRO 1,801,517 0.14% 2 0.74% 0 2 100.00% 0.22% MOROCCO 121,667,796 9.58% 21 7.81% 70 91 23.08% 10.24% NETHERLANDS 801,209 0.06% 1 0.37% 0 1 100.00% 0.11% NORWAY 0 0.00% 0 0.00% 1 1 0.00% 0.11% POLAND 108,850,710 8.57% 5 1.86% 2 7 71.43% 0.79% PORTUGAL 0 0.00% 0 0.00% 1 1 0.00% 0.11% REUNION 0 0.00% 0 0.00% 1 1 0.00% 0.11% ROMANIA 188,661,254 14.86% 53 19.70% 25 78 67.95% 8.77% RUSSIAN FEDERATION 46,067,733 3.63% 34 12.64% 85 119 28.57% 13.39% SERBIA 11,027,013 0.87% 7 2.60% 6 13 53.85% 1.46% SLOVAK REPUBLIC 13,208,750 1.04% 1 0.37% 1 2 50.00% 0.22% SLOVENIA 992,112 0.08% 1 0.37% 3 4 25.00% 0.56% SPAIN 121,405,574 9.56% 4 1.49% 9 13 30.77% 1.46% SWEDEN 0 0.00% 0 0.00% 1 1 0.00% 0.11% SWITZERLAND 100,407,519 7.91% 3 1.12% 4 7 42.86% 0.79% TAJIKISTAN 7,857,546 0.62% 12 4.46% 44 56 21.43% 6.30% TURKEY 30,032,793 2.37% 5 1.86% 10 15 33.33% 1.80% UKRAINE 1,307,956 0.10% 2 0.74% 1 3 66.67% 0.34% UNITED KINGDOM 266,500 0.02% 2 0.74% 5 7 28.57% 0.79% UNITED STATES 0 0.00% 0 0.00% 1 1 0.00% 0.11% Total 1,269,670,517 100% 269 100% 611 880 100%

Analysis by business sector

Annex 7 presents the level of interest generated by business sector in the respective countries of operation.

The following analysis is based on open tendered contracts only:

Out of the total aggregate number of tenders submitted, 41 per cent was in the MEI sector. Contracts awarded represented 44 per cent of all contracts, attracting on average 3.6 tenders per contract.

Out of the total aggregate number of tenders submitted, 40 per cent was in the Transport sector. Contracts awarded represent 39 per cent of all contracts, attracting on average 3.9 tenders per contract.

Out of the total aggregate number of tenders submitted, 19 per cent was in the Power and Energy sector. Contracts awarded represent 17 per cent of all contracts, attracting on average 3.5 tenders per contract.

Participation of entities from countries of operations

Chart 2.8.2a shows that out of the overall 880 tenders that were submitted, 77 per cent were submitted by tenderers from countries of operations. From Chart 2.8.2.b it can be seen that out of the 269 contracts awarded, 70 per cent were won by entities from countries of operations tendering in their own country and 14 per cent were won by entities from countries of operations tendering in other countries of operations. The above figures show a stable high level of participation of entities from the countries of operations in the tenders for Bank funded contracts and at the same time an increased level of success in tendering outside of their own countries as compared with 2012. The success rate of participation in the tenderers’ own countries remains high.

Chart 2.8.2 a and b Distribution of tenders by countries of operations and other countries

Entities from EBRD’s countries of operations won 225 contracts (84 per cent of all contracts) with a total value of €738 million (58 per cent of the total contract value). In most cases, entities were most successful in their own countries (winning 188 contracts for a total contract value of €539 million in their own country). There were 37 contracts worth €200 million awarded to entities from EBRD’s countries of operations in countries different from the country of origin of the tenderer.

Entities from ten countries of operations won contracts in their own countries only. These countries were Albania, Bosnia and Herzegovina, FYR Macedonia, Kyrgyz Republic, Moldova, Montenegro, Morocco Serbia, Slovenia and Tajikistan. They won contracts worth a total amount of €260 million or 20 per cent of the overall contract value.

Country and sector tendering analysis

Annex 8 presents the distribution of tenders submitted by country of origin of the tenderers and by country of operations.

Annex 9 presents the distribution of submitted tenders by country of origin of the tenderers and by business sector.

Out of all tenderers, entities from Germany diversified their tenders to the greatest extent as they submitted tenders across 11 countries of operations and across three business sectors. German entities won seven contracts spread across the MEI sector (1), Power and Energy (2) and Transport (4).

Contracts in the Russian Federation generated the highest level of interest in terms of number of tenders submitted (119), followed by Morocco (91).

2.9 Public sector procurement under sub-sovereign projects

A total of 103 contracts were signed under sub-sovereign public sector projects, showing an increase of 8 per cent compared to 2012 (95) and representing 38 per cent of the total number of contracts. These contracts have a total value of €479 million or 38 per cent of the overall contract value. In these contracts the EBRD portion of financing is 43 per cent of the total contract amount.

In 2013, six contracts were signed for projects co-financed with Instrument for Pre-accession Assistance (IPA) (Croatia: Sisak Wastewater Management Project (six)) and 46 contracts for projects co-financed with EU Cohesion Funds (Bulgaria: Burgas Integrated Urban Transport Project, Bulgaria: Varna Integrated Urban Transport Project, Romania: R2CF Water Framework).

2.10 Nuclear Safety Department The EBRD manages six nuclear safety Funds with over €4 billion in pledged contributions. Each Fund is governed by specific provisions as set out in the Rules of the Fund approved by the respective Assembly of Contributors and by the EBRD Board of Directors. The Funds are managed by the Nuclear Safety Department (NSD) on behalf of the contributing countries. Procurement under the Funds must follow the EBRD’s PP&R for public sector projects with the limitation that eligibility is restricted to entities from member countries of the respective Funds, the EU member states and the EBRD’s countries of operations.

During 2013, 68 contracts amounting to a total value of €124 million were placed under the projects financed by the Funds. This represented an increas compared to 2012 of 58 per cent in the number of contracts and of 73 per cent in value. Annex 10 provides the listing and details of all the contracts financed from Nuclear Safety Funds signed during 2013.

Table 2.10.1 provides the distribution of the NSD administered contracts by size and type. Out of the 68 contracts signed 48 were below €1 million, 21 of which were for consultancy services, representing 31 per cent of the total number of contracts and 3 per cent of the total contract value. The majority of the remaining 27 contracts signed below €1 million are for procurement of goods representing 21 per cent of the total number of contracts and 2 per cent of the total contract value. The 15 contracts with a value between €1million and €7.5 million accounted for 38 per cent of the total contract value and the five contracts with a value over €7.5 million accounted for 52 per cent of the total value of all contracts financed from the Funds. The largest contract, worth €25.2 million, was for the design and construction of the ‘Dry storage unit’ enclosures at Andreeva Bay under Northern Dimension Environmental Partnership (NDEP) Nuclear Window.

Table 2.10.1 Nuclear Safety Department-distribution of contracts by size and type (2013)

Contract Size (€M) Works Supply & Goods Consultant Total Installation Services 0~0.3 0 2 12 17 31 0.3~7.5 15 7 4 6 32 >7.5 3 1 0 1 5 Total 18 10 16 24 68 Total Value (€) 73,155,979 17,662,017 9,584,655 23,900,553 124,303,204 Average Value (€) 399,835 235,850 8,734 9,920 8,734

Table 2.10.2 provides the distribution of the NSD-funded contracts by size and by method of award. Contracts subject to open and competitive selection procedures amounted to €115.1 million which is 93 per cent of the value of total contracts placed. The value of consultancy services contracts subject to direct selection has decreased by 87 per cent compared to 2012 and amounted to €2 million (compared to €16 million in 2012).

Table 2.10.2 Nuclear Safety Department- distribution of contracts by award method (2013)

Contract Size (€M) Open Shopping Direct Competitive Total Selection 0~0.3 1 13 10 4 31 0.3~7.5 25 0 3 2 32 >7.5 4 0 0 1 5 Total 30 13 13 7 68 Total Value (€) 94,184,524 1,150,588 1,993,075 20,958,543 124,303,204 Average Value (€) 112,500 8,734 9,920 54,540 8,734

The procurement for projects administered by NSD is carried out in full compliance with the EBRD’s PP&R, except for eligibility restrictions. The established procedures between NSD and PD to determine the compliance of chosen procurement methods, other than open tender, are further enhanced through reviews by the donors to the Nuclear Safety Funds. The work programmes, which include the proposed procurement methods for planned projects, are submitted to the respective Assembly in advance of its meetings. Therefore, the Assembly approval of a work programme also constitutes its approval of the respective procurement plan and any exceptions to open tendering which the procurement plan may contain.

The decisions to proceed with direct selection are mainly influenced by the specific nature of the highly regulated nuclear industry, including various security, radiation or safety requirements.

2.11 Alternative Procurement

Alternative Procurement is the categorisation given to those contracts which are co-financed with other International Financial Institutions and for which the Board has granted an exception under paragraph 2.4 of the PP&R from the use of the Bank’s procurement procedures. In such cases, these contracts are procured under rules and procedures applicable to the co-financing institution as well as subject to acceptable alternative monitoring procedures, as set out in the request for exception approved by the Board.

Table 2.11.1 Summary of contract procured under alternative procurement procedures

Number of Contracts 51 Total Value €259,060,233 EBRD funded portion € 35,381,971 Average EBRD financing 13.3% Largest Contract €14,441,895

Two types of co-financing are represented in the data in table 2.11.1. The majority of contracts (41 of 51) were co-financed with the EU-Cohesion Fund under the Regional EU Cohesion Funds Water Co-Financing Framework R2CF Project in Romania amounting to EUR 197,971,793 or 76% of the total number of contracts by value. In addition, five contracts in Bulgaria under the Varna Integrated Urban Transport Project and Burgas Integrated Urban Transport Project were also co-financed with the EU Cohesion Funds. All these contracts were procured under national public procurement law in accordance with EU requirements

Six contracts were co-financed with the EU IPA funds in Croatia. These contracts were procured under the EU PRAG procurement procedures. Procurement conducted under EU PRAG procedures were subject to EBRD and EU Delegation prior review.

The majority of contracts (44 out of 51) were won by companies from the same country as the country of the project. Contracts were also placed with contractors from Poland (3), Spain (2), Italy and the Czech Republic (1 each).

3. Compliance and integrity

PD handled 13 procurement complaints and six concerns for Bank financed or administered contracts during the course of 2013, as compared to the 23 procurement complaints and four concerns in 20123. For reference, the following number of contracts were awarded under the Bank’s PP&R, under which participants in the respective procurement processes are eligible to submit procurement complaints and concerns to the respective clients and the Bank. There were 269 contracts signed under public sector projects and 68 under the nuclear safety funds, 2,879 consultancy contracts, funded from Bank administered TC funds and from the Bank’s own budget. Furthermore, 719 consultancy contracts were signed by OGC for retaining outside legal counsel.4

Table 3.1.1 presents a comparison of figures for complaints/concerns reviewed between 2009 and 2013, by contract type and procurement method.

Table 3.1.1 Number of complaints/concerns 2009-2013 by contract type and procurement method

Contract Type 2009 2010 2011 2012 2013 Works 37587 Goods 46563 Supply and Installation 76183 Services 00000 Consultancy 01133 (Loan or NSD Grant Funded) Consultancy (TC and Bank's own 00023 funds, administered by TCT) Consultancy (outside legal counsel 00000 retained by OGC) Total 14 20 12 27 19

In 2013, the majority of complaints/concerns were related to contracts for works (seven), with a further three complaints/concerns each related to contracts for goods and supply and installation respectively. The remaining six complaints/concerns were related to contracts for consultancy services. In 2012, the majority of complaints/concerns were equally related to contracts for works and contracts for supply and installation (eight each).

Table 3.1.2 provides a summary of the 11 complaints and five concerns that were closed in 2013. The information provided includes the nature, the business sector and the outcome of the complaint process for each of these complaints and concerns. Whilst nine of the 11 complaints were not upheld by PCC, one complaint was upheld (no 2 Bosnia and Herzegovina Road Rehabilitation Project) and one complaint was partially upheld (no 1 Kyiv City Transport: Pastrans Loan).

3 A distinction is made between those issues raised by dissatisfied parties that clients can resolve themselves and complaints that are formally addressed to and require the action of the Bank. A “concern” is any minor issue that is brought to the attention of the EBRD by a tenderer regarding the procurement process or contract award. The concern is referred to the contracting authority, which is expected to address and resolve the issue with the relevant party under PD’s supervision. If the two parties cannot come to an understanding or an agreement, the concern may be elevated to the status of a complaint. At that point, the EBRD freezes the procurement process and an investigation is undertaken.

4 The number of consultancy contracts administered by the Technical Cooperation Team (including contracts related to the Small Business Support Team (SBS) and OGC) has been included in this section as the Bank’s PP&R and, consequently, the Bank’s procurement complaints/concerns review procedures are also applicable for these contracts.

One of the five concerns was rejected by PD. The remaining four concerns were considered to have become redundant as no further correspondence was received after the Client’s and/or PD’s explanations concerning the respective allegations.

The complaints/concerns raised by unsuccessful entities in 2013 varied in nature. The following issues were raised:

 Challenging the Client’s decision not to prequalify the Complainant.  Allegation that the winning tenderer failed to meet the qualification criteria.  Challenging the result of the client’s technical evaluation for a consultancy assignment.  Allegation that the qualification criteria were not robust enough to address the risks of implementing the works.  Allegation that a proposal at the first stage of the tendering process was wrongly rejected as submitted too late.  Allegation that a tenderer had not been sent a key addendum to the tender documents.  Challenging the Client’s decision to terminate the contract negotiations for a consultancy assignment and awarding the contract to the second ranked consultant.  Allegation that the winning consultant had offered insufficient person/months and not suitably qualified personnel.  Challenging the applicability of the Bank’s PP&R.  Questioning the long duration of the tender evaluation process.  Allegation that the tenderer had not been informed of the outcome of the tender evaluation process.

Table 3.1.2 Complaints and concerns by nature and by business sector (complaints and concerns closed during 2013, presented in chronological order as received by the Bank)

Country of Project Complaint Business Nature of Complaint/Concern Outcome of the Complaint Contract Time- Originator /Concern Sector Process Amount line of € Complaint/ Concern 1. Ukraine Ukraine: Complaint MEI The Complainant accused the Client of a Following a thorough investigation 223,800,000 < 21 Kyiv City Transport: violation of the tendering process on the of all aspects of the complaint, the months Pastrans Loan following grounds: Bank arrived at the conclusion that the Complainant had failed to meet (a) the Client was wrong in prequalifying some of the post-qualification the complainant for one lot only, despite criteria, and that the complaint in the latter meeting all qualification respect of the rejection of the requirements for two lots; Complainant’s tender was therefore (b) the Client awarded the contract to a not substantiated. tenderer, who offered a product, which had not been manufactured nor certified by the However, it was found that in other Authorities by the deadline for tender aspects referred to in the complaint, submission; and the tender process and award of (c) the Client incorrectly rejected the contract did not follow in certain Complainant's tender during respects the procedures agreed with postqualifcation on the basis of a third the Bank. The complaint was party falsified audit report. therefore partially upheld, but after due consideration of all mitigating factors, it was decided by the Bank not to cancel the contract award.

2. Bosnia and Bosnia & Herzegovina Complaint Transport Whilst the submitted tenders were still PCC decided to uphold the 1,000,000 < 6 Herzegovina Road Rehabilitation under evaluation, the Complainant alleged complaint as it had been established months Project that the awarded tenderer (unnamed) was that the tenderer who had been not qualified and specifically did not have recommended for contract award a licence for an asphalt plant. had not met some of the minimum Consequently, this tenderer would not be requirements as per the tender able to perform the contract, if awarded to documents and was therefore was them. not qualified. Consequently, this contract would not be eligible for In a subsequent letter, the Complainant financing by the Bank, unless the also alleged the occurrence of Prohibited Client issued a tender evaluation

Practices in connection with this tender. report acceptable to the Bank. Consequently, this aspect of the Complaint Having noted the outcome of the was referred to the Bank’s Office of the Bank’s review of the Complaint, Chief Compliance Officer (OCCO) for the Client sent a revised evaluation their review. report to the Bank, proposing contract award to the next ranked tenderer. This report was no- objected by the Bank.

As the Complaint included allegations of prohibited practices, this matter was referred to the Office of the Chief Compliance Officer (OCCO) to assess these allegations. OCCO concluded that the allegation of prohibited practices were not substantiated and closed the matter.

3. FYR FYR Macedonia: Complaint Transport This Complaint concerns the same tender PCC noted that the Client had 15,000,000 < 6 Macedonia Corridor X as the Complaint listed in this table under carried out the procurement process months number 4. materially in accordance with the agreed procedures. PCC therefore The Complainant alleged that their (first concluded that the complaint was to stage) tender was incorrectly rejected as be rejected. "late" by the Client, claiming that in fact it was delivered on time. They further complained that the delivery receipt issued by the client as proof of delivery does not contain a time stamp.

4. FYR FYR Macedonia: Complaint Transport This Complaint concerns the same tender PCC noted that the Client had 15,000,000 < 5 Macedonia Corridor X as the Complaint listed in this table under carried out the procurement process months number 3. materially in accordance with the agreed procedures. PCC therefore The Complainant alleged that the Client concluded that the complaint was to had not sent to them a key addendum in be rejected. due time and had ignored requests for an extension to the tender deadline.

5. Bulgaria Bulgaria: Complaint Nuclear According to the Client's technical PCC noted that the Complainant’s 1,500,000 < 4 Kozloduy International Safety evaluation report for a consultancy proposal had missed the minimum months Decommissioning assignment, the Complainant had not met technical threshold very narrowly. Support Fund the threshold for their technical proposal to However, PCC concluded that this be considered for further financial appeared to be the outcome of a fair evaluation. The Complainant alleged that and rational evaluation process, free the exclusion of its proposal from the from bias. Consequently, PCC financial evaluation was not justified. decided to reject the Complaint.

6. Slovak Slovak Republic: Complaint Nuclear This Complaint concerns a different PCC concluded that the Complaint 14,600,000 < 5 Republic Bohunice International Safety contract under the same project by the was unfounded and, therefore, was months Decommissioning same Complainant as under the not to be upheld. Support Fund procurement Concern listed in this table under number 7.

The Complainant raised concerns about the qualification requirements of the tender documents for the works contract. The Complainant believed that the qualification requirements were not robust enough to address the risks of implementing the works. The Complainant requested the current tender exercise to be cancelled, the tender documents to be amended and the contract to be retendered. 7. Slovak Slovak Republic: Concern Nuclear This Complaint concerns a different PD concluded that the Concern was 26,000,000 < 6 Republic Bohunice International Safety contract under the same project by the unfounded and, therefore, was not months Decommissioning same Complainant as under the to be upheld. Support Fund procurement Complaint listed in this table under number 6. It also concerns the same However, the tender was cancelled contract as under the procurement concern for reasons unrelated to this listed in this table under number 14. Concern and the works were subsequently retendered. The Complainant raised concerns about the qualification requirements of the tender documents for the works contract. The Complainant believed that the qualification requirements were not robust enough to address the risks of implementing the works. The Complainant requested the

current tender exercise to be cancelled, the tender documents to be amended and the contract to be retendered.

8. Italy Albania: Concern Transport In a letter to the Client, which was copied As the Client had addressed the 6,330,000 < 3 Local And Regional to the Bank, a company objected to the allegations to the Complainant and months Roads rejection of its pre-qualification no further communication had been application by the Client and requested a received from the latter, PD decided postponement of the tender submission to close the case. deadline.

9. United Bulgaria: Complaint Nuclear The Complainant presented its complaint PCC decided not to uphold this 15,000,000 < 7 Kingdom Kozloduy International Safety as follows: complaint as the Client had not months Decommissioning violated its obligations in terms of Support Fund 1) The Complainant contests the Client's the procurement process. decision to terminate the contract negotiations and the Client's request for the Complainant to withdraw the amendments to the draft Contract that were previously agreed by the Complainant and the Client during the contract negotiations. The decision breaches the procurement procedures outlined in the Request for Proposal (RFP) for the assignment and the Bank’s Procurement Policies and Rules;

2) The Complainant requires the agreement reached by the Client and the Complainant (as evidenced by the initiated draft Contract) to be reinstated and the parties to conclude the contract negotiations by signature of the Contract;

3) in the event that the Contract has

already been awarded to the second ranked consultant, the Complainant: (i) contests the award of such Contract; (ii) in accordance with the rules applicable to project procurement complaints, requires the financing for this Contract to be withdrawn.

10. Czech Moldova: Complaint Power & The issues raised by the Complainant PCC decided not to uphold this 3,000,000 < 3 Republic Moldelectrica Energy concerning the competitive selection for a Complaint as it was concluded that months Transmission consultancy assignment can be the bidder with the lowest financial Rehabilitation Loan summarised as follows: proposal had met the requirements of the RFP documents and as this 1) Whilst three of the shortlisted bidder had provided the required companies submitted technical proposals evidence about having secured the that received similarly high scores, one of services of a duly qualified sub- the shortlisted consultant’s financial contractor. proposal was approximately 15% lower than the lowest of the other bidders. The Complainant believes that this could only be achieved by the former offering low qualification of the proposed personnel and/or insufficient person/month inputs, which would not be in accordance with the RFP requirements.

2) The bidder with the lowest financial proposal may not have offered the required services of duly qualified and appropriately licensed sub-consultants as required by the Request for Proposal (RFP) documents.

11. Czech Serbia: Complaint MEI The Complainant raised the concern that PCC decided not to uphold this 64,779,680 < 3 Republic Belgrade Bus Renewal the procurement process had not been complaint as it had been established months Programme conducted in accordance with the that the Complainant had not met applicable procurement law of the the technical specifications, which Republic of Serbia and since the were considered to be appropriate participants were allegedly misled, that and non-biased. Furthermore, it was this procurement process should be established that the Bank’s PP&R cancelled and re-tendered. The were applicable and not the Complainant also insisted that the procurement law of the Republic of technical specifications were Serbia. discriminatory, which consequently led to the refusal of the Complainant’s tender.

12. Sweden FYR Macedonia Complaint Power & The Complainant was concerned about the PCC concluded that the tender 3,800,000 < 6 Transmission Energy allegedly unclear scope of the contractor's documents could have been clearer months Interconnection obligations in respect of the maintenance in respect of the requirements of the after the defects liability period and its post defects liability period duration. The Complainant believed that maintenance. However, PCC was the Client was in breach of the provisions satisfied that a lack of clarity in the of paragraph 3.15 of the PP&R formulation of these requirements (description of tender documentation) and in the documents did not requested the cancellation of the tender substantially compromise the sound and the re-tendering of the contract. competitive nature of the tendering process, because the proposals of all tenderers reflected a common understanding of the requirements. Therefore, the complaint was rejected.

13. Austria Serbia: Complaint Transport The Complainant disputed the reasons for PCC concluded that the 1,750,000 < 6 Serbian Railways the rejection of their offer on the basis of Complainant had failed to months Corridor X material non-compliance relating to demonstrate that it had a valid product licences and other technical issues. permit or a temporary licence from the relevant authority for the usage of the product in question, as required by the tender documents. Consequently, the Complaint was deemed unfounded and was declined.

14. Slovak Slovak Republic: Concern Nuclear This Concern relates to the same tender as PD assessed the matter and 26,000,000 < 1 Republic Bohunice International Safety the Concern listed in this table under concluded the following: month Decommissioning number 7. Support Fund (a) The qualification criteria The originator of the Concern asked the were found generally adequate for Bank to explain the reasons for the long the nature and magnitude of the duration of the tender evaluation process contract; which had been ongoing for almost one (b) The delay of the year. evaluation process was caused by the fact that the Bank was not in a position to provide its no-objection to the client's evaluation report; (c) The extension of the tender validity was triggered by protracted tender evaluation.

The tender was eventually cancelled for reasons unrelated to this Concern and the works were subsequently retendered.

Due to the cancellation of the tender by the Client, the Concern is deemed redundant.

15. Bulgaria Bulgaria: Concern Nuclear The Concern relates to the fact that the The Bank had requested the Client 3,000,000 < 2 Kozloduy International Safety originator of the Concern had not been to inform the tenderers on the months Decommissioning informed of the outcome of the tender outcome of the tender evaluation Support Fund evaluation concerning two out of five lots without further delay. On the basis of a works contract. that a) the Bank had clearly explained the procedure to be followed in the event that the originator of the Concern wished to submit a formal complaint in the event that it was not satisfied with the outcome of the tender, and b) the fact that no further communications had been received by the Bank from the originator of

the Concern up to the end of December 2013, this Concern was considered as closed by PD.

16. Slovak Slovak Republic: Concern Nuclear This procurement Concern predominately On the basis that 2,500,000 < 2 Republic Bohunice International Safety relates to the fact that the originator of the a) the Bank had clearly explained months Decommissioning Concern had not been informed of the the procedure to be followed in the Support Fund basis upon which its tender had been event that the originator of the unsuccessful in competing for a works Concern wished to submit a formal contract. complaint in the event that it was not satisfied with the outcome of the tender, and b) the fact that no further communications had been received by the Bank from the originator of the Concern up to the end of December 2013, this Concern was considered as closed by PD.

Table 3.1.2 also provides information on the duration of the review of complaints and concerns. Whilst the review of six of the cases could be finalised within a period of less than three months, nine complaints/concerns could only be closed up to seven months after receipt by the Bank. Due to the complex nature of one of the complaints, the decision to uphold this complaint and Board approval for the proposed way forward could only be obtained 20 months after receipt of the complaint.

The complaints/concerns closed in 2013 were related to Nuclear Safety projects (seven), to Transport projects (five) and to MEI and Power & Energy projects (two each).Allegations of improper tender evaluation and biased technical specifications were the principal sources of complaints.

3.2 Prohibited practices In 2010, the Bank signed the “Agreement for Mutual Enforcement of Debarment Decisions”. The Agreement was signed by the African Development Bank Group, the Asian Development Bank, the InterAmerican Development Bank, the World Bank Group and the European Bank for Reconstruction and Development. The list of entities and individuals which are currently ineligible to become an EBRD Counterparty can be found on the Bank’s website at: http://www.ebrd.com/pages/about/integrity/list.shtml.

Entities (and their affiliates) or individuals may be ineligible to become a Bank Counterparty if EBRD determines, in accordance with EBRD’s Enforcement Policy and Procedures, that (a) they have engaged in any Prohibited Practice in the context of a Bank project, or (b) they are subject to a Third Party Finding or (c) they are subject to a Debarment Decision by a Mutual Enforcement Institution.

In 2013, no enforcement proceedings were instituted by the EBRD. Pursuant to the Agreement for the Mutual Enforcement of Debarment Decisions cross-debarment provisions of the EPP, the Bank cross- debarred 303 entities and 25 individuals. Based on debarment notices received from the World Bank Group (53 notices), the Asian Development Bank (4 notices) and the Inter-American Development Bank (5 notices). Very few of these debarred entities have had previous relationships with the EBRD. A list of all EBRD debarred entities and persons is published on the EBRD’s web site. As at 31 December 2013, four firms are ineligible to be awarded EBRD funded contracts as a result of EBRD initiated debarment action. In addition, 376 entities and 91 individuals are ineligible as a result of mutual enforcement of debarment decisions. . 3.3 Independent procurement reviews Independent Procurement Reviews (IPRs) are carried out with the view to strengthen the ability of the Bank to fulfil its fiduciary obligation with regard to the oversight of procurement and contract implementation, to complement the prior review and post review procedures applied, and to inform the Bank's management of the quality of the Bank’s fiduciary work on procurement. The projects for IPRs are selected based on: the relevance of the project or the issue reviewed to the Bank's likely future operations; lessons-learned potential; size of the Bank's investment commitment/exposure; balance among countries of operations; relative priority of operation within PD's overall work programme as well as by reference to PD’s procurement risk dashboard.

In 2013, PD commissioned two IPRs as follows:

1) Moldova Road Rehabilitation III Project (OPID 41442)

The Bank has provided long term financing for the rehabilitation of national roads in Moldova. The Bank has engaged a senior procurement expert whose review will particularly focus on contract implementation. It is expected that the IPR will be finalised in the first quarter of 2014.

2) Russian Federation: Archangelsk Municipal Water Services Development Project (OPID 20699)

The Bank has administered a project under the Northern Dimension Environmental Partnership (the “NDEP”), which will contribute significantly to decreasing the level of polluting discharges into the Barents Sea basin. The NDEP investment grant is EUR 7.3 million.

The investment programme consists of: .Upgrade of the municipal water treatment facilities and rehabilitation of water distribution networks; .Improvement of service standards and strengthening the financial and operational performance of Vodocanal; and, .Modernisation and extension of the wastewater network and collectors in view of eliminating direct discharges of untreated wastewater.

The Bank has engaged a senior procurement expert whose review will particularly focus on the conduct of the procurement processes and contract implementation. It is expected that the IPR will be finalised in the first quarter of 2014.

Listing of Contracts by Country of Operations in 2013

Op Sector OPID Op Name Contract ID Contract Name Tenderer Name Tenderer Contract Contract Procurement Signed Contract Country Country Signing Date Type Method Value (EUR)

ALBANIA Transport 34637 Albania: Fier- 57501 Fier Tepelene Road Section 2 - remaining VEGA SHPK (W) ALBANIA (W) 05 Sep 2013 Works Open 6,000,000 Tepelene works from km 26.05 to km 30.15 Road performed by VEGA sh.p.k. Rehabilitation 40153 Local And 55861 Rec 87: Reconstruction of road Lushnje - JV GPG Company sh.p.k. & ALBANIA (W) 21 Jan 2013 Works Open 4,428,203 Regional Hysgjokaj (regional) Filipos S.A. (W) Roads ALB STAR SH.P.K. ALBANIA GENER 2 SH.P.K. ALBANIA 56681 Rec 94 Reconstruction of road Vaqarr-Gropaj-Alb-Building sh.p.k (W) ALBANIA (W) 11 Jan 2013 Works Open 1,514,808 Kthesa e Kashurit ALB STAR SH.P.K. ALBANIA FUSHA SH.P.K. ALBANIA GENER 2 SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA 56702 Rec113- Reconstruction of main entrance CURRI sh.p.k. (W) ALBANIA (W) 11 Jan 2013 Works Open 634,985 road and construction of a pedestrian path Ekskluziv sh.p.k. ALBANIA along seaside on Velipoja beach KARL GEGA KONSTRUKSION ALBANIA SH.P.K. SMO Union sh.p.k. ALBANIA 56745 Rec 84- Reconstruction of road Boge-Qafe GENER 2 sh.p.k. (W) ALBANIA (W) 26 Mar 2013 Works Open 3,141,709 Thore, Shkodra Region Alb-Star sh.p,k. ALBANIA Gjikuria sh.p.k. ALBANIA Gjoka Konstruksion sh.a. ALBANIA SK-13 Patstroy BULGARIA 56746 Rec 99- Reconstruction of road Novosele- CO.Be.IN sh.p.k. (W) ALBANIA (W) 12 Mar 2013 Works Open 3,012,867 Poro-Pish Poro, Vlora Region ALBAVIA SH.P.K ALBANIA GJIKURIA SH.P.K. ALBANIA SK-13 Patstroy BULGARIA 56761 Rec106- Reconstruction of road Ura ALBAVIA sh.p.k (W) ALBANIA (W) 04 Apr 2013 Works Open 3,062,335 Vajgurore-Pashalli-Bistrovice Gjoka Konstruksion sh.a. ALBANIA 56762 Rec107- Reconstruction of road Lac-Milot in TRIKAT s.a. (W) GREECE (W) 03 Jan 2013 Works Open 2,502,642 Lezha Region 57087 Rec128- Reconstruction of road Fermentim- JV "Denis 05" sh.p.k. & ALBANIA (W) 06 Jun 2013 Works Open 403,364 Ura e Mesit-Drisht, Lot 1 "Arifaj" sh.p.k. (W) Alb Tiefbau sh.p.k. ALBANIA CURRI SH.P.K. ALBANIA SMO Union sh.p.k. ALBANIA 57261 Rec138- Reconstruction of road Surrel-Quafe-Gjikuria sh.p.k. (W) ALBANIA (W) 28 Jun 2013 Works Open 2,593,572 Priske CURRI SH.P.K. ALBANIA GENER 2 SH.P.K. ALBANIA Vezzola ITALY

Annex 1 ALBANIA Transport

40153 Local And Regional Roads

57262 Rec 52- Reconstruction of road Libonik- CURRI sh.p.k. (W) ALBANIA (W) 07 Jun 2013 Works Open 2,118,380 Rrembee-Plase ANK SH.P.K. ALBANIA COPRI CONSTRUCTION KUWAIT FILIPOS S.A. GREECE GJIKURIA SH.P.K. ALBANIA 57263 Rec 50- Reconstruction of road Kthesa e "Copri Construction KUWAIT (W) 04 Jul 2013 Works Open 1,352,113 Qarrit-Bishan-Poro-Pish Poro-Bregdet Enterprises" W.L.L. (W) CURRI SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA SALILLARI SH.P.K. ALBANIA 57281 Rec 95- Reconstruction of road Balez-Letan Salillari sh.p.k. (W) ALBANIA (W) 17 Jun 2013 Works Open 1,263,197 COPRI CONSTRUCTION KUWAIT CURRI SH.P.K. ALBANIA FILIPOS S.A. GREECE GJIKURIA SH.P.K. ALBANIA GJOKA KONSTRUKSION SH.A. ALBANIA 57282 Rec136- Reconstruction of road Berxull- Alba Konstruksion (W) ALBANIA (W) 28 Jun 2013 Works Open 997,002 Laknas ALB-BUILDING SH.P.K ALBANIA Copri Construction KUWAIT Gjikuria sh.p.k. ALBANIA Gjoka Konstuksion sh.a. ALBANIA RIVIERA SH.P.K ALBANIA Vezzola ITALY 57284 Rec137- Reconstruction of road connecting Alb-Building sh.p.k (W) ALBANIA (W) 05 Jul 2013 Works Open 1,342,429 Farka with Elbasani Road Albakonstruksion sh.p.k. ALBANIA COPRI CONSTRUCTION KUWAIT CURRI SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA GJOKA KONSTRUKSION SH.A. ALBANIA Vezzola ITALY 57301 Rec103- Reconstruction of road Qerret- S.M.O. Union sh.p.k. (W) ALBANIA (W) 10 Jun 2013 Works Open 1,134,601 Karpen, Lot 1 ALBA KONSTRUKSION ALBANIA ARIFAJ SH.P.K. ALBANIA CGP SLOVENIA DELIA GROUP SH.P.K. ALBANIA FILIPOS S.A. GREECE GENER 2 SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA GPG COMPANY SH.P.K. ALBANIA 57302 Rec129- Reconstruction of road Unaza e Re- Gjoka Konstruksion sh.a. ALBANIA (W) 06 Jun 2013 Works Open 1,122,921 Kashar (W) ALB STAR SH.P.K. ALBANIA ALBA KONSTRUKSION ALBANIA ARIFAJ SH.P.K. ALBANIA DELIA GROUP SH.P.K. ALBANIA FUSHA SH.P.K. ALBANIA

Annex 1 ALBANIA Transport

40153 Local And Regional Roads

57302 Rec129- Reconstruction of road Unaza e Re- 06 Jun 2013 Works Open 1,122,921 Kashar

S.M.O. UNION SH.P.K. ALBANIA 57303 Rec127- Reconstruction of road Kallmet I Filipos s.a. (W) GREECE (W) 12 Jun 2013 Works Open 1,436,858 Vogel-Ungrej, Lot 1 ALBA KONSTRUKSION ALBANIA ARIFAJ SH.P.K. ALBANIA CGP SLOVENIA DELIA GROUP SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA GPG COMPANY SH.P.K. ALBANIA 57304 Rec116- Reconstruction of road Mollas-Selite- Victoria Invest International KOSOVO (W) 29 May 2013 Works Open 2,132,628 Frasher sh.p.k. (W) GJIKURIA SH.P.K. ALBANIA S.M.O. UNION SH.P.K. ALBANIA 57305 Rec126- Reconstruction of road Kthesa e Serenissima Costruzioni ITALY (W) 13 Jun 2013 Works Open 3,324,647 Patosit-Roskovee s.p.a. (W) ALB STAR SH.P.K. ALBANIA GENER 2 SH.P.K. ALBANIA STRABAG AG AUSTRIA TADDEI S.P.A. ITALY 57306 Rec125- Reconstruction of road Gostime- Victoria Invest International KOSOVO (W) 10 Jun 2013 Works Open 3,058,334 Gjyrale-Belsh sh.p.k. (W) DELIA GROUP SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA GJOKA KONSTRUKSION SH.A. ALBANIA Green Line KUWAIT STRABAG AG AUSTRIA 57307 Rec 87-1- Reconstruction of road Hysgjokaj- JV Trikat s.a. & PE-VLA-KU ALBANIA (W) 19 Jun 2013 Works Open 3,258,151 Kryqezimi Pras-Vashaj sh.p.k. (W) GJIKURIA SH.P.K. ALBANIA GPG Kompani sh.p.k. ALBANIA SERENISSIMA COSTRUZIONI ITALY S.P.A. 57308 Rec130- Reconstruction of road Gose e Alba Konstruksion (W) ALBANIA (W) 28 Jun 2013 Works Open 666,825 Madhe-Gose e Vogel CURRI SH.P.K. ALBANIA RSM sh.p.k. ALBANIA S.M.O. UNION SH.P.K. ALBANIA 42319 Fier and Vlore 58581 Fieri Bypass Serenissima Costruzioni ITALY (W) 18 Mar 2013 Works Open 39,866,013 bypass roads s.p.a. (W) Aktor GREECE COPRI CONSTRUCTION KUWAIT EKO INSAAT VE TICARET LTD TURKEY GRANDI LAVORI FINCOSIT SPA ITALY IMPRESA ING. FORTUNATO ITALY FEDERICI S.P.A MAPA CONSTRUCTION, TURKEY TRADING & INDUSTRY CO. INC Onur TURKEY

Annex 1 ALBANIA Transport

42319 Fier and Vlore 58581 Fieri Bypass 18 Mar 2013 Works Open 39,866,013 bypass roads

SOCIETA ITALIANA PER ITALY CONDOTTE D'AQUA S.P.A. STRABAG AG AUSTRIA TODINI COSTRUTIONI SPA ITALY ALBANIA 24 90,368,585 ARMENIA Municipal 39815 Yerevan 51641 PP7 - Supply of New Track Components and STT Broker CJSC (W) RUSSIAN 25 Apr 2013 Works Open 1,448,891 & Env Inf Metro Maintenance Tools for Maintenance of the FEDERATION Rehabilitation Metro System ASHOTSQ LLC ARMENIA Project Eldekor XXI plus LLC RUSSIAN FEDERATION 40718 Armenian 52664 ASMWP-13 Design and Construction of Consortium ARPA-SEVAN- ARMENIA (W) 08 Aug 2013 Supply & Open 2,399,046 Small Waste Water Treatment Plant in Dilijan and KUNST (W) Installation Municipalities Jermuk Consortium SADE / BLESK ARMENIA Water Project JV Suardi JSC / Hayjr-nakhagits ITALY Institute CJSC LUDWIG PFEIFFER HOCH-UND GERMANY TIEFBAU GMBH & CO.KG RENCO S.P.A. ITALY 54442 ASMWP-1 Rehabilitation of the water supply Ararat-Chanshin LLC (W) ARMENIA (W) 29 Apr 2013 Works Open 1,326,800 network in Byureghavan and Abovyan SHMSH-23 OJSC ARMENIA 54661 ASMWP-2 Rehabilitation of the Water Supply ShmSh-23 OJSC (W) ARMENIA (W) 26 Apr 2013 Works Open 1,079,916 Network in Sevan town AIS LLC ARMENIA ARARAT-CHANSHIN LLC ARMENIA ARTEZIA LLC ARMENIA PAREX-GAZ LLC ARMENIA 55941 ASMWP-3 Rehabilitation of the Water Supply ShmSh-23 OJSC (W) ARMENIA (W) 03 Sep 2013 Works Open 2,289,808 Network and Waste Water Network in Dilijan AIS LLC ARMENIA ARPA-SEVAN OJSC ARMENIA ARTASHATSHIN LLC ARMENIA Artezia LLC ARMENIA Parex-Gaz LLC ARMENIA SADE CGTH SA FRANCE 56081 ASMWP-4 Rehabilitation of the Water Supply SADE CGTH SA (W) FRANCE (W) 18 Sep 2013 Works Open 1,389,032 Network in Tashir town, ASMWP-WORKS- DZILYO production cooperative ARMENIA 2013-04 GOWHARRUD inter-national IRAN Construction Co 56684 ASMWP-6 Rehabilitation of the water supply Arpa-Sevan OJSC (W) ARMENIA (W) 04 Oct 2013 Works Open 939,624 network in Martuni town DZILYO production cooperative ARMENIA SHMSH-23 OJSC ARMENIA 56685 ASMWP-10 Rehabilitation of the water Blesk LLC and Artezia LLC ARMENIA (W) 14 Oct 2013 Works Open 1,324,695 supply network in Artik SADE CGTH SA FRANCE SHMSH-23 OJSC ARMENIA Sunir Co IRAN 56802 ASMWP-5 Rehabilitation of the Water Supply SADE CGTH and ARTASHES FRANCE (W) 15 Oct 2013 Works Open 1,384,231 Network in Gavar and Saroukhan towns EV TATEVIK LLC (W) Agat-777 LLC ARMENIA ARPA-SEVAN OJSC ARMENIA

Annex 1 ARMENIA Municipal & Env Inf

40718 Armenian Small Municipalities Water Project

56822 ASMWP-7 Rehabilitation of the Water Parex-Gaz LLC (W) ARMENIA (W) 29 Oct 2013 Works Open 686,373 Supply Network in Chambarak Artashatshin LLC ARMENIA HB Construction LLC ARMENIA 57001 ASMWP-8 Rehabilitation of water supply Spitak-1 OJSC (W) ARMENIA (W) 13 Nov 2013 Works Open 1,799,645 network in Spitak, Jrashen and Akhtala ARTEZIA LLC ARMENIA BAGHRAMYANSHIN OJSC ARMENIA Eghvardshin OJSC ARMENIA 57002 ASMWP-9 Rehabilitation of water supply Four Directions LLC, ARMENIA (W) 13 Nov 2013 Works Open 2,526,760 network in Kapan town Ashotsq LLC (W) Magma Construction Company IRAN 57003 ASMWP-12 Rehabilitation of water supply Baghramyanshin OJSC (W) ARMENIA (W) 24 Oct 2013 Works Open 2,753,559 network in Ijevan town and Azatamut Artashatshin LLC ARMENIA community Eghvardshin OJSC ARMENIA 58401 ASMWP-11 Rehabilitation of the Waste ShmSh-23 OJSC (W) ARMENIA (W) 04 Dec 2013 Works Open 1,194,626 Water Network in Jermuk town AIS LLC ARMENIA Arpa-Sevan OJSC ARMENIA Blesk LLC RUSSIAN FEDERATION SUNIR Co. IRAN Veya LLC and Veya Stroy OJSC ARMENIA 41356 Yerevan 54443 PP 8 - Refurbishment and modernisation of JSC Electric Rolling Stock GEORGIA (W) 29 May 2013 Goods Open 2,439,150 Metro 8 units of metro cars Type 81-717 Repair Plant Tbilisi Branch Rehabilitation (ZREPS) (W) ARMENIA 15 24,982,156 AZERBAIJ Transport 43094 Roads 55263 Review and Update of the Detailed Design Destia-Finnroad Limited (W) FINLAND (W) 15 Feb 2013 Consultant Competitive 1,364,277 AN Reconstructio and Assitance with the Prequalification and Services PRO YAPI Design Co. Ltd TURKEY n and Tendering Process for the Rehabilitation of Upgrading the Mingachevir - Bahramtapa Road (R18) AZERBAI Project 1 1,364,277 JAN BOSNIA Municipal 40775 Bijeljina Phase 46884 Design and Construction of Municipal Va Tech Wabag GmbH & AUSTRIA (W) 16 Sep 2013 Works Direct 7,031,644 AND & Env Inf 2 - Wastewater Treatment Plant - EU IPA, SIDA HIGRA d.o.o. (W) Selection HERZEGO Wastewater Building Development Holding BULGARIA VINA Treatment Envitec S.A. - Alternative Tender GREECE Plant JV Coning - Tehnograd CROATIA JV Hidroinzeniring - Pfeiffer SLOVENIA JV TM.E. - Integral ITALY Mass Aritma Sistemleri Insaat TURKEY Sanayi ve Ticaret A.S. STRABAG AG AUSTRIA 51941 Construction of Main Secondary Sewer Buk Promet Doo Bijeljina BOSNIA AND 21 Feb 2013 Works Open 3,278,665 Collector No. 3 - Majevicka Street (W) HERZEGOVINA (W) Higra d.o.o. BiH-RS BOSNIA AND HERZEGOVINA

