W912EP-17-B-0003

Jacksonville District

Small Business Set Aside

Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel and Turning Basin, and Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel and Turning Basin

Hillsborough and Manatee Counties, Florida

Construction Solicitation and Specifications Volume 2 of 2

See Volume 1 of 2 for Issue Date

Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 31 21 CONTROL MONUMENT DESCRIPTIONS 00 33 50 WEATHER, WATER STAGE AND TIDE DATA

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK 01 22 00 MEASUREMENT AND PAYMENT 01 30 00 ADMINISTRATIVE PROCEDURES 01 32 01 PROJECT SCHEDULE 01 33 00 SUBMITTAL PROCEDURES 01 35 25 OWNER SAFETY REQUIREMENTS - DIVING 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS 01 45 00 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM) 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL 01 50 02 TEMPORARY CONSTRUCTION FACILITIES 01 57 20 ENVIRONMENTAL PROTECTION 01 57 25 TURBIDITY AND DISPOSAL MONITORING

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 20 23 DREDGING 35 20 26 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM - ULLAGE PROFILE 35 20 28 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM HOPPER DREDGE

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

Designation: 872 6384 E TIDAL PID: AG7341 Stamping: 6384 E 1976 MAN H-2 1987 Stability: Monument will probably hold position well Setting: Massive retaining walls Mark Condition: G Description: THEN PROCEED WEST ON PINEY POINT RD FOR 0.35 MILES, (0.56 KM) THEN PROCEED SW ON HARLEY RD FOR 0.75 MILES (1.21 KM) THRU THE SECURITY GATE, HARLEY THEN TURNS INTO NORTH DOCK RD, STAY STRAIGHT TO THE WATERS EDGE, THE BENCH MARK IS SET IN THE NE CORNER OF THE CONCRETE DOCK ON THE SOUTH SIDE OF THE BOAT BASIN, 1.6 M (5.2 FT) SOUTH OF THE NORTH EDGE OF THE DOCK, AND 1.4 M (4.6 FT) WEST OF THE EAST EDGE OF THE DOCK AND 1.4 M (4.6 FT) NORTH OF A YELLOW STEEL CLEAT SECURED TO THE CONCRETE DOCK. Observed: 2014-02-05T14:31:00Z Source: OPUS - page5 1209.04 See Also 2012-08-08

SECTION 00 31 21 Page 1 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

DESIGNATION - 872 6384 E TIDAL (continued) PID - AG7341 TIDAL BM - This is a Tidal Bench Mark. STATE/COUNTY- FL/MANATEE

This Tidal Bench Mark is designated as VM 7808 by the CENTER FOR OPERATIONAL OCEANOGRAPHIC PRODUCTS AND SERVICES.

Photographs are available for this station.

MARKER: DJ = TIDAL STATION DISK SETTING: 37 = SET IN A MASSIVE RETAINING WALL SP_SET: SEAWALL STAMPING: 6384 E 1976 MAN H-2 1987 MARK LOGO: NOS MAGNETIC: N = NO MAGNETIC MATERIAL STABILITY: B = PROBABLY HOLD POSITION/ELEVATION WELL SATELLITE: THE SITE LOCATION WAS REPORTED AS SUITABLE FOR SATELLITE: SATELLITE OBSERVATIONS - October 25, 2007

HISTORY - Date Condition Report By HISTORY - 1976 MONUMENTED NOS HISTORY - 1982 GOOD FLDNR HISTORY - 20120808 SEE DESCRIPTION FL-081

STATION DESCRIPTION -*- DESCRIBED BY FL DEPT OF NAT RES 1976. 1.2 MI WEST FROM PINEY POINT. FROM THE MAIN INTERSECTION OF US 41 AND A PAVED ROAD AT PINEY POINT PROCEED NORTHWEST ALONG THE PAVED ROAD 0.6 MILES TO AN INTERSECTION WITH A SECOND PAVED ROAD, THENCE SOUTH ALONG THIS PAVED ROAD 0.1 MILES TO AN INTERSECTION WITH A THIRD PAVED ROAD THAT LEADS TO PORT MANATEE TERMINAL, THENCE WEST ALONG THE THIRD PAVED ROAD 0.6 MILES TO A ROAD THAT RUNS BETWEEN TWO BUILDINGS, THENCE SOUTH BETWEEN THE TWO BUILDINGS 0.3 MILES TO SOUTHEAST END OF A BASIN. THE MARK IS AT NORTHEAST CORNER OF A DOCK AREA ON SOUTH SIDE OF THE BASIN, 4.7 FEET WEST OF THE EAST SIDE OF THE DOCK AREA, 5.3 FEET SOUTH OF THE NORTH SIDE OF THE DOCK AREA, SET FLUSH IN THE SOUTH SIDE OF A CONCRETE PAD FOR TWO BOLLARDS.

STATION RECOVERY (1982) -*- RECOVERED IN GOOD CONDITION. NEW DESCRIPTION FOLLOWS. BEGIN AT THE HILLSBOROUGH-MANATEE COUNTY LINE ON U.S. HIGHWAY 41, GO 1.25 MILES SOUTHWEST ON U.S. 41 TO THE JUNCTION OF PINEY POINT ROAD (ACROSS FROM AMAX PHOSPHATE INC.), GO 0.55 MILE NORTHWEST ON PINEY POINT ROAD TO THE JUNCTION OF REEDER ROAD, GO 0.1 MILE SOUTH ON REEDER ROAD TO THE JUNCTION OF THE ENTRANCE ROAD TO PORT MANATEE, GO 0.45 MILE WEST ON THE ENTRANCE ROAD TO THE PORT AND THE MARK VICINITY. *** THE MARK IS SET NEAR THE NORTHEAST CORNER OF THE

SECTION 00 31 21 Page 2 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

CONCRETE DOCK ON THE SOUTH SIDE OF THE PORT BOAT BASIN, 4.7 FEET WEST OF THE EAST EDGE OF THE DOCK, AND 5.3 FEET SOUTH OF THE NORTH EDGE OF THE DOCK.

STATION RECOVERY (2012) -*- THE DISK IS DIFFICULT TO READ. IT IS ALSO AT BIRTH 9, 100 FT NORTH OF SHED 9 AND 265 FT EAST OF THE NORTHWEST END OF SHED 9.

SECTION 00 31 21 Page 3 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

Designation: Q 261 PID: AG6024 Stamping: Q 261 1966 Stability: May hold commonly subject to ground movement Setting: Retaining wall or concrete ledge Mark Condition: Good Description: Station is located at Tampa, on Davis Island at the Peter O. Knight Airport. Mark is about 0.1 mi E of a concrete block maintenance bldg. near the S end of the N/S runway, 60 yds. W of extended CL of runway, 66 ft. SE of the center of the junction of black topped rd. (Severn Drive) and a drive leading to hangers, 51 ft. SW of a fence corner. Mark is about level with road set in top of abandoned concrete seawall which has been filled in, 18 ft. W of an orange witness post and a N/S chain-link fence. Observed: 2009-05-28T12:47:00Z See Also 2008-08-26 See Also Original Source: OPUS - page5 1209.04

SECTION 00 31 21 Page 4 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

DESIGNATION - Q 261 (continued)

PID - AG6024 TIDAL BM - This is a Tidal Bench Mark. STATE/COUNTY- FL/HILLSBOROUGH

This mark is at Peter O'knight Airport (TPF).

This Tidal Bench Mark is designated as VM 6803 by the CENTER FOR OPERATIONAL OCEANOGRAPHIC PRODUCTS AND SERVICES.

MARKER: BENCH MARK DISK SETTING: SET IN A RETAINING WALL OR CONCRETE LEDGE STAMPING: Q 261 1966 MARK LOGO: CGS MAGNETIC: NO MAGNETIC MATERIAL STABILITY: MAY HOLD, BUT OF TYPE COMMONLY SUBJECT TO SURFACE MOTION. SATELLITE: THE SITE LOCATION WAS REPORTED AS SUITABLE FOR SATELLITE OBSERVATIONS - August 26, 2008.

HISTORY - Date Condition Report By HISTORY - 1966 MONUMENTED CGS HISTORY - 20030920 GOOD USPSQD HISTORY - 20080826 GOOD FLDEP

STATION DESCRIPTION -*- AT TAMPA, ON DAVIS ISLAND AT THE PETER O. KNIGHT AIRPORT, ABOUT 0.1 MILE EAST OF THE ADMINISTRATION BUILDING, NEAR THE SOUTH END OF NORTH-SOUTH RUNWAY, 60 YARDS WEST OF THE EXTENDED CENTER LINE OF THE RUNWAY, 66 FEET SOUTHEAST OF THE CENTER OF THE JUNCTION OF A BLACK TOPPED ROAD AND A DRIVE LEADING TO THE HANGARS, 51 FEET SOUTHWEST OF A FENCE CORNER, ABOUT LEVEL WITH THE BLACK TOPPED ROAD AND SET IN THE TOP OF A CONCRETE SEA WALL WHICH IS NOT IN USE AND HAS BEEN FILLED IN ON BOTH SIDES.

STATION RECOVERY (2003) -*- FOUND IN GOOD CONDITION. ADMINISTRATION BUILDING IN 1966 DESCRIPTION NO LONGER EXISTS. A NEW CONCRETE BLOCK MAINTENANCE BUILDING WAS BUILT ON THE SAME SITE. MARK IS LOCATED IN AN ABANDONED SEA WALL LOCATED 18 FEET WEST OF AN ORANGE WITNESS POST AND A NORTH/SOUTH CHAIN LINK FENCE. THE BLACK-TOPPED ROAD IS SEVERN DRIVE. REMAINDER OF 1966 DESCRIPTION IS CORRECT.