Annex 1 BOSNIA Municipal 40775 Bijeljina Phase AND & Env Inf 2 - HERZEGO Wastewater VINA Treatment Plant

51941 Construction of Main Secondary Sewer 21 Feb 2013 Works Open 3,278,665 Collector No. 3 - Majevicka Street

RABMER Rohrtechnik GmbH, AUSTRIA Austria 55601 Consulting Services - Support to PIU HIDRO-SIMP d.o.o. of ATC BOSNIA AND 07 May 2013 Consultant Direct 49,000 Bijelina (W) HERZEGOVINA Services Selection (W) 42889 Sarajevo 51482 Project Management Supervision Engineer Consortium DIVEL d.o.o., BOSNIA AND 01 Jul 2013 Consultant Competitive 401,825 Urban Roads Integra d.o.o. and ZIL HERZEGOVINA Services Development inzenering d.d. (W) (W) Project AECOM Inocsa BOSNIA AND HERZEGOVINA IPSA BOSNIA AND HERZEGOVINA Roughton UNITED KINGDOM 51902 New construction and Upgrading of the 12th JV Euro-asfalt d.o.o BOSNIA AND 30 May 2013 Works Open 10,862,757 Transversal Road Section Sarajevo, GP ZGP d.d. HERZEGOVINA Sarajevo and Hidrogradnja (W) d.d. Saraje (W) Hering Prijedorputevi BOSNIA AND HERZEGOVINA Ozgun Insaat TURKEY Strabag AUSTRIA 52041 New Construction and Upgrading of the HP Investing (W) BOSNIA AND 03 Jun 2013 Works Open 2,273,042 South Longitudinal Road Section 1 HERZEGOVINA (W) Hering d.d. BOSNIA AND HERZEGOVINA JV Euroasfalt-JATA BOSNIA AND HERZEGOVINA Ozgun Insaat TURKEY Power and 44199 EPBiH - Hydro 58182 Project Implementation Unit Consultancy Studio Ing. G Pietrangeli ITALY (W) 15 Nov 2013 Consultant Competitive 1,947,805 Energy Power Plants Services S.R.L. (W) Services Project EGIS EAU FRANCE FICHTNER GMBH & CO.KG GERMANY NORPLAN AS NORWAY POYRY ENERGY GMBH AUSTRIA STUCKY LTD SWITZERLAND Transport 37543 Bosnia & 55225 LOT 1: Rehabilitation of Road M-18 LJUBACE JV "Jata Group & Euroasfalt BOSNIA AND 25 Feb 2013 Works Open 2,225,477 Herzegovina - ZIVINICE KM 6+765 - KM 8+095 AND M- BA" (W) HERZEGOVINA Road 18 AND DURDEVIK - VITALJ KM 19+582 - (W) Rehabilitation KM 41+708 Arapovac & Roading BOSNIA AND Project HERZEGOVINA PUTOVI D.O.O. GRUDE BOSNIA AND HERZEGOVINA 38716 Corridor Vc 56262 Construction of Motorway on Corridor Vc: JV "Euro-Asfalt d.o.o. and BOSNIA AND 07 May 2013 Works Open 24,403,100 Section Drivusa-Kakanj, Subsection Gorica- GP ZGP d.d." (W) HERZEGOVINA Biljesevo (Phase II) (W)

Annex 1 BOSNIA AND HERZEGO VINA

Transport

38716 Corridor Vc 56262 Construction of Motorway on Corridor Vc: 07 May 2013 Works Open 24,403,100 Section Drivusa-Kakanj, Subsection Gorica- Biljesevo (Phase II) HERING D.O.O BOSNIA AND HERZEGOVINA OHL ZS A.S. CZECH REPUBLIC BOSNIA 9 52,473,315 AND HERZEGO VINA BULGARIA Municipal 41377 Burgas 58582 P6 C11a, C11b, C12c & P9 C16 Engineering, DZZD DEPO-BURGAS (W) BULGARIA 21 Jun 2013 Works Alternative 4,782,801 & Env Inf Integrated design & construction for bus depot, diesel (W) Urban and methan fuel-filling station Transport 44135 Varna 58684 Trolleybuses renewal Skoda Electric a.s. (W) CZECH 13 Sep 2013 Goods Alternative 14,311,446 Integrated REPUBLIC (W) Urban Transport 58963 Rolling Stock - Diesel articulated buses Solaris Bus and Coach SA POLAND (W) 22 Oct 2013 Goods Alternative 7,980,114 Project 58981 Rolling Stock - Low-floor city diesel buses Solaris Bus and Coach SA POLAND (W) 22 Oct 2013 Goods Alternative 4,140,058 58983 Rolling Stock - New low-floor city CNG buses Solaris Bus and Coach SA POLAND (W) 22 Oct 2013 Goods Alternative 4,564,069 BULGARI 5 35,778,488 CROATIA Municipal 37187 Sisak 52101 DS Consultancy Services Supervision of EPTISA, Servicios de SPAIN (W) 18 Mar 2013 Consultant Alternative 1,391,500 & Env Inf Wastewater Design and Construction Ingenieria, S.L. (W) Services Management 54761 WW2 Waste water treatment works Cret Tehnika d.d (W) CROATIA (W) 24 May 2013 Works Alternative 10,175,000 Project secondary level of treatment 54762 Waste water equipment - Lot 2 customised Agra Trgovina d.o.o. (W) CROATIA (W) 10 May 2013 Goods Alternative 125,000 van with CCTV sewer inspection camera equipment and connected IT equipment 54901 WW1-3A-4 Construction of wastewater Koncar-Inzenjering Za CROATIA (W) 30 Aug 2013 Works Alternative 12,654,767 collection system - Galdovo complex and Energetiku I Transport d.d., Odranska & Zeleni collectors Durkin d.o.o., Astra Int. inz 55341 Waste water equipment - Lot 1 Sewerage Gradatin(W) d.o.o. (W) CROATIA (W) 21 May 2013 Goods Alternative 465,000 suction flushing tankers 56483 Construction of two river crossings Braco Kop d.o.o. (W) CROATIA (W) 27 Nov 2013 Works Alternative 498,685 underneath the Kupa river 38501 Zagreb 52162 2B SCADA procurement and installation of Koncar-Inzenjering za CROATIA (W) 25 Mar 2013 Supply & Open 296,951 Holding Water following measuring equipment Energetiku I Transport d.d. Installation and Sewer (KET) (W) Investment JVCA IMGD Ltd CROATIA Project Ozgur Cecen Engineering and TURKEY Contracting Company 39990 North 54481 Project implementation support and Safege Consulting FRANCE (W) 31 Dec 2013 Consultant Competitive 328,505 Western construction supervision Engineers, Safege d.d.o., Services Regional Rescon d.d.o. (W) Waste Water MVV Decon GmbH GERMANY Project Niras a/s Denmark and Institut DENMARK IGH d.d. Croatia P2mberlin GmbH GERMANY

Annex 1 CROATIA Municipal & Env Inf

39990 North 54481 Project implementation support and 31 Dec 2013 Consultant Competitive 328,505 Western construction supervision Services Regional Waste Water Project

Ramboll Copanhagen DENMARK Transport 39749 Port of 55481 Infrastructure Rehabilitation Project in the JV Strabag AG - Pomgrad GERMANY (W) 14 Mar 2013 Works Open 8,087,964 Sibenik Port of Sibenik Inzenjering d.o.o. (W) Infrastructure Cyes-Viadukt SPAIN Rehabilitation JV Aertssen - Coddeel BELGIUM Project KONSTRUKTOR-INZENJERING CROATIA D.D. SPLIT 42754 Croatia 58123 Supply & Installation of AWOS for Airports of Telvent Netherlands BV (W) NETHERLAND 09 Oct 2013 Supply & Open 801,209 Control ATM Pula and Split S (W) Installation Modernisation Project CROATIA 10 34,824,581 FYR Power and 27768 FYR 56222 Supply and Installation of Substation Koncar - Power Plant and CROATIA (W) 28 May 2013 Supply & Open 1,884,915 MACEDON Energy Macedonia Automation Control System, Protection and Electric Traction Eng. inc. Installation IA Transmission DC supply for 9 substations ABB Switzerland ltd SWITZERLAND Interconnectio Caraglio s.r.l. Impianti Elettrici ITALY n JVA SC Energobit SA ROMANIA MVM OVIT Orszagos HUNGARY Villamostavvezetek Zrt SEL UNITED STATES Siemens s.p.a. ITALY T&D Engineering BULGARIA 58021 Supply and Installation of a new SCADA/EMS Siemens AG Osterreich (W) AUSTRIA (W) 14 Oct 2013 Supply & Open 3,800,000 System for the National Dispatch Centre, Alstom GRID S.A.S FRANCE Installation Back-up Dispatch Centre and Market Consortium Koncar - Power CROATIA Management System Plant and Electric Transport 39311 Regional and 57163 Municipal Roads Phase III - Lot 1 - Skopje GD Granit A.D. (W) FYR 15 Apr 2013 Works Open 1,811,701 Local Roads and Polog Region MACEDONIA Programme (W) Eskavatori Company KOSOVO 57166 Municipal Roads Phase III - Lot 2 - TDGP ILINDEN AD (W) FYR 15 Apr 2013 Works Open 2,966,010 Southwest and Pelagonija Region MACEDONIA (W) GD GRANIT AD FYR MACEDONIA 57167 Municipal Roads Phase III - Lot 3 - GD BETON AD (W) FYR 15 Apr 2013 Works Open 1,854,934 Northeast and East Region MACEDONIA (W) TDGP ILINDEN AD FYR MACEDONIA 57168 Municipal Roads Phase III - Lot 4 -Vardar GD Granit A.D. (W) FYR 15 Apr 2013 Works Open 1,181,100 and Southeast Region MACEDONIA (W) Zikol dooel FYR MACEDONIA

Annex 1 FYR MACEDON IA

Transport 39311 Regional and Local Roads Programme

57181 Regional Roads Phase III - Lot 1 - R2432 GD Granit A.D. (W) FYR 22 May 2013 Works Open 577,322 Angelci-Veljusa-Vodoca-Banica MACEDONIA (W) Integral Inzenjering a.d. BOSNIA AND HERZEGOVINA Strabag AG AUSTRIA 57182 Regional Roads Phase III - Lot 2 - R2433 GD BETON AD (W) FYR 29 May 2013 Works Open 2,633,427 Radovis-Konce-Lubnica MACEDONIA (W) GD GRANIT A.D. FYR MACEDONIA Integral Inzenjering a.d. BOSNIA AND HERZEGOVINA STRABAG AG AUSTRIA 57183 Regional Roads Phase III - Lot 3 - R1107 GD Granit A.D. (W) FYR 22 May 2013 Works Open 2,342,003 Kavadarci-Musov grob MACEDONIA (W) CK-13HOLD-ING JSC BULGARIA Consortium Urban Inves & ALBANIA Companya Eskavatori SHPK ISA 2000 Ltd BULGARIA JV Vojput AD - Subotica & SMB SERBIA Gradnja STRABAG AG AUSTRIA Viadukt d.d. CROATIA 57184 Regional Roads Phase III - Lot 4 - R1201 TDGP ILINDEN AD (W) FYR 22 May 2013 Works Open 3,890,975 Struga-Debar MACEDONIA (W) CK-13HOLD-ING JSC BULGARIA GD GRANIT A.D. FYR MACEDONIA INTEGRAL INZENJERING A.D. BOSNIA AND LAKTASI HERZEGOVINA JV Vojput AD-Subotica & SMB SERBIA Gradnja STRABAG AG AUSTRIA 57602 Veles-Kadrifakovo Phase 1 - Interchange STRABAG AG (W) AUSTRIA (W) 02 Sep 2013 Works Open 1,284,490 Veles-end of third line (Veles landfill), ESKAVATORI Construction KOSOVO Lozovo, Saramzalino Company GD BETON AD FYR MACEDONIA GD GRANIT A.D. FYR MACEDONIA ISA 2000 LLC BULGARIA 57901 Municipal Roads Phase IV - Lot 1 - Skopje JV "Ilinden" AD - Struga & FYR 20 Sep 2013 Works Open 2,221,401 and Polog Region Progres 1998 dooel Gostivar MACEDONIA (W) (W)

Annex 1 FYR MACEDON IA

Transport 39311 Regional and Local Roads Programme

57901 Municipal Roads Phase IV - Lot 1 - Skopje 20 Sep 2013 Works Open 2,221,401 and Polog Region

BETON FYR MACEDONIA GRANIT AD FYR MACEDONIA 57903 Municipal Roads Phase IV - Lot 2 - JV "Ilinden" AD - Struga & FYR 20 Sep 2013 Works Open 1,985,547 Southwest and Pelagonija Region Progres 1998 dooel Gostivar MACEDONIA (W) (W) GRANIT AD FYR MACEDONIA 58521 Municipal Roads Phase IV - Lot 3 - Northeast GD Granit A.D. (W) FYR 09 Oct 2013 Works Open 2,443,846 and East Region MACEDONIA (W) 58522 Municipal Roads Phase IV - Lot 4 - Vardar GD Granit A.D. (W) FYR 09 Oct 2013 Works Open 2,053,587 and Southeast Region MACEDONIA (W) Zikol dooel FYR MACEDONIA 41327 Macedonian 58421 Section 2 - Nogaevci to Negotino CK-13 HOLD-ING JSC (W) BULGARIA 17 Jul 2013 Works Open 9,399,755 Railways - (W) Corridor X Aktor S.A. GREECE Costruzioni Linee Ferroviarie ITALY Generale Construzioni ITALY Ferroviarie S.p.A. H.F. Wiebe GmbH & Co. KG GERMANY OHL ZS, A.S. CZECH REPUBLIC PORR Bau GmbH AUSTRIA SUBTERRA A.S. CZECH REPUBLIC TERNA SA GREECE 42921 FYR 58621 Rehabilitation of Section KUMANOVO - H. F. Wiebe GmbH&Co. KG GERMANY (W) 20 Dec 2013 Works Open 39,753,619 Macedonia: BELJAKOVCE (W) Railway ACTOR GREECE Corridor VIII - JVCA Acilim TURKEY Phase I JVCA PORR AUSTRIA JVCA STRABAG AUSTRIA JVCA Tema GREECE Sinohydro CHINA SUBTERRA CZECH REPUBLIC 43997 Railways Fleet 56662 Consulting Services Assistance with Project URS Infrastructure & UNITED 03 Jul 2013 Consultant Selection 250,000 Renewal Procurement and Implementation Environment UK Limited KINGDOM (W) Services from a Project (W) shortlist ARDANUY Ingenieria, S.A SPAIN D¿APPOLONIA spa ITALY SGS Correl Ltd UNITED KINGDOM

Annex 1 FYR MACEDON IA

Transport

43997 Railways Fleet 56662 Consulting Services Assistance with Project 03 Jul 2013 Consultant Selection 250,000 Renewal Procurement and Implementation Services from a Project shortlist

SYSTRA FRANCE TECHNOMA GmbH AUSTRIA 58544 Procurement of New Freight Wagons ZOS TRNAVA A.S. (W) SLOVAK 18 Dec 2013 Goods Open 13,208,750 REPUBLIC (W)

Astra Rail Industries ROMANIA CNR Jinan railway LTD CHINA Djuro Djakovic specijalna vozila CROATIA Legios Europe AG CZECH REPUBLIC Tatravagonka Poprad SLOVAK REPUBLIC Texmaco Rail Ingenering INDIA FYR 19 95,543,382 MACEDO NIA GEORGIA Municipal 37560 Kobuleti 53283 Construction of Kobuleti waste water Azertunel LLC (W) AZERBAIJAN 23 Jul 2013 Works Open 1,697,649 & Env Inf Water treatment plant (WWTP)-Civil Works (W) Arsan Aritma Ve Insaat A.S. TURKEY Azeri Private Multi Profile Firm AZERBAIJAN JV of Company Black Sea Group GEORGIA Ltd & Coskun Aritma Sistemleri JV of Java Ltd, Fenno Water Ltd GEORGIA Oy and Erisimedi JSC Ludwig Preiffer Hoch und GERMANY Tiefbau GmbH & Co. KG 40019 Government 50324 Supply of a Compactor for operation and Galoper Ltd (W) ARMENIA (W) 04 Feb 2013 Goods Open 206,839 of Georgia maintenance of landfill BOMAG GERMANY Gr. Motors AZERBAIJAN GEORGIA 2 1,904,488 KAZAKHST Municipal 43718 Almaty Bus 54902 Supply of 200 CNG buses Zhengzhou Yutong Bus Co. CHINA (W) 26 Sep 2013 Goods Open 24,359,547 AN & Env Inf Sector Reform Ltd (W) Phase 2 Shanghai Sunwin Bus CHINA Xinjiang Sanbao Industry Group CHINA Co. Ltd Xinjiang Sanxin Investment Co. CHINA Ltd. Zyle Motor Company KOREA Power and 42039 KEGOC 55541 Rehabilitation of 220kV OHTL Ossakarovka KEC INTERNATIONAL INDIA (W) 19 Mar 2013 Supply & Open 8,892,320 Energy Osakarovka LIMITED (W) Installation Restructuring JV Gam Arak Industrial IRAN Loan Company and Kayson Inc JV Sinohydro Corporation and CHINA HYPEC 43483 Shardara HPP 58902 Modernisation Project of Shardarinskaya HPP Andritz Hydro GmbH (W) GERMANY (W) 18 Dec 2013 Supply & Open 75,107,911 Modernization LOT - Replacement / Refurbishment of Spetgidroenergomontazh RUSSIAN Installation Project Generators, Turbines & Mechanical FEDERATION Auxiliaries, Control, Protection & Electrical Auxiliaries Annex 1 KAZAKHST AN

Power and Energy

43483 Shardara HPP 58902 Modernisation Project of Shardarinskaya HPP 18 Dec 2013 Supply & Open 75,107,911 Modernization LOT - Replacement / Refurbishment of Installation Project Generators, Turbines & Mechanical Auxiliaries, Control, Protection & Electrical Tyazhmash JSC RUSSIAN Auxiliaries FEDERATION KAZAKHS 3 108,359,778 TAN KYRGYZ Municipal 38878 Bishkek Water 51921 WS-1 Lot 3 Reconstruction of pipeline along Kyrgyzenergostroi OJSC KYRGYZ 11 Apr 2013 Works Open 358,177 REPUBLIC & Env Inf Swiss SECO Manasa str. from BChK to Saadayeva Street (W) REPUBLIC (W) Grant Aziastroikompleks Ltd. KYRGYZ REPUBLIC FMU-1 Ltd KYRGYZ REPUBLIC Gidrant-teh Ltd., KYRGYZ REPUBLIC Joint Kyrgyz-Kazakh Gradient KYRGYZ Ltd REPUBLIC Kainar CJSC KYRGYZ REPUBLIC 52382 WS-1 Lot 4 Reconstruction of water mains Gradient Ltd (W) KYRGYZ 13 Feb 2013 Works Open 471,801 of the well field Severnyi REPUBLIC (W)

OJSC Kyrgyzenergostroi KYRGYZ REPUBLIC 53581 WS-1 Lot 5 Construction of pipeline along kainar CJSC Kyrgyzstan (W) KYRGYZ 12 Jun 2013 Works Open 478,860 T.Moldo Str. from BChK to Saadaeva Str. REPUBLIC (W) and along Saadaeva Str. to Orozbekova street Aziastroikompleks Ltd. KYRGYZ REPUBLIC FMU-1 Ltd. KYRGYZ REPUBLIC Gidrant-teh Ltd. KYRGYZ REPUBLIC Joint Kyrgyz-Kazakh Gradient KYRGYZ Ltd REPUBLIC OJSC Kyrgyzenergostroi KYRGYZ REPUBLIC 54342 WS-1 Lot 6 Construction of Pipeline D-325 kainar CJSC Kyrgyzstan (W) KYRGYZ 12 Jun 2013 Works Open 430,909 along Jibek-Jolu Street from Ibraimova REPUBLIC (W) Street to Osmonkula Street 1158 meters FMU-1 Ltd KYRGYZ REPUBLIC Gidrant-Teh Ltd. KYRGYZ REPUBLIC Joint Kyrgyz-Kazakh Gradient KYRGYZ Ltd. REPUBLIC KiV ltd. KYRGYZ REPUBLIC

Annex 1 KYRGYZ Municipal 38878 Bishkek Water REPUBLIC & Env Inf Swiss SECO Grant

54342 WS-1 Lot 6 Construction of Pipeline D-325 12 Jun 2013 Works Open 430,909 along Jibek-Jolu Street from Ibraimova Street to Osmonkula Street 1158 meters

Remservice CJSC KYRGYZ REPUBLIC 55581 WS-4 Supply of ultrasonic & electro- Fela Planungs AG (W) SWITZERLAN 01 Nov 2013 Goods Open 537,524 magnetic flow water meters for installation D (W) in wellfields Endress and Hauser KAZAKHSTAN Instruments International AG 40752 CHOD-2013- 54802 OWRP PP3 Lot 3.1: Supply and Installation Fela Planungs AG (W) SWITZERLAN 01 Oct 2013 Supply & Open 870,000 02-02 - Osh of Goods for Rehabilitation of Wastewater Roshard AG SWITZERLANDD (W) Installation 40753 Jalalabad 50861 PP1: Sewerage Maintenance Vehicles Uralo-Sibirskaya RUSSIAN 01 Jul 2013 Goods Open 206,279 Water including pipe cleaning vehicle, equipment Promyshlennaya Companiya FEDERATION Rehabilitation for pipe cleaning compatible with pipe (W) (W) Project cleaning vehicle 41492 Bishkek Public 55556 BPTD03 Supply of maintenance machinery Asiaautocenter Ltd (W) KYRGYZ 05 Nov 2013 Goods Open 144,464 Transport Lot 1- Item 1.2 Tractor-excavator and 1.3 REPUBLIC (W) Project Recovery truck Finance F KYRGYZ REPUBLIC Grand Motors AZERBAIJAN 57861 BPTD03 Supply of maintenance machinery Grand Motors LLC (W) AZERBAIJAN 31 Oct 2013 Goods Open 102,821 Lot 1- Item 1.1 Mobile hydraulic crane (W) AsiaAutocenter KYRGYZ REPUBLIC Finance F KYRGYZ REPUBLIC 57862 BPTD03 Supply of maintenance machinery Chelyabtransservice (W) RUSSIAN 27 Nov 2013 Goods Open 189,433 Lot 2 Item 2.1 Elevating platforms FEDERATION (W) Asiaautocenter KYRGYZ REPUBLIC Grand Motors AZERBAIJAN KYRGYZ 10 3,790,268 REPUBLI MOLDOVA Municipal 40267 Moldova - 50702 LOT 1, 2, 3+7 Supply of Maintenance Grand Motors LLC (W) AZERBAIJAN 14 May 2013 Goods Open 77,610 & Env Inf Water Utilities Equipment and Specialised Vehicles for Six (W) Development Regional Water Companies in Moldova - Bergerat Monnoyeur SRL ROMANIA Programme Soroca Boss Pro-tec GmbH GERMANY East-Auto-Lada SRL MOLDOVA SRL Auto-Prezent MOLDOVA 53141 Extension and rehabilitation of water supply SC Geprocon SA (W) ROMANIA (W) 17 Jul 2013 Works Open 976,874 system in Orhei FCP SOLDI SRL MOLDOVA JV Afina Vsh SRL ROMANIA LACATUS SRL MOLDOVA Liftmontag Tresor JVCA MOLDOVA NNC-Traversa SRL MOLDOVA Planta SRL MOLDOVA 53142 Supply of water meters for four regional Ningbo Water Meter Co. Ltd. CHINA (W) 21 Jun 2013 Goods Open 73,008 water companies in Moldova GO-WatMet-01 - (W) Leova

Annex 1 MOLDOVA Municipal 40267 Moldova - & Env Inf Water Utilities Development Programme

53142 Supply of water meters for four regional 21 Jun 2013 Goods Open 73,008 water companies in Moldova GO-WatMet-01 - Leova Itron France FRANCE 54302 Supply of Maintenance Equipment - Ceadir JVCA SC Tehno World SRL ROMANIA (W) 15 Oct 2013 Goods Open 6,369 Lunga GO-ME-2 and Techno Test SRL (W) SC San Euro Stil SRL MOLDOVA 54303 Supply of Maintenance Equipment - Soroca JVCA SC Tehno World SRL ROMANIA (W) 15 Oct 2013 Goods Open 15,160 GO-ME-2 and Techno Test SRL (W) SC San Euro Stil SRL MOLDOVA 54304 Supply of Maintenance Equipment - Leova JVCA SC Tehno World SRL ROMANIA (W) 23 Sep 2013 Goods Open 23,718 GO-ME-2 and Techno Test SRL (W) SC San Euro Stil SRL MOLDOVA 54305 Supply of Maintenance Equipment - Orhei JVCA SC Tehno World SRL ROMANIA (W) 16 Oct 2013 Goods Open 4,279 GO-ME-2 and Techno Test SRL (W) SC San Euro Stil SRL MOLDOVA 54306 Supply of Maintenance Equipment - Floresti JVCA SC Tehno World SRL ROMANIA (W) 23 Sep 2013 Goods Open 68,985 GO-ME-2 and Techno Test SRL (W) SC San Euro Stil SRL MOLDOVA 54307 Supply of Maintenance Equipment - Hincesti JVCA SC Tehno World SRL ROMANIA (W) 23 Sep 2013 Goods Open 4,279 GO-ME-2 and Techno Test SRL (W) SC San Euro Stil SRL MOLDOVA 54321 Rehabilitation of potable water network in Fedion-Com SRL (W) MOLDOVA (W) 21 Jun 2013 Works Open 830,666 Soroca FPC Lacatus SRL MOLDOVA Lucet-Izodrom MOLDOVA Paggi Adelmo SRL ITALY Promtehgaz SA MOLDOVA SC Casrep SRL ROMANIA SC Geprocon SA ROMANIA 54322 Extension of wastewater system in Leova - JV Izodromgaz Lucet- MOLDOVA (W) 20 May 2013 Works Open 646,707 LE-WWS-01 Comert (W) JV SC DAS SRL Iasi SC Expert ROMANIA Instal SRL JV TOL & SA Construzioni SRL, ITALY Mario Di Cesare SRL 54323 Supply of pumps and chlorination equipment JVCA SC Multigama Tech ROMANIA (W) 30 May 2013 Goods Open 37,052 for Leova and Floresti LEFL-PWP-01 Lot 1 SRL (W) Floresti SC Wilo Romania SRL ROMANIA 54324 Extension of potable water and wastewater JV Lucet-Izodrom (W) MOLDOVA (W) 25 Sep 2013 Works Open 318,456 in Orhei Phase 2 - LOT 1 - OR-WWS-03 JV Polimer Gaz Conducte SRL MOLDOVA Mario Di Cesare SRL ITALY SA Damicgaz MOLDOVA SA Promtehgaz MOLDOVA SC Casrep SRL ROMANIA SC Geprocon SA ROMANIA 54341 Extension of wastewater system in Ceadir- Consortium Lucet- MOLDOVA (W) 16 May 2013 Works Open 1,580,006 Lunga CL-WWS-04 Izodromgaz (W) Promtehgaz S.A. MOLDOVA

Annex 1 MOLDOVA Municipal 40267 Moldova - & Env Inf Water Utilities Development Programme

55421 Extension of water supply system in Floresti JV Polimer Gaz Conducte MOLDOVA (W) 02 Jul 2013 Works Open 2,002,508 for of Izvoara, Varvareiuca for lot 1, Ltd. & Polimer Gaz Ghindesti Domulgeni lot 2, Ghindesti, Constructii Ltd (W) Cenusa lot 3 - FL-WSS-03 JV Lucet-Izodrom MOLDOVA Promtehgaz SA MOLDOVA SA DARNIC GAZ MOLDOVA SC GEPROCON SA ROMANIA 55422 Rehabilitation of Ground Water Source for JV Polimer Gaz Conducte MOLDOVA (W) 04 Sep 2013 Works Open 909,150 Floresti FL-WSS-01 Ltd. & Polimer Gaz Constructii Ltd (W) JV Lucet-Izodrom MOLDOVA Promtehgaz SA MOLDOVA SA Damic Gaz MOLDOVA SC Geprocon SA ROMANIA Soldi SRL MOLDOVA 55424 Supply of pumps and chlorination equipment JVCA Oniko PE (W) UKRAINE (W) 21 Jun 2013 Goods Open 155,466 for Leova and Floresti LEFL-PWP-01 Lot 2 JVCA Policontract SRL MOLDOVA 56002 Water source Firladeni HI-WSS-03 PROMTEHGAZ SA (W) MOLDOVA (W) 03 Sep 2013 Works Open 836,964

JV Lucet-Izodrom MOLDOVA JV SA Darnic gaz and Sarco MOLDOVA Service SRL SC Geprocon SA ROMANIA Soldi SRL MOLDOVA 57082 LOT 1 Supply of Maintenance Equipment Grand Motors LLC (W) AZERBAIJAN 14 May 2013 Goods Open 4,445 and Specialised Vehicles for Six Regional Boss Pro-tec GmbH GERMANY(W) 57085 LOT 1, 2+3 Supply of Maintenance Grand Motors LLC (W) AZERBAIJAN 14 May 2013 Goods Open 87,825 Equipment and Specialised Vehicles for Six (W) Regional Water Companies in Moldova - Bergerat Monnoyeur SRL ROMANIA Orhei Boss Pro-tec GmbH GERMANY East-Auto-Lada SRL MOLDOVA SRL Auto-Prezent MOLDOVA 57086 LOT 1+2 Supply of Maintenance Equipment Grand Motors LLC (W) AZERBAIJAN 14 May 2013 Goods Open 8,525 and Specialised Vehicles for Six Regional Boss Pro-tec GmbH GERMANY(W) 57161 Extension of potable water and wastewater JV Polimer Gaz Conducte MOLDOVA (W) 15 Oct 2013 Works Open 1,542,260 in Orhei Phase 2 - LOT 2 - OR-WWS-03 Ltd. & Polimer Gaz Constructii Ltd (W) JV Lucet-Izodrom SRL MOLDOVA Mario Di Cesare SRL ITALY SA Promtehgaz MOLDOVA SC Casrep SRL ROMANIA SC Geprocon SA ROMANIA 57165 Supply of pumps and chlorination equipment JVCA Oniko PE (W) UKRAINE (W) 25 Jun 2013 Goods Open 1,152,490 for Leova and Floresti LEFL-PWP-01 Lot 2 JVCA Policontract SRL MOLDOVA 58041 Supply of water meters for four regional Ningbo Water Meter Co. Ltd. CHINA (W) 28 Jun 2013 Goods Open 126,750 water companies in Moldova GO-WatMet-01 - (W) Orhei Itron FRANCE

Annex 1 MOLDOVA Municipal 40267 Moldova - & Env Inf Water Utilities Development Programme

58042 Supply of water meters for four regional Ningbo Water Meter Co. Ltd. CHINA (W) 21 Jun 2013 Goods Open 126,750 water companies in Moldova GO-WatMet-01 - (W) Soroca Iton FRANCE 58061 Supply of pumps and chlorination equipment JVCA SC Multigama Tech ROMANIA (W) 04 Jun 2013 Goods Open 121,477 for Leova and Floresti LEFL-PWP-01 Lot 1 SRL (W) Leova SC Wilo Romania SRL REUNION 43827 Balti 56602 BTP01 Supply of trolleybuses SC Carpat BELAZ Service ROMANIA (W) 18 Dec 2013 Goods Open 3,666,196 Trolleybus SRL and OJSC Holding Project Management Company Belkommunmash (W) City Transport Group LLC and UKRAINE LAZ LLC Eximotor SA and Trolza-Market MOLDOVA LLC Speranta PF Com SRL and MOLDOVA Jinhua Youngman Automobile Manufacturing Co. Ltd. MOLDOV 27 15,403,975 MONTENE Municipal 41252 Danilovgrad 54642 Water supply component - Rehabilitation J.V. CMC Controlmatic MONTENEGRO 11 Sep 2013 Works Open 840,454 GRO & Env Inf Municipal and extension of water supply network Commerce d.o.o. Herceg (W) Infrastructure Novi & CMC Ekocon d.o.o. Project Logatec (W) ALB-STAR Ltd. ALBANIA J.V. Viadukt d.d. Zagreb & Asfalt CROATIA Konstruckcije d.o.o. Ludwig Pfeiffer Hoch und GERMANY Tiefbau GmbH & Co KG Power and 40219 EPCG 55362 Supply of Ancillary Equipment for Smart Mezon d.o.o. (W) MONTENEGRO 29 Mar 2013 Goods Open 961,063 Energy Metering and Meters Installation (W) Distribution Siemens d.o.o. SERBIA MONTEN 2 1,801,517 EGRO MOROCCO Power and 44057 ONE-Rural 55546 Rural Electrification Works (53 villages) Atlas Energy (W) MOROCCO 14 May 2013 Works Open 4,389,138 Energy Electrification (W) and Smart CEGELEC MOROCCO Metering ELCOTRAM MOROCCO ELECNOR SPAIN ELECTRO TADART MOROCCO EMTEYCO Maroc MOROCCO SGEE MOROCCO 55554 Rural Electrification Works (48 villages) Electricite Bellet (W) MOROCCO 19 Mar 2013 Works Open 2,670,177 (W) CEGELEC MOROCCO CONTI MOROCCO ELECNOR SA, SPAIN SPAIN ELECTRIMED MOROCCO EMTEYCO MOROCCO

Annex 1 MOROCCO Power and 44057 ONE-Rural Energy Electrification and Smart Metering

55554 Rural Electrification Works (48 villages) 19 Mar 2013 Works Open 2,670,177

ENTEG MOROCCO OURELEC MOROCCO SGEE MOROCCO 55555 Rural Electrification Works (82 villages) EMTEYCO Maroc (W) MOROCCO 09 Apr 2013 Works Open 7,002,567 (W) CEGELEC MOROCCO ELECNOR SA, SPAIN SPAIN ELECTRIMED MOROCCO ELECTRO TADART MOROCCO SERF MOROCCO 55557 Rural electrification Works (57 vilages) Somaprec (W) MOROCCO 02 Apr 2013 Works Open 2,761,127 (W) CEGELEC MOROCCO ELECNOR SA, SPAIN SPAIN ELECTRICITE BELLET MOROCCO ELECTRIMED MOROCCO OURELEC MOROCCO 55558 Rural Electrification Works (79 vilages) OURELEC (W) MOROCCO 30 Apr 2013 Works Open 3,827,140 (W) CEGELEC MOROCCO ELECTRIMED MOROCCO ENTEG MOROCCO 55559 Rural Electrification Works (50 villages) PACIFEL (W) MOROCCO 02 Apr 2013 Works Open 1,797,281 (W) CEGELEC MOROCCO ELCOTRAM MOROCCO ELECTRIMED MOROCCO ELECTRO TADART MOROCCO 55560 Rural electrification Works (55 villages) TEGAEL MAROC (W) MOROCCO 14 May 2013 Works Open 3,064,657 (W) CEGELEC MOROCCO CONTI CORPORATION MOROCCO EMTEYCO MAROC MOROCCO 55823 Rural Electrification Works (131 Villages) OURELEC (W) MOROCCO 30 Apr 2013 Works Open 3,918,749 (W) CONTI Corporation MOROCCO ELECTRO TADART MOROCCO ENTEG MOROCCO ISOTRON Maroc MOROCCO 56261 Rural Electrification Works (68 Villages) TEGAEL MAROC (W) MOROCCO 27 May 2013 Works Open 586,994 (W) CEGELEC MOROCCO ELECTRO AIT ASOUNE MOROCCO 56281 Rural Electrification Works (68 Villages) ELECTRIMED (W) MOROCCO 21 May 2013 Works Open 23,657,046 (W) CEGELEC MOROCCO SGEE MOROCCO

Annex 1 MOROCCO Power and 44057 ONE-Rural Energy Electrification and Smart Metering

56281 Rural Electrification Works (68 Villages) 21 May 2013 Works Open 23,657,046

SOMAPREC MOROCCO TEGAEL MAROC MOROCCO 56301 Rural Electrification Works (45 villages) CEGELEC (W) MOROCCO 03 Jun 2013 Works Open 39,632,311 (W) Atlas Energy/Imadrelec MOROCCO Electro Industrie MOROCCO 56302 Rural Electrification Works (20 villages) Somaprec (W) MOROCCO 07 Jun 2013 Works Open 688,419 (W) ELECTRIMED MOROCCO ELECTRO AIT SAOUNE MOROCCO ICOMEL/SORULEC MOROCCO 56321 Rural Elefctrification Words (41 Villages) EMTEYCO Maroc (W) MOROCCO 16 May 2013 Works Open 3,870,221 (W) CEGELEC MOROCCO SISTEM MOROCCO 56322 Rural Electrification works (74 villages) Atlas Energy (W) MOROCCO 03 Jun 2013 Works Open 6,297,352 (W) CEGELEC MOROCCO ELECTRIMED MOROCCO 56323 Rural Electrification Works (106 villages) Atlas Energy (W) MOROCCO 06 Jun 2013 Works Open 2,486,013 (W) CEGELEC MOROCCO EMTEYCO MOROCCO ISONTRON MOROCCO TEGAEL MOROCCO 56324 Rural Electrification Works (29 villages) ELECTRO TAFOGHALT (W) MOROCCO 06 Jun 2013 Works Open 1,507,016 (W) CEGELEC MOROCCO TECH ELEC MOROCCO TEGAEL MAROC MOROCCO 56325 Rural Electrification Works (46 villages) Somaprec (W) MOROCCO 06 Jun 2013 Works Open 2,186,471 (W) CEGELEC MOROCCO 56326 Rural Electrification Works (73 villages) Somaprec (W) MOROCCO 06 Jun 2013 Works Open 2,038,986 (W) CEGELEC MOROCCO TEGAEL MAROC MOROCCO 56342 Rural Electrification Works (55 Villages) ELECTRO TAFOGHALT (W) MOROCCO 06 Jun 2013 Works Open 3,513,594 (W) GEGELEC MOROCCO Groupement PACIFEL / MOROCCO IMADRELEC TEGAEL MAROC MOROCCO 56343 Rural Electrification Works (26 Villages) ELECTRIMED (W) MOROCCO 21 May 2013 Works Open 2,473,425 (W) EMTEYCO MAROC MOROCCO GAMAF MOROCCO

Annex 1 MOROCCO Power and 44057 ONE-Rural Energy Electrification and Smart Metering

56343 Rural Electrification Works (26 Villages) 21 May 2013 Works Open 2,473,425

GEGELEC MOROCCO PACIFEL MOROCCO SISTEM MOROCCO 56361 Rural Electrification Works (54 Villages) ELCOTRAM (W) MOROCCO 06 Jun 2013 Works Open 3,299,113 (W) CONTI Corporation MOROCCO EMTEYCO MOROCCO LUMAFRIC MOROCCO MOROCC 21 121,667,796 ROMANIA Municipal 33932 Bucharest 54881 P3 Procurement of electrical pumps and SC Elsaco Electronic SRL ROMANIA (W) 19 Dec 2013 Supply & Open 3,279,252 & Env Inf Multi-Sector control systems for substations, spread over SC Radcom SRL & SC Griro SA & ROMANIA Installation Project the 6 distribution sectors of Radet SC Pro T.C. Grup SRL (Radet) SC Romib SA & SC Electro-Total ROMANIA SRL SC TMUCB SA ROMANIA Termigas SpA ITALY 39276 R2CF Iasi Sub- 56461 CL4 - Upgrading of Timisesti catchment S.C. Daroconstruct SRL (W) ROMANIA (W) 02 Apr 2013 Works Alternative 2,083,621 Project fields Verseni and Zvoranesti 56463 CL11 - Upgrading of water and sewerage S.C. TMUCB SA (W) ROMANIA (W) 26 Apr 2013 Works Alternative 4,218,194 systems in Tg Frumos 56464 CL12 - Upgrading of sewers in Harlau S.C. Iasicon S.A. (W) ROMANIA (W) 10 May 2013 Works Alternative 1,801,413 56604 CL13 - Upgrading of water and sewerage S.C. Iasicon S.A. (W) ROMANIA (W) 03 Jun 2013 Works Alternative 3,344,230 systems in Podu Ilioaiei 40338 Sibiu 54522 Upgrade and Refurbishment of Streets along JV SC Terra Buiding SRL, SC ROMANIA (W) 12 Apr 2013 Works Open 259,399 Municipality Public Transport Routes - Area Grigore CONSAL SRL (W) Loan - Phase Ureche - Anatole France Sreets -from JV Cycasa Canteras Y ROMANIA II Savings Constructiones SA Bilbao Suc./Semnalizare SC Comtram SA ROMANIA SC Geiger Transilvania SRL ROMANIA 57061 Upgrade and Refurbishment of Streets - SC Comtram SA (W) ROMANIA (W) 31 Oct 2013 Works Open 130,753 Vasile Parvan Street from Savings SC CONSTRUCTII SA ROMANIA SC Terra Buiding SRL ROMANIA 41175 R2CF Targu 54842 MS-TA-YB-05 Tarnaveni - Rehabilitation of SC Edas Exim SRL,SC Tehnic ROMANIA (W) 28 Feb 2013 Works Alternative 4,003,640 Mures Sub- DWTP Trust SA,SC Beespeed Project Automatizari SRL,SC Datcomp SRL (W) 55121 MS-L&I-YB-08 Ludus and Iernut - SC Veolia Water Solutions ROMANIA (W) 25 Mar 2013 Works Alternative 7,757,133 Rehabilitation of WWTP and Technologies Romania SRL (W) 56541 MS-SG&CS-YB-04 Sighisoara and Cristuru SC AEG Tehnology SRL (W) ROMANIA (W) 19 Jun 2013 Works Alternative 5,814,189 Secuiesc - Rehabilitation of DWTPs 56542 MS-VN-RB-06- Valea Nirajului - new main Hidroconstructia S.A. (W) ROMANIA (W) 04 Jun 2013 Works Alternative 4,029,642 trunk 58921 MS-RG-RB-05 Reghin extension of sewerage SC Geiger Transilvania SRL, ROMANIA (W) 12 Sep 2013 Works Alternative 2,316,109 system, wastewater pumping stations and SC Lasprom SRL (W) discharge pipes