STATION RECOVERY (2008) -*- RECOVERY NOTE BY FL DEPT OF ENV PRO 2008 (BPJ) -*- RECOVERED AS DESCRIBED.

SECTION 00 31 21 Page 5 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

Manatee Harbor Survey Control

NOTE: There are two survey control monuments at this project that are named “872 6384 K”. One is from 2004 and the other is from 2007. Use caution when establishing staff gauges or calibrating equipment for “real time” positioning operations. Monument “872 6384 K (2004)” was positioned by a long term (>4 hours) GPS observation and is stored in the NGS OPUS-DB system having a permanent Identifier (PID) of BBBT27. This monument is mainly used for horizontal positioning.

Monument “872 6384 K TIDAL (2007)” is a “tidal datum mark”, and is often, but not always, used for vertical datum calibration and verification of field operations. Other tidal datum marks exist and the survey notes should be consulted to verify which was used for a specific survey.

SECTION 00 31 21 Page 6 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

Designation: 872 6384 K (2004) PID: BBBT27 Stamping: 6384 K 2004 Stability: Monument will probably hold position well Setting: Retaining wall or concrete ledge Description: From the intersection of I-275 and US 41, proceed North on US 41 for 3.3 miles to Piney Point Road. Turn Left on Piney Point Road for 0.4 miles to Port Manatee Security Gate.

Enter Port Security Gate on North Dock Street for 0.5 miles to Eastern Avenue. Turn right on Eastern Ave. proceed 0.15 miles and bear left on Coastal Street. Take Coastal Street to end. Mark is located on the northwest corner of the seawall. Observed: 2009-04-28T13:56:00Z Source: OPUS - page5 1209.04 See Also Original

SECTION 00 31 21 Page 7 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

DESIGNATION - 872 6384 K TIDAL (2007) PID - DL1871 TIDAL BM - This is a Tidal Bench Mark.

MARKER: SURVEY DISK SETTING: SET IN A MASSIVE RETAINING WALL STAMPING: 6384 K 2007 MARK LOGO: FLDEP MAGNETIC: NO MAGNETIC MATERIAL STABILITY: PROBABLY HOLD POSITION/ELEVATION WELL SATELLITE: THE SITE LOCATION WAS REPORTED AS SUITABLE FOR SATELLITE OBSERVATIONS - November 07, 2007

SECTION 00 31 21 Page 8 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

DESIGNATION - 872 6384 K TIDAL (2007) (continued)

STATION DESCRIPTION -- TO REACH FROM THE INTERSECTION OF INTERSTATE 275 (EXIT 2) AND U.S. HIGHWAY 41 (TAMIAMI TRAIL) UNDERPASS IN RUBONIA, GO NORTHERLY ON U.S. HIGHWAY 41 FOR 3.35 MI TO THE JUNCTION OF PINEY POINT ROAD ON THE LEFT, TURN LEFT ON PINEY POINT ROAD AND GO NORTHWEST FOR 0.45 MI TO THE ENTRANCE TO THE ACCESS CONTROL CENTER OF PORT MANATEE ON THE LEFT, AFTER OBTAINING PASSAGE FROM CONTROL CENTER, CONTINUE THROUGH THE GATE GO WEST ON NORTH DOCK STREET FOR 0.45 MI TO THE ENTRANCE DRIVE INTO THE PORTS BERTH 7 ON THE LEFT, TURN LEFT AND GO SOUTHERLY FOR 0.05 MI TO THE MARK ON THE RIGHT, SET FLUSH IN THE TOP OF THE CONCRETE SEAWALL IN THE NORTHEAST CORNER OF THE BOAT BASIN.

LOCATED 468.0 FT NORTHEAST OF NOS TIDAL STATION DISK STAMPED 6384 C 1976, 83.0 FT EAST-NORTHEAST OF FLDEP SURVEY DISK STAMPED 6384 L 2007, 50.3 FT SOUTHEAST OF THE FIRST MOORING BOLLARD WEST OF THE NORTHEAST CORNER OF THE BOAT BASIN, 45.6 FT NORTH OF THE FIRST MOORING BOLLARD SOUTH OF THE NORTHEAST CORNER OF THE BOAT BASIN AND 42.4 FT WEST-NORTHWEST OF THE WEST FACE OF WAREHOUSE NUMBER TWO.