Annex 1 ROMANIA Municipal & Env Inf

41177 R2CF 57341 Rehabilitation of the water network in S.C. Fluid Serv S.A. (W) ROMANIA (W) 29 Oct 2013 Works Open 114,641 Constanta sub- Predeal City - (from 15374 MELF Constanta SC Insigra SRL ROMANIA 41178 R2CF Sibiu 59141 CL1 - Extension and rehabilitation of the SC Constructii SA (W) ROMANIA (W) 17 Jul 2013 Works Alternative 2,441,713 sub-project water supply and swerege networks in Avrig and Marsa Localities 59161 CL2 - Wastewater Treatment Plant for Avrig SC Gavella Com SRL, SC ROMANIA (W) 17 Jul 2013 Works Alternative 3,499,633 and Marsa localities and the mechano- Terra Med SRL (W) electrical rehabilitation of the Avrig water catchment 59162 CL3 - Water mains Apa Secaselor Water SC A.C.I. BISTRITA SA (W) ROMANIA (W) 27 Sep 2013 Works Alternative 8,351,163 main Sibiu-Ocna Sibiului, Water main Ocna Sibiului-Miercurea Sibiului 59163 CL4 - Extension and rehabilitation of water SC Universal Business SA ROMANIA (W) 22 Apr 2013 Works Alternative 3,880,723 distribution and sewerage networks in Ocna (W) Sibiului locality 59164 CL5 - Wastewater Treatment Plant for Ocna SC de Constructii Napoca SA ROMANIA (W) 29 Apr 2013 Works Alternative 1,388,236 Sibiului locality (W) 59167 CL9 - Extension and rehabilitation of water SC Geiger Transilvania SRL ROMANIA (W) 12 Jul 2013 Works Alternative 4,753,199 distribution and sewerage networks in (W) Cisnadie and Rasinari localities 59168 CL10 - Rehabilitation of water catchment SC Hidroconstructia SA, SC ROMANIA (W) 06 Nov 2013 Works Alternative 2,828,914 and water mains for Fagaras municipality General Concrete Cernavoda SRL, SC Benni Prest SRL (W) 59169 CL11 - Extension and rehabilitation of water SC RECON SI DOJE SRL (W) ROMANIA (W) 14 Jun 2013 Works Alternative 9,728,610 distribution and sewerage networks in Fagaras municipality 41633 Medias Urban 50961 PMMR contract for Road Infrastructure in Tehnic Asist SRL, Kiat Group ROMANIA (W) 29 Mar 2013 Works Direct 4,269,996 Infrastructure Ighisul Nou Village, Medias Municipality, Construct SRL, Proiect Selection Rehabilitation Sibiu County Bucuresti sRL (W) project 41890 R2CF Brasov 55666 CW7 - Extension and erhabilitation of water SC Ocide Construccion SA SPAIN (W) 02 Apr 2013 Works Alternative 13,999,465 sub-project transport in Agglomeration Brasov-Sacele (W) 42129 R2CF Buzau 55403 CL5 - Upgrading of water and sewage SC Hidroconstructia SA and ROMANIA (W) 12 Feb 2013 Works Alternative 14,441,895 sub-project systems in Pogoanele and Patarlagele SC General Concrete Cernavoda SRL (W) 42130 R2CF 56842 CL8-Works at water sources and WWTP of SC Rotary Constructii SRL & ROMANIA (W) 28 Feb 2013 Works Alternative 8,488,753 Dambovita - Gaesti and Titu Comsa SA (W) Targoviste 59223 CP1A-Leak detection SC EE Test SA (W) ROMANIA (W) 11 Nov 2013 Goods Alternative 81,957 Sub-Project 59224 CP3-Procurement and installation of SCADA SC Secvision Business ROMANIA (W) 19 Sep 2013 Supply & Alternative 1,253,055 equipment Solutions SRL,SC Mikon Installation Systems SRL,SC Palex Constructii SR (W) 43137 R2CF Timis 57201 CL9 Extension and modernization of the Videli SRL & Lucy Star SRL ROMANIA (W) 28 Mar 2013 Works Alternative 4,162,172 water and sewerage networks in Sanmihaiu (W) Roman and Utvin

Annex 1 ROMANIA Municipal & Env Inf

43137 R2CF Timis

57706 CL14 Extension and modernisation of water SC Grup Construct SRL and ROMANIA (W) 08 Mar 2013 Works Alternative 4,112,765 and sewerage networks in Gataia and Ludwig Pfeiffer Hoch-und Ciacova Tiefbau GmbH & Co KG (W) 57721 CL10 Extension and modernisation of water Victor Construct SRL (W) ROMANIA (W) 14 Mar 2013 Works Alternative 2,913,051 and sewerage networks in Sacalaz 57722 CL16 Extension and modernisation of water Constructim SA and ROMANIA (W) 22 Mar 2013 Works Alternative 2,166,936 and sewerage networks in Buzias Multinstal SRL (W) 43189 R2CF Dolj 57982 CL2 Craiova WTP - Isainita WTP EMIT Ercole Marelli Impianti ITALY (W) 04 Mar 2013 Works Alternative 8,289,506 Water Sub- Tecnologici S.p.a., SC Mitliv Project Exim SRL (W) 57983 CL3 Calafat - WTP and WWTP and Trunk S.C. CORAL SRL TULCEA, ROMANIA (W) 07 May 2013 Works Alternative 9,060,822 Main from Calafat to Poiana mare S.C. ENERGOMONTAJ SA 57984 CL4 Craiova WWTP Landfill SC GECOROM S.A., ISPE S.A ROMANIA (W) 13 Mar 2013 Works Alternative 1,599,384 (W) 57986 CL6 Filiasi WWTP SC UTI GRUP S.A., SC ROMANIA (W) 03 Jan 2013 Works Alternative 3,533,392 DANEX CONSULT S.R.L (W) 57987 CL7 New water and wastewater networks in SC POLYSTART IMPEX SRL, ROMANIA (W) 19 Apr 2013 Works Alternative 7,289,050 Poiana Mare SC TCIF SA CRAIOVA, SC CONFORT SA (W) 57988 CL8 Rehabilitation & extension of W&WW SC GRUP PRIMACONS ROMANIA (W) 27 Mar 2013 Works Alternative 5,245,117 networks in Bailesti S.R.L., VIALES Z OBRAS PUBLICAS S.A. (W) 57989 CL10 Transfer sewers + Regional WWTPs in SC Mitliv Exim SRL, EMIT ROMANIA (W) 07 Jun 2013 Works Alternative 14,230,279 Rastu Nou & Bechet Ercole Marelli Impianti Tecnologici S.p.A. (W) 57990 CL12 Transfer collector Segarcea and SC EDAS EXIM, SC EUROPAN ROMANIA (W) 15 Apr 2013 Works Alternative 2,717,228 wastewater treatment plant PROD SRL (W) 57991 CL13 The water source and the water and SC Constructii Erbasu S.A., ROMANIA (W) 05 Apr 2013 Works Alternative 6,360,811 sewerage networks in Segarcea SC Polystart Impex SRL (W) 58861 CS4 Project Audit SC ELITE AUDIT S.R.L. (W) ROMANIA (W) 28 Jun 2013 Consultant Alternative 10,015 Services 58881 CL11 Water Sources extension of water FIN CONSTRUCT SRL, OPRA ROMANIA (W) 12 Sep 2013 Works Alternative 7,896,755 networks and new wastewater network in CONSTRUZIONI SRL (W) Dalubeni Calarasi and Bechet 43216 R2CF Satu 58787 SM-CL-05 WWTP construction in Tasnad and SC 3T Construct SRL, Stulz ROMANIA (W) 17 May 2013 Works Alternative 4,409,971 Mare Sub- Ardud cities Planaqua GmbH (W) Project 59202 SM-CL-04 Refurbishment and extension of SC Interfrigo Logistrics SRL, ROMANIA (W) 31 Oct 2013 Works Alternative 3,434,221 WWTP in Negresti Oas City and construction ESC Edas Exim SRL (W) of WWTP in Livada City 59203 SM-CS-03 Auditing services of the Project SC KPMG Audit SRL (W) ROMANIA (W) 20 Nov 2013 Consultant Alternative 34,831 Services Transport 44271 CFR Financial 57461 Consulting Services - Small Assignments Drew Transport Consultants UNITED 22 Apr 2013 Consultant Direct 16,500 Restructuring (W) KINGDOM (W) Services Selection

ROMANI 46 206,042,336

Annex 1 RUSSIAN Municipal 35294 Sakha 51483 Pe-1.2 Lot ST Procurement of special LLC TD Techindustria (W) RUSSIAN 21 Aug 2013 Goods Open 114,710 FEDERATI & Env Inf (Yakutia) vehicles trucks for Zhigansk FEDERATION ON Republican (W) MSDP GUP LLC Spectechnika-Sever RUSSIAN ZhKH FEDERATION LLC TPF Lenaprom-stroysnab RUSSIAN FEDERATION 53682 Pe-2c Laying of Heating Mains and Supplying LLC Stroimontazh-2002 (W) RUSSIAN 13 Jun 2013 Works Open 1,585,177 Water to Boiler Plant of Srednekolymsk- FEDERATION Retender (W) 37966 NDEP - 52681 A-2 Installation of 2 GHS, 45 IHS to provide LLC Spetsgazavtomatika RUSSIAN 17 Jan 2013 Supply & Open 4,858,053 District heat supply after decommissioning of small Russia (W) FEDERATION Installation heating coal fired boiler houses (W) Component of the Kaliningrad Water & Env. Services Rehabilitation Programme. COMMITMENT 40899 Pskov water 58523 1A - Completion of work components Garantstroyservice Ltd. (W) RUSSIAN 09 Dec 2013 Works Direct 2,675,105 and included in construction of groundwater FEDERATION Selection wastewater intake (W) improvement 41188 Vologda 50041 7 Reconstruction of Molochnoye settlement LLC Energostroy (W) RUSSIAN 05 Dec 2013 Supply & Open 3,639,985 District heat supply system - DH-6.1 + DH-6.3 FEDERATION Installation Heating (W) 55764 5 Reconstruction and Construction of heat LLC Termoizolstroy (W) RUSSIAN 04 Sep 2013 Works Open 1,188,564 transmission pipelines LLC Aquaplast RUSSIANFEDERATION DH8.2+DH8.4+DH9.4+DH9.6+DH9.7 FEDERATION 41847 Lipetsk 51645 Rehabilitation of Aeration and Sedimentation Firma SENS CJSC (W) RUSSIAN 06 Feb 2013 Works Open 5,003,805 Wastewater Tanks of WWTP Lipetsk-3 x Aeration Tanks FEDERATION Treatment and 8 existing secondary sedimentation (W) Plant 54041 Construction of a air blower station Firma SENS CJSC (W) RUSSIAN 25 Nov 2013 Works Open 2,342,834 FEDERATION (W) 43283 Sakha 52732 LOT 4 - Supply of equipment for energy LLC BR Trade (W) RUSSIAN 25 Jan 2013 Goods Open 423,796 (Yakutia) efficiency boilers and related services - FEDERATION Energy Burners (W) Efficiency 52733 LOT 1 - Supply of equipment for energy Vostoktechtorg CJSC (W) RUSSIAN 10 Jun 2013 Goods Open 340,446 Programme efficiency boilers and related services - FEDERATION Pumps (W) Elit-Teplo M LLC, Russia RUSSIAN FEDERATION KSB LLC RUSSIAN FEDERATION

Annex 1 RUSSIAN Municipal FEDERATI & Env Inf ON

43283 Sakha (Yakutia) Energy Efficiency 52733 LOT 1 - Supply of equipment for energy 10 Jun 2013 Goods Open 340,446 Programme efficiency boilers and related services - Pumps

Liask-T LLC RUSSIAN FEDERATION PromHimTech LLC RUSSIAN FEDERATION 56182 Heating Mains Reconstruction of Tiksi Variant Plus LLC (W) RUSSIAN 28 Aug 2013 Works Open 4,189,171 FEDERATION (W) LLC TeploMontazh RUSSIAN FEDERATION LLC Yakutskie teplvie seti RUSSIAN FEDERATION Power and 44222 Vladivostok 56821 Vladivostok Combined Heat and Power Plant, ENERGAS LLC (W) RUSSIAN 25 Jun 2013 Supply & Open 8,092,161 Energy Combined Slovenia.Three Booster Compressor Stations FEDERATION Installation Heat & Power and Gas Treatment (W) Plant CJSC Gas Systems RUSSIAN FEDERATION CJSJ NPK Unicmash RUSSIAN FEDERATION Consortium : GEA Grasso RUSSIAN Refregeration OOO & CJSC Fir FEDERATION HAFI Engineering & Consulting AUSTRIA Gesellschaft m.b.H SFERA LLC RUSSIAN FEDERATION 58462 Procurement of Three Booster Exhaust Heat OJSC "Power Machines" (W) RUSSIAN 26 Nov 2013 Goods Open 6,964,753 Boilers FEDERATION (W) CJSC TEP-Holdings RUSSIAN FEDERATION EKOL, spol. s.r.o. CZECH REPUBLIC Interenergo LCC RUSSIAN FEDERATION JV: CJSC PIK Energotrast & RUSSIAN MasgTechnologia FEDERATION OJSC HC Energomash-Stroy RUSSIAN FEDERATION OJSC Podolskiy RUSSIAN Mashinostroitelnyi plant FEDERATION TECHNOSERV AS LTD RUSSIAN FEDERATION ZIO Podolsk Mashinostroitelnyi RUSSIAN plant FEDERATION ZIOMAR RUSSIAN FEDERATION

Annex 1 RUSSIAN FEDERATI ON

Transport 41905 RZD Energy 56467 Lot 1: Supply of LED Lighting Equipment and JSC "SpetsProm" (W) RUSSIAN 04 Jun 2013 Supply & Open 217,911 Efficiency Installation Supervision Services FEDERATION Installation Project (W) JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "Lider Light Trade" RUSSIAN FEDERATION JSC "Philips" RUSSIAN FEDERATION OJSC "Proton" RUSSIAN FEDERATION 56482 Lot 2: Supply of LED Lighting Equipment and OJSC "Miassky RUSSIAN 04 Jun 2013 Supply & Open 193,008 Installation Supervision Services Mashinebuilding Plant" (W) FEDERATION Installation (W) JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "Philips" RUSSIAN FEDERATION JSC "Prosoft Trading" RUSSIAN FEDERATION JSC "SPETSPROM" RUSSIAN FEDERATION JSC NPP "EnergoTechService" RUSSIAN FEDERATION 56501 Lot 3: Supply of LED Lighting Equipment and Optogan CJSC (W) RUSSIAN 04 Jun 2013 Supply & Open 212,338 Installation Supervision Services FEDERATION Installation (W) JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "Philips" RUSSIAN FEDERATION JSC "SPETSPROM" RUSSIAN FEDERATION OJSC "Proton" RUSSIAN FEDERATION 56502 Lot 4: Supply of LED Lighting Equipment and Optogan CJSC (W) RUSSIAN 04 Jun 2013 Supply & Open 145,042 Installation Supervision Services FEDERATION Installation (W) JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "PHILIPS" RUSSIAN FEDERATION JSC "SPETSPROM" RUSSIAN FEDERATION OJSC "MIASSKY RUSSIAN MASHINEBUILDING PLANT" FEDERATION

Annex 1 RUSSIAN FEDERATI ON

Transport 41905 RZD Energy Efficiency Project

56503 Lot 5: Supply of LED Lighting Equipment and JSC "SpetsProm" (W) RUSSIAN 04 Jun 2013 Supply & Open 98,354 Installation Supervision Services FEDERATION Installation (W) JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "LiderLight Trade" RUSSIAN FEDERATION JSC "Philips" RUSSIAN FEDERATION OJSC "MIASSKY RUSSIAN MASHINEBUILDING PLANT" FEDERATION 58341 No.1. Set of LED light fixtures for JSC Prosoft Trading (W) RUSSIAN 25 Oct 2013 Supply & Open 162,046 illumination facility of the site: Sverdlovsk FEDERATION Installation Infrastructure Directorate of Yekaterinburg- (W) Sortirovochnyi hump yard JSC Philips RUSSIAN FEDERATION JSC Svetlana ¿E RUSSIAN FEDERATION OJSC Miassky Mashinebuilding RUSSIAN plant FEDERATION 58342 No.2. Set of LED light fixtures for JSC BL Trade (W) RUSSIAN 25 Oct 2013 Supply & Open 145,407 illumination facility of the site: Moscow FEDERATION Installation Infrastructure Directorate, Bryansk-Lgovcky (W) station CJSC Svetlana - OE RUSSIAN FEDERATION JSC Leader Light Trade RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION 58343 No.3. Set of LED light fixtures for JSC BL Trade (W) RUSSIAN 25 Oct 2013 Supply & Open 97,063 illumination facility of the site: West Siberian FEDERATION Installation Infrastructure Directorate, Barabinsk station (W) CJSC Svetlana - OE RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION 58344 No.4. Set of LED light fixtures for JSC Prosoft Trading (W) RUSSIAN 25 Oct 2013 Supply & Open 141,046 illumination facility of the site: Privolzhsky FEDERATION Installation Infrastructure Directorate, Volzhsky station (W) CJSC Svetlana - OE RUSSIAN FEDERATION JSC Leader Light Trade RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION

Annex 1 RUSSIAN FEDERATI ON

Transport 41905 RZD Energy Efficiency Project

58361 No.5. Set of LED light fixtures for OJSC "Miassky RUSSIAN 25 Oct 2013 Supply & Open 105,884 illumination facility of the site: South Urals Mashinebuilding Plant" (W) FEDERATION Installation Infrastructure Directorate, (W) Metallurgicheskaya station CJSC Svetlana - OE RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION JSC PROSOFT- TRADING RUSSIAN FEDERATION JSC SpetsProm RUSSIAN FEDERATION 58362 No.6. Set of LED light fixtures for JSC Prosoft Trading (W) RUSSIAN 25 Oct 2013 Supply & Open 143,361 illumination facility of the site: East Siberian FEDERATION Installation Infrastructure Directorate, Ulan-Ude station (W) CJSC Svetlana - OE RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION 58363 No.7. Set of LED light fixtures for JSC BL Trade (W) RUSSIAN 25 Oct 2013 Supply & Open 99,499 illumination facility of the site: Trans-Baikal FEDERATION Installation Infrastructure Directorate, Chita-1 station (W) CJSC Svetlana - OE RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION 58364 No.9. Set of LED light fixtures for JSC BL Trade (W) RUSSIAN 25 Oct 2013 Supply & Open 215,749 illumination facility of the site: South Eastern CJSC Svetlana - OE RUSSIAN Installation Infrastructure Directorate, Stoilenskaya FEDERATION station railway yard "A" and railway yard "B" JSC ¿Philips¿ RUSSIAN FEDERATION 58365 No.10. Set of LED light fixtures for CJSC Svetlana-OE (W) RUSSIAN 25 Oct 2013 Supply & Open 342,873 illumination facility of the site: Oktyabrsk FEDERATION Installation Infrastructure Directorate, Belomorsk station (W) JSC Philips RUSSIAN FEDERATION JSC SpetsProm RUSSIAN FEDERATION 58366 No.11. Set of LED light fixtures for OJSC "Miassky RUSSIAN 25 Oct 2013 Supply & Open 104,989 illumination facility of the site: Kuibyshev Mashinebuilding Plant" (W) FEDERATION Installation Infrastructure Directorate, Ruzayevka station (W) JSC Leader Light Trade RUSSIAN FEDERATION JSC NPP EnergoTechService RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION

Annex 1 RUSSIAN FEDERATI ON

Transport 41905 RZD Energy Efficiency Project

58366 No.11. Set of LED light fixtures for 25 Oct 2013 Supply & Open 104,989 illumination facility of the site: Kuibyshev Installation Infrastructure Directorate, Ruzayevka station

JSC SpetsProm RUSSIAN FEDERATION 58367 No.12. Set of LED light fixtures for CJSC Transenercom (W) RUSSIAN 25 Oct 2013 Supply & Open 66,563 illumination facility of the site: North FEDERATION Installation Caucasus Infrastructure Directorate, (W) Novorossiysk station CJSC Optogan¿ RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION OJSC Miaasky Machinebuilding RUSSIAN Plant FEDERATION 58501 No.8. Set of LED light fixtures for CJSC Optogan (W) RUSSIAN 07 Nov 2013 Supply & Open 161,599 illumination facility of the site: Far East FEDERATION Installation Infrastructure Directorate, Khabarovs -1 (W) station CJSC Optogan RUSSIAN FEDERATION CJSC Svetlana-Opto Electronika RUSSIAN FEDERATION JSC NPP EnergoTechService RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION JSC SpetsProm RUSSIAN FEDERATION 58982 Lot 1 Intelligent energy-saving LED-based JSC Ecolight (W) RUSSIAN 20 Dec 2013 Supply & Open 151,839 lighting system for Anapa railway station FEDERATION Installation (W) RUSSIAN 31 44,223,130 FEDERAT ION SERBIA Municipal 44014 Belgrade Bus 52662 New low-floor articulated buses x 200 Solaris Bus and Coach SA POLAND (W) 08 Mar 2013 Goods Open 63,877,499 & Env Inf Renewal Ashok Leyland Ltd INDIA Programme Ikarbus ad in restructuring SERBIA factory of buses and Special Iveco Czech as with JVCA Iveco CZECH France SA REPUBLIC LLC Russian Buses-GAZ Group RUSSIAN FEDERATION Man Truck & Bus AG Dachauer GERMANY Volvo Bus Corporation SE-40508 SWEDEN Power and 41923 EPS Kolubara 55441 A1 Bucket Wheel Excavator Thyssen Krupp AG (W) GERMANY (W) 28 Mar 2013 Supply & Open 30,908,985 Energy Environmental Installation Improvement NOEN a.s. CZECH REPUBLIC Tenova Takraf GmbH GERMANY 55542 A 2 Belt Conveyor System Kopex Joint Stock Company POLAND (W) 28 Mar 2013 Supply & Open 28,288,971 (W) Installation

Annex 1 SERBIA

Power and 41923 EPS Kolubara Energy Environmental Improvement

55542 A 2 Belt Conveyor System 28 Mar 2013 Supply & Open 28,288,971 Installation FAM Magdeburg GERMANY FAMUR SA Mining Machinery POLAND Factory 55544 A 3 Spreader Sandvik Mining and AUSTRIA (W) 26 Apr 2013 Supply & Open 14,380,506 Construction Materials Installation Handling GmbH & Co KG COPEX-FAMAGO Sp.z.o.o POLAND FAM Magdeburg Forderanlagen GERMANY und Baumachinen GmbH Takraf GmbH GERMANY 55545 A 4 Power Supply Monprojekt d.o.o. (W) SERBIA (W) 26 Apr 2013 Supply & Open 1,823,806 ABB Automation GmbH GERMANY Installation Siemens d.o.o. SERBIA Transport 35414 Serbian 58562 Jackscrews with bearing capacity of 8x20t Bertolotti S.p.A (W) ITALY (W) 21 Nov 2013 Goods Open 95,680 Railways : with two control desks Oficine Meccaniche BBM S.p.A ITALY Rollingstock TZV Gredelj in bankruptcy CROATIA 38711 Serbia 36461 Supply of Electric Multiple Units Stadler Rail AG (W) SWITZERLAN 04 Mar 2013 Goods Open 98,999,995 Railways D (W) EMUs No other Tenderers UNITED KINGDOM 39750 K10 58721 Construction of Highway E 80 Section: Trace Group Hold (W) BULGARIA 23 Dec 2013 Works Open 15,364,224 Parallel - non-commercial road, Bela Palanka (W) - Pirot (West) AKTOR SA GREECE Alexandre Barbosa Borges AS PORTUGAL Construcciones Rubau SA SPAIN E80 BEPA ITALY EURO-ASFALT D.O.O. BOSNIA AND SARAJEVO HERZEGOVINA INTEGRAL INZENJERING A.D. BOSNIA AND LAKTASI HERZEGOVINA STRABAG AG AUSTRIA 41125 Serbian 56741 Track Renewal Materials Lot 1 - procurement MORAVIA STEEL A.S. (W) CZECH 29 Apr 2013 Goods Open 9,295,560 Railways of rails of 49E1 & 60E1 type, grade R260 REPUBLIC (W) Corridor X TATA STEEL FRANCE VOEST ALPINA AUSTRIA 56743 Track Maintenance Equipment Lot 4 - Geismar (W) FRANCE (W) 22 May 2013 Goods Open 681,902 sleeper removal/insertion machine NEW SOREMA ITALY 56744 Track Maintenance Equipment Lot 2 - rail- Geismar (W) FRANCE (W) 22 May 2013 Goods Open 1,010,079 road vehicle for track mainenance MAN Importer Srbija-Dewaco SERBIA do.o. 57421 Track Maintenance Equipment Lot 1 - Terra Srbija d.o.o. (W) SERBIA (W) 07 May 2013 Goods Open 77,545 constructional machines 57422 Track Renewal Materials Lot 2 - procurement Vossloh Min Skretnice d.o.o. SERBIA (W) 17 Jun 2013 Goods Open 1,644,570 of new switches with elastic fastening (W) DIV D.O.O. CROATIA VOESTALPINA VAE GmbH GERMANY

Annex 1 SERBIA

Transport

41125 Serbian Railways Corridor X

57423 Track Renewal Materials Lot 6 - procurement Alpine Kamen d.o.o. (W) SERBIA (W) 17 Jun 2013 Goods Open 4,286,409 of crushed stone for ballast prizm 57424 Track Renewal Materials Lot 7 - procurement PYRKONIT d.o.o. (W) SERBIA (W) 17 Jun 2013 Goods Open 175,109 of AT portions with moulds Elektro-Thermit GmbH & Co.KG GERMANY 57425 Track Renewal Materials Lot 8 - procurement OPTICUS d.o.o. (W) SERBIA (W) 17 Jun 2013 Goods Open 621,488 of geocomposite Huesker Synthetic GmbH GERMANY 57426 Track Renewal Materials Lot 9 - procurement Kraiburg Elastik GmbH (W) GERMANY (W) 17 Jun 2013 Goods Open 387,634 of road structures made of rubber elements DIV D.O.O. CROATIA 57521 Track Maintenance Equipment Lot 3 - VAIA CAR SpA (W) ITALY (W) 07 Aug 2013 Goods Open 2,988,000 procuremetn of rail loader excavator GEISMAR FRANCE Tesmec SpA ITALY 57541 Track Renewal Materials Lot 4 - procurement IMPREGNACIJA a.d. (W) SERBIA (W) 07 Aug 2013 Goods Open 2,398,086 of imregnated wooden sleepers Fürstenberg THP GERMANY 57542 Track Renewal Materials Lot 3 - procurement DIV d.o.o. (W) CROATIA (W) 07 Aug 2013 Goods Open 4,934,064 of concrete sleepers with elastic rail DW Schwellen GmbH GERMANY fastenings ZPSV OHL GROUP AD CZECH REPUBLIC 57561 Track Renewal Materials Lot 5 - procurement DIV d.o.o. (W) CROATIA (W) 07 Aug 2013 Goods Open 1,540,380 of rail fastenings type K for wooden sleepers and rails type 49E1 57781 Track Maintenance Equipment Lot 5 - ROBEL Bahnbaumaschinen GERMANY (W) 07 Aug 2013 Goods Open 991,193 procurement of light track maintenance GmbH (W) machinery GEATECH S.p.A. ITALY GEISMAR FRANCE SERBIA 22 284,771,686 SLOVENIA Power and 40417 SOSTANJ 54821 Supply and Installation of Coal Transport - Rudis (W) SLOVENIA (W) 28 Feb 2013 Supply & Open 992,112 Energy Thermal Stage 2 Installation Power Plant EZOTECH d.d. SLOVENIA SONOEN a.s. CZECH REPUBLIC SLOVENI 1 992,112 TAJIKISTA Municipal 40717 Com No. 50142 PP1.1 LOT 1 Supply of Maintenance Doro Ltd (W) TAJIKISTAN 24 May 2013 Goods Open 135,446 N & Env Inf CHNT-2013- Equipment (W) 02-01 Burkhyon Ltd. TAJIKISTAN Switzerland Grand Motors MMC AZERBAIJAN North Tajik Intertekhnologya CJSC RUSSIAN Water Project FEDERATION Account - Khurshedy-Khorazm Ltd. TAJIKISTAN North Tajik SupplyQuip Ltd. MAURITIUS Water Tojplast Ltd. TAJIKISTAN Rehabilitation 53261 PP3.4-Rehabiliation of Water Supply Network Orieno Sorvo Ltd. (W) TAJIKISTAN 29 May 2013 Works Open 576,529 Project in Kairakkum City LOT 1 (W) Boyut Khiranur Ltd. TAJIKISTAN Farrukhruz-1 Ltd TAJIKISTAN Hayot Ltd. TAJIKISTAN MKM Somony Ltd. TAJIKISTAN

Annex 1 TAJIKISTA Municipal 40717 Com No. N & Env Inf CHNT-2013- 02-01 Switzerland North Tajik Water Project Account - North Tajik Water Rehabilitation 53261 PP3.4-Rehabiliation of Water Supply Network 29 May 2013 Works Open 576,529 Project in Kairakkum City LOT 1

Rohat Ltd. TAJIKISTAN Tajik SGEM JSC TAJIKISTAN 53362 PP3.6 Rehabilitation of water supply network Sokhtmony Dekhot Ltd (W) TAJIKISTAN 25 Apr 2013 Works Open 269,929 in Taboshar City (W) Shafof Ltd TAJIKISTAN Sokhtmon Ltd TAJIKISTAN Zarya Vostok SUE TAJIKISTAN 53501 PP3.2-Rehabilitation of water supply network Juziy Zimiston Ltd. (W) TAJIKISTAN 14 May 2013 Works Open 1,755,376 in Gafurov City (W) Firuz Ltd. TAJIKISTAN Madina Ltd. TAJIKISTAN Nigina Ltd. TAJIKISTAN Rohat Ltd. TAJIKISTAN Yahyo Company Ltd. TAJIKISTAN 53661 PP3.1-Rehabilitation of water supply network Umed-1 Ltd. (W) TAJIKISTAN 14 May 2013 Works Open 640,867 in Chkalovsk City (W) Khurshedi Tobon Ltd TAJIKISTAN Magma Construction Company IRAN 55621 PP1.1 LOT 2 Specialised Vehicles LLC Khurshedi Khorasm (W) TAJIKISTAN 10 May 2013 Goods Open 1,040,578 (W) Burkhyon Ltd. TAJIKISTAN Doro Ltd. TAJIKISTAN Grand Motors MMC AZERBAIJAN SupplyQuip Ltd. MAURITIUS Tojplast Ltd. TAJIKISTAN 41642 Central Tajik 53582 CTWRP-001 Comprehensive survey of General Directorate of TAJIKISTAN 20 May 2013 Consultant Competitive 132,218 Water underground water sources and detailed Geology under the (W) Services Rehabilitation design for location of the New Well field in Government of the Republic Project Tursunzoda and Gissar cities of Taiikista (W) State Institution Tojikobdekhot TAJIKISTAN 56021 CTWRP-002 LOT 2 Office Equipment Doro Ltd (W) TAJIKISTAN 29 May 2013 Goods Open 12,645 (W) Electrogidromash LLC TAJIKISTAN 56221 CTWRP-004 Renovation of Kuktosh water LLC Obi Dekhot (W) TAJIKISTAN 30 Oct 2013 Works Open 134,434 intake in Somoniyon (W) CJSC Monalit 05 TAJIKISTAN Consortium LLC Bodoma and TAJIKISTAN LLC Zinat LLC Kalasoz TAJIKISTAN LLC Osari TAJIKISTAN LLC Oyandasoz TAJIKISTAN LLC Solekh 2012 TAJIKISTAN 56421 CTWRP-009 Construction of water main and Electrogidromash LLC and TAJIKISTAN 20 Nov 2013 Works Open 1,648,713 renovation of distribution network in Khurshedi Khorazm LLC (W) Somoniyon city LLC Gayur-1 TAJIKISTAN LLC Khudoyor / LLC Obi Dekhot TAJIKISTAN / LLC Sugdiyon

Annex 1 TAJIKISTA Municipal N & Env Inf

41642 Central Tajik Water Rehabilitation Project

56421 CTWRP-009 Construction of water main and 20 Nov 2013 Works Open 1,648,713 renovation of distribution network in Somoniyon city

LLC Navruz-2003 TAJIKISTAN LLC Rokhat TAJIKISTAN LLC Sichiyon TAJIKISTAN LLC Umed TAJIKISTAN 41769 EBSF-2013-01- 53143 KhSWMP-001 Specialised vehicles; waste Diana & Co LLC (W) TAJIKISTAN 23 Jul 2013 Goods Open 1,060,061 14 Khujand collection trucks and machinery (W) Solid Waste Bark Sokhtmon LLC TAJIKISTAN Management Doro Ltd TAJIKISTAN Grand Motors LLC AZERBAIJAN Unit Export.Ltd UNITED KINGDOM Xinjiang Sanbao Industry Group CHINA Co. Ltd Zeppelin International AG SWITZERLAND 55363 KhSWMP-004 Supply of containers, special Sharifi Khuchandy Co. Ltd TAJIKISTAN 20 Sep 2013 Goods Open 450,750 uniform and working tools (W) (W) Barz Co Ltd TAJIKISTAN CJS Company Nauselmash TAJIKISTAN Khujandprommash Co Ltd TAJIKISTAN KM Sadaf SHAN-Yuy Co Ltd TAJIKISTAN SP Khaydarov S.K TAJIKISTAN SUE Factory Zaria Vostoka TAJIKISTAN YS 3/5 Enterprise TAJIKISTAN TAJIKIST 13 7,921,546 TURKEY Municipal 41222 Bodrum 52181 Procurement of goods for the water network Samsun Makina San. A.S. TURKEY (W) 21 Feb 2013 Goods Open 762,758 & Env Inf Water rehabilitation Tranche 1- pipes Tender No: (W) 2012/ 162384 52661 Procurement of Goods for the Water Samsun Makina San. A.S. TURKEY (W) 07 Jan 2013 Goods Open 472,370 Network Rehabilitation Bodrum - Gumbet (W) High Level Zone - Tranche 1 52841 Rehabilitation of the Existing Water Network GELISIM Insaat Tur. San. Ve TURKEY (W) 03 Apr 2013 Works Open 1,061,392 Bodrum - procurement of works for Tic. Lfd Sti. (W) installation works - 2012-162414 - Tranche 43170 Mersin 54042 Engineering and Supervision Consultancy TEMELSU Uluslararasi TURKEY (W) 10 Oct 2013 Consultant Competitive 1,200,325 Wastewater Services Mühendislik Hizmetleri A.S., Services Project SRP Schneider & Partner Ingeni (W) DORSCH International GERMANY Consultants GmbH & Su-Yapi Muhendislik ve Musavirlik AS EPTISA Servicios De Ingeniera, SPAIN SL. & EPTISA Muh. Mus Hiz Bil. Fichtner Water & Transportation GERMANY GmbH ILF Beratende Ingenieure ZT AUSTRIA GmbH & CDM Smith Europe GmbH

Annex 1 TURKEY Municipal & Env Inf

43170 Mersin 54042 Engineering and Supervision Consultancy 10 Oct 2013 Consultant Competitive 1,200,325 Wastewater Services Services Project

SAFEGE & TEMPO Altyapi BELGIUM Mühendislik Müsavirlik TURKEY 4 3,496,845 UKRAINE Municipal 39299 Lviv Public 55922 Used refursbished tram car rolling stock and Erfurter Verkehrsbetriebe GERMANY (W) 13 May 2013 Goods Direct 254,000 & Env Inf Transport spare parts AG (W) Selection Financing 39789 Lviv Road 49964 Phase II Works for road and tram lines ONUR Taahhut Tasimacilik TURKEY (W) 03 Jun 2013 Works Open 26,535,948 Rehabilitation reconstruction in Lviv City -Tram Lines 2 & 6 Ve Ticaret Ltd.CTI (W) and - Lots 1-6 ELECNOR S.A. SPAIN Power and 40147 South Ukraine 58561 Construction of OHL 750 kV Zaporizhzhia Instalaciones Inabensa, S.A. SPAIN (W) 14 Aug 2013 Supply & Open 55,480,675 Energy Transmission NPP - Kakhova (W) Installation Project CJS ENGINEERING- RUSSIAN CONSTRUCTION SOYUZ-GRID FEDERATION DALEKOVOD D.D. CROATIA ENGINEERING LLC RUSSIAN FEDERATION JYOTI STRUCTURES LIMITED INDIA KALPATARU POWER INDIA TRANSMISSION LTD KEC INTERNATIONAL LIMITED INDIA Transport 40185 Pan-European 58641 OPRC for M06 Kiev to Chop Highway - ELSAMEX Internacionale SPAIN (W) 31 Dec 2013 Works Open 50,533,933 Corridors Contract 1 km 434+230 - km 621+500 ONUR TAAHHUT TASHIMACILIK TURKEY VC TICARET LTD STI. STRABAG JVCA AUSTRIA 58661 OPRC - supervision of works and services Egis International (W) FRANCE (W) 21 Nov 2013 Consultant Competitive 1,219,700 IC CONSULENTEN AUSTRIA Services ZIVILTECHNIKER GESMBH LOUIS BERGER SAS FRANCE MOTT MACDONALD LTD UNITED KINGDOM UKRAINE 5 134,024,256 Grand Total 269 1,269,670,515 (W) Indicates the name and the country of the winning tenderer. All subsequent tenderers listed were unsuccessful in competing for the respective contract.