SECTION 00 31 21 Page 9 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

U.S. DEPARTMENT OF COMMERCE National Oceanic and Atmospheric Administration National Ocean Service

Station ID: 8726384 PUBLICATION DATE: 10/06/2010 Name: PORT MANATEE, TAMPA BAY, FLORIDA NOAA Chart: 11416 Latitude: 27° 38.3' N USGS Quad: COCKROACH BAY Longitude: 82° 33.7' W

To reach the tidal bench marks from the main intersection of U.S. Highway 41 and a medium duty road at Piney Point, proceed NW along the medium duty road for 1.0 km (0.6 mi) to an intersection with a light duty road, continue south along the light duty road for 0.2 km (0.1 mi) to an intersection with a second light duty road leading to the Port Manatee Terminal, continue west along this road for 1.0 km (0.6 mi) to a road that runs between two buildings, proceed south between the two buildings to a turning basin. The bench marks are around the basin in the port area. The tide station is located just north of the NW corner of the turning basin along the bulkhead fronting the bay, near Berth 5.

T I D A L B E N C H M A R K S

PRIMARY BENCH MARK STAMPING: 6384 E 1976 DESIGNATION: 872 6384 E TIDAL MONUMENTATION: Tidal Station disk VM#: 7808 AGENCY: National Ocean Survey (NOS) PID#: AG7341 SETTING CLASSIFICATION: Concrete dock

The primary bench mark is a disk set in the NE corner of the concrete dock on the south side of the boat basin, 1.6 m (5.2 ft) south of the north edge of the dock, 1.4 m (4.6 ft) west of the east edge of the dock, and 1.4 m (4.6 ft) north of a yellow steel cleat secured to the concrete dock.

BENCH MARK STAMPING: 6384 C 1976 DESIGNATION: 872 6384 C TIDAL

MONUMENTATION: Tidal Station disk VM#: 7807 AGENCY: National Ocean Survey (NOS) PID#: AG7340 SETTING CLASSIFICATION: Building foundation

The bench mark is a disk set in the concrete footing of a blue aluminum building (warehouse) located east of the Port Manatee turning basin area, 43.37 m (142.29 ft) east of the easternmost bulkhead of the basin, 1.19 m (3.90 ft) north of the southernmost garage door of two doors on the west side of the building, and 0.30 m (0.98 ft) west of the building.

SECTION 00 31 21 Page 10 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

BENCH MARK STAMPING: 6384 F 1976 DESIGNATION: 872 6384 F TIDAL

MONUMENTATION: Tidal Station disk VM#: 7809 AGENCY: National Ocean Survey (NOS) PID#: AG7342 SETTING CLASSIFICATION: base of structure

The bench mark is a disk set in the south side of a concrete pad for two bollards at the NW corner of the dock on the south side of the Port Manatee Boat basin, 1.46 m (4.79 ft) south of the north edge of the dock, and 1.37 m (4.49 ft) east of the west edge of the dock.

BENCH MARK STAMPING: 6384 K 2004 DESIGNATION: 872 6384 K MONUMENTATION: Tidal Station disk VM#: 17596 AGENCY: National Ocean Service (NOS) PID: SETTING CLASSIFICATION: Sea wall

The bench mark is a disk set in the western sea wall 80.25 m (263.29 ft) SW from the western corner of the Florida Fish and Wildlife building at the entrance the pump station, 52.50 m (172.24 ft ) SW of Fire hydrant K81A in the NE corner of the parking lot, 10.20 m (33.46 ft) SW from the center of the only bollard on the north sea wall, and 6.40 m (21.00 ft) NE of the most northern bollard on the western sea wall.

BENCH MARK STAMPING: 6384 L 2004 DESIGNATION: 872 6384 L MONUMENTATION: Tidal Station disk VM#: 17597 AGENCY: National Ocean Service (NOS) PID: SETTING CLASSIFICATION: concrete Sea wall

From the junction of U.S. 275 south and U.S. 41 north, proceed 5.5 km (3.4 mi) on U.S 41 north, then proceed west on Piney point Rd for 0.5 km (0.35 mi), then proceed SW on Harley rd for 1.21 km (0.75 mi) thru the security gate, Harley Rd then turns into North Dock Rd, the bench mark is a disk set flush in the western sea wall, 55.29 m (181.40 ft) NW from the NW corner of the Fraternidad Service Corp., 13.38 m (43.90 ft) NE from the 9th bollard from the north on the western sea wall, 3.15 M (10.33 ft) SE from the 8th bollard from the north on the western sea wall.