Annex 1 Listing of Signed Contracts by Country of Operations 2013 - Level of Bank Financing Op Country Sector OPID Op Name Contract Contract Name Tenderer Name Tenderer Country Contract Signing Contract Procurement Signed Contract Fund Source Fund Source ID Date Type Method Value (EUR) Portion (EUR) %

ALBANIA Transport 40153 Local And Regional Roads 55861 Rec 87: Reconstruction of JV GPG Company sh.p.k. & Filipos S.A. ALBANIA (W) 21 Jan 2013 Works Open 4,428,203 2,214,102 50.00% road Lushnje - Hysgjokaj (W) (regional) ALB STAR SH.P.K. ALBANIA GENER 2 SH.P.K. ALBANIA 40153 Local And Regional Roads 56681 Rec 94 Reconstruction of Alb-Building sh.p.k (W) ALBANIA (W) 11 Jan 2013 Works Open 1,514,808 757,404 50.00% road Vaqarr-Gropaj-Kthesa e ALB STAR SH.P.K. ALBANIA Kashurit FUSHA SH.P.K. ALBANIA GENER 2 SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA 40153 Local And Regional Roads 56702 Rec113- Reconstruction of CURRI sh.p.k. (W) ALBANIA (W) 11 Jan 2013 Works Open 634,985 317,493 50.00% main entrance road and Ekskluziv sh.p.k. ALBANIA construction of a pedestrian KARL GEGA KONSTRUKSION SH.P.K. ALBANIA path along seaside on SMO Union sh.p.k. ALBANIA 40153 Local And Regional Roads 56745 Rec 84- Reconstruction of GENER 2 sh.p.k. (W) ALBANIA (W) 26 Mar 2013 Works Open 3,141,709 1,570,855 50.00% road Boge-Qafe Thore, Alb-Star sh.p,k. ALBANIA Shkodra Region Gjikuria sh.p.k. ALBANIA Gjoka Konstruksion sh.a. ALBANIA SK-13 Patstroy BULGARIA 40153 Local And Regional Roads 56746 Rec 99- Reconstruction of CO.Be.IN sh.p.k. (W) ALBANIA (W) 12 Mar 2013 Works Open 3,012,867 1,506,433 50.00% road Novosele-Poro-Pish ALBAVIA SH.P.K ALBANIA Poro, Vlora Region GJIKURIA SH.P.K. ALBANIA SK-13 Patstroy BULGARIA 40153 Local And Regional Roads 56761 Rec106- Reconstruction of ALBAVIA sh.p.k (W) ALBANIA (W) 04 Apr 2013 Works Open 3,062,335 1,531,168 50.00% road Ura Vajgurore-Pashalli- Gjoka Konstruksion sh.a. ALBANIA 40153 Local And Regional Roads 56762 Rec107- Reconstruction of TRIKAT s.a. (W) GREECE (W) 03 Jan 2013 Works Open 2,502,642 1,251,321 50.00% road Lac-Milot in Lezha 40153 Local And Regional Roads 57087 Rec128- Reconstruction of JV "Denis 05" sh.p.k. & "Arifaj" sh.p.k. ALBANIA (W) 06 Jun 2013 Works Open 403,364 201,682 50.00% road Fermentim-Ura e Mesit- (W) Drisht, Lot 1 Alb Tiefbau sh.p.k. ALBANIA CURRI SH.P.K. ALBANIA SMO Union sh.p.k. ALBANIA 40153 Local And Regional Roads 57261 Rec138- Reconstruction of Gjikuria sh.p.k. (W) ALBANIA (W) 28 Jun 2013 Works Open 2,593,572 1,296,786 50.00% road Surrel-Quafe-Priske CURRI SH.P.K. ALBANIA GENER 2 SH.P.K. ALBANIA Vezzola ITALY 40153 Local And Regional Roads 57262 Rec 52- Reconstruction of CURRI sh.p.k. (W) ALBANIA (W) 07 Jun 2013 Works Open 2,118,380 1,059,190 50.00% road Libonik-Rrembee-Plase ANK SH.P.K. ALBANIA COPRI CONSTRUCTION KUWAIT FILIPOS S.A. GREECE GJIKURIA SH.P.K. ALBANIA 40153 Local And Regional Roads 57263 Rec 50- Reconstruction of "Copri Construction Enterprises" W.L.L. KUWAIT (W) 04 Jul 2013 Works Open 1,352,113 676,060 50.00% road Kthesa e Qarrit-Bishan- (W) Poro-Pish Poro-Bregdet CURRI SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA SALILLARI SH.P.K. ALBANIA 40153 Local And Regional Roads 57281 Rec 95- Reconstruction of Salillari sh.p.k. (W) ALBANIA (W) 17 Jun 2013 Works Open 1,263,197 631,599 50.00% road Balez-Letan COPRI CONSTRUCTION KUWAIT CURRI SH.P.K. ALBANIA FILIPOS S.A. GREECE GJIKURIA SH.P.K. ALBANIA GJOKA KONSTRUKSION SH.A. ALBANIA 40153 Local And Regional Roads 57282 Rec136- Reconstruction of Alba Konstruksion (W) ALBANIA (W) 28 Jun 2013 Works Open 997,002 498,501 50.00% road Berxull-Laknas ALB-BUILDING SH.P.K ALBANIA

Annex 1a ALBANIA Transport

40153 Local And Regional Roads 57282 Rec136- Reconstruction of 28 Jun 2013 Works Open 997,002 498,501 50.00% road Berxull-Laknas Copri Construction KUWAIT Gjikuria sh.p.k. ALBANIA Gjoka Konstuksion sh.a. ALBANIA RIVIERA SH.P.K ALBANIA Vezzola ITALY 40153 Local And Regional Roads 57284 Rec137- Reconstruction of Alb-Building sh.p.k (W) ALBANIA (W) 05 Jul 2013 Works Open 1,342,429 671,215 50.00% road connecting Farka with Albakonstruksion sh.p.k. ALBANIA Elbasani Road COPRI CONSTRUCTION KUWAIT CURRI SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA GJOKA KONSTRUKSION SH.A. ALBANIA Vezzola ITALY 40153 Local And Regional Roads 57301 Rec103- Reconstruction of S.M.O. Union sh.p.k. (W) ALBANIA (W) 10 Jun 2013 Works Open 1,134,601 567,301 50.00% road Qerret-Karpen, Lot 1 ALBA KONSTRUKSION ALBANIA ARIFAJ SH.P.K. ALBANIA CGP SLOVENIA DELIA GROUP SH.P.K. ALBANIA FILIPOS S.A. GREECE GENER 2 SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA GPG COMPANY SH.P.K. ALBANIA 40153 Local And Regional Roads 57302 Rec129- Reconstruction of Gjoka Konstruksion sh.a. (W) ALBANIA (W) 06 Jun 2013 Works Open 1,122,921 561,460 50.00% road Unaza e Re-Kashar ALB STAR SH.P.K. ALBANIA ALBA KONSTRUKSION ALBANIA ARIFAJ SH.P.K. ALBANIA DELIA GROUP SH.P.K. ALBANIA FUSHA SH.P.K. ALBANIA S.M.O. UNION SH.P.K. ALBANIA 40153 Local And Regional Roads 57303 Rec127- Reconstruction of Filipos s.a. (W) GREECE (W) 12 Jun 2013 Works Open 1,436,858 718,429 50.00% road Kallmet I Vogel-Ungrej, ALBA KONSTRUKSION ALBANIA Lot 1 ARIFAJ SH.P.K. ALBANIA CGP SLOVENIA DELIA GROUP SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA GPG COMPANY SH.P.K. ALBANIA 40153 Local And Regional Roads 57304 Rec116- Reconstruction of Victoria Invest International sh.p.k. KOSOVO (W) 29 May 2013 Works Open 2,132,628 1,066,314 50.00% road Mollas-Selite-Frasher (W) GJIKURIA SH.P.K. ALBANIA S.M.O. UNION SH.P.K. ALBANIA 40153 Local And Regional Roads 57305 Rec126- Reconstruction of Serenissima Costruzioni s.p.a. (W) ITALY (W) 13 Jun 2013 Works Open 3,324,647 1,662,324 50.00% road Kthesa e Patosit- ALB STAR SH.P.K. ALBANIA Roskovee GENER 2 SH.P.K. ALBANIA STRABAG AG AUSTRIA TADDEI S.P.A. ITALY 40153 Local And Regional Roads 57306 Rec125- Reconstruction of Victoria Invest International sh.p.k. KOSOVO (W) 10 Jun 2013 Works Open 3,058,334 1,529,167 50.00% road Gostime-Gjyrale-Belsh (W) DELIA GROUP SH.P.K. ALBANIA GJIKURIA SH.P.K. ALBANIA GJOKA KONSTRUKSION SH.A. ALBANIA Green Line KUWAIT STRABAG AG AUSTRIA 40153 Local And Regional Roads 57307 Rec 87-1- Reconstruction of JV Trikat s.a. & PE-VLA-KU sh.p.k. (W) ALBANIA (W) 19 Jun 2013 Works Open 3,258,151 1,629,075 50.00% road Hysgjokaj-Kryqezimi Pras-Vashaj GJIKURIA SH.P.K. ALBANIA GPG Kompani sh.p.k. ALBANIA SERENISSIMA COSTRUZIONI S.P.A. ITALY 40153 Local And Regional Roads 57308 Rec130- Reconstruction of Alba Konstruksion (W) ALBANIA (W) 28 Jun 2013 Works Open 666,825 333,412 50.00% road Gose e Madhe-Gose e CURRI SH.P.K. ALBANIA Vogel RSM sh.p.k. ALBANIA S.M.O. UNION SH.P.K. ALBANIA

Annex 1a ALBANIA Transport

34637 Albania: Fier-Tepelene Road 57501 Fier Tepelene Road Section VEGA SHPK (W) ALBANIA (W) 05 Sep 2013 Works Open 6,000,000 0 0.00% Rehabilitation Project 2 - remaining works from km 26.05 to km 30.15 42319 Fier and Vlore bypass roads 58581 Fieri Bypass Serenissima Costruzioni s.p.a. (W) ITALY (W) 18 Mar 2013 Works Open 39,866,013 39,866,013 100.00% Aktor GREECE COPRI CONSTRUCTION KUWAIT EKO INSAAT VE TICARET LTD TURKEY GRANDI LAVORI FINCOSIT SPA ITALY IMPRESA ING. FORTUNATO FEDERICI S.P.A ITALY

MAPA CONSTRUCTION, TRADING & TURKEY INDUSTRY CO. INC Onur TURKEY SOCIETA ITALIANA PER CONDOTTE D'AQUA ITALY S.P.A. STRABAG AG AUSTRIA TODINI COSTRUTIONI SPA ITALY Total ALBANIA 24 90,368,585 62,117,302 68.74% ARMENIA Municipal & 39815 Yerevan Metro Rehabilitation 51641 PP7 - Supply of New Track STT Broker CJSC (W) RUSSIAN 25 Apr 2013 Works Open 1,448,891 0 0.00% Env Inf Project Components and FEDERATION Maintenance Tools for (W) Maintenance of the Metro ASHOTSQ LLC ARMENIA System Eldekor XXI plus LLC RUSSIAN FEDERATION 40718 Armenian Small Municipalities 52664 ASMWP-13 Design and Consortium ARPA-SEVAN-KUNST (W) ARMENIA (W) 08 Aug 2013 Supply & Open 2,399,046 666,402 27.78% Water Project Construction of Waste Water Installati Treatment Plant in Dilijan Consortium SADE / BLESK ARMENIA on and Jermuk JV Suardi JSC / Hayjr-nakhagits Institute ITALY CJSC LUDWIG PFEIFFER HOCH-UND TIEFBAU GERMANY GMBH & CO.KG RENCO S.P.A. ITALY 40718 Armenian Small Municipalities 54442 ASMWP-1 Rehabilitation of Ararat-Chanshin LLC (W) ARMENIA (W) 29 Apr 2013 Works Open 1,326,800 359,345 27.08% Water Project the water supply network in SHMSH-23 OJSC ARMENIA 41356 Yerevan Metro Rehabilitation 54443 PP 8 - Refurbishment and JSC Electric Rolling Stock Repair Plant GEORGIA (W) 29 May 2013 Goods Open 2,439,150 2,439,150 100.00% project Phase II modernisation of 8 units of Tbilisi Branch (ZREPS) (W) metro cars Type 81-717 40718 Armenian Small Municipalities 54661 ASMWP-2 Rehabilitation of ShmSh-23 OJSC (W) ARMENIA (W) 26 Apr 2013 Works Open 1,079,916 292,477 27.08% Water Project the Water Supply Network in AIS LLC ARMENIA Sevan town ARARAT-CHANSHIN LLC ARMENIA ARTEZIA LLC ARMENIA PAREX-GAZ LLC ARMENIA 40718 Armenian Small Municipalities 55941 ASMWP-3 Rehabilitation of ShmSh-23 OJSC (W) ARMENIA (W) 03 Sep 2013 Works Open 2,289,808 620,156 27.08% Water Project the Water Supply Network AIS LLC ARMENIA and Waste Water Network in ARPA-SEVAN OJSC ARMENIA Dilijan ARTASHATSHIN LLC ARMENIA Artezia LLC ARMENIA Parex-Gaz LLC ARMENIA SADE CGTH SA FRANCE 40718 Armenian Small Municipalities 56081 ASMWP-4 Rehabilitation of SADE CGTH SA (W) FRANCE (W) 18 Sep 2013 Works Open 1,389,032 376,196 27.08% Water Project the Water Supply Network in DZILYO production cooperative ARMENIA Tashir town, ASMWP- GOWHARRUD inter-national Construction Co IRAN WORKS-2013-04 40718 Armenian Small Municipalities 56684 ASMWP-6 Rehabilitation of Arpa-Sevan OJSC (W) ARMENIA (W) 04 Oct 2013 Works Open 939,624 254,481 27.08% Water Project the water supply network in DZILYO production cooperative ARMENIA Martuni town SHMSH-23 OJSC ARMENIA 40718 Armenian Small Municipalities 56685 ASMWP-10 Rehabilitation of Blesk LLC and Artezia LLC (W) ARMENIA (W) 14 Oct 2013 Works Open 1,324,695 331,174 25.00% Water Project the water supply network in SADE CGTH SA FRANCE Artik SHMSH-23 OJSC ARMENIA Sunir Co IRAN 40718 Armenian Small Municipalities 56802 ASMWP-5 Rehabilitation of SADE CGTH and ARTASHES EV TATEVIK FRANCE (W) 15 Oct 2013 Works Open 1,384,231 374,896 27.08% Water Project the Water Supply Network in LLC (W) Gavar and Saroukhan towns

Annex 1a ARMENIA Municipal & Env Inf

40718 Armenian Small Municipalities 56802 ASMWP-5 Rehabilitation of 15 Oct 2013 Works Open 1,384,231 374,896 27.08% Water Project the Water Supply Network in Gavar and Saroukhan towns Agat-777 LLC ARMENIA ARPA-SEVAN OJSC ARMENIA 40718 Armenian Small Municipalities 56822 ASMWP-7 Rehabilitation of Parex-Gaz LLC (W) ARMENIA (W) 29 Oct 2013 Works Open 686,373 185,893 27.08% Water Project the Water Supply Network in Artashatshin LLC ARMENIA Chambarak HB Construction LLC ARMENIA 40718 Armenian Small Municipalities 57001 ASMWP-8 Rehabilitation of Spitak-1 OJSC (W) ARMENIA (W) 13 Nov 2013 Works Open 1,799,645 487,404 27.08% Water Project water supply network in ARTEZIA LLC ARMENIA Spitak, Jrashen and Akhtala BAGHRAMYANSHIN OJSC ARMENIA Eghvardshin OJSC ARMENIA 40718 Armenian Small Municipalities 57002 ASMWP-9 Rehabilitation of Four Directions LLC, Ashotsq LLC (W) ARMENIA (W) 13 Nov 2013 Works Open 2,526,760 684,331 27.08% Water Project water supply network in Kapan town Magma Construction Company IRAN 40718 Armenian Small Municipalities 57003 ASMWP-12 Rehabilitation of Baghramyanshin OJSC (W) ARMENIA (W) 24 Oct 2013 Works Open 2,753,559 745,756 27.08% Water Project water supply network in Artashatshin LLC ARMENIA Ijevan town and Azatamut Eghvardshin OJSC ARMENIA 40718 Armenian Small Municipalities 58401 ASMWP-11 Rehabilitation of ShmSh-23 OJSC (W) ARMENIA (W) 04 Dec 2013 Works Open 1,194,626 323,544 27.08% Water Project the Waste Water Network in AIS LLC ARMENIA Jermuk town Arpa-Sevan OJSC ARMENIA Blesk LLC RUSSIAN FEDERATION SUNIR Co. IRAN Veya LLC and Veya Stroy OJSC ARMENIA Total ARMENIA 15 24,982,156 8,141,205 32.59% AZERBAIJAN Transport 43094 Roads Reconstruction and 55263 Review and Update of the Destia-Finnroad Limited (W) FINLAND (W) 15 Feb 2013 Consulta Competitive 1,364,277 1,040,550 76.27% Upgrading Project Detailed Design and nt Assitance with the PRO YAPI Design Co. Ltd TURKEY Services Total AZERBAIJAN 1 1,364,277 1,040,550 76.27% BOSNIA AND Municipal & 42889 Sarajevo Urban Roads 51482 Project Management Consortium DIVEL d.o.o., Integra d.o.o. BOSNIA AND 01 Jul 2013 Consulta Competitive 401,825 343,440 85.47% HERZEGOVIN Env Inf Development Project Supervision Engineer and ZIL inzenering d.d. (W) HERZEGOVINA nt A (W) Services AECOM Inocsa BOSNIA AND HERZEGOVINA IPSA BOSNIA AND HERZEGOVINA Roughton UNITED KINGDOM

42889 Sarajevo Urban Roads 51902 New construction and JV Euro-asfalt d.o.o Sarajevo, GP ZGP BOSNIA AND 30 May 2013 Works Open 10,862,757 9,284,408 85.47% Development Project Upgrading of the 12th d.d. Sarajevo and Hidrogradnja d.d. HERZEGOVINA Transversal Road Section Saraje (W) (W) Hering Prijedorputevi BOSNIA AND HERZEGOVINA Ozgun Insaat TURKEY Strabag AUSTRIA 40775 Bijeljina Phase 2 - Wastewater 51941 Construction of Main Buk Promet Doo Bijeljina (W) BOSNIA AND 21 Feb 2013 Works Open 3,278,665 3,278,665 100.00% Treatment Plant Secondary Sewer Collector HERZEGOVINA No. 3 - Majevicka Street (W) Higra d.o.o. BiH-RS BOSNIA AND HERZEGOVINA RABMER Rohrtechnik GmbH, Austria AUSTRIA 42889 Sarajevo Urban Roads 52041 New Construction and HP Investing (W) BOSNIA AND 03 Jun 2013 Works Open 2,273,042 1,942,771 85.47% Development Project Upgrading of the South HERZEGOVINA Longitudinal Road Section 1 (W) Hering d.d. BOSNIA AND HERZEGOVINA JV Euroasfalt-JATA BOSNIA AND HERZEGOVINA Ozgun Insaat TURKEY 40775 Bijeljina Phase 2 - Wastewater 55601 Consulting Services - HIDRO-SIMP d.o.o. of ATC Bijelina (W) BOSNIA AND 07 May 2013 Consulta Direct Selection 49,000 49,000 100.00% Treatment Plant Support to PIU HERZEGOVINA nt (W) Services Power and 44199 EPBiH - Hydro Power Plants 58182 Project Implementation Unit Studio Ing. G Pietrangeli S.R.L. (W) ITALY (W) 15 Nov 2013 Consulta Competitive 1,947,805 1,947,805 100.00% Energy Project Consultancy Services EGIS EAU FRANCE nt Services

Annex 1a BOSNIA AND HERZEGOVIN A

Power and 44199 EPBiH - Hydro Power Plants 58182 Project Implementation Unit 15 Nov 2013 Consulta Competitive 1,947,805 1,947,805 100.00% Energy Project Consultancy Services nt FICHTNER GMBH & CO.KG GERMANY Services NORPLAN AS NORWAY POYRY ENERGY GMBH AUSTRIA STUCKY LTD SWITZERLAND Transport 37543 Bosnia & Herzegovina Road 55225 LOT 1: Rehabilitation of JV "Jata Group & Euroasfalt BA" (W) BOSNIA AND 25 Feb 2013 Works Open 2,225,477 1,902,117 85.47% Rehabilitation Project Road M-18 LJUBACE - HERZEGOVINA ZIVINICE KM 6+765 - KM (W) 8+095 AND M-18 AND Arapovac & Roading BOSNIA AND DURDEVIK - VITALJ KM HERZEGOVINA 19+582 - KM 41+708 PUTOVI D.O.O. GRUDE BOSNIA AND HERZEGOVINA 38716 Corridor Vc 56262 Construction of Motorway JV "Euro-Asfalt d.o.o. and GP ZGP d.d." BOSNIA AND 07 May 2013 Works Open 24,403,100 20,857,350 85.47% on Corridor Vc: Section (W) HERZEGOVINA Drivusa-Kakanj, Subsection (W) Gorica-Biljesevo (Phase II) HERING D.O.O BOSNIA AND HERZEGOVINA OHL ZS A.S. CZECH REPUBLIC

Total BOSNIA AND HERZEGOVINA 8 45,441,671 39,605,556 87.16% BULGARIA Municipal & 41377 Burgas Integrated Urban 58582 P6 C11a, C11b, C12c & P9 DZZD DEPO-BURGAS (W) BULGARIA (W) 21 Jun 2013 Works Alternative 4,782,801 698,579 14.61% Env Inf Transport Project C16 Engineering, design & construction for bus depot, 44135 Varna Integrated Urban 58684 Trolleybuses renewal Skoda Electric a.s. (W) CZECH 13 Sep 2013 Goods Alternative 14,311,446 1,500,000 10.48% Transport Project REPUBLIC (W) 44135 Varna Integrated Urban 58963 Rolling Stock - Diesel Solaris Bus and Coach SA (W) POLAND (W) 22 Oct 2013 Goods Alternative 7,980,114 2,178,799 27.30% Transport Project articulated buses 44135 Varna Integrated Urban 58981 Rolling Stock - Low-floor city Solaris Bus and Coach SA (W) POLAND (W) 22 Oct 2013 Goods Alternative 4,140,058 1,130,354 27.30% Transport Project diesel buses 44135 Varna Integrated Urban 58983 Rolling Stock - New low-floor Solaris Bus and Coach SA (W) POLAND (W) 22 Oct 2013 Goods Alternative 4,564,069 1,246,121 27.30% Transport Project city CNG buses Total BULGARIA 5 35,778,488 6,753,852 18.88% CROATIA Municipal & 37187 Sisak Wastewater 52101 DS Consultancy Services EPTISA, Servicios de Ingenieria, S.L. SPAIN (W) 18 Mar 2013 Consulta Alternative 1,391,500 382,915 27.52% Env Inf Management Project Supervision of Design and (W) nt Construction Services 38501 Zagreb Holding Water and 52162 2B SCADA procurement and Koncar-Inzenjering za Energetiku I CROATIA (W) 25 Mar 2013 Supply & Open 296,951 296,951 100.00% Sewer Investment Project installation of following Transport d.d. (KET) (W) Installati measuring equipment JVCA IMGD Ltd CROATIA on Ozgur Cecen Engineering and Contracting TURKEY Company 39990 North Western Regional Waste 54481 Project implementation Safege Consulting Engineers, Safege FRANCE (W) 31 Dec 2013 Consulta Competitive 328,505 300,000 91.32% Water Project support and construction d.d.o., Rescon d.d.o. (W) nt supervision MVV Decon GmbH GERMANY Services Niras a/s Denmark and Institut IGH d.d. DENMARK Croatia P2mberlin GmbH GERMANY Ramboll Copanhagen DENMARK 37187 Sisak Wastewater 54761 WW2 Waste water Tehnika d.d (W) CROATIA (W) 24 May 2013 Works Alternative 10,175,000 2,800,160 27.52% Management Project treatment works Cret 37187 Sisak Wastewater 54762 Waste water equipment - Agra Trgovina d.o.o. (W) CROATIA (W) 10 May 2013 Goods Alternative 125,000 34,400 27.52% Management Project Lot 2 customised van with CCTV sewer inspection 37187 Sisak Wastewater 54901 WW1-3A-4 Construction of Koncar-Inzenjering Za Energetiku I CROATIA (W) 30 Aug 2013 Works Alternative 12,654,767 3,482,592 27.52% Management Project wastewater collection Transport d.d., Durkin d.o.o., Astra Int. system - Galdovo complex inz (W) 37187 Sisak Wastewater 55341 Waste water equipment - Gradatin d.o.o. (W) CROATIA (W) 21 May 2013 Goods Alternative 465,000 127,968 27.52% Management Project Lot 1 Sewerage suction 37187 Sisak Wastewater 56483 Construction of two river Braco Kop d.o.o. (W) CROATIA (W) 27 Nov 2013 Works Alternative 498,685 137,238 27.52% Management Project crossings underneath the Transport 39749 Port of Sibenik Infrastructure 55481 Infrastructure Rehabilitation JV Strabag AG - Pomgrad Inzenjering GERMANY (W) 14 Mar 2013 Works Open 8,087,964 6,470,371 80.00% Rehabilitation Project Project in the Port of Sibenik d.o.o. (W) Cyes-Viadukt SPAIN JV Aertssen - Coddeel BELGIUM

Annex 1a CROATIA

Transport 39749 Port of Sibenik Infrastructure 55481 Infrastructure Rehabilitation 14 Mar 2013 Works Open 8,087,964 6,470,371 80.00% Rehabilitation Project Project in the Port of Sibenik

KONSTRUKTOR-INZENJERING D.D. SPLIT CROATIA

42754 Croatia Control ATM 58123 Supply & Installation of Telvent Netherlands BV (W) NETHERLANDS 09 Oct 2013 Supply & Open 801,209 801,209 100.00% Modernisation Project AWOS for Airports of Pula (W) Installati and Split on

Total CROATIA 10 34,824,581 14,833,804 42.60% FYR Power and 27768 FYR Macedonia Transmission 56222 Supply and Installation of Koncar - Power Plant and Electric CROATIA (W) 28 May 2013 Supply & Open 1,884,915 1,884,915 100.00% MACEDONIA Energy Interconnection Substation Automation Traction Eng. inc. (W) Installati Control System, Protection ABB Switzerland ltd SWITZERLAND on and DC supply for 9 Caraglio s.r.l. Impianti Elettrici ITALY substations JVA SC Energobit SA ROMANIA MVM OVIT Orszagos Villamostavvezetek Zrt HUNGARY

SEL UNITED STATES Siemens s.p.a. ITALY T&D Engineering BULGARIA 27768 FYR Macedonia Transmission 58021 Supply and Installation of a Siemens AG Osterreich (W) AUSTRIA (W) 14 Oct 2013 Supply & Open 3,800,000 3,800,000 100.00% Interconnection new SCADA/EMS System for Alstom GRID S.A.S FRANCE Installati the National Dispatch Consortium Koncar - Power Plant and Electric CROATIA on Centre, Back-up Dispatch Transport 43997 Railways Fleet Renewal Project 56662 Consulting Services URS Infrastructure & Environment UK UNITED 03 Jul 2013 Consulta Selection from 250,000 250,000 100.00% Assistance with Project Limited (W) KINGDOM (W) nt a shortlist Procurement and ARDANUY Ingenieria, S.A SPAIN Services Implementation D¿APPOLONIA spa ITALY SGS Correl Ltd UNITED KINGDOM

SYSTRA FRANCE TECHNOMA GmbH AUSTRIA 39311 Regional and Local Roads 57163 Municipal Roads Phase III - GD Granit A.D. (W) FYR 15 Apr 2013 Works Open 1,811,701 1,811,701 100.00% Programme Lot 1 - Skopje and Polog MACEDONIA Region (W) Eskavatori Company KOSOVO 39311 Regional and Local Roads 57166 Municipal Roads Phase III - TDGP ILINDEN AD (W) FYR 15 Apr 2013 Works Open 2,966,010 2,966,010 100.00% Programme Lot 2 - Southwest and MACEDONIA Pelagonija Region (W) GD GRANIT AD FYR MACEDONIA

39311 Regional and Local Roads 57167 Municipal Roads Phase III - GD BETON AD (W) FYR 15 Apr 2013 Works Open 1,854,934 1,854,934 100.00% Programme Lot 3 - Northeast and East MACEDONIA Region (W) TDGP ILINDEN AD FYR MACEDONIA

39311 Regional and Local Roads 57168 Municipal Roads Phase III - GD Granit A.D. (W) FYR 15 Apr 2013 Works Open 1,181,100 1,181,100 100.00% Programme Lot 4 -Vardar and Southeast MACEDONIA Region (W) Zikol dooel FYR MACEDONIA

39311 Regional and Local Roads 57181 Regional Roads Phase III - GD Granit A.D. (W) FYR 22 May 2013 Works Open 577,322 577,322 100.00% Programme Lot 1 - R2432 Angelci- MACEDONIA Veljusa-Vodoca-Banica (W) Integral Inzenjering a.d. BOSNIA AND HERZEGOVINA Strabag AG AUSTRIA 39311 Regional and Local Roads 57182 Regional Roads Phase III - GD BETON AD (W) FYR 29 May 2013 Works Open 2,633,427 2,633,427 100.00% Programme Lot 2 - R2433 Radovis- MACEDONIA Konce-Lubnica (W) GD GRANIT A.D. FYR MACEDONIA

Integral Inzenjering a.d. BOSNIA AND HERZEGOVINA STRABAG AG AUSTRIA

Annex 1a FYR MACEDONIA

Transport

39311 Regional and Local Roads 57183 Regional Roads Phase III - GD Granit A.D. (W) FYR 22 May 2013 Works Open 2,342,003 2,342,003 100.00% Programme Lot 3 - R1107 Kavadarci- MACEDONIA Musov grob (W) CK-13HOLD-ING JSC BULGARIA Consortium Urban Inves & Companya ALBANIA Eskavatori SHPK ISA 2000 Ltd BULGARIA JV Vojput AD - Subotica & SMB Gradnja SERBIA STRABAG AG AUSTRIA Viadukt d.d. CROATIA 39311 Regional and Local Roads 57184 Regional Roads Phase III - TDGP ILINDEN AD (W) FYR 22 May 2013 Works Open 3,890,975 3,890,975 100.00% Programme Lot 4 - R1201 Struga-Debar MACEDONIA (W) CK-13HOLD-ING JSC BULGARIA GD GRANIT A.D. FYR MACEDONIA

INTEGRAL INZENJERING A.D. LAKTASI BOSNIA AND HERZEGOVINA JV Vojput AD-Subotica & SMB Gradnja SERBIA STRABAG AG AUSTRIA 39311 Regional and Local Roads 57602 Veles-Kadrifakovo Phase 1 - STRABAG AG (W) AUSTRIA (W) 02 Sep 2013 Works Open 1,284,490 1,284,490 100.00% Programme Interchange Veles-end of ESKAVATORI Construction Company KOSOVO third line (Veles landfill), GD BETON AD FYR MACEDONIA Lozovo, Saramzalino GD GRANIT A.D. FYR MACEDONIA

ISA 2000 LLC BULGARIA 39311 Regional and Local Roads 57901 Municipal Roads Phase IV - JV "Ilinden" AD - Struga & Progres FYR 20 Sep 2013 Works Open 2,221,401 2,221,401 100.00% Programme Lot 1 - Skopje and Polog 1998 dooel Gostivar (W) MACEDONIA Region (W) BETON FYR MACEDONIA

GRANIT AD FYR MACEDONIA

39311 Regional and Local Roads 57903 Municipal Roads Phase IV - JV "Ilinden" AD - Struga & Progres FYR 20 Sep 2013 Works Open 1,985,547 1,985,547 100.00% Programme Lot 2 - Southwest and 1998 dooel Gostivar (W) MACEDONIA Pelagonija Region (W) GRANIT AD FYR MACEDONIA

41327 Macedonian Railways - 58421 Section 2 - Nogaevci to CK-13 HOLD-ING JSC (W) BULGARIA (W) 17 Jul 2013 Works Open 9,399,755 9,399,755 100.00% Corridor X Negotino Aktor S.A. GREECE Costruzioni Linee Ferroviarie S.p.A. ITALY Generale Construzioni Ferroviarie S.p.A. ITALY H.F. Wiebe GmbH & Co. KG GERMANY OHL ZS, A.S. CZECH REPUBLIC

PORR Bau GmbH AUSTRIA SUBTERRA A.S. CZECH REPUBLIC

TERNA SA GREECE 39311 Regional and Local Roads 58521 Municipal Roads Phase IV - GD Granit A.D. (W) FYR 09 Oct 2013 Works Open 2,443,846 2,443,846 100.00% Programme Lot 3 - Northeast and East MACEDONIA Region (W) 39311 Regional and Local Roads 58522 Municipal Roads Phase IV - GD Granit A.D. (W) FYR 09 Oct 2013 Works Open 2,053,587 2,053,587 100.00% Programme Lot 4 - Vardar and MACEDONIA Southeast Region (W) Zikol dooel FYR MACEDONIA

43997 Railways Fleet Renewal Project 58544 Procurement of New Freight ZOS TRNAVA A.S. (W) SLOVAK 18 Dec 2013 Goods Open 13,208,750 13,208,750 100.00% Wagons REPUBLIC (W) Astra Rail Industries ROMANIA CNR Jinan railway LTD CHINA

Annex 1a FYR MACEDONIA

Transport

43997 Railways Fleet Renewal Project 58544 Procurement of New Freight 18 Dec 2013 Goods Open 13,208,750 13,208,750 100.00% Wagons

Djuro Djakovic specijalna vozila CROATIA Legios Europe AG CZECH REPUBLIC

Tatravagonka Poprad SLOVAK REPUBLIC Texmaco Rail Ingenering INDIA 42921 FYR Macedonia: Railway 58621 Rehabilitation of Section H. F. Wiebe GmbH&Co. KG (W) GERMANY (W) 20 Dec 2013 Works Open 39,753,619 39,753,619 100.00% Corridor VIII - Phase I KUMANOVO - BELJAKOVCE ACTOR GREECE JVCA Acilim TURKEY JVCA PORR AUSTRIA JVCA STRABAG AUSTRIA JVCA Tema GREECE Sinohydro CHINA SUBTERRA CZECH REPUBLIC

Total FYR MACEDONIA 19 95,543,382 95,543,382 100.00% GEORGIA Municipal & 37560 Kobuleti Water 53283 Construction of Kobuleti Azertunel LLC (W) AZERBAIJAN 23 Jul 2013 Works Open 1,697,649 1,438,685 84.75% Env Inf waste water treatment plant (W) (WWTP)-Civil Works Arsan Aritma Ve Insaat A.S. TURKEY Azeri Private Multi Profile Firm LLC AZERBAIJAN JV of Company Black Sea Group Ltd & GEORGIA Coskun Aritma Sistemleri JV of Java Ltd, Fenno Water Ltd Oy and GEORGIA Erisimedi JSC Ludwig Preiffer Hoch und Tiefbau GmbH & GERMANY Co. KG Total GEORGIA 1 1,697,649 1,438,685 84.75% KAZAKHSTAN Municipal & 43718 Almaty Bus Sector Reform 54902 Supply of 200 CNG buses Zhengzhou Yutong Bus Co. Ltd (W) CHINA (W) 26 Sep 2013 Goods Open 24,359,547 24,359,547 100.00% Env Inf Phase 2 Shanghai Sunwin Bus Corporation CHINA Xinjiang Sanbao Industry Group Co. Ltd CHINA Xinjiang Sanxin Investment Co. Ltd. CHINA Zyle Motor Company KOREA Power and 42039 KEGOC Osakarovka 55541 Rehabilitation of 220kV KEC INTERNATIONAL LIMITED (W) INDIA (W) 19 Mar 2013 Supply & Open 8,892,320 8,892,320 100.00% Energy Restructuring Loan OHTL Ossakarovka JV Gam Arak Industrial Company and Kayson IRAN Installati Inc on JV Sinohydro Corporation and HYPEC CHINA 43483 Shardara HPP Modernization 58902 Modernisation Project of Andritz Hydro GmbH (W) GERMANY (W) 18 Dec 2013 Supply & Open 75,107,911 49,600,000 66.04% Project Shardarinskaya HPP LOT - Spetgidroenergomontazh RUSSIAN Installati Replacement / FEDERATION on Refurbishment of Tyazhmash JSC RUSSIAN Generators, Turbines & FEDERATION Total KAZAKHSTAN 3 108,359,778 82,851,867 76.46% KYRGYZ Municipal & 40753 Jalalabad Water Rehabilitation 50861 PP1: Sewerage Maintenance Uralo-Sibirskaya Promyshlennaya RUSSIAN 01 Jul 2013 Goods Open 206,279 206,279 100.00% REPUBLIC Env Inf Project Vehicles including pipe Companiya (W) FEDERATION cleaning vehicle, equipment (W) 41492 Bishkek Public Transport 55556 BPTD03 Supply of Asiaautocenter Ltd (W) KYRGYZ 05 Nov 2013 Goods Open 144,464 93,902 65.00% Project maintenance machinery Lot REPUBLIC (W) 1- Item 1.2 Tractor- Finance F KYRGYZ excavator and 1.3 Recovery REPUBLIC truck Grand Motors AZERBAIJAN 41492 Bishkek Public Transport 57861 BPTD03 Supply of Grand Motors LLC (W) AZERBAIJAN 31 Oct 2013 Goods Open 102,821 66,834 65.00% Project maintenance machinery Lot (W) 1- Item 1.1 Mobile hydraulic AsiaAutocenter KYRGYZ crane REPUBLIC Finance F KYRGYZ REPUBLIC 41492 Bishkek Public Transport 57862 BPTD03 Supply of Chelyabtransservice (W) RUSSIAN 27 Nov 2013 Goods Open 189,433 123,131 65.00% Project maintenance machinery Lot FEDERATION 2 Item 2.1 Elevating (W) platforms Asiaautocenter KYRGYZ REPUBLIC Grand Motors AZERBAIJAN

Annex 1a Total KYRGYZ REPUBLIC 4 642,997 490,146 76.23% MOLDOVA Municipal & 40267 Moldova - Water Utilities 50702 LOT 1, 2, 3+7 Supply of Grand Motors LLC (W) AZERBAIJAN 14 May 2013 Goods Open 77,610 25,611 33.00% Env Inf Development Programme Maintenance Equipment and (W) Specialised Vehicles for Six Bergerat Monnoyeur SRL ROMANIA Regional Water Companies Boss Pro-tec GmbH GERMANY in Moldova - Soroca East-Auto-Lada SRL MOLDOVA SRL Auto-Prezent MOLDOVA 40267 Moldova - Water Utilities 53141 Extension and rehabilitation SC Geprocon SA (W) ROMANIA (W) 17 Jul 2013 Works Open 976,874 325,625 33.33% Development Programme of water supply system in FCP SOLDI SRL MOLDOVA Orhei JV Afina Vsh SRL ROMANIA LACATUS SRL MOLDOVA Liftmontag Tresor JVCA MOLDOVA NNC-Traversa SRL MOLDOVA Planta SRL MOLDOVA 40267 Moldova - Water Utilities 53142 Supply of water meters for Ningbo Water Meter Co. Ltd. (W) CHINA (W) 21 Jun 2013 Goods Open 73,008 24,336 33.33% Development Programme four regional water Itron France FRANCE 40267 Moldova - Water Utilities 54302 Supply of Maintenance JVCA SC Tehno World SRL and Techno ROMANIA (W) 15 Oct 2013 Goods Open 6,369 2,123 33.33% Development Programme Equipment - Ceadir Lunga Test SRL (W) GO-ME-2 SC San Euro Stil SRL MOLDOVA 40267 Moldova - Water Utilities 54303 Supply of Maintenance JVCA SC Tehno World SRL and Techno ROMANIA (W) 15 Oct 2013 Goods Open 15,160 5,053 33.33% Development Programme Equipment - Soroca GO-ME- Test SRL (W) 2 SC San Euro Stil SRL MOLDOVA 40267 Moldova - Water Utilities 54304 Supply of Maintenance JVCA SC Tehno World SRL and Techno ROMANIA (W) 23 Sep 2013 Goods Open 23,718 7,906 33.33% Development Programme Equipment - Leova GO-ME-2 Test SRL (W) SC San Euro Stil SRL MOLDOVA 40267 Moldova - Water Utilities 54305 Supply of Maintenance JVCA SC Tehno World SRL and Techno ROMANIA (W) 16 Oct 2013 Goods Open 4,279 1,426 33.33% Development Programme Equipment - Orhei GO-ME-2 Test SRL (W) SC San Euro Stil SRL MOLDOVA 40267 Moldova - Water Utilities 54306 Supply of Maintenance JVCA SC Tehno World SRL and Techno ROMANIA (W) 23 Sep 2013 Goods Open 68,985 22,995 33.33% Development Programme Equipment - Floresti GO-ME- Test SRL (W) 2 SC San Euro Stil SRL MOLDOVA 40267 Moldova - Water Utilities 54307 Supply of Maintenance JVCA SC Tehno World SRL and Techno ROMANIA (W) 23 Sep 2013 Goods Open 4,279 1,426 33.33% Development Programme Equipment - Hincesti GO-ME- Test SRL (W) 2 SC San Euro Stil SRL MOLDOVA 40267 Moldova - Water Utilities 54321 Rehabilitation of potable Fedion-Com SRL (W) MOLDOVA (W) 21 Jun 2013 Works Open 830,666 276,889 33.33% Development Programme water network in Soroca FPC Lacatus SRL MOLDOVA Lucet-Izodrom MOLDOVA Paggi Adelmo SRL ITALY Promtehgaz SA MOLDOVA SC Casrep SRL ROMANIA SC Geprocon SA ROMANIA 40267 Moldova - Water Utilities 54322 Extension of wastewater JV Izodromgaz Lucet-Comert (W) MOLDOVA (W) 20 May 2013 Works Open 646,707 215,569 33.33% Development Programme system in Leova - LE-WWS- JV SC DAS SRL Iasi SC Expert Instal SRL ROMANIA 01 JV TOL & SA Construzioni SRL, Mario Di ITALY Cesare SRL 40267 Moldova - Water Utilities 54323 Supply of pumps and JVCA SC Multigama Tech SRL (W) ROMANIA (W) 30 May 2013 Goods Open 37,052 12,351 33.33% Development Programme chlorination equipment for SC Wilo Romania SRL ROMANIA 40267 Moldova - Water Utilities 54324 Extension of potable water JV Lucet-Izodrom (W) MOLDOVA (W) 25 Sep 2013 Works Open 318,456 106,152 33.33% Development Programme and wastewater in Orhei JV Polimer Gaz Conducte SRL MOLDOVA Phase 2 - LOT 1 - OR-WWS- Mario Di Cesare SRL ITALY 03 SA Damicgaz MOLDOVA SA Promtehgaz MOLDOVA SC Casrep SRL ROMANIA SC Geprocon SA ROMANIA 40267 Moldova - Water Utilities 54341 Extension of wastewater Consortium Lucet-Izodromgaz (W) MOLDOVA (W) 16 May 2013 Works Open 1,580,006 526,616 33.33% Development Programme system in Ceadir-Lunga CL- Promtehgaz S.A. MOLDOVA 40267 Moldova - Water Utilities 55421 Extension of water supply JV Polimer Gaz Conducte Ltd. & MOLDOVA (W) 02 Jul 2013 Works Open 2,002,508 667,503 33.33% Development Programme system in Floresti for of Polimer Gaz Constructii Ltd (W) Izvoara, Varvareiuca for lot JV Lucet-Izodrom MOLDOVA 1, Ghindesti Domulgeni lot Promtehgaz SA MOLDOVA 2, Ghindesti, Cenusa lot 3 - SA DARNIC GAZ MOLDOVA FL-WSS-03 SC GEPROCON SA ROMANIA

Annex 1a MOLDOVA Municipal & Env Inf

40267 Moldova - Water Utilities 55422 Rehabilitation of Ground JV Polimer Gaz Conducte Ltd. & MOLDOVA (W) 04 Sep 2013 Works Open 909,150 300,019 33.00% Development Programme Water Source for Floresti FL- Polimer Gaz Constructii Ltd (W) WSS-01 JV Lucet-Izodrom MOLDOVA Promtehgaz SA MOLDOVA SA Damic Gaz MOLDOVA SC Geprocon SA ROMANIA Soldi SRL MOLDOVA 40267 Moldova - Water Utilities 55424 Supply of pumps and JVCA Oniko PE (W) UKRAINE (W) 21 Jun 2013 Goods Open 155,466 51,822 33.33% Development Programme chlorination equipment for JVCA Policontract SRL MOLDOVA 40267 Moldova - Water Utilities 56002 Water source Firladeni HI- PROMTEHGAZ SA (W) MOLDOVA (W) 03 Sep 2013 Works Open 836,964 278,988 33.33% Development Programme WSS-03 JV Lucet-Izodrom MOLDOVA JV SA Darnic gaz and Sarco Service SRL MOLDOVA SC Geprocon SA ROMANIA Soldi SRL MOLDOVA 43827 Balti Trolleybus Project 56602 BTP01 Supply of SC Carpat BELAZ Service SRL and OJSC ROMANIA (W) 18 Dec 2013 Goods Open 3,666,196 2,383,030 65.00% trolleybuses Holding Management Company Belkommunmash (W) City Transport Group LLC and LAZ LLC UKRAINE Eximotor SA and Trolza-Market LLC MOLDOVA Speranta PF Com SRL and Jinhua Youngman MOLDOVA Automobile Manufacturing Co. Ltd.

40267 Moldova - Water Utilities 57082 LOT 1 Supply of Grand Motors LLC (W) AZERBAIJAN 14 May 2013 Goods Open 4,445 1,482 33.33% Development Programme Maintenance Equipment and Boss Pro-tec GmbH GERMANY(W) 40267 Moldova - Water Utilities 57085 LOT 1, 2+3 Supply of Grand Motors LLC (W) AZERBAIJAN 14 May 2013 Goods Open 87,825 29,275 33.33% Development Programme Maintenance Equipment and (W) Specialised Vehicles for Six Bergerat Monnoyeur SRL ROMANIA Regional Water Companies Boss Pro-tec GmbH GERMANY in Moldova - Orhei East-Auto-Lada SRL MOLDOVA SRL Auto-Prezent MOLDOVA 40267 Moldova - Water Utilities 57086 LOT 1+2 Supply of Grand Motors LLC (W) AZERBAIJAN 14 May 2013 Goods Open 8,525 2,842 33.33% Development Programme Maintenance Equipment and Boss Pro-tec GmbH GERMANY(W) 40267 Moldova - Water Utilities 57161 Extension of potable water JV Polimer Gaz Conducte Ltd. & MOLDOVA (W) 15 Oct 2013 Works Open 1,542,260 514,087 33.33% Development Programme and wastewater in Orhei Polimer Gaz Constructii Ltd (W) Phase 2 - LOT 2 - OR-WWS- JV Lucet-Izodrom SRL MOLDOVA 03 Mario Di Cesare SRL ITALY SA Promtehgaz MOLDOVA SC Casrep SRL ROMANIA SC Geprocon SA ROMANIA 40267 Moldova - Water Utilities 57165 Supply of pumps and JVCA Oniko PE (W) UKRAINE (W) 25 Jun 2013 Goods Open 1,152,490 384,163 33.33% Development Programme chlorination equipment for JVCA Policontract SRL MOLDOVA 40267 Moldova - Water Utilities 58041 Supply of water meters for Ningbo Water Meter Co. Ltd. (W) CHINA (W) 28 Jun 2013 Goods Open 126,750 42,250 33.33% Development Programme four regional water Itron FRANCE 40267 Moldova - Water Utilities 58042 Supply of water meters for Ningbo Water Meter Co. Ltd. (W) CHINA (W) 21 Jun 2013 Goods Open 126,750 42,250 33.33% Development Programme four regional water Iton FRANCE 40267 Moldova - Water Utilities 58061 Supply of pumps and JVCA SC Multigama Tech SRL (W) ROMANIA (W) 04 Jun 2013 Goods Open 121,477 40,492 33.33% Development Programme chlorination equipment for SC Wilo Romania SRL REUNION Total MOLDOVA 27 15,272,946 6,248,604 40.91% MONTENEGR Municipal & 41252 Danilovgrad Municipal 54642 Water supply component - J.V. CMC Controlmatic Commerce d.o.o. MONTENEGRO 11 Sep 2013 Works Open 840,454 706,264 84.03% O Env Inf Infrastructure Project Rehabilitation and extension Herceg Novi & CMC Ekocon d.o.o. (W) of water supply network Logatec (W) ALB-STAR Ltd. ALBANIA J.V. Viadukt d.d. Zagreb & Asfalt CROATIA Konstruckcije d.o.o. Ludwig Pfeiffer Hoch und Tiefbau GmbH & GERMANY Co KG Power and 40219 EPCG Metering and 55362 Supply of Ancillary Mezon d.o.o. (W) MONTENEGRO 29 Mar 2013 Goods Open 961,063 961,063 100.00% Energy Distribution Project Equipment for Smart Meters (W) Installation Siemens d.o.o. SERBIA Total MONTENEGRO 2 1,801,517 1,667,327 92.55% MOROCCO Power and 44057 ONE-Rural Electrification and 55546 Rural Electrification Works Atlas Energy (W) MOROCCO (W) 14 May 2013 Works Open 4,389,138 4,389,138 100.00% Energy Smart Metering (53 villages)

Annex 1a MOROCCO Power and 44057 ONE-Rural Electrification and 55546 Rural Electrification Works 14 May 2013 Works Open 4,389,138 4,389,138 100.00% Energy Smart Metering (53 villages) CEGELEC MOROCCO ELCOTRAM MOROCCO ELECNOR SPAIN ELECTRO TADART MOROCCO EMTEYCO Maroc MOROCCO SGEE MOROCCO 44057 ONE-Rural Electrification and 55554 Rural Electrification Works Electricite Bellet (W) MOROCCO (W) 19 Mar 2013 Works Open 2,670,177 2,670,177 100.00% Smart Metering (48 villages) CEGELEC MOROCCO CONTI MOROCCO ELECNOR SA, SPAIN SPAIN ELECTRIMED MOROCCO EMTEYCO MOROCCO ENTEG MOROCCO OURELEC MOROCCO SGEE MOROCCO 44057 ONE-Rural Electrification and 55555 Rural Electrification Works EMTEYCO Maroc (W) MOROCCO (W) 09 Apr 2013 Works Open 7,002,567 7,002,567 100.00% Smart Metering (82 villages) CEGELEC MOROCCO ELECNOR SA, SPAIN SPAIN ELECTRIMED MOROCCO ELECTRO TADART MOROCCO SERF MOROCCO 44057 ONE-Rural Electrification and 55557 Rural electrification Works Somaprec (W) MOROCCO (W) 02 Apr 2013 Works Open 2,761,127 2,761,127 100.00% Smart Metering (57 vilages) CEGELEC MOROCCO ELECNOR SA, SPAIN SPAIN ELECTRICITE BELLET MOROCCO ELECTRIMED MOROCCO OURELEC MOROCCO 44057 ONE-Rural Electrification and 55558 Rural Electrification Works OURELEC (W) MOROCCO (W) 30 Apr 2013 Works Open 3,827,140 3,827,140 100.00% Smart Metering (79 vilages) CEGELEC MOROCCO ELECTRIMED MOROCCO ENTEG MOROCCO 44057 ONE-Rural Electrification and 55559 Rural Electrification Works PACIFEL (W) MOROCCO (W) 02 Apr 2013 Works Open 1,797,281 1,797,281 100.00% Smart Metering (50 villages) CEGELEC MOROCCO ELCOTRAM MOROCCO ELECTRIMED MOROCCO ELECTRO TADART MOROCCO 44057 ONE-Rural Electrification and 55560 Rural electrification Works TEGAEL MAROC (W) MOROCCO (W) 14 May 2013 Works Open 3,064,657 3,064,657 100.00% Smart Metering (55 villages) CEGELEC MOROCCO CONTI CORPORATION MOROCCO EMTEYCO MAROC MOROCCO 44057 ONE-Rural Electrification and 55823 Rural Electrification Works OURELEC (W) MOROCCO (W) 30 Apr 2013 Works Open 3,918,749 3,918,749 100.00% Smart Metering (131 Villages) CONTI Corporation MOROCCO ELECTRO TADART MOROCCO ENTEG MOROCCO ISOTRON Maroc MOROCCO 44057 ONE-Rural Electrification and 56261 Rural Electrification Works TEGAEL MAROC (W) MOROCCO (W) 27 May 2013 Works Open 586,994 586,994 100.00% Smart Metering (68 Villages) CEGELEC MOROCCO ELECTRO AIT ASOUNE MOROCCO 44057 ONE-Rural Electrification and 56281 Rural Electrification Works ELECTRIMED (W) MOROCCO (W) 21 May 2013 Works Open 23,657,046 23,657,046 100.00% Smart Metering (68 Villages) CEGELEC MOROCCO SGEE MOROCCO SOMAPREC MOROCCO TEGAEL MAROC MOROCCO 44057 ONE-Rural Electrification and 56301 Rural Electrification Works CEGELEC (W) MOROCCO (W) 03 Jun 2013 Works Open 39,632,311 39,632,311 100.00% Smart Metering (45 villages) Atlas Energy/Imadrelec MOROCCO Electro Industrie MOROCCO 44057 ONE-Rural Electrification and 56302 Rural Electrification Works Somaprec (W) MOROCCO (W) 07 Jun 2013 Works Open 688,419 688,419 100.00% Smart Metering (20 villages) ELECTRIMED MOROCCO ELECTRO AIT SAOUNE MOROCCO ICOMEL/SORULEC MOROCCO 44057 ONE-Rural Electrification and 56321 Rural Elefctrification Words EMTEYCO Maroc (W) MOROCCO (W) 16 May 2013 Works Open 3,870,221 3,870,221 100.00% Smart Metering (41 Villages)

Annex 1a MOROCCO Power and Energy

44057 ONE-Rural Electrification and 56321 Rural Elefctrification Words 16 May 2013 Works Open 3,870,221 3,870,221 100.00% Smart Metering (41 Villages) CEGELEC MOROCCO SISTEM MOROCCO 44057 ONE-Rural Electrification and 56322 Rural Electrification works Atlas Energy (W) MOROCCO (W) 03 Jun 2013 Works Open 6,297,352 6,297,352 100.00% Smart Metering (74 villages) CEGELEC MOROCCO ELECTRIMED MOROCCO 44057 ONE-Rural Electrification and 56323 Rural Electrification Works Atlas Energy (W) MOROCCO (W) 06 Jun 2013 Works Open 2,486,013 2,486,013 100.00% Smart Metering (106 villages) CEGELEC MOROCCO EMTEYCO MOROCCO ISONTRON MOROCCO TEGAEL MOROCCO 44057 ONE-Rural Electrification and 56324 Rural Electrification Works ELECTRO TAFOGHALT (W) MOROCCO (W) 06 Jun 2013 Works Open 1,507,016 1,507,016 100.00% Smart Metering (29 villages) CEGELEC MOROCCO TECH ELEC MOROCCO TEGAEL MAROC MOROCCO 44057 ONE-Rural Electrification and 56325 Rural Electrification Works Somaprec (W) MOROCCO (W) 06 Jun 2013 Works Open 2,186,471 2,186,471 100.00% Smart Metering (46 villages) CEGELEC MOROCCO 44057 ONE-Rural Electrification and 56326 Rural Electrification Works Somaprec (W) MOROCCO (W) 06 Jun 2013 Works Open 2,038,986 2,038,986 100.00% Smart Metering (73 villages) CEGELEC MOROCCO TEGAEL MAROC MOROCCO 44057 ONE-Rural Electrification and 56342 Rural Electrification Works ELECTRO TAFOGHALT (W) MOROCCO (W) 06 Jun 2013 Works Open 3,513,594 3,513,594 100.00% Smart Metering (55 Villages) GEGELEC MOROCCO Groupement PACIFEL / IMADRELEC MOROCCO TEGAEL MAROC MOROCCO 44057 ONE-Rural Electrification and 56343 Rural Electrification Works ELECTRIMED (W) MOROCCO (W) 21 May 2013 Works Open 2,473,425 2,473,425 100.00% Smart Metering (26 Villages) EMTEYCO MAROC MOROCCO GAMAF MOROCCO GEGELEC MOROCCO PACIFEL MOROCCO SISTEM MOROCCO 44057 ONE-Rural Electrification and 56361 Rural Electrification Works ELCOTRAM (W) MOROCCO (W) 06 Jun 2013 Works Open 3,299,113 3,299,113 100.00% Smart Metering (54 Villages) CONTI Corporation MOROCCO EMTEYCO MOROCCO LUMAFRIC MOROCCO Total MOROCCO 21 121,667,796 121,667,796 100.00% ROMANIA Municipal & 41633 Medias Urban Infrastructure 50961 PMMR contract for Road Tehnic Asist SRL, Kiat Group Construct ROMANIA (W) 29 Mar 2013 Works Direct Selection 4,269,996 1,419,463 33.24% Env Inf Rehabilitation project Infrastructure in Ighisul Nou SRL, Proiect Bucuresti sRL (W) Village, Medias Municipality, 40338 Sibiu Municipality Loan - Phase 54522 Upgrade and Refurbishment JV SC Terra Buiding SRL, SC CONSAL ROMANIA (W) 12 Apr 2013 Works Open 259,399 209,193 80.65% II of Streets along Public SRL (W) Transport Routes - Area JV Cycasa Canteras Y Constructiones SA ROMANIA Grigore Ureche - Anatole Bilbao Suc./Semnalizare France Sreets -from Savings SC Comtram SA ROMANIA SC Geiger Transilvania SRL ROMANIA 41175 R2CF Targu Mures Sub-Project 54842 MS-TA-YB-05 Tarnaveni - SC Edas Exim SRL,SC Tehnic Trust ROMANIA (W) 28 Feb 2013 Works Alternative 4,003,640 452,812 11.31% Rehabilitation of DWTP SA,SC Beespeed Automatizari SRL,SC Datcomp SRL (W) 33932 Bucharest Multi-Sector Project 54881 P3 Procurement of electrical SC Elsaco Electronic SRL (W) ROMANIA (W) 19 Dec 2013 Supply & Open 3,279,252 3,279,252 100.00% (Radet) pumps and control systems SC Radcom SRL & SC Griro SA & SC Pro T.C. ROMANIA Installati for substations, spread over Grup SRL on the 6 distribution sectors of SC Romib SA & SC Electro-Total SRL ROMANIA Radet SC TMUCB SA ROMANIA Termigas SpA ITALY 41175 R2CF Targu Mures Sub-Project 55121 MS-L&I-YB-08 Ludus and SC Veolia Water Solutions and ROMANIA (W) 25 Mar 2013 Works Alternative 7,757,133 877,332 11.31% Iernut - Rehabilitation of Technologies Romania SRL (W) 42129 R2CF Buzau sub-project 55403 CL5 - Upgrading of water SC Hidroconstructia SA and SC General ROMANIA (W) 12 Feb 2013 Works Alternative 14,441,895 1,733,027 12.00% and sewage systems in Concrete Cernavoda SRL (W) Pogoanele and Patarlagele 41890 R2CF Brasov sub-project 55666 CW7 - Extension and SC Ocide Construccion SA (W) SPAIN (W) 02 Apr 2013 Works Alternative 13,999,465 1,623,938 11.60% erhabilitation of water 39276 R2CF Iasi Sub-Project 56461 CL4 - Upgrading of Timisesti S.C. Daroconstruct SRL (W) ROMANIA (W) 02 Apr 2013 Works Alternative 2,083,621 260,453 12.50% catchment fields Verseni and

Annex 1a ROMANIA Municipal & Env Inf

39276 R2CF Iasi Sub-Project 56463 CL11 - Upgrading of water S.C. TMUCB SA (W) ROMANIA (W) 26 Apr 2013 Works Alternative 4,218,194 527,274 12.50% and sewerage systems in Tg 39276 R2CF Iasi Sub-Project 56464 CL12 - Upgrading of sewers S.C. Iasicon S.A. (W) ROMANIA (W) 10 May 2013 Works Alternative 1,801,413 225,177 12.50% 41175 R2CF Targu Mures Sub-Project 56541 MS-SG&CS-YB-04 Sighisoara SC AEG Tehnology SRL (W) ROMANIA (W) 19 Jun 2013 Works Alternative 5,814,189 657,585 11.31% and Cristuru Secuiesc - 41175 R2CF Targu Mures Sub-Project 56542 MS-VN-RB-06- Valea Hidroconstructia S.A. (W) ROMANIA (W) 04 Jun 2013 Works Alternative 4,029,642 455,752 11.31% Nirajului - new main trunk 39276 R2CF Iasi Sub-Project 56604 CL13 - Upgrading of water S.C. Iasicon S.A. (W) ROMANIA (W) 03 Jun 2013 Works Alternative 3,344,230 418,034 12.50% and sewerage systems in 42130 R2CF Dambovita -Targoviste 56842 CL8-Works at water sources SC Rotary Constructii SRL & Comsa SA ROMANIA (W) 28 Feb 2013 Works Alternative 8,488,753 933,763 11.00% Sub-Project and WWTP of Gaesti and (W) 40338 Sibiu Municipality Loan - Phase 57061 Upgrade and Refurbishment SC Comtram SA (W) ROMANIA (W) 31 Oct 2013 Works Open 130,753 105,446 80.65% II of Streets - Vasile Parvan SC CONSTRUCTII SA ROMANIA Street from Savings SC Terra Buiding SRL ROMANIA 43137 R2CF Timis 57201 CL9 Extension and Videli SRL & Lucy Star SRL (W) ROMANIA (W) 28 Mar 2013 Works Alternative 4,162,172 542,747 13.04% modernization of the water and sewerage networks in 41177 R2CF Constanta sub-project 57341 Rehabilitation of the water S.C. Fluid Serv S.A. (W) ROMANIA (W) 29 Oct 2013 Works Open 114,641 114,641 100.00% network in Predeal City - SC Insigra SRL ROMANIA 43137 R2CF Timis 57706 CL14 Extension and SC Grup Construct SRL and Ludwig ROMANIA (W) 08 Mar 2013 Works Alternative 4,112,765 536,305 13.04% modernisation of water and Pfeiffer Hoch-und Tiefbau GmbH & Co sewerage networks in Gataia KG (W) 43137 R2CF Timis 57721 CL10 Extension and Victor Construct SRL (W) ROMANIA (W) 14 Mar 2013 Works Alternative 2,913,051 379,862 13.04% modernisation of water and 43137 R2CF Timis 57722 CL16 Extension and Constructim SA and Multinstal SRL ROMANIA (W) 22 Mar 2013 Works Alternative 2,166,936 282,568 13.04% modernisation of water and (W) 43189 R2CF Dolj Water Sub-Project 57982 CL2 Craiova WTP - Isainita EMIT Ercole Marelli Impianti ITALY (W) 04 Mar 2013 Works Alternative 8,289,506 804,082 9.70% WTP Tecnologici S.p.a., SC Mitliv Exim SRL (W) 43189 R2CF Dolj Water Sub-Project 57983 CL3 Calafat - WTP and S.C. CORAL SRL TULCEA, S.C. ROMANIA (W) 07 May 2013 Works Alternative 9,060,822 878,900 9.70% WWTP and Trunk Main from ENERGOMONTAJ SA (W) 43189 R2CF Dolj Water Sub-Project 57984 CL4 Craiova WWTP Landfill SC GECOROM S.A., ISPE S.A (W) ROMANIA (W) 13 Mar 2013 Works Alternative 1,599,384 155,140 9.70%

43189 R2CF Dolj Water Sub-Project 57986 CL6 Filiasi WWTP SC UTI GRUP S.A., SC DANEX CONSULT ROMANIA (W) 03 Jan 2013 Works Alternative 3,533,392 342,739 9.70% S.R.L (W) 43189 R2CF Dolj Water Sub-Project 57987 CL7 New water and SC POLYSTART IMPEX SRL, SC TCIF SA ROMANIA (W) 19 Apr 2013 Works Alternative 7,289,050 707,038 9.70% wastewater networks in CRAIOVA, SC CONFORT SA (W) 43189 R2CF Dolj Water Sub-Project 57988 CL8 Rehabilitation & SC GRUP PRIMACONS S.R.L., VIALES Z ROMANIA (W) 27 Mar 2013 Works Alternative 5,245,117 508,776 9.70% extension of W&WW OBRAS PUBLICAS S.A. (W) 43189 R2CF Dolj Water Sub-Project 57989 CL10 Transfer sewers + SC Mitliv Exim SRL, EMIT Ercole Marelli ROMANIA (W) 07 Jun 2013 Works Alternative 14,230,279 1,380,337 9.70% Regional WWTPs in Rastu Impianti Tecnologici S.p.A. (W) Nou & Bechet 43189 R2CF Dolj Water Sub-Project 57990 CL12 Transfer collector SC EDAS EXIM, SC EUROPAN PROD SRL ROMANIA (W) 15 Apr 2013 Works Alternative 2,717,228 263,571 9.70% Segarcea and wastewater (W) 43189 R2CF Dolj Water Sub-Project 57991 CL13 The water source and SC Constructii Erbasu S.A., SC Polystart ROMANIA (W) 05 Apr 2013 Works Alternative 6,360,811 616,999 9.70% the water and sewerage Impex SRL (W) 43216 R2CF Satu Mare Sub-Project 58787 SM-CL-05 WWTP SC 3T Construct SRL, Stulz Planaqua ROMANIA (W) 17 May 2013 Works Alternative 4,409,971 485,097 11.00% construction in Tasnad and GmbH (W) 43189 R2CF Dolj Water Sub-Project 58861 CS4 Project Audit SC ELITE AUDIT S.R.L. (W) ROMANIA (W) 28 Jun 2013 Consulta Alternative 10,015 971 9.70% nt Services 43189 R2CF Dolj Water Sub-Project 58881 CL11 Water Sources FIN CONSTRUCT SRL, OPRA ROMANIA (W) 12 Sep 2013 Works Alternative 7,896,755 765,985 9.70% extension of water networks CONSTRUZIONI SRL (W) and new wastewater 41175 R2CF Targu Mures Sub-Project 58921 MS-RG-RB-05 Reghin SC Geiger Transilvania SRL, SC ROMANIA (W) 12 Sep 2013 Works Alternative 2,316,109 261,952 11.31% extension of sewerage Lasprom SRL (W) system, wastewater 41178 R2CF Sibiu sub-project 59141 CL1 - Extension and SC Constructii SA (W) ROMANIA (W) 17 Jul 2013 Works Alternative 2,441,713 268,588 11.00% rehabilitation of the water supply and swerege

Annex 1a ROMANIA Municipal & Env Inf

41178 R2CF Sibiu sub-project 59161 CL2 - Wastewater Treatment SC Gavella Com SRL, SC Terra Med SRL ROMANIA (W) 17 Jul 2013 Works Alternative 3,499,633 384,960 11.00% Plant for Avrig and Marsa (W) localities and the mechano- 41178 R2CF Sibiu sub-project 59162 CL3 - Water mains Apa SC A.C.I. BISTRITA SA (W) ROMANIA (W) 27 Sep 2013 Works Alternative 8,351,163 918,628 11.00% Secaselor Water main Sibiu- Ocna Sibiului, Water main 41178 R2CF Sibiu sub-project 59163 CL4 - Extension and SC Universal Business SA (W) ROMANIA (W) 22 Apr 2013 Works Alternative 3,880,723 426,880 11.00% rehabilitation of water distribution and sewerage 41178 R2CF Sibiu sub-project 59164 CL5 - Wastewater Treatment SC de Constructii Napoca SA (W) ROMANIA (W) 29 Apr 2013 Works Alternative 1,388,236 152,706 11.00% Plant for Ocna Sibiului 41178 R2CF Sibiu sub-project 59167 CL9 - Extension and SC Geiger Transilvania SRL (W) ROMANIA (W) 12 Jul 2013 Works Alternative 4,753,199 522,852 11.00% rehabilitation of water distribution and sewerage 41178 R2CF Sibiu sub-project 59168 CL10 - Rehabilitation of SC Hidroconstructia SA, SC General ROMANIA (W) 06 Nov 2013 Works Alternative 2,828,914 311,181 11.00% water catchment and water Concrete Cernavoda SRL, SC Benni mains for Fagaras Prest SRL (W) 41178 R2CF Sibiu sub-project 59169 CL11 - Extension and SC RECON SI DOJE SRL (W) ROMANIA (W) 14 Jun 2013 Works Alternative 9,728,610 1,070,147 11.00% rehabilitation of water distribution and sewerage 43216 R2CF Satu Mare Sub-Project 59202 SM-CL-04 Refurbishment SC Interfrigo Logistrics SRL, ESC Edas ROMANIA (W) 31 Oct 2013 Works Alternative 3,434,221 377,764 11.00% and extension of WWTP in Exim SRL (W) Negresti Oas City and 43216 R2CF Satu Mare Sub-Project 59203 SM-CS-03 Auditing services SC KPMG Audit SRL (W) ROMANIA (W) 20 Nov 2013 Consulta Alternative 34,831 3,831 11.00% of the Project nt Services 42130 R2CF Dambovita -Targoviste 59223 CP1A-Leak detection SC EE Test SA (W) ROMANIA (W) 11 Nov 2013 Goods Alternative 81,957 9,015 11.00% Sub-Project 42130 R2CF Dambovita -Targoviste 59224 CP3-Procurement and SC Secvision Business Solutions SRL,SC ROMANIA (W) 19 Sep 2013 Supply & Alternative 1,253,055 137,836 11.00% Sub-Project installation of SCADA Mikon Systems SRL,SC Palex Installati equipment Constructii SR (W) on

Transport 44271 CFR Financial Restructuring 57461 Consulting Services - Small Drew Transport Consultants (W) UNITED 22 Apr 2013 Consulta Direct Selection 16,500 16,500 100.00% Assignments KINGDOM (W) nt Services Total ROMANIA 46 206,042,336 26,807,099 13.01% RUSSIAN Municipal & 41188 Vologda District Heating 50041 7 Reconstruction of LLC Energostroy (W) RUSSIAN 05 Dec 2013 Supply & Open 3,639,985 1,665,105 45.74% FEDERATION Env Inf Molochnoye settlement heat FEDERATION Installati supply system - DH-6.1 + (W) on DH-6.3 35294 Sakha (Yakutia) Republican 51483 Pe-1.2 Lot ST Procurement LLC TD Techindustria (W) RUSSIAN 21 Aug 2013 Goods Open 114,710 114,710 100.00% MSDP GUP ZhKH of special vehicles trucks for FEDERATION Zhigansk (W) LLC Spectechnika-Sever RUSSIAN FEDERATION LLC TPF Lenaprom-stroysnab RUSSIAN FEDERATION 41847 Lipetsk Wastewater Treatment 51645 Rehabilitation of Aeration Firma SENS CJSC (W) RUSSIAN 06 Feb 2013 Works Open 5,003,805 5,003,805 100.00% Plant and Sedimentation Tanks of FEDERATION WWTP Lipetsk-3 x Aeration (W) 43283 Sakha (Yakutia) Energy 52732 LOT 4 - Supply of LLC BR Trade (W) RUSSIAN 25 Jan 2013 Goods Open 423,796 423,796 100.00% Efficiency Programme equipment for energy FEDERATION efficiency boilers and related (W) 43283 Sakha (Yakutia) Energy 52733 LOT 1 - Supply of Vostoktechtorg CJSC (W) RUSSIAN 10 Jun 2013 Goods Open 340,446 340,446 100.00% Efficiency Programme equipment for energy FEDERATION efficiency boilers and related (W) services - Pumps Elit-Teplo M LLC, Russia RUSSIAN FEDERATION KSB LLC RUSSIAN FEDERATION Liask-T LLC RUSSIAN FEDERATION

Annex 1a RUSSIAN Municipal & FEDERATION Env Inf

43283 Sakha (Yakutia) Energy 52733 LOT 1 - Supply of 10 Jun 2013 Goods Open 340,446 340,446 100.00% Efficiency Programme equipment for energy efficiency boilers and related services - Pumps

PromHimTech LLC RUSSIAN FEDERATION 35294 Sakha (Yakutia) Republican 53682 Pe-2c Laying of Heating LLC Stroimontazh-2002 (W) RUSSIAN 13 Jun 2013 Works Open 1,585,177 1,585,177 100.00% MSDP GUP ZhKH Mains and Supplying Water FEDERATION to Boiler Plant of (W) 41847 Lipetsk Wastewater Treatment 54041 Construction of a air blower Firma SENS CJSC (W) RUSSIAN 25 Nov 2013 Works Open 2,342,834 2,342,834 100.00% Plant station FEDERATION (W) 41188 Vologda District Heating 55764 5 Reconstruction and LLC Termoizolstroy (W) RUSSIAN 04 Sep 2013 Works Open 1,188,564 1,188,564 100.00% Construction of heat LLC Aquaplast RUSSIANFEDERATION transmission pipelines FEDERATION 43283 Sakha (Yakutia) Energy 56182 Heating Mains Variant Plus LLC (W) RUSSIAN 28 Aug 2013 Works Open 4,189,171 4,189,171 100.00% Efficiency Programme Reconstruction of Tiksi FEDERATION (W) LLC TeploMontazh RUSSIAN FEDERATION LLC Yakutskie teplvie seti RUSSIAN FEDERATION 40899 Pskov water and wastewater 58523 1A - Completion of work Garantstroyservice Ltd. (W) RUSSIAN 09 Dec 2013 Works Direct Selection 2,675,105 2,675,105 100.00% improvement project components included in FEDERATION construction of groundwater (W) Power and 44222 Vladivostok Combined Heat & 56821 Vladivostok Combined Heat ENERGAS LLC (W) RUSSIAN 25 Jun 2013 Supply & Open 8,092,161 695,601 8.60% Energy Power Plant and Power Plant, FEDERATION Installati Slovenia.Three Booster (W) on Compressor Stations and CJSC Gas Systems RUSSIAN Gas Treatment FEDERATION CJSJ NPK Unicmash RUSSIAN FEDERATION Consortium : GEA Grasso Refregeration OOO RUSSIAN & CJSC Fir FEDERATION HAFI Engineering & Consulting Gesellschaft AUSTRIA m.b.H SFERA LLC RUSSIAN FEDERATION 44222 Vladivostok Combined Heat & 58462 Procurement of Three OJSC "Power Machines" (W) RUSSIAN 26 Nov 2013 Goods Open 6,964,753 763,876 10.97% Power Plant Booster Exhaust Heat Boilers FEDERATION (W) CJSC TEP-Holdings RUSSIAN FEDERATION EKOL, spol. s.r.o. CZECH REPUBLIC

Interenergo LCC RUSSIAN FEDERATION JV: CJSC PIK Energotrast & MasgTechnologia RUSSIAN FEDERATION OJSC HC Energomash-Stroy RUSSIAN FEDERATION OJSC Podolskiy Mashinostroitelnyi plant RUSSIAN FEDERATION TECHNOSERV AS LTD RUSSIAN FEDERATION ZIO Podolsk Mashinostroitelnyi plant RUSSIAN FEDERATION ZIOMAR RUSSIAN FEDERATION Transport 41905 RZD Energy Efficiency Project 56467 Lot 1: Supply of LED JSC "SpetsProm" (W) RUSSIAN 04 Jun 2013 Supply & Open 217,911 217,911 100.00% Lighting Equipment and FEDERATION Installati Installation Supervision (W) on Services JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "Lider Light Trade" RUSSIAN FEDERATION

Annex 1a RUSSIAN FEDERATION

Transport 41905 RZD Energy Efficiency Project 56467 Lot 1: Supply of LED 04 Jun 2013 Supply & Open 217,911 217,911 100.00% Lighting Equipment and Installati Installation Supervision on Services

JSC "Philips" RUSSIAN FEDERATION OJSC "Proton" RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 56482 Lot 2: Supply of LED OJSC "Miassky Mashinebuilding Plant" RUSSIAN 04 Jun 2013 Supply & Open 193,008 193,008 100.00% Lighting Equipment and (W) FEDERATION Installati Installation Supervision (W) on Services JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "Philips" RUSSIAN FEDERATION JSC "Prosoft Trading" RUSSIAN FEDERATION JSC "SPETSPROM" RUSSIAN FEDERATION JSC NPP "EnergoTechService" RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 56501 Lot 3: Supply of LED Optogan CJSC (W) RUSSIAN 04 Jun 2013 Supply & Open 212,338 212,338 100.00% Lighting Equipment and FEDERATION Installati Installation Supervision (W) on Services JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "Philips" RUSSIAN FEDERATION JSC "SPETSPROM" RUSSIAN FEDERATION OJSC "Proton" RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 56502 Lot 4: Supply of LED Optogan CJSC (W) RUSSIAN 04 Jun 2013 Supply & Open 145,042 145,042 100.00% Lighting Equipment and FEDERATION Installati Installation Supervision (W) on Services JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "PHILIPS" RUSSIAN FEDERATION JSC "SPETSPROM" RUSSIAN FEDERATION OJSC "MIASSKY MASHINEBUILDING PLANT" RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 56503 Lot 5: Supply of LED JSC "SpetsProm" (W) RUSSIAN 04 Jun 2013 Supply & Open 98,354 98,354 100.00% Lighting Equipment and FEDERATION Installati Installation Supervision (W) on Services JSC "Eco Svet Center" RUSSIAN FEDERATION JSC "LiderLight Trade" RUSSIAN FEDERATION JSC "Philips" RUSSIAN FEDERATION OJSC "MIASSKY MASHINEBUILDING PLANT" RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58341 No.1. Set of LED light JSC Prosoft Trading (W) RUSSIAN 25 Oct 2013 Supply & Open 162,046 162,046 100.00% fixtures for illumination FEDERATION Installati facility of the site: (W) on Sverdlovsk Infrastructure JSC Philips RUSSIAN Directorate of Yekaterinburg- FEDERATION Sortirovochnyi hump yard JSC Svetlana ¿E RUSSIAN FEDERATION OJSC Miassky Mashinebuilding plant RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58342 No.2. Set of LED light JSC BL Trade (W) RUSSIAN 25 Oct 2013 Supply & Open 145,407 145,407 100.00% fixtures for illumination FEDERATION Installati facility of the site: Moscow (W) on Infrastructure Directorate, Bryansk-Lgovcky station

Annex 1a RUSSIAN FEDERATION

Transport

41905 RZD Energy Efficiency Project 58342 No.2. Set of LED light 25 Oct 2013 Supply & Open 145,407 145,407 100.00% fixtures for illumination Installati facility of the site: Moscow on Infrastructure Directorate, CJSC Svetlana - OE RUSSIAN Bryansk-Lgovcky station FEDERATION JSC Leader Light Trade RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58343 No.3. Set of LED light JSC BL Trade (W) RUSSIAN 25 Oct 2013 Supply & Open 97,063 97,063 100.00% fixtures for illumination FEDERATION Installati facility of the site: West (W) on Siberian Infrastructure CJSC Svetlana - OE RUSSIAN Directorate, Barabinsk FEDERATION station JSC Philips RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58344 No.4. Set of LED light JSC Prosoft Trading (W) RUSSIAN 25 Oct 2013 Supply & Open 141,046 141,046 100.00% fixtures for illumination FEDERATION Installati facility of the site: (W) on Privolzhsky Infrastructure CJSC Svetlana - OE RUSSIAN Directorate, Volzhsky station FEDERATION JSC Leader Light Trade RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58361 No.5. Set of LED light OJSC "Miassky Mashinebuilding Plant" RUSSIAN 25 Oct 2013 Supply & Open 105,884 105,884 100.00% fixtures for illumination (W) FEDERATION Installati facility of the site: South (W) on Urals Infrastructure CJSC Svetlana - OE RUSSIAN Directorate, FEDERATION Metallurgicheskaya station JSC Philips RUSSIAN FEDERATION JSC PROSOFT- TRADING RUSSIAN FEDERATION JSC SpetsProm RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58362 No.6. Set of LED light JSC Prosoft Trading (W) RUSSIAN 25 Oct 2013 Supply & Open 143,361 143,361 100.00% fixtures for illumination FEDERATION Installati facility of the site: East (W) on Siberian Infrastructure CJSC Svetlana - OE RUSSIAN Directorate, Ulan-Ude FEDERATION station JSC Philips RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58363 No.7. Set of LED light JSC BL Trade (W) RUSSIAN 25 Oct 2013 Supply & Open 99,499 99,499 100.00% fixtures for illumination FEDERATION Installati facility of the site: Trans- (W) on Baikal Infrastructure CJSC Svetlana - OE RUSSIAN Directorate, Chita-1 station FEDERATION JSC Philips RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58364 No.9. Set of LED light JSC BL Trade (W) RUSSIAN 25 Oct 2013 Supply & Open 215,749 215,749 100.00% fixtures for illumination CJSC Svetlana - OE RUSSIANFEDERATION Installati facility of the site: South FEDERATION on Eastern Infrastructure JSC ¿Philips¿ RUSSIAN Directorate, Stoilenskaya FEDERATION 41905 RZD Energy Efficiency Project 58365 No.10. Set of LED light CJSC Svetlana-OE (W) RUSSIAN 25 Oct 2013 Supply & Open 342,873 342,873 100.00% fixtures for illumination FEDERATION Installati facility of the site: Oktyabrsk (W) on Infrastructure Directorate, JSC Philips RUSSIAN Belomorsk station FEDERATION JSC SpetsProm RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58366 No.11. Set of LED light OJSC "Miassky Mashinebuilding Plant" RUSSIAN 25 Oct 2013 Supply & Open 104,989 104,989 100.00% fixtures for illumination (W) FEDERATION Installati facility of the site: Kuibyshev (W) on Infrastructure Directorate, Ruzayevka station

Annex 1a RUSSIAN FEDERATION

Transport

41905 RZD Energy Efficiency Project 58366 No.11. Set of LED light 25 Oct 2013 Supply & Open 104,989 104,989 100.00% fixtures for illumination Installati facility of the site: Kuibyshev on Infrastructure Directorate, JSC Leader Light Trade RUSSIAN Ruzayevka station FEDERATION JSC NPP EnergoTechService RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION JSC SpetsProm RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58367 No.12. Set of LED light CJSC Transenercom (W) RUSSIAN 25 Oct 2013 Supply & Open 66,563 66,563 100.00% fixtures for illumination FEDERATION Installati facility of the site: North (W) on Caucasus Infrastructure CJSC Optogan¿ RUSSIAN Directorate, Novorossiysk FEDERATION station JSC Philips RUSSIAN FEDERATION OJSC Miaasky Machinebuilding Plant RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58501 No.8. Set of LED light CJSC Optogan (W) RUSSIAN 07 Nov 2013 Supply & Open 161,599 161,599 100.00% fixtures for illumination FEDERATION Installati facility of the site: Far East (W) on Infrastructure Directorate, CJSC Optogan RUSSIAN Khabarovs -1 station FEDERATION CJSC Svetlana-Opto Electronika RUSSIAN FEDERATION JSC NPP EnergoTechService RUSSIAN FEDERATION JSC Philips RUSSIAN FEDERATION JSC SpetsProm RUSSIAN FEDERATION 41905 RZD Energy Efficiency Project 58982 Lot 1 Intelligent energy- JSC Ecolight (W) RUSSIAN 20 Dec 2013 Supply & Open 151,839 151,839 100.00% saving LED-based lighting FEDERATION Installati system for Anapa railway (W) on station Total RUSSIAN FEDERATION 30 39,365,077 23,792,761 60.44% SERBIA Municipal & 44014 Belgrade Bus Renewal 52662 New low-floor articulated Solaris Bus and Coach SA (W) POLAND (W) 08 Mar 2013 Goods Open 63,877,499 63,877,499 100.00% Env Inf Programme buses x 200 Ashok Leyland Ltd INDIA Ikarbus ad in restructuring factory of buses SERBIA and Special Vehicles Iveco Czech as with JVCA Iveco France SA CZECH REPUBLIC

LLC Russian Buses-GAZ Group RUSSIAN FEDERATION Man Truck & Bus AG Dachauer GERMANY Volvo Bus Corporation SE-40508 SWEDEN Power and 41923 EPS Kolubara Environmental 55441 A1 Bucket Wheel Excavator Thyssen Krupp AG (W) GERMANY (W) 28 Mar 2013 Supply & Open 30,908,985 30,908,985 100.00% Energy Improvement NOEN a.s. CZECH REPUBLIC Installati on Tenova Takraf GmbH GERMANY 41923 EPS Kolubara Environmental 55542 A 2 Belt Conveyor System Kopex Joint Stock Company (W) POLAND (W) 28 Mar 2013 Supply & Open 28,288,971 28,288,971 100.00% Improvement FAM Magdeburg GERMANY Installati FAMUR SA Mining Machinery Factory POLAND on 41923 EPS Kolubara Environmental 55544 A 3 Spreader Sandvik Mining and Construction AUSTRIA (W) 26 Apr 2013 Supply & Open 14,380,506 14,380,506 100.00% Improvement Materials Handling GmbH & Co KG (W) Installati on COPEX-FAMAGO Sp.z.o.o POLAND FAM Magdeburg Forderanlagen und GERMANY Baumachinen GmbH Takraf GmbH GERMANY 41923 EPS Kolubara Environmental 55545 A 4 Power Supply Monprojekt d.o.o. (W) SERBIA (W) 26 Apr 2013 Supply & Open 1,823,806 1,823,806 100.00% Improvement ABB Automation GmbH GERMANY Installati Siemens d.o.o. SERBIA on

Annex 1a SERBIA

Transport 38711 Serbia Railways EMUs 36461 Supply of Electric Multiple Stadler Rail AG (W) SWITZERLAND 04 Mar 2013 Goods Open 98,999,995 98,999,995 100.00% Units (W) No other Tenderers UNITED KINGDOM

41125 Serbian Railways Corridor X 56741 Track Renewal Materials Lot MORAVIA STEEL A.S. (W) CZECH 29 Apr 2013 Goods Open 9,295,560 9,295,560 100.00% 1 - procurement of rails of REPUBLIC (W) 49E1 & 60E1 type, grade TATA STEEL FRANCE R260 VOEST ALPINA AUSTRIA 41125 Serbian Railways Corridor X 56743 Track Maintenance Geismar (W) FRANCE (W) 22 May 2013 Goods Open 681,902 681,902 100.00% Equipment Lot 4 - sleeper NEW SOREMA ITALY 41125 Serbian Railways Corridor X 56744 Track Maintenance Geismar (W) FRANCE (W) 22 May 2013 Goods Open 1,010,079 1,010,079 100.00% Equipment Lot 2 - rail-road MAN Importer Srbija-Dewaco do.o. SERBIA 41125 Serbian Railways Corridor X 57421 Track Maintenance Terra Srbija d.o.o. (W) SERBIA (W) 07 May 2013 Goods Open 77,545 77,545 100.00% Equipment Lot 1 - 41125 Serbian Railways Corridor X 57422 Track Renewal Materials Lot Vossloh Min Skretnice d.o.o. (W) SERBIA (W) 17 Jun 2013 Goods Open 1,644,570 1,644,570 100.00% 2 - procurement of new DIV D.O.O. CROATIA switches with elastic VOESTALPINA VAE GmbH GERMANY 41125 Serbian Railways Corridor X 57423 Track Renewal Materials Lot Alpine Kamen d.o.o. (W) SERBIA (W) 17 Jun 2013 Goods Open 4,286,409 4,286,409 100.00% 6 - procurement of crushed 41125 Serbian Railways Corridor X 57424 Track Renewal Materials Lot PYRKONIT d.o.o. (W) SERBIA (W) 17 Jun 2013 Goods Open 175,109 175,109 100.00% 7 - procurement of AT Elektro-Thermit GmbH & Co.KG GERMANY 41125 Serbian Railways Corridor X 57425 Track Renewal Materials Lot OPTICUS d.o.o. (W) SERBIA (W) 17 Jun 2013 Goods Open 621,488 621,488 100.00% 8 - procurement of Huesker Synthetic GmbH GERMANY 41125 Serbian Railways Corridor X 57426 Track Renewal Materials Lot Kraiburg Elastik GmbH (W) GERMANY (W) 17 Jun 2013 Goods Open 387,634 387,634 100.00% 9 - procurement of road DIV D.O.O. CROATIA 41125 Serbian Railways Corridor X 57521 Track Maintenance VAIA CAR SpA (W) ITALY (W) 07 Aug 2013 Goods Open 2,988,000 2,988,000 100.00% Equipment Lot 3 - GEISMAR FRANCE procuremetn of rail loader Tesmec SpA ITALY 41125 Serbian Railways Corridor X 57541 Track Renewal Materials Lot IMPREGNACIJA a.d. (W) SERBIA (W) 07 Aug 2013 Goods Open 2,398,086 2,398,086 100.00% 4 - procurement of Fürstenberg THP GERMANY 41125 Serbian Railways Corridor X 57542 Track Renewal Materials Lot DIV d.o.o. (W) CROATIA (W) 07 Aug 2013 Goods Open 4,934,064 4,934,064 100.00% 3 - procurement of concrete DW Schwellen GmbH GERMANY sleepers with elastic rail ZPSV OHL GROUP AD CZECH REPUBLIC fastenings 41125 Serbian Railways Corridor X 57561 Track Renewal Materials Lot DIV d.o.o. (W) CROATIA (W) 07 Aug 2013 Goods Open 1,540,380 1,540,380 100.00% 5 - procurement of rail fastenings type K for 41125 Serbian Railways Corridor X 57781 Track Maintenance ROBEL Bahnbaumaschinen GmbH (W) GERMANY (W) 07 Aug 2013 Goods Open 991,193 991,193 100.00% Equipment Lot 5 - procurement of light track GEATECH S.p.A. ITALY maintenance machinery GEISMAR FRANCE 35414 Serbian Railways : Rollingstock 58562 Jackscrews with bearing Bertolotti S.p.A (W) ITALY (W) 21 Nov 2013 Goods Open 95,680 95,680 100.00% capacity of 8x20t with two Oficine Meccaniche BBM S.p.A ITALY control desks TZV Gredelj in bankruptcy CROATIA 39750 K10 58721 Construction of Highway E Trace Group Hold (W) BULGARIA (W) 23 Dec 2013 Works Open 15,364,224 15,364,224 100.00% 80 Section: Parallel - non- AKTOR SA GREECE commercial road, Bela Alexandre Barbosa Borges AS PORTUGAL Palanka - Pirot (West) Construcciones Rubau SA SPAIN E80 BEPA ITALY EURO-ASFALT D.O.O. SARAJEVO BOSNIA AND HERZEGOVINA INTEGRAL INZENJERING A.D. LAKTASI BOSNIA AND HERZEGOVINA STRABAG AG AUSTRIA Total SERBIA 22 284,771,686 284,771,686 100.00% SLOVENIA Power and 40417 SOSTANJ Thermal Power Plant 54821 Supply and Installation of Rudis (W) SLOVENIA (W) 28 Feb 2013 Supply & Open 992,112 992,112 100.00% Energy Coal Transport - Stage 2 EZOTECH d.d. SLOVENIA Installati SONOEN a.s. CZECH REPUBLIC on

Total SLOVENIA 1 992,112 992,112 100.00% TAJIKISTAN Municipal & 40717 North Tajik Water 50142 PP1.1 LOT 1 Supply of Doro Ltd (W) TAJIKISTAN 24 May 2013 Goods Open 135,446 135,446 100.00% Env Inf Rehabilitation Maintenance Equipment (W)