SECTION 00 31 21 Page 11 SECTION 00 31 21 CONTROL MONUMENT DESCRIPTIONS

T I D A L D A T U M S

Tidal datums at PORT MANATEE, TAMPA BAY based on:

LENGTH OF SERIES: 9 YEARS TIME PERIOD: December 1999 - November 2008 TIDAL EPOCH: 1983-2001 CONTROL TIDE STATION: 8726520 ST. PETERSBURG, TAMPA BAY

Elevations of tidal datums referred to Mean Lower Low Water (MLLW):

METERS MEAN HIGHER HIGH WATER MHHW = 0.669 MEAN HIGH WATER MHW = 0.585 North American Vertical Datum 1988 NAVD88 = 0.471 MEAN SEA LEVEL MSL = 0.355 MEAN LOW WATER MLW = 0.112 MEAN LOWER LOW WATER MLLW = 0.000

Bench Mark Elevation Information In METERS above:

Stamping or Designation MLLW 6384 E 1976 2.604 6384 C 1976 2.980 6384 F 1976 2.589 6384 K 2004 2.585 6384 L 2004 2.585

SECTION 00 31 21 Page 12 SECTION 00 33 50 WEATHER, WATER STAGE AND TIDE DATA

1. The following water stage, wave, wind, and weather data are provided for inclusion into the subject Plans and Specifications. The following water level datums are provided for information only and are not to be utilized in conjunction with any contract related hydrographic surveying.

2. A technical review has been performed on the following data and this memo, signed by Chief, Water Resources Engineering Branch, signifies EN-W Branch Quality Control Certification.

a) Water Stages. Water levels in the project area are mainly affected by wind and tidal fluctuations of the Gulf of Mexico and Tampa Bay which are mixed (diurnal and semi-diurnal). The project area is also subject to storm surges from hurricanes and tropical storms from June through November. Surges from extratropical storms may affect the area during any time of the year.

Elevations of tidal datums in the vicinity of the project area are provided in the following table. All datum elevations in this table are referred to mean lower low water (MLLW). The datums in Table 1 and Table 2 are taken from tide station 8726384 (Port Manatee, FL) and tide station 8726572 (The Kitchen, FL) and are based on the 1983-2001 tidal epoch. The Port Manatee tide station tidal datum analysis period was established by the National Oceanic and Atmospheric Administration (NOAA), National Ocean Service (NOS), on 1 December 1999 and continued to 30 November 2008. The Kitchen tide station tidal datum analysis period was established by the NOAA NOS, on 1 December 1978 and continued to 31 December 1978. It was then re- established on 1 February 1979 and continued to 31 March 1979. This tide station was established by the NOAA NOS. Additional information on these and other nearby tide stations is available at this NOAA website: https://tidesandcurrents.noaa.gov/map/index.shtml?type=BenchMarkSheets®ion=Florida.

Table 1. Datum Information for Tide Station 8726384

Station ID: 8726384 PUBLICATION DATE: 9/28/2010 Name: Port Manatee, FL NOAA Chart: 11416 Latitude: 27° 38.3' N USGS Quad: Cockroach Bay Longitude: 82° 33.8' W

Highest Observed Water Level (6 Sept 04) = 4.49 Feet Mean Higher High Water (MHHW) = 2.20 Feet Mean High Water (MHW) = 1.92 Feet North American Vertical Datum – 1988 (NAVD) = 1.55 Feet Mean Sea Level (MSL) = 1.17 Feet Mean Tide Level (MTL) = 1.15 Feet Mean Low Water (MLW) = 0.37 Feet Mean Lower Low Water (MLLW) = 0.00 Feet Lowest Observed Water Level (3 Jan 08) = -2.02 Feet

SECTION 00 33 50 Page 1 SECTION 00 33 50 WEATHER, WATER STAGE AND TIDE DATA

Table 2. Datum Information for Tide Station 8726572

Station ID: 8726572 PUBLICATION DATE: 8/30/2007 Name: The Kitchen, FL NOAA Chart: 11413 Latitude: 27° 49.2' N USGS Quad: Gibsonton Longitude: 82° 23.2' W

Highest Observed Water Level = Not Available Mean Higher High Water (MHHW) = 2.41 Feet Mean High Water (MHW) = 2.13 Feet North American Vertical Datum – 1988 (NAVD) = 1.51 Feet Mean Sea Level (MSL) = 1.23 Feet Mean Tide Level (MTL) = 1.23 Feet Mean Low Water (MLW) = 0.34 Feet Mean Lower Low Water (MLLW) = 0.00 Feet Lowest Observed Water Level (3 Jan 08) = Not Available

Daily tidal predictions at locations along the coastlines of North and South America, including locations in the vicinity of the project area can be found in the publication East Coast of North and South America Tide Tables, U.S. Department of Commerce, National Oceanic and Atmospheric Administration, National Ocean Service.

In addition to daily tidal predictions, this publication provides mean and spring tide ranges and mean tide levels. Some astronomical data is also included, such as time of sunrise, sunset, moonrise, and moonset. This publication is available through NOAA. Tidal data provided in this publication can also be found at the following NOAA website: http://tidesandcurrents.noaa.gov/.

b) Wind and Wave Data. The following publications include wind and wave information in the vicinity of the project area. These publications are available for review at the following websites, or they may be ordered directly from the agencies indicated.