Annex 1a TAJIKISTAN Municipal & 40717 North Tajik Water 50142 PP1.1 LOT 1 Supply of 24 May 2013 Goods Open 135,446 135,446 100.00% Env Inf Rehabilitation Maintenance Equipment Burkhyon Ltd. TAJIKISTAN Grand Motors MMC AZERBAIJAN Intertekhnologya CJSC RUSSIAN FEDERATION Khurshedy-Khorazm Ltd. TAJIKISTAN SupplyQuip Ltd. MAURITIUS Tojplast Ltd. TAJIKISTAN 41769 Khujand Solid Waste 53143 KhSWMP-001 Specialised Diana & Co LLC (W) TAJIKISTAN 23 Jul 2013 Goods Open 1,060,061 530,031 50.00% Management Project vehicles; waste collection (W) trucks and machinery Bark Sokhtmon LLC TAJIKISTAN Doro Ltd TAJIKISTAN Grand Motors LLC AZERBAIJAN Unit Export.Ltd UNITED KINGDOM

Xinjiang Sanbao Industry Group Co. Ltd CHINA Zeppelin International AG SWITZERLAND 40717 North Tajik Water 53261 PP3.4-Rehabiliation of Water Orieno Sorvo Ltd. (W) TAJIKISTAN 29 May 2013 Works Open 576,529 311,326 54.00% Rehabilitation Supply Network in (W) Kairakkum City LOT 1 Boyut Khiranur Ltd. TAJIKISTAN Farrukhruz-1 Ltd TAJIKISTAN Hayot Ltd. TAJIKISTAN MKM Somony Ltd. TAJIKISTAN Rohat Ltd. TAJIKISTAN Tajik SGEM JSC TAJIKISTAN 40717 North Tajik Water 53501 PP3.2-Rehabilitation of Juziy Zimiston Ltd. (W) TAJIKISTAN 14 May 2013 Works Open 1,755,376 1,070,779 61.00% Rehabilitation water supply network in (W) Gafurov City Firuz Ltd. TAJIKISTAN Madina Ltd. TAJIKISTAN Nigina Ltd. TAJIKISTAN Rohat Ltd. TAJIKISTAN Yahyo Company Ltd. TAJIKISTAN 41642 Central Tajik Water 53582 CTWRP-001 Comprehensive General Directorate of Geology under TAJIKISTAN 20 May 2013 Consulta Competitive 132,218 52,887 40.00% Rehabilitation Project survey of underground the Government of the Republic of (W) nt water sources and detailed Taiikista (W) Services design for location of the State Institution Tojikobdekhot TAJIKISTAN 40717 North Tajik Water 53661 PP3.1-Rehabilitation of Umed-1 Ltd. (W) TAJIKISTAN 14 May 2013 Works Open 640,867 640,867 100.00% Rehabilitation water supply network in (W) Chkalovsk City Khurshedi Tobon Ltd TAJIKISTAN Magma Construction Company IRAN 41769 Khujand Solid Waste 55363 KhSWMP-004 Supply of Sharifi Khuchandy Co. Ltd (W) TAJIKISTAN 20 Sep 2013 Goods Open 450,750 225,375 50.00% Management Project containers, special uniform (W) and working tools Barz Co Ltd TAJIKISTAN CJS Company Nauselmash TAJIKISTAN Khujandprommash Co Ltd TAJIKISTAN KM Sadaf SHAN-Yuy Co Ltd TAJIKISTAN SP Khaydarov S.K TAJIKISTAN SUE Factory Zaria Vostoka TAJIKISTAN YS 3/5 Enterprise TAJIKISTAN 40717 North Tajik Water 55621 PP1.1 LOT 2 Specialised LLC Khurshedi Khorasm (W) TAJIKISTAN 10 May 2013 Goods Open 1,040,578 1,040,578 100.00% Rehabilitation Vehicles (W) Burkhyon Ltd. TAJIKISTAN Doro Ltd. TAJIKISTAN Grand Motors MMC AZERBAIJAN SupplyQuip Ltd. MAURITIUS Tojplast Ltd. TAJIKISTAN 41642 Central Tajik Water 56021 CTWRP-002 LOT 2 Office Doro Ltd (W) TAJIKISTAN 29 May 2013 Goods Open 12,645 5,047 39.91% Rehabilitation Project Equipment (W) Electrogidromash LLC TAJIKISTAN 41642 Central Tajik Water 56221 CTWRP-004 Renovation of LLC Obi Dekhot (W) TAJIKISTAN 30 Oct 2013 Works Open 134,434 51,288 38.15% Rehabilitation Project Kuktosh water intake in (W) Somoniyon CJSC Monalit 05 TAJIKISTAN Consortium LLC Bodoma and LLC Zinat TAJIKISTAN

Annex 1a TAJIKISTAN Municipal & Env Inf

41642 Central Tajik Water 56221 CTWRP-004 Renovation of 30 Oct 2013 Works Open 134,434 51,288 38.15% Rehabilitation Project Kuktosh water intake in Somoniyon

LLC Kalasoz TAJIKISTAN LLC Osari TAJIKISTAN LLC Oyandasoz TAJIKISTAN LLC Solekh 2012 TAJIKISTAN 41642 Central Tajik Water 56421 CTWRP-009 Construction of Electrogidromash LLC and Khurshedi TAJIKISTAN 20 Nov 2013 Works Open 1,648,713 606,657 36.80% Rehabilitation Project water main and renovation Khorazm LLC (W) (W) of distribution network in LLC Gayur-1 TAJIKISTAN Somoniyon city LLC Khudoyor / LLC Obi Dekhot / LLC TAJIKISTAN Sugdiyon LLC Navruz-2003 TAJIKISTAN LLC Rokhat TAJIKISTAN LLC Sichiyon TAJIKISTAN LLC Umed TAJIKISTAN Total TAJIKISTAN 12 7,651,617 4,670,281 61.04% TURKEY Municipal & 41222 Bodrum Water 52181 Procurement of goods for Samsun Makina San. A.S. (W) TURKEY (W) 21 Feb 2013 Goods Open 762,758 762,758 100.00% Env Inf the water network rehabilitation Tranche 1- 41222 Bodrum Water 52661 Procurement of Goods for Samsun Makina San. A.S. (W) TURKEY (W) 07 Jan 2013 Goods Open 472,370 472,370 100.00% the Water Network Rehabilitation Bodrum - 41222 Bodrum Water 52841 Rehabilitation of the Existing GELISIM Insaat Tur. San. Ve Tic. Lfd TURKEY (W) 03 Apr 2013 Works Open 1,061,392 1,061,392 100.00% Water Network Bodrum - Sti. (W) procurement of works for 43170 Mersin Wastewater Project 54042 Engineering and Supervision TEMELSU Uluslararasi Mühendislik TURKEY (W) 10 Oct 2013 Consulta Competitive 1,200,325 1,200,325 100.00% Consultancy Services Hizmetleri A.S., SRP Schneider & nt Partner Ingeni (W) Services DORSCH International Consultants GmbH & GERMANY Su-Yapi Muhendislik ve Musavirlik AS EPTISA Servicios De Ingeniera, SL. & EPTISA SPAIN Muh. Mus Hiz Bil. Fichtner Water & Transportation GmbH GERMANY ILF Beratende Ingenieure ZT GmbH & CDM AUSTRIA Smith Europe GmbH SAFEGE & TEMPO Altyapi Mühendislik BELGIUM Müsavirlik Total TURKEY 4 3,496,845 3,496,845 100.00% UKRAINE Municipal & 39789 Lviv Road Rehabilitation and 49964 Phase II Works for road and ONUR Taahhut Tasimacilik Ve Ticaret TURKEY (W) 03 Jun 2013 Works Open 26,535,948 11,000,000 41.45% Env Inf Modernisation Project tram lines reconstruction in Ltd.CTI (W) Lviv City -Tram Lines 2 & 6 - ELECNOR S.A. SPAIN 39299 Lviv Public Transport Financing 55922 Used refursbished tram car Erfurter Verkehrsbetriebe AG (W) GERMANY (W) 13 May 2013 Goods Direct Selection 254,000 254,000 100.00% Project rolling stock and spare parts Power and 40147 South Ukraine Transmission 58561 Construction of OHL 750 kV Instalaciones Inabensa, S.A. (W) SPAIN (W) 14 Aug 2013 Supply & Open 55,480,675 27,740,338 50.00% Energy Project Zaporizhzhia NPP - Kakhova CJS ENGINEERING-CONSTRUCTION SOYUZ- RUSSIAN Installati GRID FEDERATION on DALEKOVOD D.D. CROATIA ENGINEERING LLC RUSSIAN FEDERATION JYOTI STRUCTURES LIMITED INDIA KALPATARU POWER TRANSMISSION LTD INDIA

KEC INTERNATIONAL LIMITED INDIA Transport 40185 Pan-European Corridors 58641 OPRC for M06 Kiev to Chop ELSAMEX Internacionale (W) SPAIN (W) 31 Dec 2013 Works Open 50,533,933 50,533,933 100.00% Highway - Contract 1 km ONUR TAAHHUT TASHIMACILIK VC TICARET TURKEY 434+230 - km 621+500 LTD STI. STRABAG JVCA AUSTRIA 40185 Pan-European Corridors 58661 OPRC - supervision of works Egis International (W) FRANCE (W) 21 Nov 2013 Consulta Competitive 1,219,700 1,219,700 100.00% and services IC CONSULENTEN ZIVILTECHNIKER AUSTRIA nt GESMBH Services LOUIS BERGER SAS FRANCE MOTT MACDONALD LTD UNITED KINGDOM

Total UKRAINE 5 134,024,256 90,747,971 67.71%

Annex 1a Grand Total 260 1,254,089,750 877,678,831 69.99% (*) Please note that some of the contracts are both grant and loan funded. See explanation in our detailed Annual Procurement Review Annex 1a

Annex 1a Listing of Signed Contracts by Country of Operations - Bank Administered Grants Country Sector Grant ID Grant Name Contract ID Contract Name Tenderer Name Tenderer Country Contract Signing Date Contract Type Procure Signed Contract Fund Source Fund ment Value (EUR) Portion (EUR) Source % Method

BOSNIA AND Municipal & 40775 Vodovod I 46884 Design and Construction of Va Tech Wabag GmbH & AUSTRIA (W) 16 Sep 2013 Works Direct 7,031,644 5,975,000 84.97% HERZEGOVINA Env Inf Kanalizacija Municipal Wastewater Treatment HIGRA d.o.o. (W) Selectio Bijeljina Plant - EU IPA, SIDA n Total BOSNIA AND HERZEGOVINA 1 7,031,644 5,975,000 84.97% GEORGIA Municipal & 40019 Government of 50324 Supply of a Compactor for Galoper Ltd (W) ARMENIA (W) 04 Feb 2013 Goods Open 206,839 206,839 100.00% Env Inf Georgia operation and maintenance of BOMAG GERMANY landfill Gr. Motors AZERBAIJAN Total GEORGIA 1 206,839 206,839 100.00% KYRGYZ REPUBLIC Municipal & 38878 Bishkek Water 51921 WS-1 Lot 3 Reconstruction of Kyrgyzenergostroi OJSC KYRGYZ REPUBLIC 11 Apr 2013 Works Open 358,177 358,177 100.00% Env Inf Swiss SECO Grant pipeline along Manasa str. from (W) (W) BChK to Saadayeva Street Aziastroikompleks Ltd. KYRGYZ REPUBLIC FMU-1 Ltd KYRGYZ REPUBLIC Gidrant-teh Ltd., KYRGYZ REPUBLIC Joint Kyrgyz-Kazakh Gradient KYRGYZ REPUBLIC Ltd Kainar CJSC KYRGYZ REPUBLIC 52382 WS-1 Lot 4 Reconstruction of Gradient Ltd (W) KYRGYZ REPUBLIC 13 Feb 2013 Works Open 471,801 471,801 100.00% water mains of the well field (W) Severnyi OJSC Kyrgyzenergostroi KYRGYZ REPUBLIC 53581 WS-1 Lot 5 Construction of pipeline kainar CJSC Kyrgyzstan KYRGYZ REPUBLIC 12 Jun 2013 Works Open 478,860 478,860 100.00% along T.Moldo Str. from BChK to (W) (W) Saadaeva Str. and along Saadaeva Aziastroikompleks Ltd. KYRGYZ REPUBLIC Str. to Orozbekova street FMU-1 Ltd. KYRGYZ REPUBLIC Gidrant-teh Ltd. KYRGYZ REPUBLIC Joint Kyrgyz-Kazakh Gradient KYRGYZ REPUBLIC Ltd OJSC Kyrgyzenergostroi KYRGYZ REPUBLIC 54342 WS-1 Lot 6 Construction of Pipeline kainar CJSC Kyrgyzstan KYRGYZ REPUBLIC 12 Jun 2013 Works Open 430,909 430,909 100.00% D-325 along Jibek-Jolu Street from (W) (W) Ibraimova Street to Osmonkula FMU-1 Ltd KYRGYZ REPUBLIC Street 1158 meters Gidrant-Teh Ltd. KYRGYZ REPUBLIC Joint Kyrgyz-Kazakh Gradient KYRGYZ REPUBLIC Ltd. KiV ltd. KYRGYZ REPUBLIC Remservice CJSC KYRGYZ REPUBLIC 55581 WS-4 Supply of ultrasonic & electro- Fela Planungs AG (W) SWITZERLAND 01 Nov 2013 Goods Open 537,524 537,524 100.00% magnetic flow water meters for (W) installation in wellfields Endress and Hauser KAZAKHSTAN Instruments International AG

40752 CHOD-2013-02- 54802 OWRP PP3 Lot 3.1: Supply and Fela Planungs AG (W) SWITZERLAND 01 Oct 2013 Supply & Open 870,000 870,000 100.00% 02 - Osh Water Installation of Goods for Roshard AG SWITZERLAND(W) Installation 41492 Comm. No. EBSF- 55556 BPTD03 Supply of maintenance Asiaautocenter Ltd (W) KYRGYZ REPUBLIC 05 Nov 2013 Goods Open 144,464 50,562 35.00% 2011-12-185 - machinery Lot 1- Item 1.2 Tractor- (W) Bishkek Public excavator and 1.3 Recovery truck Finance F KYRGYZ REPUBLIC Transport OpID Grand Motors AZERBAIJAN 41492. Non- 57861 BPTD03 Supply of maintenance Grand Motors LLC (W) AZERBAIJAN (W) 31 Oct 2013 Goods Open 102,821 35,987 35.00% nuclear machinery Lot 1- Item 1.1 Mobile AsiaAutocenter KYRGYZ REPUBLIC Finance F KYRGYZ REPUBLIC Investment hydraulic crane Grant.

Annex 1b KYRGYZ REPUBLIC Municipal & Env Inf

41492 Comm. No. EBSF- 2011-12-185 - Bishkek Public Transport OpID 41492. Non- nuclear Investment 57862 BPTD03 Supply of maintenance Chelyabtransservice (W) RUSSIAN 27 Nov 2013 Goods Open 189,433 66,302 35.00% Grant. machinery Lot 2 Item 2.1 Elevating FEDERATION (W) platforms Asiaautocenter KYRGYZ REPUBLIC Grand Motors AZERBAIJAN Total KYRGYZ REPUBLIC 9 3,583,989 3,300,122 92.08% RUSSIAN Municipal & 37966 NDEP - District 52681 A-2 Installation of 2 GHS, 45 IHS to LLC Spetsgazavtomatika RUSSIAN 17 Jan 2013 Supply & Open 4,858,053 4,858,053 100.00% FEDERATION Env Inf heating provide heat supply after Russia (W) FEDERATION (W) Installation Component of the decommissioning of small coal fired Kaliningrad Water boiler houses & Env. Services Rehabilitation Programme. COMMITMENT NO - NDEP-2012- 01-02 Total RUSSIAN FEDERATION 1 4,858,053 4,858,053 100.00% TAJIKISTAN Municipal & 40717 Com No. CHNT- 53261 PP3.4-Rehabiliation of Water Supply Orieno Sorvo Ltd. (W) TAJIKISTAN (W) 29 May 2013 Works Open 576,529 265,203 46.00% Env Inf 2013-02-01 Network in Kairakkum City LOT 1 Boyut Khiranur Ltd. TAJIKISTAN Switzerland North Farrukhruz-1 Ltd TAJIKISTAN Tajik Water Hayot Ltd. TAJIKISTAN Project Account - MKM Somony Ltd. TAJIKISTAN North Tajik Water Rohat Ltd. TAJIKISTAN Tajik SGEM JSC TAJIKISTAN Rehabilitation 53362 PP3.6 Rehabilitation of water supply Sokhtmony Dekhot Ltd (W) TAJIKISTAN (W) 25 Apr 2013 Works Open 269,929 269,929 100.00% Project network in Taboshar City Shafof Ltd TAJIKISTAN Sokhtmon Ltd TAJIKISTAN Zarya Vostok SUE TAJIKISTAN 53501 PP3.2-Rehabilitation of water supply Juziy Zimiston Ltd. (W) TAJIKISTAN (W) 14 May 2013 Works Open 1,755,376 684,597 39.00% network in Gafurov City Firuz Ltd. TAJIKISTAN Madina Ltd. TAJIKISTAN Nigina Ltd. TAJIKISTAN Rohat Ltd. TAJIKISTAN Yahyo Company Ltd. TAJIKISTAN 41642 EBRD Special 56021 CTWRP-002 LOT 2 Office Doro Ltd (W) TAJIKISTAN (W) 29 May 2013 Goods Open 12,645 7,598 60.09% Fund - Central Equipment Electrogidromash LLC TAJIKISTAN Tajik Water 56221 CTWRP-004 Renovation of Kuktosh LLC Obi Dekhot (W) TAJIKISTAN (W) 30 Oct 2013 Works Open 134,434 83,146 61.85% Rehabilitation - water intake in Somoniyon CJSC Monalit 05 TAJIKISTAN SUE "Khojagii Consortium LLC Bodoma and TAJIKISTAN Manziliyu- LLC Zinat LLC Kalasoz TAJIKISTAN Kommunali" LLC Osari TAJIKISTAN LLC Oyandasoz TAJIKISTAN LLC Solekh 2012 TAJIKISTAN 41769 EBSF-2013-01-14 53143 KhSWMP-001 Specialised vehicles; Diana & Co LLC (W) TAJIKISTAN (W) 23 Jul 2013 Goods Open 1,060,061 530,031 50.00% Khujand Solid waste collection trucks and Bark Sokhtmon LLC TAJIKISTAN Waste machinery Doro Ltd TAJIKISTAN Management Grand Motors LLC AZERBAIJAN Unit Export.Ltd UNITED KINGDOM Xinjiang Sanbao Industry CHINA Group Co. Ltd Zeppelin International AG SWITZERLAND

Annex 1b TAJIKISTAN Municipal & Env Inf

41769 EBSF-2013-01-14 Khujand Solid Waste Management

55363 KhSWMP-004 Supply of containers, Sharifi Khuchandy Co. Ltd TAJIKISTAN (W) 20 Sep 2013 Goods Open 450,750 225,375 50.00% special uniform and working tools (W) Barz Co Ltd TAJIKISTAN CJS Company Nauselmash TAJIKISTAN Khujandprommash Co Ltd TAJIKISTAN KM Sadaf SHAN-Yuy Co Ltd TAJIKISTAN SP Khaydarov S.K TAJIKISTAN SUE Factory Zaria Vostoka TAJIKISTAN YS 3/5 Enterprise TAJIKISTAN Total TAJIKISTAN 7 4,259,724 2,065,878 48.50% Grand Total 19 19,940,249 16,405,892 82.28% Multi financed contracts will be counted as individual contracts both in this report and in: Listing of Signed Contracts by Country of Operations (€ Value) - Level of Bank Financing

Annex 1b AWARDS BY COUNTRY OF ORIGIN OF THE TENDERS (VALUE IN €) 2009-2013

Country Name 2009 2010 2011 2012 2013 Total ALBANIA 0 715,559 23,162,375 0 36,695,351 60,573,284 ARMENIA 4,559,679 0 2,302,000 1,164,980 18,527,691 26,554,350 AUSTRIA 93,849,301 108,196,047 52,337,038 67,375,433 26,496,640 348,254,459 AZERBAIJAN 0 0 30,168,240 0 1,978,873 32,147,113 BELARUS 0 12,747,955 0 0 0 12,747,955 BELGIUM 233,880 0 0 0 0 233,880 BOSNIA AND HERZEGOVINA 20,671,923 15,613,699 35,178,236 216,079,147 43,493,866 331,036,872 BULGARIA 0 0 6,111,269 2,986,278 29,546,780 38,644,327 CANADA 0 0 0 212,058 0 212,058 CHINA 7,802,259 39,742,408 0 27,330,701 24,686,055 99,561,423 CROATIA 28,617,463 16,726,841 93,873,467 80,481,010 32,574,762 252,273,542 CZECH REPUBLIC 13,650,000 11,587,090 0 61,674,947 23,607,006 110,519,043 DENMARK 700,000 0 0 0 0 700,000 FINLAND 0 0 9,619,641 0 1,364,277 10,983,918 FRANCE 30,200,000 7,870,031 43,534,172 17,179,271 6,013,449 104,796,923 FYR MACEDONIA 0 0 125,241 2,296,880 25,961,853 28,383,974 GEORGIA 2,460,484 226,612,839 93,050 2,823,176 2,439,150 234,428,699 GERMANY 20,278,035 118,854,333 12,264,268 22,794,135 155,491,307 329,682,077 GREECE 0 0 43,283,783 210,148,177 3,939,500 257,371,460 HUNGARY 0 0 359,788 0 0 359,788 INDIA 0 213,465,361 129,573,855 0 8,892,320 351,931,536 ISRAEL 2,457,519 3,537,113 0 6,935,959 0 12,930,591 ITALY 3,170,804 0 239,001,385 16,726,047 56,511,651 315,409,887 KAZAKHSTAN 66,683,688 50,065,329 157,308,947 85,868,370 0 359,926,334 KOREA 0 7,756,997 72,831,654 0 0 80,588,651 KOSOVO - - - - 5,190,962 5,190,962 KUWAIT 0 0 15,258,409 0 1,352,113 16,610,522 KYRGYZ REPUBLIC 0 0 637,835 3,881,165 1,884,211 6,403,211 LATVIA 0 0 0 9,733,157 0 9,733,157 LITHUANIA 0 0 1,133,775 2,590,945 0 3,724,720 LUXEMBOURG 0 0 2,035,918 0 0 2,035,918 MAURITIUS 0 0 0 216,317 0 216,317 MOLDOVA 0 0 0 10,527,985 8,666,718 19,194,703 MONTENEGRO 2,082,258 0 13,974,218 1,227,666 1,801,517 19,085,659 MOROCCO - - - - 121,667,796 121,667,796 NETHERLANDS 0 0 267,762 0 801,209 1,068,971 POLAND 9,846,286 32,841,238 2,028,558 0 108,850,710 153,566,793 ROMANIA 21,449,625 13,850,716 167,026,730 158,590,002 188,661,254 549,578,328 RUSSIAN FEDERATION 41,595,640 265,689,295 125,769,653 60,129,891 46,067,733 539,252,211 SERBIA 3,915,166 238,000 1,573,095 140,030 11,027,013 16,893,304 SLOVAK REPUBLIC 0 0 0 405,791 13,208,750 13,614,541 SLOVENIA 0 55,583,496 95,771,021 33,402,403 992,112 185,749,032 SPAIN 0 0 42,875,452 28,750,810 121,405,574 193,031,836 SWEDEN 0 0 8,966,002 0 0 8,966,002 SWITZERLAND 9,768 1,450,000 1,154,872 0 100,407,519 103,022,159 TAJIKISTAN 0 2,318,174 5,374,034 4,965,229 7,857,546 20,514,983 TURKEY 0 428,063,243 22,628,256 127,115,456 30,032,793 607,839,748 UKRAINE 405,472 25,102,959 183,888,741 7,088,800 1,307,956 217,793,928 UNITED KINGDOM 686,670 165,460 3,810,998 4,955,300 266,500 9,884,928 Total 375,325,920 1,658,794,182 1,645,303,736 1,275,797,517 1,269,670,517 6,224,891,871

ANNEX 2 AWARDS BY COUNTRY OF ORIGIN OF THE TENDERERS (NUMBER) 2009 - 2013 Country Name 2009 2010 2011 2012 2013 Total

ALBANIA 0 1 14 0 17 32 ARMENIA 1 0 4 3 12 20 AUSTRIA 8 9 6 9 4 36 AZERBAIJAN 0 0 1 0 6 7 BELARUS 0 1 0 0 0 1 BELGIUM 1 0 0 0 0 1 BOSNIA AND HERZEGOVINA 20 14 13 13 7 67 BULGARIA 0 0 1 2 3 6 CANADA 0 0 0 3 0 3 CHINA 2 2 0 1 4 9 CROATIA 6 5 7 11 9 38 CZECH REPUBLIC 1 1 0 2 2 6 DENMARK 1 0 0 0 0 1 FINLAND 0 0 2 0 1 3 FRANCE 1 4 5 5 6 21 FYR MACEDONIA 0 0 2 1 12 15 GEORGIA 2 7 2 2 1 14 GERMANY 6 11 9 9 7 42 GREECE 0 0 1 1 2 4 HUNGARY 0 0 1 0 0 1 INDIA 0 3 1 0 1 5 ISRAEL 1 1 0 1 0 3 ITALY 1 0 12 6 6 25 KAZAKHSTAN 1 5 13 9 0 28 KOREA 0 1 1 0 0 2 KOSOVO - - - - 2 2 KUWAIT 0 0 1 0 1 2 KYRGYZ REPUBLIC 0 0 2 7 5 14 LATVIA 0 0 0 3 0 3 LITHUANIA 0 0 1 1 0 2 LUXEMBOURG 0 0 1 0 0 1 MAURITIUS 0 0 0 1 0 1 MOLDOVA 0 0 0 22 8 30 MONTENEGRO 2 0 4 5 2 13 MOROCCO - - - - 21 21 NETHERLANDS 0 0 1 0 1 2 POLAND 1 2 2 0 5 10 ROMANIA 7 5 45 32 53 142 RUSSIAN FEDERATION 8 21 24 20 34 107 SERBIA 2 1 1 1 7 12 SLOVAK REPUBLIC 0 0 0 1 1 2 SLOVENIA 0 3 4 6 1 14 SPAIN 0 0 9 4 4 17 SWEDEN 0 0 2 0 0 2 SWITZERLAND 1 1 1 0 3 6 TAJIKISTAN 0 5 8 13 12 38 TURKEY 0 3 2 3 5 13 UKRAINE 1 4 11 4 2 22 UNITED KINGDOM 1 3 5 6 2 17 Total 75 113 219 207 269 883

ANNEX 3 ANNEX 3 Awards by Country of Origin of the Tenderers by Contract Type 2013

Tenderer Country Works Supply & Installation Goods Consultant Services Total (EUR) ALBANIA 36,695,351 36,695,351 ARMENIA 15,921,806 2,399,046 206,839 18,527,691 AUSTRIA 8,316,134 18,180,506 26,496,640 AZERBAIJAN 1,697,649 281,225 1,978,874 BOSNIA AND HERZEGOVINA 43,043,041 450,825 43,493,866 BULGARIA 29,546,780 29,546,780 CHINA 24,686,055 24,686,055 CROATIA 23,328,452 2,181,866 7,064,444 32,574,762 CZECH REPUBLIC 23,607,006 23,607,006 FINLAND 1,364,277 1,364,277 FRANCE 2,773,263 1,691,981 1,548,205 6,013,449 FYR MACEDONIA 25,961,853 25,961,853 GEORGIA 2,439,150 2,439,150 GERMANY 47,841,581 106,016,896 1,632,828 155,491,305 GREECE 3,939,500 3,939,500 INDIA 8,892,320 8,892,320 ITALY 51,480,166 3,083,680 1,947,805 56,511,651 KOSOVO 5,190,962 5,190,962 KUWAIT 1,352,113 1,352,113 KYRGYZ REPUBLIC 1,739,747 144,464 1,884,211 MOLDOVA 8,666,718 8,666,718 MONTENEGRO 840,454 961,063 1,801,517 MOROCCO 121,667,796 121,667,796 NETHERLANDS 801,209 801,209 POLAND 28,288,971 80,561,739 108,850,710 ROMANIA 180,054,628 4,532,307 4,029,472 44,846 188,661,253 RUSSIAN FEDERATION 18,433,546 19,394,770 8,239,418 46,067,734 SERBIA 1,823,806 9,203,207 11,027,013 SLOVAK REPUBLIC 13,208,750 13,208,750 SLOVENIA 992,112 992,112 SPAIN 64,533,398 55,480,675 1,391,500 121,405,573 SWITZERLAND 870,000 99,537,519 100,407,519 TAJIKISTAN 5,025,848 2,699,480 132,218 7,857,546 TURKEY 27,597,340 1,235,128 1,200,325 30,032,793 UKRAINE 1,307,956 1,307,956 UNITED KINGDOM 266,500 266,500 Total 725,648,126 249,854,484 285,821,404 8,346,501 1,269,670,515 Annex 4 Awards by Country of Origin of the Tenderers by Procurement Method 2013

Tenderer Country Open Direct Selection Competitive Selection Alternative* Total (EUR) from a shortlist ALBANIA 36,695,351 36,695,351 ARMENIA 18,527,691 18,527,691 AUSTRIA 19,464,996 7,031,644 26,496,640 AZERBAIJAN 1,978,873 1,978,873 BOSNIA AND HERZEGOVINA 43,043,041 49,000 401,825 43,493,866 BULGARIA 24,763,979 4,782,801 29,546,780 CHINA 24,686,055 24,686,055 CROATIA 8,656,310 23,918,452 32,574,762 CZECH REPUBLIC 9,295,560 14,311,446 23,607,006 FINLAND 1,364,277 1,364,277 FRANCE 4,465,244 1,548,205 6,013,449 FYR MACEDONIA 25,961,853 25,961,853 GEORGIA 2,439,150 2,439,150 GERMANY 155,237,305 254,000 155,491,305 GREECE 3,939,500 3,939,500 INDIA 8,892,320 8,892,320 ITALY 46,274,340 1,947,805 8,289,506 56,511,651 KOSOVO 5,190,962 5,190,962 KUWAIT 1,352,113 1,352,113 KYRGYZ REPUBLIC 1,884,211 1,884,211 MOLDOVA 8,666,718 8,666,718 MONTENEGRO 1,801,517 1,801,517 MOROCCO 121,667,796 121,667,796 NETHERLANDS 801,209 801,209 POLAND 92,166,470 16,684,241 108,850,711 ROMANIA 8,708,436 4,269,996 175,682,822 188,661,254 RUSSIAN FEDERATION 43,392,628 2,675,105 46,067,733 SERBIA 11,027,013 11,027,013 SLOVAK REPUBLIC 13,208,750 13,208,750 SLOVENIA 992,112 992,112 SPAIN 106,014,608 15,390,965 121,405,573 SWITZERLAND 100,407,519 100,407,519 TAJIKISTAN 7,725,328 132,218 7,857,546 TURKEY 28,832,468 1,200,325 30,032,793 UKRAINE 1,307,956 1,307,956 UNITED KINGDOM 16,500 250,000 266,500 Total 989,469,382 14,296,245 6,594,655 250,000 259,060,233 1,269,670,515

* This method is used for contracts awarded not in Annex 5 accordance with the Bank’s PP&Rs Contracts Awarded by Country of Origin of the Tenderers 2013

Country of Winning Tenderer: ALBANIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ALBANIA Transport Alb-Building sh.p.k Rec 94 Reconstruction of road Vaqarr-Gropaj- 11 Jan 2013 Works Open 56681 1,514,808 Kthesa e Kashurit Rec137- Reconstruction of road connecting Farka 05 Jul 2013 Works Open 57284 1,342,429 with Elbasani Road Alba Konstruksion Rec136- Reconstruction of road Berxull-Laknas 28 Jun 2013 Works Open 57282 997,002

Rec130- Reconstruction of road Gose e Madhe- 28 Jun 2013 Works Open 57308 666,825 Gose e Vogel ALBAVIA sh.p.k Rec106- Reconstruction of road Ura Vajgurore- 04 Apr 2013 Works Open 56761 3,062,335 Pashalli-Bistrovice CO.Be.IN sh.p.k. Rec 99- Reconstruction of road Novosele-Poro-Pish 12 Mar 2013 Works Open 56746 3,012,867 Poro, Vlora Region CURRI sh.p.k. Rec113- Reconstruction of main entrance road and 11 Jan 2013 Works Open 56702 634,985 construction of a pedestrian path along seaside on Velipoja beach Rec 52- Reconstruction of road Libonik-Rrembee- 07 Jun 2013 Works Open 57262 2,118,380 Plase GENER 2 sh.p.k. Rec 84- Reconstruction of road Boge-Qafe Thore, 26 Mar 2013 Works Open 56745 3,141,709 Shkodra Region Gjikuria sh.p.k. Rec138- Reconstruction of road Surrel-Quafe- 28 Jun 2013 Works Open 57261 2,593,572 Priske Gjoka Konstruksion sh.a. Rec129- Reconstruction of road Unaza e Re-Kashar 06 Jun 2013 Works Open 57302 1,122,921

JV "Denis 05" sh.p.k. & Rec128- Reconstruction of road Fermentim-Ura e 06 Jun 2013 Works Open 57087 403,364 "Arifaj" sh.p.k. Mesit-Drisht, Lot 1 JV GPG Company sh.p.k. Rec 87: Reconstruction of road Lushnje - 21 Jan 2013 Works Open 55861 4,428,203 & Filipos S.A. Hysgjokaj (regional) JV Trikat s.a. & PE-VLA- Rec 87-1- Reconstruction of road Hysgjokaj- 19 Jun 2013 Works Open 57307 3,258,151 KU sh.p.k. Kryqezimi Pras-Vashaj S.M.O. Union sh.p.k. Rec103- Reconstruction of road Qerret-Karpen, Lot 10 Jun 2013 Works Open 57301 1,134,601 1 Salillari sh.p.k. Rec 95- Reconstruction of road Balez-Letan 17 Jun 2013 Works Open 57281 1,263,197 VEGA SHPK Fier Tepelene Road Section 2 - remaining works 05 Sep 2013 Works Open 57501 6,000,000 from km 26.05 to km 30.15 performed by VEGA sh.p.k. Total ALBANIA 17 36,695,351 Country of Winning Tenderer: ARMENIA

Annex 6 Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ARMENIA Municipal & Env Inf Ararat-Chanshin LLC ASMWP-1 Rehabilitation of the water supply 29 Apr 2013 Works Open 54442 1,326,800 network in Byureghavan and Abovyan Arpa-Sevan OJSC ASMWP-6 Rehabilitation of the water supply 04 Oct 2013 Works Open 56684 939,624 network in Martuni town Baghramyanshin OJSC ASMWP-12 Rehabilitation of water supply network 24 Oct 2013 Works Open 57003 2,753,559 in Ijevan town and Azatamut community

Blesk LLC and Artezia LLC ASMWP-10 Rehabilitation of the water supply 14 Oct 2013 Works Open 56685 1,324,695 network in Artik Consortium ARPA-SEVAN- ASMWP-13 Design and Construction of Waste 08 Aug 2013 Supply & Installation Open 52664 2,399,046 KUNST Water Treatment Plant in Dilijan and Jermuk Four Directions LLC, ASMWP-9 Rehabilitation of water supply network 13 Nov 2013 Works Open 57002 2,526,760 Ashotsq LLC in Kapan town Parex-Gaz LLC ASMWP-7 Rehabilitation of the Water Supply 29 Oct 2013 Works Open 56822 686,373 Network in Chambarak ShmSh-23 OJSC ASMWP-2 Rehabilitation of the Water Supply 26 Apr 2013 Works Open 54661 1,079,916 Network in Sevan town ASMWP-3 Rehabilitation of the Water Supply 03 Sep 2013 Works Open 55941 2,289,808 Network and Waste Water Network in Dilijan ASMWP-11 Rehabilitation of the Waste Water 04 Dec 2013 Works Open 58401 1,194,626 Network in Jermuk town Spitak-1 OJSC ASMWP-8 Rehabilitation of water supply network 13 Nov 2013 Works Open 57001 1,799,645 in Spitak, Jrashen and Akhtala GEORGIA Municipal & Env Inf Galoper Ltd Supply of a Compactor for operation and 04 Feb 2013 Goods Open 50324 206,839 maintenance of landfill Total ARMENIA 12 18,527,691 Country of Winning Tenderer: AUSTRIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) BOSNIA AND HERZEGOVINAMunicipal & Env Inf Va Tech Wabag GmbH & Design and Construction of Municipal Wastewater 16 Sep 2013 Works Direct Selection 46884 7,031,644 HIGRA d.o.o. Treatment Plant - EU IPA, SIDA FYR MACEDONIA Power and Energy Siemens AG Osterreich Supply and Installation of a new SCADA/EMS 14 Oct 2013 Supply & Installation Open 58021 3,800,000 System for the National Dispatch Centre, Back-up Dispatch Centre and Market Management System

Transport STRABAG AG Veles-Kadrifakovo Phase 1 - Interchange Veles- 02 Sep 2013 Works Open 57602 1,284,490 end of third line (Veles landfill), Lozovo, Saramzalino SERBIA Power and Energy Sandvik Mining and A 3 Spreader 26 Apr 2013 Supply & Installation Open 55544 14,380,506 Construction Materials Handling GmbH & Co KG

Total AUSTRIA 4 26,496,640 Country of Winning Tenderer: AZERBAIJAN

Annex 6 Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) GEORGIA Municipal & Env Inf Azertunel LLC Construction of Kobuleti waste water treatment 23 Jul 2013 Works Open 53283 1,697,649 plant (WWTP)-Civil Works KYRGYZ REPUBLIC Municipal & Env Inf Grand Motors LLC BPTD03 Supply of maintenance machinery Lot 1- 31 Oct 2013 Goods Open 57861 102,821 Item 1.1 Mobile hydraulic crane MOLDOVA Municipal & Env Inf Grand Motors LLC LOT 1, 2, 3+7 Supply of Maintenance Equipment 14 May 2013 Goods Open 50702 77,610 and Specialised Vehicles for Six Regional Water Companies in Moldova - Soroca

LOT 1 Supply of Maintenance Equipment and 14 May 2013 Goods Open 57082 4,445 Specialised Vehicles for Six Regional Water Companies in Moldova - Hincesti LOT 1, 2+3 Supply of Maintenance Equipment and 14 May 2013 Goods Open 57085 87,825 Specialised Vehicles for Six Regional Water Companies in Moldova - Orhei LOT 1+2 Supply of Maintenance Equipment and 14 May 2013 Goods Open 57086 8,525 Specialised Vehicles for Six Regional Water Companies in Moldova -Leova Total AZERBAIJAN 6 1,978,873 Country of Winning Tenderer: BOSNIA AND HERZEGOVINA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) BOSNIA AND HERZEGOVINAMunicipal & Env Inf Buk Promet Doo Bijeljina Construction of Main Secondary Sewer Collector 21 Feb 2013 Works Open 51941 3,278,665 No. 3 - Majevicka Street Consortium DIVEL d.o.o., Project Management Supervision Engineer 01 Jul 2013 Consultant Services Competitive 51482 401,825 Integra d.o.o. and ZIL inzenering d.d. HIDRO-SIMP d.o.o. of Consulting Services - Support to PIU 07 May 2013 Consultant Services Direct Selection 55601 49,000 ATC Bijelina HP Investing New Construction and Upgrading of the South 03 Jun 2013 Works Open 52041 2,273,042 Longitudinal Road Section 1 JV Euro-asfalt d.o.o New construction and Upgrading of the 12th 30 May 2013 Works Open 51902 10,862,757 Sarajevo, GP ZGP d.d. Transversal Road Section Sarajevo and Hidrogradnja d.d. Saraje

Transport JV "Euro-Asfalt d.o.o. and Construction of Motorway on Corridor Vc: Section 07 May 2013 Works Open 56262 24,403,100 GP ZGP d.d." Drivusa-Kakanj, Subsection Gorica-Biljesevo (Phase II) JV "Jata Group & LOT 1: Rehabilitation of Road M-18 LJUBACE - 25 Feb 2013 Works Open 55225 2,225,477 Euroasfalt BA" ZIVINICE KM 6+765 - KM 8+095 AND M-18 AND DURDEVIK - VITALJ KM 19+582 - KM 41+708

Total BOSNIA AND HERZEGOVINA 7 43,493,866 Country of Winning Tenderer: BULGARIA

Annex 6 Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) BULGARIA Municipal & Env Inf DZZD DEPO-BURGAS P6 C11a, C11b, C12c & P9 C16 Engineering, 21 Jun 2013 Works Alternative 58582 4,782,801 design & construction for bus depot, diesel and methan fuel-filling station FYR MACEDONIA Transport CK-13 HOLD-ING JSC Section 2 - Nogaevci to Negotino 17 Jul 2013 Works Open 58421 9,399,755 SERBIA Transport Trace Group Hold Construction of Highway E 80 Section: Parallel - 23 Dec 2013 Works Open 58721 15,364,224 non-commercial road, Bela Palanka - Pirot (West)

Total BULGARIA 3 29,546,780 Country of Winning Tenderer: CHINA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) KAZAKHSTAN Municipal & Env Inf Zhengzhou Yutong Bus Supply of 200 CNG buses 26 Sep 2013 Goods Open 54902 24,359,547 Co. Ltd MOLDOVA Municipal & Env Inf Ningbo Water Meter Co. Supply of water meters for four regional water 21 Jun 2013 Goods Open 53142 73,008 Ltd. companies in Moldova GO-WatMet-01 - Leova

Supply of water meters for four regional water 28 Jun 2013 Goods Open 58041 126,750 companies in Moldova GO-WatMet-01 - Orhei

Supply of water meters for four regional water 21 Jun 2013 Goods Open 58042 126,750 companies in Moldova GO-WatMet-01 - Soroca

Total CHINA 4 24,686,055 Country of Winning Tenderer: CROATIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) CROATIA Municipal & Env Inf Agra Trgovina d.o.o. Waste water equipment - Lot 2 customised van 10 May 2013 Goods Alternative 54762 125,000 with CCTV sewer inspection camera equipment and connected IT equipment Braco Kop d.o.o. Construction of two river crossings underneath the 27 Nov 2013 Works Alternative 56483 498,685 Kupa river Gradatin d.o.o. Waste water equipment - Lot 1 Sewerage suction 21 May 2013 Goods Alternative 55341 465,000 flushing tankers Koncar-Inzenjering za 2B SCADA procurement and installation of 25 Mar 2013 Supply & Installation Open 52162 296,951 Energetiku I Transport following measuring equipment d.d. (KET) Koncar-Inzenjering Za WW1-3A-4 Construction of wastewater collection 30 Aug 2013 Works Alternative 54901 12,654,767 Energetiku I Transport system - Galdovo complex and Odranska & Zeleni d.d., Durkin d.o.o., Astra collectors Int. inz Tehnika d.d WW2 Waste water treatment works Cret 24 May 2013 Works Alternative 54761 10,175,000 secondary level of treatment

Annex 6 FYR MACEDONIA Power and Energy Koncar - Power Plant and Supply and Installation of Substation Automation 28 May 2013 Supply & Installation Open 56222 1,884,915 Electric Traction Eng. inc. Control System, Protection and DC supply for 9 substations SERBIA Transport DIV d.o.o. Track Renewal Materials Lot 3 - procurement of 07 Aug 2013 Goods Open 57542 4,934,064 concrete sleepers with elastic rail fastenings

Track Renewal Materials Lot 5 - procurement of 07 Aug 2013 Goods Open 57561 1,540,380 rail fastenings type K for wooden sleepers and rails type 49E1 Total CROATIA 9 32,574,762 Country of Winning Tenderer: CZECH REPUBLIC Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) BULGARIA Municipal & Env Inf Skoda Electric a.s. Trolleybuses renewal 13 Sep 2013 Goods Alternative 58684 14,311,446 SERBIA Transport MORAVIA STEEL A.S. Track Renewal Materials Lot 1 - procurement of 29 Apr 2013 Goods Open 56741 9,295,560 rails of 49E1 & 60E1 type, grade R260 Total CZECH REPUBLIC 2 23,607,006 Country of Winning Tenderer: FINLAND Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) AZERBAIJAN Transport Destia-Finnroad Limited Review and Update of the Detailed Design and 15 Feb 2013 Consultant Services Competitive 55263 1,364,277 Assitance with the Prequalification and Tendering Process for the Rehabilitation of the Mingachevir - Bahramtapa Road (R18) Total FINLAND 1 1,364,277 Country of Winning Tenderer: FRANCE Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ARMENIA Municipal & Env Inf SADE CGTH and ASMWP-5 Rehabilitation of the Water Supply 15 Oct 2013 Works Open 56802 1,384,231 ARTASHES EV TATEVIK Network in Gavar and Saroukhan towns LLC SADE CGTH SA ASMWP-4 Rehabilitation of the Water Supply 18 Sep 2013 Works Open 56081 1,389,032 Network in Tashir town, ASMWP-WORKS-2013-04

CROATIA Municipal & Env Inf Safege Consulting Project implementation support and construction 31 Dec 2013 Consultant Services Competitive 54481 328,505 Engineers, Safege d.d.o., supervision Rescon d.d.o. SERBIA Transport Geismar Track Maintenance Equipment Lot 4 - sleeper 22 May 2013 Goods Open 56743 681,902 removal/insertion machine Track Maintenance Equipment Lot 2 - rail-road 22 May 2013 Goods Open 56744 1,010,079 vehicle for track mainenance TAJIKISTAN Transport LOUIS BERGER Procurement & Implementation Assistance 27 Sep 2013 Consultant Services Direct Selection 59121 64,000 (Technical Assistance - Grant funded) UKRAINE Transport Egis International OPRC - supervision of works and services 21 Nov 2013 Consultant Services Competitive 58661 1,219,700 Total FRANCE 7 6,077,449

Annex 6 Country of Winning Tenderer: FYR MACEDONIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) FYR MACEDONIA Transport GD BETON AD Municipal Roads Phase III - Lot 3 - Northeast and 15 Apr 2013 Works Open 57167 1,854,934 East Region Regional Roads Phase III - Lot 2 - R2433 Radovis- 29 May 2013 Works Open 57182 2,633,427 Konce-Lubnica GD Granit A.D. Municipal Roads Phase III - Lot 1 - Skopje and 15 Apr 2013 Works Open 57163 1,811,701 Polog Region Municipal Roads Phase III - Lot 4 -Vardar and 15 Apr 2013 Works Open 57168 1,181,100 Southeast Region Regional Roads Phase III - Lot 1 - R2432 Angelci- 22 May 2013 Works Open 57181 577,322 Veljusa-Vodoca-Banica Regional Roads Phase III - Lot 3 - R1107 22 May 2013 Works Open 57183 2,342,003 Kavadarci-Musov grob Municipal Roads Phase IV - Lot 3 - Northeast and 09 Oct 2013 Works Open 58521 2,443,846 East Region Municipal Roads Phase IV - Lot 4 - Vardar and 09 Oct 2013 Works Open 58522 2,053,587 Southeast Region JV "Ilinden" AD - Struga Municipal Roads Phase IV - Lot 1 - Skopje and 20 Sep 2013 Works Open 57901 2,221,401 & Progres 1998 dooel Polog Region Gostivar Municipal Roads Phase IV - Lot 2 - Southwest and 20 Sep 2013 Works Open 57903 1,985,547 Pelagonija Region TDGP ILINDEN AD Municipal Roads Phase III - Lot 2 - Southwest and 15 Apr 2013 Works Open 57166 2,966,010 Pelagonija Region Regional Roads Phase III - Lot 4 - R1201 Struga- 22 May 2013 Works Open 57184 3,890,975 Debar Total FYR MACEDONIA 12 25,961,853 Country of Winning Tenderer: GEORGIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ARMENIA Municipal & Env Inf JSC Electric Rolling Stock PP 8 - Refurbishment and modernisation of 8 units 29 May 2013 Goods Open 54443 2,439,150 Repair Plant Tbilisi of metro cars Type 81-717 Branch (ZREPS) Total GEORGIA 1 2,439,150

Annex 6 Country of Winning Tenderer: GERMANY Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) CROATIA Transport JV Strabag AG - Pomgrad Infrastructure Rehabilitation Project in the Port of 14 Mar 2013 Works Open 55481 8,087,964 Inzenjering d.o.o. Sibenik

FYR MACEDONIA Transport H. F. Wiebe GmbH&Co. Rehabilitation of Section KUMANOVO - 20 Dec 2013 Works Open 58621 39,753,619 KG BELJAKOVCE KAZAKHSTAN Power and Energy Andritz Hydro GmbH Modernisation Project of Shardarinskaya HPP LOT - 18 Dec 2013 Supply & Installation Open 58902 75,107,911 Replacement / Refurbishment of Generators, Turbines & Mechanical Auxiliaries, Control, Protection & Electrical Auxiliaries SERBIA Power and Energy Thyssen Krupp AG A1 Bucket Wheel Excavator 28 Mar 2013 Supply & Installation Open 55441 30,908,985 Transport Kraiburg Elastik GmbH Track Renewal Materials Lot 9 - procurement of 17 Jun 2013 Goods Open 57426 387,634 road structures made of rubber elements ROBEL Track Maintenance Equipment Lot 5 - procurement 07 Aug 2013 Goods Open 57781 991,193 Bahnbaumaschinen of light track maintenance machinery GmbH UKRAINE Municipal & Env Inf Erfurter Verkehrsbetriebe Used refursbished tram car rolling stock and spare 13 May 2013 Goods Direct Selection 55922 254,000 AG parts Total GERMANY 7 155,491,307 Country of Winning Tenderer: GREECE Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ALBANIA Transport Filipos s.a. Rec127- Reconstruction of road Kallmet I Vogel- 12 Jun 2013 Works Open 57303 1,436,858 Ungrej, Lot 1 TRIKAT s.a. Rec107- Reconstruction of road Lac-Milot in Lezha 03 Jan 2013 Works Open 56762 2,502,642 Region Total GREECE 2 3,939,500 Country of Winning Tenderer: INDIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) KAZAKHSTAN Power and Energy KEC INTERNATIONAL Rehabilitation of 220kV OHTL Ossakarovka 19 Mar 2013 Supply & Installation Open 55541 8,892,320 LIMITED Total INDIA 1 8,892,320 Country of Winning Tenderer: ITALY Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ALBANIA Transport Serenissima Costruzioni Rec126- Reconstruction of road Kthesa e Patosit- 13 Jun 2013 Works Open 57305 3,324,647 s.p.a. Roskovee Fieri Bypass 18 Mar 2013 Works Open 58581 39,866,013 BOSNIA AND HERZEGOVINAPower and Energy Studio Ing. G Pietrangeli Project Implementation Unit Consultancy Services 15 Nov 2013 Consultant Services Competitive 58182 1,947,805 S.R.L.

Annex 6 ROMANIA Municipal & Env Inf EMIT Ercole Marelli CL2 Craiova WTP - Isainita WTP 04 Mar 2013 Works Alternative 57982 8,289,506 Impianti Tecnologici S.p.a., SC Mitliv Exim SRL

SERBIA Transport Bertolotti S.p.A Jackscrews with bearing capacity of 8x20t with 21 Nov 2013 Goods Open 58562 95,680 two control desks VAIA CAR SpA Track Maintenance Equipment Lot 3 - procuremetn 07 Aug 2013 Goods Open 57521 2,988,000 of rail loader excavator Total ITALY 6 56,511,651 Country of Winning Tenderer: KOSOVO Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ALBANIA Transport Victoria Invest Rec116- Reconstruction of road Mollas-Selite- 29 May 2013 Works Open 57304 2,132,628 International sh.p.k. Frasher Rec125- Reconstruction of road Gostime-Gjyrale- 10 Jun 2013 Works Open 57306 3,058,334 Belsh Total KOSOVO 2 5,190,962 Country of Winning Tenderer: KUWAIT Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ALBANIA Transport "Copri Construction Rec 50- Reconstruction of road Kthesa e Qarrit- 04 Jul 2013 Works Open 57263 1,352,113 Enterprises" W.L.L. Bishan-Poro-Pish Poro-Bregdet Total KUWAIT 1 1,352,113 Country of Winning Tenderer: KYRGYZ REPUBLIC Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) KYRGYZ REPUBLIC Municipal & Env Inf Asiaautocenter Ltd BPTD03 Supply of maintenance machinery Lot 1- 05 Nov 2013 Goods Open 55556 144,464 Item 1.2 Tractor-excavator and 1.3 Recovery truck

Gradient Ltd WS-1 Lot 4 Reconstruction of water mains of the 13 Feb 2013 Works Open 52382 471,801 well field Severnyi kainar CJSC Kyrgyzstan WS-1 Lot 5 Construction of pipeline along T.Moldo 12 Jun 2013 Works Open 53581 478,860 Str. from BChK to Saadaeva Str. and along Saadaeva Str. to Orozbekova street WS-1 Lot 6 Construction of Pipeline D-325 along 12 Jun 2013 Works Open 54342 430,909 Jibek-Jolu Street from Ibraimova Street to Osmonkula Street 1158 meters Kyrgyzenergostroi OJSC WS-1 Lot 3 Reconstruction of pipeline along 11 Apr 2013 Works Open 51921 358,177 Manasa str. from BChK to Saadayeva Street Total KYRGYZ REPUBLIC 5 1,884,211

Annex 6 Country of Winning Tenderer: MOLDOVA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) MOLDOVA Municipal & Env Inf Consortium Lucet- Extension of wastewater system in Ceadir-Lunga 16 May 2013 Works Open 54341 1,580,006 Izodromgaz CL-WWS-04 Fedion-Com SRL Rehabilitation of potable water network in Soroca 21 Jun 2013 Works Open 54321 830,666

JV Izodromgaz Lucet- Extension of wastewater system in Leova - LE- 20 May 2013 Works Open 54322 646,707 Comert WWS-01 JV Lucet-Izodrom Extension of potable water and wastewater in 25 Sep 2013 Works Open 54324 318,456 Orhei Phase 2 - LOT 1 - OR-WWS-03 JV Polimer Gaz Conducte Extension of water supply system in Floresti for of 02 Jul 2013 Works Open 55421 2,002,508 Ltd. & Polimer Gaz Izvoara, Varvareiuca for lot 1, Ghindesti Constructii Ltd Domulgeni lot 2, Ghindesti, Cenusa lot 3 - FL-WSS- 03 Rehabilitation of Ground Water Source for Floresti 04 Sep 2013 Works Open 55422 909,150 FL-WSS-01 Extension of potable water and wastewater in 15 Oct 2013 Works Open 57161 1,542,260 Orhei Phase 2 - LOT 2 - OR-WWS-03 PROMTEHGAZ SA Water source Firladeni HI-WSS-03 03 Sep 2013 Works Open 56002 836,964 Total MOLDOVA 8 8,666,718 Country of Winning Tenderer: MONTENEGRO Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) MONTENEGRO Municipal & Env Inf J.V. CMC Controlmatic Water supply component - Rehabilitation and 11 Sep 2013 Works Open 54642 840,454 Commerce d.o.o. Herceg extension of water supply network Novi & CMC Ekocon d.o.o. Logatec Power and Energy Mezon d.o.o. Supply of Ancillary Equipment for Smart Meters 29 Mar 2013 Goods Open 55362 961,063 Installation Total MONTENEGRO 2 1,801,517 Country of Winning Tenderer: MOROCCO Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) MOROCCO Power and Energy Atlas Energy Rural Electrification Works (53 villages) 14 May 2013 Works Open 55546 4,389,138 Rural Electrification works (74 villages) 03 Jun 2013 Works Open 56322 6,297,352 Rural Electrification Works (106 villages) 06 Jun 2013 Works Open 56323 2,486,013 CEGELEC Rural Electrification Works (45 villages) 03 Jun 2013 Works Open 56301 39,632,311 ELCOTRAM Rural Electrification Works (54 Villages) 06 Jun 2013 Works Open 56361 3,299,113 Electricite Bellet Rural Electrification Works (48 villages) 19 Mar 2013 Works Open 55554 2,670,177 ELECTRIMED Rural Electrification Works (68 Villages) 21 May 2013 Works Open 56281 23,657,046 Rural Electrification Works (26 Villages) 21 May 2013 Works Open 56343 2,473,425 ELECTRO TAFOGHALT Rural Electrification Works (29 villages) 06 Jun 2013 Works Open 56324 1,507,016

Annex 6 MOROCCO Power and Energy

ELECTRO TAFOGHALT Rural Electrification Works (55 Villages) 06 Jun 2013 Works Open 56342 3,513,594 EMTEYCO Maroc Rural Electrification Works (82 villages) 09 Apr 2013 Works Open 55555 7,002,567 Rural Elefctrification Words (41 Villages) 16 May 2013 Works Open 56321 3,870,221 OURELEC Rural Electrification Works (79 vilages) 30 Apr 2013 Works Open 55558 3,827,140 Rural Electrification Works (131 Villages) 30 Apr 2013 Works Open 55823 3,918,749 PACIFEL Rural Electrification Works (50 villages) 02 Apr 2013 Works Open 55559 1,797,281 Somaprec Rural electrification Works (57 vilages) 02 Apr 2013 Works Open 55557 2,761,127 Rural Electrification Works (20 villages) 07 Jun 2013 Works Open 56302 688,419 Rural Electrification Works (46 villages) 06 Jun 2013 Works Open 56325 2,186,471 Rural Electrification Works (73 villages) 06 Jun 2013 Works Open 56326 2,038,986 TEGAEL MAROC Rural electrification Works (55 villages) 14 May 2013 Works Open 55560 3,064,657 Rural Electrification Works (68 Villages) 27 May 2013 Works Open 56261 586,994 Total MOROCCO 21 121,667,796 Country of Winning Tenderer: NETHERLANDS Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) CROATIA Transport Telvent Netherlands BV Supply & Installation of AWOS for Airports of Pula 09 Oct 2013 Supply & Installation Open 58123 801,209 and Split Total NETHERLANDS 1 801,209 Country of Winning Tenderer: POLAND Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) BULGARIA Municipal & Env Inf Solaris Bus and Coach SA Rolling Stock - Diesel articulated buses 22 Oct 2013 Goods Alternative 58963 7,980,114 Rolling Stock - Low-floor city diesel buses 22 Oct 2013 Goods Alternative 58981 4,140,058 Rolling Stock - New low-floor city CNG buses 22 Oct 2013 Goods Alternative 58983 4,564,069 SERBIA Municipal & Env Inf Solaris Bus and Coach SA New low-floor articulated buses x 200 08 Mar 2013 Goods Open 52662 63,877,499

Power and Energy Kopex Joint Stock A 2 Belt Conveyor System 28 Mar 2013 Supply & Installation Open 55542 28,288,971 Company Total POLAND 5 108,850,710 Country of Winning Tenderer: ROMANIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) MOLDOVA Municipal & Env Inf JVCA SC Multigama Tech Supply of pumps and chlorination equipment for 30 May 2013 Goods Open 54323 37,052 SRL Leova and Floresti LEFL-PWP-01 Lot 1 Floresti

Supply of pumps and chlorination equipment for 04 Jun 2013 Goods Open 58061 121,477 Leova and Floresti LEFL-PWP-01 Lot 1 Leova

JVCA SC Tehno World Supply of Maintenance Equipment - Ceadir Lunga 15 Oct 2013 Goods Open 54302 6,369 SRL and Techno Test SRL GO-ME-2

Annex 6 MOLDOVA Municipal & Env Inf

JVCA SC Tehno World SRL and Techno Test SRL Supply of Maintenance Equipment - Soroca GO-ME- 15 Oct 2013 Goods Open 54303 15,160 2 Supply of Maintenance Equipment - Leova GO-ME- 23 Sep 2013 Goods Open 54304 23,718 2 Supply of Maintenance Equipment - Orhei GO-ME- 16 Oct 2013 Goods Open 54305 4,279 2 Supply of Maintenance Equipment - Floresti GO-ME- 23 Sep 2013 Goods Open 54306 68,985 2 Supply of Maintenance Equipment - Hincesti GO- 23 Sep 2013 Goods Open 54307 4,279 ME-2 SC Carpat BELAZ Service BTP01 Supply of trolleybuses 18 Dec 2013 Goods Open 56602 3,666,196 SRL and OJSC Holding Management Company Belkommunmash

SC Geprocon SA Extension and rehabilitation of water supply 17 Jul 2013 Works Open 53141 976,874 system in Orhei ROMANIA Municipal & Env Inf Constructim SA and CL16 Extension and modernisation of water and 22 Mar 2013 Works Alternative 57722 2,166,936 Multinstal SRL sewerage networks in Buzias FIN CONSTRUCT SRL, CL11 Water Sources extension of water networks 12 Sep 2013 Works Alternative 58881 7,896,755 OPRA CONSTRUZIONI and new wastewater network in Dalubeni Calarasi SRL and Bechet Hidroconstructia S.A. MS-VN-RB-06- Valea Nirajului - new main trunk 04 Jun 2013 Works Alternative 56542 4,029,642 JV SC Terra Buiding SRL, Upgrade and Refurbishment of Streets along 12 Apr 2013 Works Open 54522 259,399 SC CONSAL SRL Public Transport Routes - Area Grigore Ureche - Anatole France Sreets -from Savings S.C. CORAL SRL TULCEA, CL3 Calafat - WTP and WWTP and Trunk Main 07 May 2013 Works Alternative 57983 9,060,822 S.C. ENERGOMONTAJ SA from Calafat to Poiana mare

S.C. Daroconstruct SRL CL4 - Upgrading of Timisesti catchment fields 02 Apr 2013 Works Alternative 56461 2,083,621 Verseni and Zvoranesti S.C. Fluid Serv S.A. Rehabilitation of the water network in Predeal City - 29 Oct 2013 Works Open 57341 114,641 (from 15374 MELF Constanta Loan Savings)

S.C. Iasicon S.A. CL12 - Upgrading of sewers in Harlau 10 May 2013 Works Alternative 56464 1,801,413 CL13 - Upgrading of water and sewerage systems 03 Jun 2013 Works Alternative 56604 3,344,230 in Podu Ilioaiei S.C. TMUCB SA CL11 - Upgrading of water and sewerage systems 26 Apr 2013 Works Alternative 56463 4,218,194 in Tg Frumos SC 3T Construct SRL, SM-CL-05 WWTP construction in Tasnad and 17 May 2013 Works Alternative 58787 4,409,971 Stulz Planaqua GmbH Ardud cities SC A.C.I. BISTRITA SA CL3 - Water mains Apa Secaselor Water main Sibiu- 27 Sep 2013 Works Alternative 59162 8,351,163 Ocna Sibiului, Water main Ocna Sibiului-Miercurea Sibiului SC AEG Tehnology SRL MS-SG&CS-YB-04 Sighisoara and Cristuru Secuiesc 19 Jun 2013 Works Alternative 56541 5,814,189 - Rehabilitation of DWTPs

Annex 6 ROMANIA Municipal & Env Inf

SC Comtram SA Upgrade and Refurbishment of Streets - Vasile 31 Oct 2013 Works Open 57061 130,753 Parvan Street from Savings SC Constructii Erbasu CL13 The water source and the water and 05 Apr 2013 Works Alternative 57991 6,360,811 S.A., SC Polystart Impex sewerage networks in Segarcea SRL SC Constructii SA CL1 - Extension and rehabilitation of the water 17 Jul 2013 Works Alternative 59141 2,441,713 supply and swerege networks in Avrig and Marsa Localities SC de Constructii Napoca CL5 - Wastewater Treatment Plant for Ocna 29 Apr 2013 Works Alternative 59164 1,388,236 SA Sibiului locality SC Edas Exim SRL,SC MS-TA-YB-05 Tarnaveni - Rehabilitation of DWTP 28 Feb 2013 Works Alternative 54842 4,003,640 Tehnic Trust SA,SC Beespeed Automatizari SRL,SC Datcomp SRL SC EDAS EXIM, SC CL12 Transfer collector Segarcea and wastewater 15 Apr 2013 Works Alternative 57990 2,717,228 EUROPAN PROD SRL treatment plant SC EE Test SA CP1A-Leak detection 11 Nov 2013 Goods Alternative 59223 81,957 SC ELITE AUDIT S.R.L. CS4 Project Audit 28 Jun 2013 Consultant Services Alternative 58861 10,015 SC Elsaco Electronic SRL P3 Procurement of electrical pumps and control 19 Dec 2013 Supply & Installation Open 54881 3,279,252 systems for substations, spread over the 6 distribution sectors of Radet SC Gavella Com SRL, SC CL2 - Wastewater Treatment Plant for Avrig and 17 Jul 2013 Works Alternative 59161 3,499,633 Terra Med SRL Marsa localities and the mechano-electrical rehabilitation of the Avrig water catchment

SC GECOROM S.A., ISPE CL4 Craiova WWTP Landfill 13 Mar 2013 Works Alternative 57984 1,599,384 S.A SC Geiger Transilvania CL9 - Extension and rehabilitation of water 12 Jul 2013 Works Alternative 59167 4,753,199 SRL distribution and sewerage networks in Cisnadie and Rasinari localities SC Geiger Transilvania MS-RG-RB-05 Reghin extension of sewerage 12 Sep 2013 Works Alternative 58921 2,316,109 SRL, SC Lasprom SRL system, wastewater pumping stations and discharge pipes SC Grup Construct SRL CL14 Extension and modernisation of water and 08 Mar 2013 Works Alternative 57706 4,112,765 and Ludwig Pfeiffer Hoch- sewerage networks in Gataia and Ciacova und Tiefbau GmbH & Co KG SC GRUP PRIMACONS CL8 Rehabilitation & extension of W&WW 27 Mar 2013 Works Alternative 57988 5,245,117 S.R.L., VIALES Z OBRAS networks in Bailesti PUBLICAS S.A. SC Hidroconstructia SA CL5 - Upgrading of water and sewage systems in 12 Feb 2013 Works Alternative 55403 14,441,895 and SC General Concrete Pogoanele and Patarlagele Cernavoda SRL

Annex 6 ROMANIA Municipal & Env Inf

SC Hidroconstructia SA, CL10 - Rehabilitation of water catchment and 06 Nov 2013 Works Alternative 59168 2,828,914 SC General Concrete water mains for Fagaras municipality Cernavoda SRL, SC Benni Prest SRL

SC Interfrigo Logistrics SM-CL-04 Refurbishment and extension of WWTP 31 Oct 2013 Works Alternative 59202 3,434,221 SRL, ESC Edas Exim SRL in Negresti Oas City and construction of WWTP in Livada City SC KPMG Audit SRL SM-CS-03 Auditing services of the Project 20 Nov 2013 Consultant Services Alternative 59203 34,831 SC Mitliv Exim SRL, EMIT CL10 Transfer sewers + Regional WWTPs in Rastu 07 Jun 2013 Works Alternative 57989 14,230,279 Ercole Marelli Impianti Nou & Bechet Tecnologici S.p.A.

SC POLYSTART IMPEX CL7 New water and wastewater networks in 19 Apr 2013 Works Alternative 57987 7,289,050 SRL, SC TCIF SA Poiana Mare CRAIOVA, SC CONFORT SA SC RECON SI DOJE SRL CL11 - Extension and rehabilitation of water 14 Jun 2013 Works Alternative 59169 9,728,610 distribution and sewerage networks in Fagaras municipality SC Rotary Constructii SRL CL8-Works at water sources and WWTP of Gaesti 28 Feb 2013 Works Alternative 56842 8,488,753 & Comsa SA and Titu SC Secvision Business CP3-Procurement and installation of SCADA 19 Sep 2013 Supply & Installation Alternative 59224 1,253,055 Solutions SRL,SC Mikon equipment Systems SRL,SC Palex Constructii SR SC Universal Business SA CL4 - Extension and rehabilitation of water 22 Apr 2013 Works Alternative 59163 3,880,723 distribution and sewerage networks in Ocna Sibiului locality SC UTI GRUP S.A., SC CL6 Filiasi WWTP 03 Jan 2013 Works Alternative 57986 3,533,392 DANEX CONSULT S.R.L SC Veolia Water Solutions MS-L&I-YB-08 Ludus and Iernut - Rehabilitation of 25 Mar 2013 Works Alternative 55121 7,757,133 and Technologies WWTP Romania SRL

Tehnic Asist SRL, Kiat PMMR contract for Road Infrastructure in Ighisul 29 Mar 2013 Works Direct Selection 50961 4,269,996 Group Construct SRL, Nou Village, Medias Municipality, Sibiu County Proiect Bucuresti sRL Victor Construct SRL CL10 Extension and modernisation of water and 14 Mar 2013 Works Alternative 57721 2,913,051 sewerage networks in Sacalaz Videli SRL & Lucy Star CL9 Extension and modernization of the water and 28 Mar 2013 Works Alternative 57201 4,162,172 SRL sewerage networks in Sanmihaiu Roman and Utvin

Total ROMANIA 53 188,661,254 Country of Winning Tenderer: RUSSIAN FEDERATION

Annex 6 Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) ARMENIA Municipal & Env Inf STT Broker CJSC PP7 - Supply of New Track Components and 25 Apr 2013 Works Open 51641 1,448,891 Maintenance Tools for Maintenance of the Metro System KYRGYZ REPUBLIC Municipal & Env Inf Chelyabtransservice BPTD03 Supply of maintenance machinery Lot 2 27 Nov 2013 Goods Open 57862 189,433 Item 2.1 Elevating platforms Uralo-Sibirskaya PP1: Sewerage Maintenance Vehicles including 01 Jul 2013 Goods Open 50861 206,279 Promyshlennaya pipe cleaning vehicle, equipment for pipe cleaning Companiya compatible with pipe cleaning vehicle RUSSIAN FEDERATIONMunicipal & Env Inf Firma SENS CJSC Rehabilitation of Aeration and Sedimentation 06 Feb 2013 Works Open 51645 5,003,805 Tanks of WWTP Lipetsk-3 x Aeration Tanks and 8 existing secondary sedimentation tanks Construction of a air blower station 25 Nov 2013 Works Open 54041 2,342,834 Garantstroyservice Ltd. 1A - Completion of work components included in 09 Dec 2013 Works Direct Selection 58523 2,675,105 construction of groundwater intake LLC BR Trade LOT 4 - Supply of equipment for energy efficiency 25 Jan 2013 Goods Open 52732 423,796 boilers and related services - Burners

LLC Energostroy 7 Reconstruction of Molochnoye settlement heat 05 Dec 2013 Supply & Installation Open 50041 3,639,985 supply system - DH-6.1 + DH-6.3 LLC Spetsgazavtomatika A-2 Installation of 2 GHS, 45 IHS to provide heat 17 Jan 2013 Supply & Installation Open 52681 4,858,053 Russia supply after decommissioning of small coal fired boiler houses LLC Stroimontazh-2002 Pe-2c Laying of Heating Mains and Supplying 13 Jun 2013 Works Open 53682 1,585,177 Water to Boiler Plant of Srednekolymsk-Retender

LLC TD Techindustria Pe-1.2 Lot ST Procurement of special vehicles 21 Aug 2013 Goods Open 51483 114,710 trucks for Zhigansk LLC Termoizolstroy 5 Reconstruction and Construction of heat 04 Sep 2013 Works Open 55764 1,188,564 transmission pipelines DH8.2+DH8.4+DH9.4+DH9.6+DH9.7 Variant Plus LLC Heating Mains Reconstruction of Tiksi 28 Aug 2013 Works Open 56182 4,189,171 Vostoktechtorg CJSC LOT 1 - Supply of equipment for energy efficiency 10 Jun 2013 Goods Open 52733 340,446 boilers and related services - Pumps Power and Energy ENERGAS LLC Vladivostok Combined Heat and Power Plant, 25 Jun 2013 Supply & Installation Open 56821 8,092,161 Slovenia.Three Booster Compressor Stations and Gas Treatment OJSC "Power Machines" Procurement of Three Booster Exhaust Heat 26 Nov 2013 Goods Open 58462 6,964,753 Boilers Transport CJSC Optogan No.8. Set of LED light fixtures for illumination 07 Nov 2013 Supply & Installation Open 58501 161,599 facility of the site: Far East Infrastructure Directorate, Khabarovs -1 station CJSC Svetlana-OE No.10. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58365 342,873 facility of the site: Oktyabrsk Infrastructure Directorate, Belomorsk station

Annex 6 RUSSIAN FEDERATION

Transport

CJSC Transenercom No.12. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58367 66,563 facility of the site: North Caucasus Infrastructure Directorate, Novorossiysk station

JSC "SpetsProm" Lot 1: Supply of LED Lighting Equipment and 04 Jun 2013 Supply & Installation Open 56467 217,911 Installation Supervision Services Lot 5: Supply of LED Lighting Equipment and 04 Jun 2013 Supply & Installation Open 56503 98,354 Installation Supervision Services JSC BL Trade No.2. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58342 145,407 facility of the site: Moscow Infrastructure Directorate, Bryansk-Lgovcky station No.3. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58343 97,063 facility of the site: West Siberian Infrastructure Directorate, Barabinsk station No.7. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58363 99,499 facility of the site: Trans-Baikal Infrastructure Directorate, Chita-1 station No.9. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58364 215,749 facility of the site: South Eastern Infrastructure Directorate, Stoilenskaya station railway yard "A" and railway yard "B" JSC Ecolight Lot 1 Intelligent energy-saving LED-based lighting 20 Dec 2013 Supply & Installation Open 58982 151,839 system for Anapa railway station JSC Prosoft Trading No.1. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58341 162,046 facility of the site: Sverdlovsk Infrastructure Directorate of Yekaterinburg-Sortirovochnyi hump yard No.4. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58344 141,046 facility of the site: Privolzhsky Infrastructure Directorate, Volzhsky station No.6. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58362 143,361 facility of the site: East Siberian Infrastructure Directorate, Ulan-Ude station OJSC "Miassky Lot 2: Supply of LED Lighting Equipment and 04 Jun 2013 Supply & Installation Open 56482 193,008 Mashinebuilding Plant" Installation Supervision Services No.5. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58361 105,884 facility of the site: South Urals Infrastructure Directorate, Metallurgicheskaya station No.11. Set of LED light fixtures for illumination 25 Oct 2013 Supply & Installation Open 58366 104,989 facility of the site: Kuibyshev Infrastructure Directorate, Ruzayevka station Optogan CJSC Lot 3: Supply of LED Lighting Equipment and 04 Jun 2013 Supply & Installation Open 56501 212,338 Installation Supervision Services Lot 4: Supply of LED Lighting Equipment and 04 Jun 2013 Supply & Installation Open 56502 145,042 Installation Supervision Services Total RUSSIAN FEDERATION 34 46,067,733

Annex 6 Country of Winning Tenderer: SERBIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) SERBIA Power and Energy Monprojekt d.o.o. A 4 Power Supply 26 Apr 2013 Supply & Installation Open 55545 1,823,806 Transport Alpine Kamen d.o.o. Track Renewal Materials Lot 6 - procurement of 17 Jun 2013 Goods Open 57423 4,286,409 crushed stone for ballast prizm IMPREGNACIJA a.d. Track Renewal Materials Lot 4 - procurement of 07 Aug 2013 Goods Open 57541 2,398,086 imregnated wooden sleepers OPTICUS d.o.o. Track Renewal Materials Lot 8 - procurement of 17 Jun 2013 Goods Open 57425 621,488 geocomposite PYRKONIT d.o.o. Track Renewal Materials Lot 7 - procurement of AT 17 Jun 2013 Goods Open 57424 175,109 portions with moulds Terra Srbija d.o.o. Track Maintenance Equipment Lot 1 - 07 May 2013 Goods Open 57421 77,545 constructional machines Vossloh Min Skretnice Track Renewal Materials Lot 2 - procurement of 17 Jun 2013 Goods Open 57422 1,644,570 d.o.o. new switches with elastic fastening Total SERBIA 7 11,027,013 Country of Winning Tenderer: SLOVAK REPUBLIC Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) FYR MACEDONIA Transport ZOS TRNAVA A.S. Procurement of New Freight Wagons 18 Dec 2013 Goods Open 58544 13,208,750 Total SLOVAK REPUBLIC 1 13,208,750 Country of Winning Tenderer: SLOVENIA Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) SLOVENIA Power and Energy Rudis Supply and Installation of Coal Transport - Stage 2 28 Feb 2013 Supply & Installation Open 54821 992,112

Total SLOVENIA 1 992,112 Country of Winning Tenderer: SPAIN Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) CROATIA Municipal & Env Inf EPTISA, Servicios de DS Consultancy Services Supervision of Design and 18 Mar 2013 Consultant Services Alternative 52101 1,391,500 Ingenieria, S.L. Construction ROMANIA Municipal & Env Inf SC Ocide Construccion SA CW7 - Extension and erhabilitation of water 02 Apr 2013 Works Alternative 55666 13,999,465 transport in Agglomeration Brasov-Sacele UKRAINE Power and Energy Instalaciones Inabensa, Construction of OHL 750 kV Zaporizhzhia NPP - 14 Aug 2013 Supply & Installation Open 58561 55,480,675 S.A. Kakhova Transport ELSAMEX Internacionale OPRC for M06 Kiev to Chop Highway - Contract 1 31 Dec 2013 Works Open 58641 50,533,933 km 434+230 - km 621+500 Total SPAIN 4 121,405,574 Country of Winning Tenderer: SWITZERLAND

Annex 6 Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) KYRGYZ REPUBLIC Municipal & Env Inf Fela Planungs AG OWRP PP3 Lot 3.1: Supply and Installation of 01 Oct 2013 Supply & Installation Open 54802 870,000 Goods for Rehabilitation of Wastewater Treatment Plant in Osh WS-4 Supply of ultrasonic & electro-magnetic flow 01 Nov 2013 Goods Open 55581 537,524 water meters for installation in wellfields SERBIA Transport Stadler Rail AG Supply of Electric Multiple Units 04 Mar 2013 Goods Open 36461 98,999,995 Total SWITZERLAND 3 100,407,519 Country of Winning Tenderer: TAJIKISTAN Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) TAJIKISTAN Municipal & Env Inf Diana & Co LLC KhSWMP-001 Specialised vehicles; waste collection 23 Jul 2013 Goods Open 53143 1,060,061 trucks and machinery Doro Ltd PP1.1 LOT 1 Supply of Maintenance Equipment 24 May 2013 Goods Open 50142 135,446

CTWRP-002 LOT 2 Office Equipment 29 May 2013 Goods Open 56021 12,645 Electrogidromash LLC CTWRP-009 Construction of water main and 20 Nov 2013 Works Open 56421 1,648,713 and Khurshedi Khorazm renovation of distribution network in Somoniyon LLC city General Directorate of CTWRP-001 Comprehensive survey of 20 May 2013 Consultant Services Competitive 53582 132,218 Geology under the underground water sources and detailed design Government of the for location of the New Well field in Tursunzoda Republic of Taiikista and Gissar cities Juziy Zimiston Ltd. PP3.2-Rehabilitation of water supply network in 14 May 2013 Works Open 53501 1,755,376 Gafurov City LLC Khurshedi Khorasm PP1.1 LOT 2 Specialised Vehicles 10 May 2013 Goods Open 55621 1,040,578 LLC Obi Dekhot CTWRP-004 Renovation of Kuktosh water intake in 30 Oct 2013 Works Open 56221 134,434 Somoniyon Orieno Sorvo Ltd. PP3.4-Rehabiliation of Water Supply Network in 29 May 2013 Works Open 53261 576,529 Kairakkum City LOT 1 Sharifi Khuchandy Co. Ltd KhSWMP-004 Supply of containers, special uniform 20 Sep 2013 Goods Open 55363 450,750 and working tools Sokhtmony Dekhot Ltd PP3.6 Rehabilitation of water supply network in 25 Apr 2013 Works Open 53362 269,929 Taboshar City Umed-1 Ltd. PP3.1-Rehabilitation of water supply network in 14 May 2013 Works Open 53661 640,867 Chkalovsk City Total TAJIKISTAN 12 7,857,546

Annex 6 Country of Winning Tenderer: TURKEY Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) TURKEY Municipal & Env Inf GELISIM Insaat Tur. San. Rehabilitation of the Existing Water Network 03 Apr 2013 Works Open 52841 1,061,392 Ve Tic. Lfd Sti. Bodrum - procurement of works for installation works - 2012-162414 - Tranche 1 Samsun Makina San. A.S. Procurement of goods for the water network 21 Feb 2013 Goods Open 52181 762,758 rehabilitation Tranche 1- pipes Tender No: 2012/ 162384 Procurement of Goods for the Water Network 07 Jan 2013 Goods Open 52661 472,370 Rehabilitation Bodrum - Gumbet High Level Zone - Tranche 1 TEMELSU Uluslararasi Engineering and Supervision Consultancy Services 10 Oct 2013 Consultant Services Competitive 54042 1,200,325 Mühendislik Hizmetleri A.S., SRP Schneider & Partner Ingeni UKRAINE Municipal & Env Inf ONUR Taahhut Phase II Works for road and tram lines 03 Jun 2013 Works Open 49964 26,535,948 Tasimacilik Ve Ticaret reconstruction in Lviv City -Tram Lines 2 & 6 - Lots Ltd.CTI 1-6 Total TURKEY 5 30,032,793 Country of Winning Tenderer: UKRAINE Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) MOLDOVA Municipal & Env Inf JVCA Oniko PE Supply of pumps and chlorination equipment for 21 Jun 2013 Goods Open 55424 155,466 Leova and Floresti LEFL-PWP-01 Lot 2 Floresti

Supply of pumps and chlorination equipment for 25 Jun 2013 Goods Open 57165 1,152,490 Leova and Floresti LEFL-PWP-01 Lot 2 Leova

Total UKRAINE 2 1,307,956 Country of Winning Tenderer: UNITED KINGDOM Op Country Sector Winning Tenderer Contract Name Contract Signing Contract Type Procurement Contract ID Signed Contract Date Method Value (EUR) FYR MACEDONIA Transport URS Infrastructure & Consulting Services Assistance with Project 03 Jul 2013 Consultant Services Selection from a shortlist56662 250,000 Environment UK Limited Procurement and Implementation ROMANIA Transport Drew Transport Consulting Services - Small Assignments 22 Apr 2013 Consultant Services Direct Selection 57461 16,500 Consultants Total UNITED KINGDOM 2 266,500 Grand Total * 269 1,269,670,515

Annex 6 Distribution of Tenders Submitted by Country of Operations and by Business Sector 2013

Op Country Sector Winning Tenders Other Tenders Aggregate ALBANIA Transport 24 94 118 ALBANIA 24 94 118 ARMENIA Municipal & Env Inf 15 39 54 ARMENIA 15 39 54 AZERBAIJAN Transport 1 1 2 AZERBAIJAN 1 1 2 BOSNIA AND HERZEGOVINA Municipal & Env Inf 6 11 17 Power and Energy 1 5 6 Transport 2 4 6 BOSNIA AND HERZEGOVINA 9 27 29 BULGARIA Municipal & Env Inf 5 0 5 BULGARIA 5 0 5 CROATIA Municipal & Env Inf 8 6 14 Transport 2 3 5 CROATIA 10 9 19 FYR MACEDONIA Power and Energy 2 9 11 Transport 17 54 71 FYR MACEDONIA 19 63 82 GEORGIA Municipal & Env Inf 2 7 9 GEORGIA 2 7 9 KAZAKHSTAN Municipal & Env Inf 1 4 5 Power and Energy 2 4 6 KAZAKHSTAN 3 8 11 KYRGYZ REPUBLIC Municipal & Env Inf 10 24 34 KYRGYZ REPUBLIC 10 24 34 MOLDOVA Municipal & Env Inf 27 65 92 MOLDOVA 27 65 92 MONTENEGRO Municipal & Env Inf 1 3 4 Power and Energy 1 1 2 MONTENEGRO 2 4 6 MOROCCO Power and Energy 21 74 95 MOROCCO 21 74 95 ROMANIA Municipal & Env Inf 45 10 55 Transport 1 0 1 ROMANIA 46 10 56 RUSSIAN FEDERATION Municipal & Env Inf 11 9 20 Power and Energy 2 14 16 Transport 18 56 74 RUSSIAN FEDERATION 31 79 110 SERBIA Municipal & Env Inf 1 6 7 Power and Energy 4 9 13 Transport 17 26 43 SERBIA 22 41 63 SLOVENIA Power and Energy 1 2 3 SLOVENIA 1 2 3 TAJIKISTAN Municipal & Env Inf 12 54 66 TAJIKISTAN 12 54 66 TURKEY Municipal & Env Inf 4 5 9 TURKEY 4 5 9 UKRAINE Municipal & Env Inf 2 1 3 Power and Energy 1 6 7 Transport 2 5 7 UKRAINE 5 12 17 Grand Total 269 615 880

Annex 7 Annex 7 Distribution of Tenders Submitted by Country of Origin of the Tenderers and Country of Operations 2013

Tenderer Country Op Country Winning Tenders Other Tenders Aggregate ALBANIA ALBANIA 17 65 82 FYR MACEDONIA 0 1 1 MONTENEGRO 0 1 1 Total ALBANIA 17 67 84 ARMENIA ARMENIA 11 28 39 GEORGIA 1 0 1 Total ARMENIA 12 28 40 AUSTRIA ALBANIA 0 3 3 BOSNIA AND HERZEGOVINA 1 3 4 FYR MACEDONIA 2 8 10 RUSSIAN FEDERATION 0 1 1 SERBIA 1 2 3 TURKEY 0 1 1 UKRAINE 0 2 2 Total AUSTRIA 4 20 24 AZERBAIJAN GEORGIA 1 2 3 KYRGYZ REPUBLIC 1 2 3 MOLDOVA 4 0 4 TAJIKISTAN 0 3 3 Total AZERBAIJAN 6 7 13 BELGIUM CROATIA 0 1 1 TURKEY 0 1 1 Total BELGIUM 0 2 2 BOSNIA AND HERZEGOVINA BOSNIA AND HERZEGOVINA 7 9 16 FYR MACEDONIA 0 3 3 SERBIA 0 2 2 Total BOSNIA AND HERZEGOVINA 7 14 21 BULGARIA ALBANIA 0 2 2 BULGARIA 1 0 1 FYR MACEDONIA 1 5 6 SERBIA 1 0 1 Total BULGARIA 3 7 10 CHINA FYR MACEDONIA 0 2 2 KAZAKHSTAN 1 4 5 MOLDOVA 3 0 3 TAJIKISTAN 0 1 1 Total CHINA 4 7 11 CROATIA CROATIA 6 2 8 FYR MACEDONIA 1 3 4 MONTENEGRO 0 1 1 SERBIA 2 3 5 UKRAINE 0 1 1 Total CROATIA 9 10 19 CZECH REPUBLIC BOSNIA AND HERZEGOVINA 0 1 1 BULGARIA 1 0 1 FYR MACEDONIA 0 4 4 RUSSIAN FEDERATION 0 1 1 SERBIA 1 3 4 SLOVENIA 0 1 1