1. U.S. Coast Pilot Volume 5, Atlantic Coast: Gulf of Mexico, Puerto Rico and Virgin Islands, U.S. Department of Commerce, National Oceanic and Atmospheric Administration, National Ocean Service. This publication supplements the navigational information shown on the NOAA/NOS nautical charts, and also provides miscellaneous meteorological data. This publication can be purchased through NOAA, and is available for review at the following website : http://nauticalcharts.noaa.gov/nsd/cpdownload.htm. .

2. U. S. Army Corps of Engineers’ Coastal & Hydraulics Laboratory, Wave Information Study (WI S) Database. This Internet webpage presents wave hindcast data for various stations located along the Atlantic and Gulf of Mexico coastlines within the United States. The closest of these stations (#73270) lies near the seaward end of the Tampa Harbor entrance channel , at latitude 27.6° and longitude -82.9°. A vai l abl e data i ncl udes a hi ndcast ti me seri es of wave

SECTION 00 33 50 Page 2 SECTION 00 33 50 WEATHER, WATER STAGE AND TIDE DATA

heights, periods, and directi ons taken at 1-hour intervals for the 24-year period extending from 1980-2004, at a stati on l ocated i n 10 meters (33 f eet) of water. Thi s webpage al so provi des l i nks to WI S summary tabl es and pl ots, as wel l as other sources of wave data. These data products are avai l abl e at the f ol l owi ng websi te: http://wis.usace.army.mil/. .

3. National Data Buoy Center (NDBC) Website. This Internet website provides a wide range of real-time and archived meteorological and oceanographic data collected at offshore and nearshore stations worldwide. Data provided on this website includes wind speed, wind gusts, atmospheric pressure, air temperature, sea temperature, wave height, and wave period. Gage readings are updated hourly, and archived data is available for most stations. The website address for data relevant to this project site is http://www.ndbc.noaa.gov/maps/Florida.shtml.

c) Weather Conditions. The project area is subject to tropical storms and hurricanes from June through November, and to windy and/or rainy weather during any time of the year. The climate of the area is essentially tropical, and temperatures below freezing are rare. The wet season in the project area is from May through October. Rainfall during these months is closely associated with convective activity. These rainfall events are normally of short duration and amounts are spatially variable. In general, the winter months constitute the dry season. Rainfall during the winter months is usually associated with mid-latitude systems (fronts and low pressure systems) and is distributed in a more spatially uniform pattern. Occasionally, daily rainfall in the dry season can be quite heavy as mid-latitude systems penetrate into central Florida. Dangerous thunderstorms can occur in this area at any time of the year.

It shall be the contractor's responsibility to obtain information concerning weather conditions in the project area. The Climate Data Online website http://www.ncdc.noaa.gov/cdo-web/ published by NOAA’s National Centers for Environmental Information (formerly the National Climatic Data Center) in Asheville, North Carolina contains climatological and meteorological observations and data relevant to this region. Available data includes quality controlled daily, monthly, seasonal, and yearly measurements of temperature, precipitation, wind, and degree days as well as radar data and 30-year climate normals.

The Summary of Monthly Normals product available at the following web link provides monthly average values for temperature, precipitation, and other information. The Tampa Intl AP, Florida, NOAA rain gage in proximity to the project location provides a Summary of Monthly Normals over the period of record from 1981 through 2010. This station is located at latitude 27° 58’ N, longitude 82° 32’ W and data can be accessed through: http://www.ncdc.noaa.gov/cdo- web/datatools/normals

SECTION 00 33 50 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 REFERENCES 1.2 WORK COVERED BY CONTRACT DOCUMENTS 1.2.1 Project Description 1.2.2 Location 1.2.3 Safety Requirements 1.2.4 Work Performed by Others 1.3 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK 1.4 LIQUIDATED DAMAGES - CONSTRUCTION 1.5 PHYSICAL DATA 1.5.1 Physical Conditions 1.5.2 Weather, Water Stage and Tide Data 1.5.3 Contractor Investigation 1.5.4 Maritime Traffic 1.5.5 Obstruction of Channel 1.5.6 Hydrographic Surveys 1.6 LAYOUT OF WORK 1.6.1 Established Project Control 1.6.2 Layout 1.6.3 Survey 1.7 DAMAGE TO WORK

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 11 00 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

GDRs SECTION 00 31 32 Geotechnical Data Report for Alafia River Maintenance Dredging, Entrance Channel and Turning Basin, 32-Foot Project, Hillsborough County, Florida; and SECTION 00 31 32 Geotechnical Data Report for Manatee Harbor Maintenance Dredging, Entrance Channel and Turning Basin, 40-Foot Project, Manatee County, Florida (Two Documents)

EM 385-1-1 Safety and Health Requirements Manual

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

Project work will be divided into a Base plus four options. The Base of work includes dredging shoal material from the Alafia River Channel and disposal of material into DMPF 3-D. The required depth for Alafia River is 33 and 34 feet with one foot of allowable overdepth. The four options consists of maintenance dredging of the Alafia River Channel and Turning Basin, as well as the Manatee Harbor Entrance Channel and the Turning Basin. The required depth for Manatee Harbor is 40 feet with one foot of allowable overdepth. All excavated material from Manatee Harbor will be placed in the designated upland disposal area. Work also includes environmental species observers, turbidity monitoring, bird monitoring, sea turtle trawl sweeping and relocation, mobilization, and operation and maintenance of DMPF 3-D and the Manatee Harbor upland disposal area at the direction of the Contracting Officer.