Annex 8 Total CZECH REPUBLIC 2 10 12 DENMARK CROATIA 0 2 2 FYR MACEDONIA 0 0 0 Total DENMARK 0 2 2 FINLAND AZERBAIJAN 1 0 1 GEORGIA 0 0 0 Total FINLAND 1 0 1 FRANCE ARMENIA 2 2 4 BOSNIA AND HERZEGOVINA 0 1 1 CROATIA 1 0 1 FYR MACEDONIA 0 2 2 MOLDOVA 0 3 3 SERBIA 2 3 5 UKRAINE 1 1 2 Total FRANCE 6 12 18 FYR MACEDONIA FYR MACEDONIA 12 11 23 Total FYR MACEDONIA 12 11 23 GEORGIA ARMENIA 1 0 1 GEORGIA 0 2 2 Total GEORGIA 1 2 3 GERMANY ARMENIA 0 1 1 BOSNIA AND HERZEGOVINA 0 1 1 CROATIA 1 2 3 FYR MACEDONIA 1 1 2 GEORGIA 0 2 2 KAZAKHSTAN 1 0 1 MOLDOVA 0 4 4 MONTENEGRO 0 1 1 SERBIA 3 11 14 TURKEY 0 2 2 UKRAINE 1 0 1 Total GERMANY 7 25 32 GREECE ALBANIA 2 4 6 FYR MACEDONIA 0 4 4 SERBIA 0 1 1 Total GREECE 2 9 11 HUNGARY FYR MACEDONIA 0 1 1 Total HUNGARY 0 1 1 INDIA FYR MACEDONIA 0 1 1 KAZAKHSTAN 1 0 1 SERBIA 0 1 1 UKRAINE 0 3 3 Total INDIA 1 5 6 IRAN ARMENIA 0 4 4 KAZAKHSTAN 0 1 1 TAJIKISTAN 0 1 1 Total IRAN 0 6 6 ITALY ALBANIA 2 9 11 ARMENIA 0 2 2 BOSNIA AND HERZEGOVINA 1 0 1 FYR MACEDONIA 0 5 5 MOLDOVA 0 4 4 ROMANIA 1 1 2 SERBIA 2 5 7 Total ITALY 6 26 32 KAZAKHSTAN KYRGYZ REPUBLIC 0 1 1

Annex 8 Total KAZAKHSTAN 0 1 1 KOREA KAZAKHSTAN 0 1 1 Total KOREA 0 1 1 KOSOVO ALBANIA 2 0 2 FYR MACEDONIA 0 2 2 Total KOSOVO 2 2 4 KUWAIT ALBANIA 1 6 7 Total KUWAIT 1 6 7 KYRGYZ REPUBLIC KYRGYZ REPUBLIC 5 20 25 Total KYRGYZ REPUBLIC 5 20 25 MAURITIUS TAJIKISTAN 0 2 2 Total MAURITIUS 0 2 2 MOLDOVA MOLDOVA 8 38 46 Total MOLDOVA 8 38 46 MONTENEGRO MONTENEGRO 2 0 2 Total MONTENEGRO 2 0 2 MOROCCO MOROCCO 21 70 91 Total MOROCCO 21 70 91 NETHERLANDS CROATIA 1 0 1 Total NETHERLANDS 1 0 1 NORWAY BOSNIA AND HERZEGOVINA 0 1 1 Total NORWAY 0 1 1 POLAND BULGARIA 3 0 3 SERBIA 2 2 4 Total POLAND 5 2 7 PORTUGAL SERBIA 0 1 1 Total PORTUGAL 0 1 1 REUNION MOLDOVA 0 1 1 Total REUNION 0 1 1 ROMANIA FYR MACEDONIA 0 2 2 MOLDOVA 10 14 24 ROMANIA 43 9 52 Total ROMANIA 53 25 78 RUSSIAN FEDERATION ARMENIA 1 2 3 KAZAKHSTAN 0 2 2 KYRGYZ REPUBLIC 2 0 2 MOLDOVA 0 0 0 RUSSIAN FEDERATION 31 77 108 SERBIA 0 1 1 TAJIKISTAN 0 1 1 UKRAINE 0 2 2 Total RUSSIAN 34 85 119 FEDERATION SERBIA FYR MACEDONIA 0 2 2 MONTENEGRO 0 1 1 SERBIA 7 3 10 Total SERBIA 7 6 13 SLOVAK REPUBLIC FYR MACEDONIA 1 1 2 Total SLOVAK REPUBLIC 1 1 2 SLOVENIA ALBANIA 0 2 2 SLOVENIA 1 1 2 Total SLOVENIA 1 3 4 SPAIN CROATIA 1 1 2 FYR MACEDONIA 0 1 1 MOROCCO 0 4 4 ROMANIA 1 0 1

Annex 8 SPAIN

SERBIA 0 1 1 TURKEY 0 1 1 UKRAINE 2 1 3 Total SPAIN 4 9 13 SWEDEN SERBIA 0 1 1 Total SWEDEN 0 1 1 SWITZERLAND BOSNIA AND HERZEGOVINA 0 1 1 FYR MACEDONIA 0 1 1 KYRGYZ REPUBLIC 2 1 3 SERBIA 1 0 1 TAJIKISTAN 0 1 1 Total SWITZERLAND 3 4 7 TAJIKISTAN TAJIKISTAN 12 44 56 Total TAJIKISTAN 12 44 56 TURKEY ALBANIA 0 3 3 AZERBAIJAN 0 1 1 BOSNIA AND HERZEGOVINA 0 2 2 CROATIA 0 1 1 FYR MACEDONIA 0 1 1 GEORGIA 0 1 1 TURKEY 4 0 4 UKRAINE 1 1 2 Total TURKEY 5 10 15 UKRAINE MOLDOVA 2 1 3 Total UKRAINE 2 1 3 UNITED KINGDOM BOSNIA AND HERZEGOVINA 0 1 1 FYR MACEDONIA 1 1 2 ROMANIA 1 0 1 SERBIA 0 1 1 TAJIKISTAN 0 1 1 UKRAINE 0 1 1 Total UNITED KINGDOM 2 5 7 UNITED STATES FYR MACEDONIA 0 1 1 Total UNITED STATES 0 1 1 Grand Total 269 611 880

Annex 8

Annex 8 Distribution of Tenders Submitted by Country of Origin of the Tenderers and by Business Sector 2013

Tenderer Country Sector Winning Tenders Other Tenders Aggregate ALBANIA Municipal & Env Inf 0 1 1 Transport 17 66 83 Total ALBANIA 17 67 84 ARMENIA Municipal & Env Inf 12 28 40 Total ARMENIA 12 28 40 AUSTRIA Municipal & Env Inf 1 3 4 Transport 1 15 16 Power and Energy 2 2 4 Total AUSTRIA 4 20 24 AZERBAIJAN Municipal & Env Inf 6 7 13 Total AZERBAIJAN 6 7 13 BELGIUM Municipal & Env Inf 0 1 1 Transport 0 1 1 Total BELGIUM 0 2 2 BOSNIA AND HERZEGOVINA Transport 2 8 10 Municipal & Env Inf 5 6 11 Total BOSNIA AND HERZEGOVINA 7 14 21 BULGARIA Power and Energy 0 1 1 Transport 2 6 8 Municipal & Env Inf 1 0 1 Total BULGARIA 3 7 10 CHINA Municipal & Env Inf 4 4 8 Power and Energy 0 1 1 Transport 0 2 2 Total CHINA 4 7 11 CROATIA Municipal & Env Inf 6 2 8 Power and Energy 1 2 3 Transport 2 6 8 Total CROATIA 9 10 19 CZECH REPUBLIC Municipal & Env Inf 1 1 2 Transport 1 6 7 Power and Energy 0 3 3 Total CZECH REPUBLIC 2 10 12 DENMARK Transport 0 0 0 Municipal & Env Inf 0 2 2 Total DENMARK 0 2 2 FINLAND Municipal & Env Inf 0 0 0 Transport 1 0 1 Total FINLAND 1 0 1 FRANCE Power and Energy 0 2 2 Transport 4 6 10 Municipal & Env Inf 2 4 6 Total FRANCE 6 12 18 FYR MACEDONIA Transport 12 11 23 Total FYR MACEDONIA 12 11 23 GEORGIA Municipal & Env Inf 1 2 3 Total GEORGIA 1 2 3 GERMANY Municipal & Env Inf 1 13 14 Power and Energy 2 6 8

Annex 9 GERMANY

Transport 4 6 10 Total GERMANY 7 25 32 GREECE Transport 2 9 11 Total GREECE 2 9 11 HUNGARY Power and Energy 0 1 1 Total HUNGARY 0 1 1 INDIA Transport 0 1 1 Municipal & Env Inf 0 1 1 Power and Energy 1 3 4 Total INDIA 1 5 6 IRAN Power and Energy 0 1 1 Municipal & Env Inf 0 5 5 Total IRAN 0 6 6 ITALY Transport 4 17 21 Power and Energy 1 2 3 Municipal & Env Inf 1 7 8 Total ITALY 6 26 32 KAZAKHSTAN Municipal & Env Inf 0 1 1 Total KAZAKHSTAN 0 1 1 KOREA Municipal & Env Inf 0 1 1 Total KOREA 0 1 1 KOSOVO Transport 2 2 4 Total KOSOVO 2 2 4 KUWAIT Transport 1 6 7 Total KUWAIT 1 6 7 KYRGYZ REPUBLIC Municipal & Env Inf 5 20 25 Total KYRGYZ REPUBLIC 5 20 25 MAURITIUS Municipal & Env Inf 0 2 2 Total MAURITIUS 0 2 2 MOLDOVA Municipal & Env Inf 8 38 46 Total MOLDOVA 8 38 46 MONTENEGRO Power and Energy 1 0 1 Municipal & Env Inf 1 0 1 Total MONTENEGRO 2 0 2 MOROCCO Power and Energy 21 70 91 Total MOROCCO 21 70 91 NETHERLANDS Transport 1 0 1 Total NETHERLANDS 1 0 1 NORWAY Power and Energy 0 1 1 Total NORWAY 0 1 1 POLAND Power and Energy 1 2 3 Municipal & Env Inf 4 0 4 Transport 0 0 0 Total POLAND 5 2 7 PORTUGAL Transport 0 1 1 Total PORTUGAL 0 1 1 REUNION Municipal & Env Inf 0 1 1 Total REUNION 0 1 1 ROMANIA Power and Energy 0 1 1 Transport 0 1 1 Municipal & Env Inf 53 23 76 Total ROMANIA 53 25 78 RUSSIAN FEDERATION Transport 18 56 74 Municipal & Env Inf 14 13 27 Power and Energy 2 16 18 Total RUSSIAN FEDERATION 34 85 119

Annex 9 SERBIA Power and Energy 1 2 3 Municipal & Env Inf 0 1 1 Transport 6 3 9 Total SERBIA 7 6 13 SLOVAK REPUBLIC Transport 1 1 2 Total SLOVAK REPUBLIC 1 1 2 SLOVENIA Power and Energy 1 1 2 Municipal & Env Inf 0 1 1 Transport 0 2 2 Total SLOVENIA 1 4 5 SPAIN Power and Energy 1 4 5 Transport 1 3 4 Municipal & Env Inf 2 1 3 Total SPAIN 4 8 12 SWEDEN Municipal & Env Inf 0 1 1 Total SWEDEN 0 1 1 SWITZERLAND Power and Energy 0 2 2 Transport 1 0 1 Municipal & Env Inf 2 2 4 Total SWITZERLAND 3 4 7 TAJIKISTAN Municipal & Env Inf 12 44 56 Total TAJIKISTAN 12 44 56 TURKEY Transport 0 6 6 Municipal & Env Inf 5 4 9 Total TURKEY 5 10 15 UKRAINE Municipal & Env Inf 2 1 3 Total UKRAINE 2 1 3 UNITED KINGDOM Municipal & Env Inf 0 2 2 Transport 2 3 5 Total UNITED KINGDOM 2 5 7 UNITED STATES Power and Energy 0 1 1 Total UNITED STATES 0 1 1 Grand Total 269 611 880

Annex 9 Contracts for Nuclear Safety Department Managed Funds 2013

Fund Name Fund Country Contract Contract Name Tenderer Name Tenderer Country Contract Contract Type Procurem Grant Name Signed Contract Fund Portion Name ID Signing Date ent Value (EUR) (EUR) Method Bohunice International SLOVAK 48242 V1 NPP Decommissioning 2nd Stage Plan Westinghouse Electric Germany GERMANY 21 Jun 2013 Consultant ServicesCompetitiveBIDSF 16 - Bohunice International 4,975,000 4,975,000 Decommissioning Support REPUBLIC &Licensing Documentation (W) Decommissioning Support Fund Fund NUKEM GMBH GERMANY NUVIA LTD UNITED KINGDOM SPECIALUS MONTAZAS NTP LITHUANIA AMEC NUCLEAR INTERNATIONAL UNITED KINGDOM LIMITED GAS NATURAL FENOSA SPAIN 52202 Conditioning of Buffer Storage Areas ROBO Piestany a.s (W) SLOVAK REPUBLIC 05 Feb 2013 Works Open BIDSF 16 - Bohunice International 399,835 399,835 OHL ZS A.S. CZECH REPUBLIC Decommissioning Support Fund CHLADIACE VEZE BOHUNICE SLOVAK REPUBLIC VUJE A.S. SLOVAK REPUBLIC 52203 Building conditioning - premises for technical HANT BA DS a.s (W) SLOVAK REPUBLIC 31 Jan 2013 Supply & InstallationOpen BIDSF 16 - Bohunice International 765,320 765,320 documentation centre ZIPP BRATISLAVA SLOVAK REPUBLIC Decommissioning Support Fund VUJE A.S. SLOVAK REPUBLIC CHLADIACE VEZE BOHUNICE SLOVAK REPUBLIC 52204 Dismantling of outdoor not contaminated Petr Brezina - APB Plezen (W) CZECH REPUBLIC 26 Apr 2013 Supply & InstallationOpen BIDSF 19 - Bohunice International 708,611 708,611 facilities and objects Decommissioning Support Fund Grant HANT BA DS A.S SLOVAK REPUBLIC Agrrement METROSTAV CZECH REPUBLIC ZIPP BRATISLAVA SLOVAK REPUBLIC hochtief CZECH REPUBLIC ROBO PIESTANY A.S SLOVAK REPUBLIC VUJE A.S. SLOVAK REPUBLIC 52205 Laboratory equipment necessary for the Canberra-Packard s.r.o (W) SLOVAK REPUBLIC 26 Aug 2013 Goods Open BIDSF 16 - Bohunice International 469,527 469,527 process of V1 NPP decommissioning Decommissioning Support Fund 53303 Dismantling of Technical Equipment in the Chemcomex Praha a.s (W) CZECH REPUBLIC 26 Apr 2013 Supply & InstallationOpen BIDSF 19 - Bohunice International 7,517,619 7,517,619 V1 NPP Turbine Hall Decommissioning Support Fund Grant METROSTAV CZECH REPUBLIC Agrrement ZIPP BRATISLAVA SLOVAK REPUBLIC Hochtief CZ CZECH REPUBLIC CKD Praha CZECH REPUBLIC Skoda power sro SLOVAK REPUBLIC VUJE A.S. SLOVAK REPUBLIC 54284 Personnel training for the purposes of V1 VUJE a.s. (W) SLOVAK REPUBLIC 12 Sep 2013 Consultant ServicesDirect SelectionBIDSF 16 - Bohunice International 510,622 510,622 NPP Decommissioning Stage I Decommissioning Support Fund 54541 Dismantling of Electric Power Supply Systems EZ-Elektromont a.s (W) SLOVAK REPUBLIC 08 Jul 2013 Supply & InstallationOpen BIDSF 19 - Bohunice International 2,182,200 2,182,200 VUJE A.S. SLOVAK REPUBLIC Decommissioning Support Fund Grant Agrrement sag SLOVAK REPUBLIC ppa energo SLOVAK REPUBLIC ohl zs CZECH REPUBLIC ZIPP BRATISLAVA SLOVAK REPUBLIC METROSTAV CZECH REPUBLIC 55681 Lot 7 Energy Efficieny in Public Buildings MATEP spol (W) SLOVAK REPUBLIC 21 Aug 2013 Supply & InstallationOpen BIDSF 15 1,046,803 1,046,803

Annex 10 Bohunice International SLOVAK Decommissioning Support REPUBLIC Fund

55681 Lot 7 Energy Efficieny in Public Buildings 21 Aug 2013 Supply & InstallationOpen BIDSF 15 1,046,803 1,046,803 termomont SLOVAK REPUBLIC DYNAMIK HOLDING AS SLOVAK REPUBLIC pkb invest SLOVAK REPUBLIC ava-stav SLOVAK REPUBLIC 55742 Transport and Packaging Forma for ROBO Piestany a.s (W) SLOVAK REPUBLIC 20 Sep 2013 Goods Open BIDSF 16 - Bohunice International 2,935,547 2,935,547 Decommissioning of V1 NPP - Stage 1 Decommissioning Support Fund 55761 Equipment for PMU Offices and V1 NPP Nova Interier Studio, s.r.o. (W) SLOVAK REPUBLIC 25 Jul 2013 Supply & InstallationShopping BIDSF 13 248,602 206,340 Decommissioning Information NABYTOK BODNAR SLOVAK REPUBLIC HBS INTERIOR SLOVAK REPUBLIC NEUDOEFLER SLOVAK REPUBLIC 55762 Publicity Equipment for V1 NPP Motion Zone, s.r.o (W) SLOVAK REPUBLIC 25 Jul 2013 Supply & InstallationShopping BIDSF 13 235,850 195,714 Decommissioning Information Centre nexus agency SLOVAK REPUBLIC larsen SLOVAK REPUBLIC mw promotion SLOVAK REPUBLIC 56041 legal services Bobak Bollova a spol s.r.o (W) SLOVAK REPUBLIC 19 Jun 2013 Consultant ServicesDirect SelectionBIDSF 15 12,000 12,000 Total BIDSF 13 22,007,535 21,925,137 Chernobyl Shelter Fund UKRAINE 54841 Supply of Personal Protective Equipment for Limited Liability Company UKRAINE 06 Feb 2013 Goods Shopping Chernobyl Shelter Fund: Phase I 68,454 68,454 Workers Lot No 1 Research and Development Implementation Enterprise IKAR (W) PE TRADING HOUSE, TRUDIAGA UKRAINE

55141 Supply of Personal Protective Equipment for Company "AV Center" Ltd (W) UKRAINE 20 Feb 2013 Goods Shopping Chernobyl Shelter Fund: Phase I 121,000 121,000 Workers Lots No 2 and 3 Implementation PE TRADING HOUSE, TRUDIAGA UKRAINE

ANKON-TRADE LTD UKRAINE

IE HONEYWELL UKRAINE Total CSF 2 189,454 189,454 Ignalina International LITHUANIA 54621 Expertise Statement for technical design of UAB Ekspertika (W) LITHUANIA 12 Feb 2013 Consultant ServicesDirect SelectionConsultancy Services for the Initial 27,000 27,000 Decommissioning Support 400kV overhead power transmission Alytys Phase - Part 1 of the Projet Power Fund substation to Lithuania-Poland state border Interconnection between Lithuania and Poland (the LitPol Link Project) 54862 Technical and contractual support of LitPol Poyry SwedPower AB (W) SWEDEN 17 May 2013 Consultant ServicesSelection fromConsultancy a shortlist Services for the Initial 283,104 283,104 Link during implementation of the contract Phase - Part 1 of the Projet Power for the 500 MW HVDC converter station with Interconnection between Lithuania 400 kV switchyard and Poland (the LitPol Link Project) 57801 Legal support services to INPP in finalising Taylor Wessing LLP (W) UNITED KINGDOM 11 Oct 2013 Consultant ServicesDirect SelectionIgnalina Nuclear Power Plant: 47,880 47,880 the B2/3/4 global settlement and related Consultancy services in 2012 as an amendment to the B2/3/4 contract integral part of Phase 4 (2011-2013) Total IIDSF 3 357,984 357,984 Kozloduy International BULGARIA 50902 PROJECT 9f - Design modification and Atomenergoremont PLC (W) BULGARIA 01 Nov 2013 Goods Open Kozloduy IDSF - Grant No. 038 112,500 112,500 Decommissioning Support construction of the Seismic Qualification RISK ENGINEERING LTD BULGARIA Fund 50905 PROJECT 13a-1 - Supply of Mobile Elevating KIROV CME Limited (W) BULGARIA 16 Jan 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 59,890 59,890 Work Platforms for Dismantling in Turbine Holland Lift International NETHERLANDS Hall Euromarket Construction JSC BULGARIA SPECIALUS MONTAZAS NTP LITHUANIA 50906 PROJECT 13a-2 - Supply of Fork Lift RAD Engineering Ltd (W) BULGARIA 16 Jan 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 82,880 82,880 Transport Equipment for Dismantling in Balkancar Record JSC BULGARIA Turbine Hall EUROMARKET BULGARIA SPECIALUS MONTAZAS NTP LITHUANIA 50907 PROJECT 13a-3 - Supply of Diamond Wire CEDIMA GmbH (W) GERMANY 11 Jan 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 92,608 92,608 Cutting Equipment for Dismantling in Turbine HILTI Bulgaria Ltd. BULGARIA Hall ENSA SPAIN SPECIALUS MONTAZAS NTP LITHUANIA

Annex 10 Kozloduy International BULGARIA Decommissioning Support Fund

50908 PROJECT 13a-4 - Lots 1&3 Supply of Kammarton Bulgaria Ltd (W) BULGARIA 19 Feb 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 39,314 39,314 Handheld Tools & Equipment for Dismantling Trega Ltd. BULGARIA in Turbine Hall Euromarket BRD Ltd. BULGARIA 50910 Phase III Lot 1 - Rehabilitation and Unincorporated Partnership BULGARIA 17 Jul 2013 Supply & InstallationOpen Kozloduy IDSF - Grant No. 13 1,382,258 967,581 Refurbishment of 400/220/110kV 'Plovdiv' Consortium Elektroluks Substation - reconstruction of switchyard Elektroistok - Izgradnja (W) 220kV EL Kontrol EOOD BULGARIA RUDIN-DINEV & ZHELEV & SIE GP BULGARIA

EL TEST LTD BULGARIA 50911 Phase III Lot 2 - Reconstruction and Rudin-Dinev & Zhelev & SIE GP BULGARIA 17 Jul 2013 Supply & InstallationOpen Kozloduy IDSF - Grant No. 13 1,844,631 1,291,242 extension of 110/20kV 'Shabla' Substation (W) EMU JSCo BULGARIA ETRA EL BULGARIA ELEKTROLUKS TABAKOV I SINOVE BULGARIA LTD SIEMENS EOOD BULGARIA ENERGY-KA Ltd. BULGARIA EFACEC ENGENHARIA, SA PORTUGAL RISK BULGARIA 50912 Phase III Lot 3 - Implementation of a EFACEC Engenharia S.A. (W) BULGARIA 17 Jul 2013 Supply & InstallationOpen Kozloduy IDSF - Grant No. 13 1,730,123 1,211,086 Substation Automation System (SAS) at 'TPP MVM OVIT National Power Line HUNGARY Varna Switchyard' Company Ltd. ABB System Consortium BULGARIA ELEKTROLUKS TABAKOV I SINOVE BULGARIA LTD ENERGY-KA Ltd. BULGARIA SIEMENS AG OSTERREICH AUSTRIA 50921 R-Project 5A: Independent evaluation of Risk Engineering Ltd (W) BULGARIA 03 Jun 2013 Consultant ServicesCompetitiveKozloduy IDSF - Infrastructure re 67,300 67,300 ISAR for the technical design National Radioactive Waste Disposal Facility 50922 R-Project 5B & 4H - Independent Assessment Risk Engineering Ltd (W) BULGARIA 23 Sep 2013 Consultant ServicesSelection fromKozloduy a shortlist IDSF - Infrastructure re 175,262 175,262 of the DD and Supervision of the WORLEYPARSONS BULGARIA National Radioactive Waste Disposal Infrastructure Preparation of Radiana Site Viaduct 99 SA BULGARIA Facility 51301 Technical Assistance for design CHP in Sofia Ramboll Danmark A/S (W) DENMARK 08 Mar 2013 Consultant ServicesCompetitiveKozloduy IDSF - Grant No. 037 1,488,000 1,488,000 with RDF utilisation Grotmij GmbH GERMANY RSP Rieman, Sonnenschein&Partner GERMANY GmbH WORLEYPARSONS EUROPE ENERGY BULGARIA SERVICES LTD. 51781 Decommissioning-Repository Project Empresarios Agrupados SPAIN 24 Jan 2013 Consultant ServicesCompetitiveKIDSF - Decommissioning-Repository 14,135,862 14,135,862 Management Unit Consultant for SERAW Internacional, S.A. (W) PMU Consultant AMEC NUCLEAR INTERNATIONAL UNITED KINGDOM LIMITED 52581 Supervision of the implementation, signing EnCon Services Ltd. (W) BULGARIA 22 Jul 2013 Consultant ServicesCompetitiveKozloduy IDSF - Grant No. 040 163,041 163,041 off the disbursements and evaluating the FICHTNER GMBH GERMANY preliminary effect of measures EnEffect Group BULGARIA MATTIG MANAGEMENT PARTNERS AUSTRIA

52582 Lot 1 - Implementation of work including LOT ZAPAD DZZD (W) BULGARIA 10 Jun 2013 Works Open Kozloduy IDSF - Grant No. 040 4,215,403 4,215,403 supply of equipment, control devices and all BRUNATA BULGARIA BULGARIA necessary prefabricated and raw materials ENEMONA BULGARIA DZZD Konsortium za inzhenering, BULGARIA proektirane i izgrazdane GP Group BULGARIA Union Future BULGARIA Bakanstroy BULGARIA STRABAG AG AUSTRIA 53121 PMU Consultant Energy Pro DM Ltd (W) BULGARIA 26 Jun 2013 Consultant ServicesDirect SelectionKozloduy IDSF - Grant No. 041 - 50,000 50,000 Energy Efficiency in Public Buildings in

Annex 10 Kozloduy International BULGARIA Decommissioning Support Fund

53123 Lot 1 - Implementation of work including PLANEX ltd (W) BULGARIA 09 Jul 2013 Works Open Energy Efficiency for Public Buildings 695,790 347,895 supply of equipment, control devices and all in Burgas PSG AD BULGARIA necessary prefabricated and raw materials DZZD Cosortium for Engineering, BULGARIA design and construction Alliance Alfa Erhold Burgas Zavodski Stroeji PS Pazarjik AD BULGARIA DZZD "MFK FOR PLOVDIV" BULGARIA 53181 Consultancy service for Supervision of the Bulgarian Consulting Center BULGARIA 08 Oct 2013 Consultant ServicesCompetitiveKozloduy IDSF - Grant No. 3 54,540 54,540 implementation, signing off the (BCC), Bulgaria (W) disbursements and evaluating the EnEffect Group BULGARIA preliminary effect for Energy Efficiency in Public Buildings - second stage implementation (8 buildings) under KIDSF ENCON SERVICES LTD. BULGARIA GA 030A MATTIG MANAGEMENT PARTNERS AUSTRIA

Ecoengineering BULGARIA

53265 Technical Assistance Consultant to the MEET SIMLOGIC EOOD (W) BULGARIA 27 Feb 2013 Consultant ServicesCompetitiveKozloduy IDSF - Grant No. 3 74,800 74,800 on Implementation of the Project for EE Improvement in 8 Public buildings II Stage Building Research Institute-NISI, BULGARIA EOOD 54061 PROJECT 13a-4 - Lot 2 Supply of Handheld KIROV JSco (W) BULGARIA 24 Jan 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 8,734 8,734 Tools & Equipment for Dismantling in Turbine Hall Euromarket BRD Ltd. BULGARIA

54062 PROJECT 13a-4 -Lot 4 Supply of Handheld Euromarket Group (W) BULGARIA 16 Jan 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 10,614 10,614 Tools & Equipment for Dismantling in Turbine Hall Tachev Galving Ltd. BULGARIA

54261 PROJECT 32b-1 : Lot 1: Supply of new KIROV Compressors Ltd, BULGARIA 08 Jul 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 13,900 13,900 utilities for Plasma Melting Facility Bulgaria (W) Grasys CJSC RUSSIAN FEDERATION

Atlas Copco Bulgaria EOOD BULGARIA

EUROMARKET COMPRESSORS BULGARIA J.S.CO., BULGARIA IGS ITALY

WTC Wasd.Techn.Center BULGARIA

KAMMARTON BULGARIA LTD BULGARIA

Go Ahead Technic Ltd. BULGARIA

54421 PROJECT 16a - Communication Support for MI Media Group (W) BULGARIA 11 Feb 2013 Consultant ServicesDirect SelectionKozloduy IDSF - Grant No. 038 48,985 48,985 Environmental Impact Assessment of KNPP 54622 SupervisionUnits 1-4 Decommissioning of the implementation, signing Standart Konsult EOOD (W) BULGARIA 29 Apr 2013 Consultant ServicesDirect SelectionEnergy Efficiency in Public Buildings in 24,880 24,880 off the disbursements and evaluating the Stara Zagora 54921 R-projectpreliminary 4C-1 effect Design of Water Supply for Energoproekt JSC (W) BULGARIA 04 Mar 2013 Consultant ServicesSelection fromKozloduy a shortlist IDSF - Infrastructure re 28,779 28,779 the Radiana Site National Radioactive Waste Disposal Facility

Annex 10 Kozloduy International BULGARIA Decommissioning Support Fund

54921 R-project 4C-1 Design of Water Supply for 04 Mar 2013 Consultant ServicesSelection fromKozloduy a shortlist IDSF - Infrastructure re 28,779 28,779 the Radiana Site National Radioactive Waste Disposal SWECO ENERGOPROEKT JSC BULGARIA Facility

HPC Bulgaria BULGARIA

SP-90 OOD BULGARIA 55041 Implementation of work including supply of Consortium "Enemona - Ivkom BULGARIA 29 Jul 2013 Works Open Energy Efficiency in Public Buildings in 1,102,492 551,246 equipment, control devices and all necessary Komers" (W) Stara Zagora prefabricated and raw materials Alliance Alfa Erhold Burgas BULGARIA Stroitelna Kompania Zagora EAD BULGARIA PSG AD BULGARIA Stara Zagora 2013 DZZD BULGARIA Magnito DZZD BULGARIA 55102 Lot 1 - Implementation of work including Protektor BG EOOD (W) BULGARIA 12 Aug 2013 Works Open Energy Efficiency in Publilc Buildings in 558,496 279,248 supply of equipment, control devices and all Plovdiv DZZD MKF for Plovdiv BULGARIA necessary prefabricated and raw materials 55242 Supervision of the implementation, signing Transconsult-BG Ltd (W) BULGARIA 10 Jul 2013 Consultant ServicesDirect SelectionEnergy Efficiency in Publilc Buildings in 74,990 74,990 off the disbursements and evaluating the Plovdiv 55301 PROJECT 12b-4 Supply of Equipment for Size Proinstall Ltd, Bulgaria (W) BULGARIA 19 Sep 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 98,920 98,920 Reduction Areas in the Turbine Hall of Units EUROMARKET BULGARIA 1 and 2 ELTRAK - BULGARIA BULGARIA 55501 Supervision of the implementation, signing EN AR Consult Ltd (W) BULGARIA 22 Jul 2013 Consultant ServicesDirect SelectionEnergy Efficiency for Public Buildings 48,000 48,000 off the disbursements and evaluating the in Burgas 55842 Lot 2 - Implementation of work including Alliance Energo-vod (W) BULGARIA 10 Jun 2013 Works Open Kozloduy IDSF - Grant No. 040 6,963,301 6,963,301 supply of equipment, control devices and all UNIVERSAL STORY CONSULT BULGARIA necessary prefabricated and raw materials BALKANSTROY BULGARIA STRABAG AG BULGARIA TRACE GRUP HOLD PLC BULGARIA MIKS-CONSTRUCTION BULGARIA 55843 Lot 3 - Implementation of work including Trace Group Hold (W) BULGARIA 10 Jun 2013 Works Open Kozloduy IDSF - Grant No. 040 8,385,951 8,385,951 supply of equipment, control devices and all ENEMONA BULGARIA necessary prefabricated and raw materials SIENIT BULGARIA Strabag AG BULGARIA 56042 Lot 4 - Implementation of work including Alliance Energo-vod (W) BULGARIA 10 Jun 2013 Works Open Kozloduy IDSF - Grant No. 040 6,036,919 6,036,919 supply of equipment, control devices and all Planex BULGARIA necessary prefabricated and raw materials STANILOV-SUNNY COM BULGARIA 56841 PROJECT 12b-5 Supervision of Installation of TANGRA - AV Ltd (W) BULGARIA 02 Sep 2013 Consultant ServicesDirect SelectionKozloduy IDSF - Grant No. 038 9,920 9,920 Ventilation Equipment for arrangement of size reduction areas in the TH of KNPP Units 56921 PROJECT 32b-1: Lot 2: Supply of new EUROMARKET Compressors BULGARIA 10 Jul 2013 Goods Shopping Kozloduy IDSF - Grant No. 038 69,820 69,820 utilities for Plasma Melting Facility J.S.Co., Bulgaria (W) Grasys CJSC RUSSIAN FEDERATION Atlas Copco Bulgaria EOOD BULGARIA IGS ITALY KIROV COMPRESSORS LTD, BULGARIA BULGARIA WTC Wasd.Techn.Center BULGARIA KAMMARTON BULGARIA LTD BULGARIA 57081 Lot 2- Implementation of work including DZZD BURGAS-2013 (W) BULGARIA 12 Jul 2013 Works Open Energy Efficiency for Public Buildings 560,664 280,332 supply of equipment, control devices and all DZZD Cosortium for Engineering, BULGARIA in Burgas necessary prefabricated and raw materials design and construction Alliance Alfa Erhold Burgas BULGARIA PLANEX LTD BULGARIA DZZD Bolidstroy 2013 BULGARIA

Annex 10 Kozloduy International BULGARIA Decommissioning Support Fund

57083 Lot 3 - Implementation of work including BULELEKTRIX LTD (W) BULGARIA 12 Jul 2013 Works Open Energy Efficiency for Public Buildings 611,958 305,979 supply of equipment, control devices and all PSG AD BULGARIA in Burgas necessary prefabricated and raw materials DZZD Toploizolacionny sistemy BULGARIA PLANEX LTD BULGARIA 57084 Lot 4- Implementation of work including BILDNIX Ltd (W) BULGARIA 15 Jul 2013 Works Open Energy Efficiency for Public Buildings 545,151 272,575 supply of equipment, control devices and all Alliance Alfa Erhold Burgas BULGARIA in Burgas necessary prefabricated and raw materials PLANEX LTD BULGARIA 57482 Lot 2 - Implementation of work including DZZD Nadex Group Engineering BULGARIA 26 Aug 2013 Works Open Energy Efficiency in Publilc Buildings in 546,856 273,428 supply of equipment, control devices and all 2013 (W) Plovdiv necessary prefabricated and raw materials PSG AD BULGARIA ZAPRYANOVI - 03 OOD BULGARIA DZZD "MFK FOR PLOVDIV" BULGARIA 57483 Lot 3 - Implementation of work including DZZD "MFK for Plovdiv" (W) BULGARIA 26 Aug 2013 Works Open Energy Efficiency in Publilc Buildings in 699,780 349,890 supply of equipment, control devices and all Plovdiv necessary prefabricated and raw materials PSG AD BULGARIA

Alliance Alfa Erhold Burgas BULGARIA MIG Engineering BULGARIA 57484 Lot 4 - Implementation of work including Zapryanovi - 03 OOD (W) BULGARIA 12 Aug 2013 Works Open Energy Efficiency in Publilc Buildings in 721,173 360,587 supply of equipment, control devices and all Plovdiv necessary prefabricated and raw materials SBSEE Plovdiv BULGARIA Alliance Alfa Erhold Burgas BULGARIA Zavodski Stroeji PS Pazarjik AD BULGARIA DZZD "MFK FOR PLOVDIV" BULGARIA 57485 Lot 5 - Implementation of work including Consortium SBS EE Plovdiv (W) BULGARIA 12 Aug 2013 Works Open Energy Efficiency in Publilc Buildings in 1,429,227 714,613 supply of equipment, control devices and all Plovdiv necessary prefabricated and raw materials DZZD "MFK FOR PLOVDIV" BULGARIA Total KIDSF 41 55,063,713 49,840,816 Northern Dimension RUSSIAN 43551 Adaptation of the Nerpa Shipyard JSC Shiprepairing Centre RUSSIAN FEDERATION 19 Jun 2013 Works NDEP Fund 5 5,067,539 5,067,539 Environmental Partnership: FEDERATION Infrastructure Required to Dismantle the Zvyozdochka (W) Nuclear Window 43562 DesignLepse manufacture and supervision of OOO Stroytekhnika (W) RUSSIAN FEDERATION 23 Oct 2013 Goods Open NDEP Fund 7 719,979 719,979 installation and commissioning of trolley for LLC Spetstekhcomplect RUSSIAN FEDERATION transporatation of casks betwenn pier and CJSC NovEnergoProm RUSSIAN FEDERATION the Accumulation Pad JSC Votkinsky Plant RUSSIAN FEDERATION 46882 Unloading of spent Nuclear Fuel from Papa- JSC Shiprepairing Centre RUSSIAN FEDERATION 11 May 2013 Works Open NDEP Fund 6 9,382,052 9,382,052 class submarine reactors (Hull No. 501) Zvyozdochka (W)

49685 9: Detailed design, construction and OJSC Rosspetsmontazh (W) RUSSIAN FEDERATION 21 Mar 2013 Works Open NDEP Fund 7 25,233,392 25,233,392 commissioning of the DSU Enclosure Kurchatov Institute RUSSIAN FEDERATION

51401 Consultancy Services of Russian FSUE " Research and Technical RUSSIAN FEDERATION 04 Feb 2013 Consultant ServicesDirect SelectionNDEP Fund 10 729,139 729,139 Organisations to provide technical support to Centre of Radiation-Chemical the Russian regulatory authorities during the Safety & Hygiene" (W) Lepse decommissioning 51762 Development of SFA removal technology JSC NIKIET (W) RUSSIAN FEDERATION 01 Feb 2013 Consultant ServicesDirect SelectionNDEP Fund 4 356,800 356,800 from SNF pool-type store in Andreeva Bay 53341 Design, manufacture, installation and OOO Stroytekhnika (W) RUSSIAN FEDERATION 15 Jun 2013 Goods Open NDEP Fund 7 4,680,968 4,680,968 commissioning of a retrieval machine to LLC "SpetsTechKomplekt" RUSSIAN FEDERATION support retrieval of SNF from DSU cells CSC "NovEnergoProm RUSSIAN FEDERATION JSC Afrikantov OKBM RUSSIAN FEDERATION 53941 Site operator services during preparatory FSUE SevRAO (W) RUSSIAN FEDERATION 11 Oct 2013 Consultant ServicesDirect SelectionNDEP Fund 4 52,859 52,859 works and removal of SFA 54701 Project Management (servies of the Federal State Unitary Enterprise RUSSIAN FEDERATION 14 Feb 2013 Consultant Services NDEP Fund 6 461,791 461,791 International Consultant and the PMU) "Federal Centre for Nuclear & Radiation Safety" (W)

Total NDEP NW 9 46,684,518 46,684,518 Grand Total 68 124,303,204 118,997,908

Annex 10 Procurement Listing of Contracts by Country of Operations (signed in 2013 entered into the CRA system after the data freeze) Op Country Sector OPID Op Name Contract ID Contract Name Tenderer Name Tenderer Contract Signing Contract Type Procurement Signed Contract Country Date Method Value (EUR)

ROMANIA Municipal & Env 41175 R2CF Targu 59647 MS-L&I-RB-08 Ludus & Iernut Rehabilitation, extension of water supply systems, SC Izorep SRL (W) ROMANIA (W) 13 Dec 2013 Works Alternative 5,960,375 Inf Mures Sub- sewerage systems, pumping stations, wastewater pumping station and discharge pipes Project

42766 R2CF Braila Sub- 60021 P9-R Extension of water networks, new tank, sewage network, sewage pumping station - S.C. TMUCB SA (W) ROMANIA (W) 24 Jan 2013 Works Alternative 3,982,148 Project Viziru agglomeration

60023 P3-Y Rehabilitation Gropeni catchment and new treatment plant, raw water and drinking SC Arcon AG SA and ROMANIA (W) 07 Jun 2013 Works Alternative 12,471,532 water pumping stations, raw water and drinking water main pipes-Regional System SC Tancrad SRL (W)

43137 R2CF Timis 59382 CL17 LOT 3 Water Treatment Plant in Sannicolau Mare, Gataia, Recas SC Beespeed ROMANIA (W) 20 Aug 2013 Works Alternative 941,802 Automatizari SRL, SC Datcomp SRL (W) 59701 CL17 LOT 1 Water Treatment Plant in Sannicolau Mare, Gataia, Recas SC Beespeed ROMANIA (W) 20 Aug 2013 Works Alternative 1,257,614 Automatizari SRL, SC Datcomp SRL (W) 59703 CL17 LOT 2 New Water Treatment Plant in Gataia SC Beespeed ROMANIA (W) 20 Aug 2013 Works Alternative 933,759 Automatizari SRL, SC Datcomp SRL (W) 43362 R2CF Bacau sub- 59683 CL1 WWTP Bacau Aktor S.A. (W) GREECE (W) 06 Mar 2013 Works Alternative 9,638,749 project 59783 CL5 Rehabilitation STA Caraboaia SC ERG Termrom ROMANIA (W) 22 Mar 2013 Works Alternative 3,827,326 SA, Conextrust SA, Amici (W) 43548 R2CF Bihor Sub- 59524 CL4 - Tinca WWTP SC OMS Romania ROMANIA (W) 29 Apr 2013 Works Alternative 1,719,678 Project SRL, SC Rono Aqua SRL (W) 59525 CL5 - Extension of sewerage network in Tinca SC SIMBAC SA (W) ROMANIA (W) 27 Mar 2013 Works Alternative 1,265,300

59561 CL9 - Extension of sewerage networks in Osorhei, Alparea, Fughiu SC OMS Romania ROMANIA (W) 06 Jul 2013 Works Alternative 2,067,131 SRL, SC Instalatii Montaj SRL (W)

59567 CL14 - Improvement works to Oradea WWTP SC Keviep Epitoipari ROMANIA (W) 25 Jan 2013 Works Alternative 1,699,292 es Kereskedelmi SRL, SC Rono Aqua SRL (W)

42129 R2CF Buzau sub- 59901 CS3 Audit services SC BDO Audit SRL ROMANIA (W) 19 Aug 2013 Consultant Alternative 26,727 project (W) Services Grand Total 11 45,791,433 (W) Indicates the name and the country of the winning tenderer . All subsequent tenderers listed were unsuccessful in competing for the respective contract.

Annex 11