1.2.2 Location

The Tampa Harbor work is located in Hillsborough Bay, Hillsborough County, Florida. The Mantee Harbor work is located in Manatee County, Florida. Both project sites are accessible by water from the surrounding bays. The Upland Disposal Area, upland pipeline route, and return water ditches at the Manatee Harbor portion of the project can be accessed by land.

1.2.3 Safety Requirements

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS and EM 385-1-1.

W912EP-17-B-0003 SECTION 01 11 00 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.2.4 Work Performed by Others

See paragraph PROJECT COORDINATION of Section 01 30 00 ADMINISTRATIVE PROCEDURES.

1.3 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK

a. Read this paragraph in conjunction with the Clause COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (FAR 52.211-10) of Section 00700 CONTRACT CLAUSES in Volume 1.

b. In addition to the above, the following shall apply: The phrase "commence work" means "commence dredging". The commencement time indicated applies unless precluded by inclement weather as determined by the Contracting Officer.

1.4 LIQUIDATED DAMAGES - CONSTRUCTION

Refer to the Clause LIQUIDATED DAMAGES - CONSTRUCTION (FAR 52.211-12) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.5 PHYSICAL DATA

Read this paragraph in conjunction with the Clause PHYSICAL DATA (FAR 52.236-4) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.5.1 Physical Conditions

The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys and/or by core borings. When the indicated physical conditions are the result of site investigations by core borings, the core boring logs and laboratory data are in two Geotechnical Data Reports (GDRs) indicated in paragraph REFERENCES above, and the core boring locations are shown on the drawings. Also, see the GDRs for instructions concerning availability of core borings for inspection.

1.5.2 Weather, Water Stage and Tide Data

See Section 00 33 50 WEATHER, WATER STAGE AND TIDE DATA.

1.5.3 Contractor Investigation

Refer to the Clause SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (FAR 52.236-3) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.5.4 Maritime Traffic

Marine traffic in the project area consists of Naval, cruise ships, commercial, pleasure, and small recreational vessels of all types and sizes which can be accommodated by existing depths.

1.5.5 Obstruction of Channel

The Government will not undertake to keep the channel free from vessels or other obstructions, except to the extent of such regulations, if any, as may be prescribed by the Secretary of the Army, in accordance with the provisions of Section 7 of the River and Harbor Act approved 8 August

W912EP-17-B-0003 SECTION 01 11 00 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1917. The Contractor will be required to conduct the work in such manner as to obstruct navigation as little as possible, and in case the Contractor's plant so obstructs the channel as to make difficult or endanger the passage of any vessels, said plant shall be promptly moved on the approach of any vessel to such an extent as may be necessary to afford a practicable passage. Upon completion of the work the Contractor shall promptly remove his plant, including ranges, buoys, piles, and other marks placed by him under the contract in navigable waters or on shore.

1.5.6 Hydrographic Surveys

Hydrographic surveys are posted at the following web address: http://www.saj.usace.army.mil/Missions/CivilWorks/Navigation/HydroSurveys Survey numbers are indicated on the drawings.

1.6 LAYOUT OF WORK

Read this paragraph in conjunction with the Clause LAYOUT OF WORK (FAR 52.236-17) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.6.1 Established Project Control

The Government has established monuments along the work site(s). Each monument is represented in the contract drawings by a Designation and in most cases, an alphanumeric Permanent Identifier (PID). Information concerning the location and elevations can be found within the Survey Notes on the plan sheets. The Survey Notes for each included field survey will cite a particular survey number, and specify the control used to conduct that survey. Additional information is included in the Survey Notes that must be duplicated if an attempt to recreate the subject survey is desired.

For navigation channels, the Government has established tidal calibration sites for projects constructed and maintained to a tidal datum. Each tidal calibration site is represented in the plan sheet drawings by Station ID, and is cited in the Survey Notes. All projects constructed and maintained to a tidal datum shall be calibrated to the Station ID specified in the plan sheet drawings. Information regarding the location and associated benchmarks of the referenced Station ID is included in the Monument Description section of these specifications.

See Section 00 31 21 CONTROL MONUMENT DESCRIPTIONS.

1.6.2 Layout

From the monuments, control data and elevations established by the Government, the Contractor shall complete the layout of the work and shall be responsible for all measurements that may be required for the execution of the work to the location and limit marks prescribed in the specifications or on the contract drawings, subject to such modifications as the Contracting Officer may require to meet changed conditions or as a result of necessary modifications to the contract work.

1.6.3 Survey

The Contractor shall furnish, at his own expense, such stakes, templates, platforms, equipment, tools and material, and all labor as may be required in laying out any part of the work from the monuments, control data and elevations established by the Government. It shall be the responsibility

W912EP-17-B-0003 SECTION 01 11 00 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

of the Contractor to maintain and preserve all stakes and other marks established by the Contracting Officer until authorized to remove them, and if such marks are destroyed by the Contractor or through his negligence, prior to their authorized removal, they may be replaced by the Contracting Officer, at his discretion, and the expense of replacement will be deducted from any amounts due or to become due the Contractor. The Contracting Officer may require that work be suspended at any time when location and limit marks established by the Contractor are not reasonably adequate to permit checking of the work.

1.7 DAMAGE TO WORK

The responsibility for damage to any part of the permanent work shall be as set forth in Clause PERMITS AND RESPONSIBILITIES of Section 00700 CONTRACT CLAUSES in Volume 1. However, if, in the judgment of the Contracting Officer, any part of the permanent work performed by the Contractor is damaged by flood, earthquake, hurricane, or tornado, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound engineering and construction practices in the conduct of the work, the Contractor will make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable contract unit or lump sum prices as fixed and established in the contract. If, in the opinion of the Contracting Officer, there are no contract unit or lump sum prices applicable to any part of such work, an equitable adjustment pursuant to Clause CHANGES of Section 00700 CONTRACT CLAUSES in Volume 1 will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or lump sum prices. Except as herein provided, damage to all work (including temporary construction), utilities, materials, equipment and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section --

W912EP-17-B-0003 SECTION 01 11 00 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 22 00

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1.1 SUMMARY 1.1.1 Reference 1.2 RESIDENT MANAGMENT SYSTEM (RMS) 1.2.1 Definition 1.2.2 Instructions 1.3 SUBMITTALS 1.4 JOB PAYMENT ITEMS 1.4.1 Mobilization and Demobilization (Line Item 0001) 1.4.2 Interim Mobilization (Line Item 0016) 1.4.3 Turbidity Monitoring (Line Items 0003, 0010, 0018, 0025 and 0032) 1.4.4 Environmental Species Observers (Line Items 0004, 0011, 0019, 0026 and 0033) 1.4.5 Mobilization and Demobilization for Sea Turtle Trawling and Relocation (For Hopper Dredges Only)(Line Items 0005, 0012, 0020, 0027 and 0034) 1.5 UNIT PRICE PAYMENT ITEMS 1.5.1 Excavation, Unclassified (Line Items 0002, 0009, 0017, 0024 and 0031) 1.5.1.1 Payment 1.5.1.2 Measurement 1.5.1.3 Unit of Measure 1.5.2 Sea Turtle Trawling and Relocation (For Hopper Dredges Only)(Line Items 0006, 0013, 0021, 0028 and 0035) 1.5.2.1 Payment 1.5.2.2 Measurement 1.5.2.3 Unit of Measure 1.5.3 Standby Time (Line Items 0007, 0014, 0022, 0029 and 0036) 1.5.3.1 Measurement and Payment 1.5.3.2 Unit of Measure 1.5.4 Bird Monitoring (Line Items 0008, 0015, 0023, 0030 and 0037) 1.5.4.1 Payment 1.5.4.2 Measurement 1.5.4.3 Unit of Measure

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 PAYMENT PROCEDURES 3.1.1 Requesting Progress Payment 3.1.2 Options and Modification CLINS

W912EP-17-B-0003 SECTION 01 22 00 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 22 00 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 22 00

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1.1 SUMMARY

This section describes how Line Items will be measured and paid for when making progress payments. Work to be measured is described in specification sections listed for each Line Item. Measurement procedures for payment, required quantity survey or procurement documentation and payment restrictions are described in applicable specification sections. Allocate costs for work not specifically mentioned to the Line Item most closely associated with work involved. Unless there is a specific Line Item for administrative costs, such as Quality Control and Safety, allocate such costs proportionally across all Line Items.

1.1.1 Reference

The publication listed below forms a part of this specification to the extent referenced. This publication is referred to in the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 1110-2-1003 (2013) Engineering and Design, Hydrographic Surveying

1.2 RESIDENT MANAGMENT SYSTEM (RMS)

1.2.1 Definition

The terms "Contract Line Item Number (CLIN)" and "Line Item" are interchangeable herein (e.g.: CLIN 0001 is Line Item 0001). The term "CLIN" is a contracting term used in the Resident Management System (RMS) payment data base.

1.2.2 Instructions

See Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL for instructions on linking a CLIN to a schedule of values of pay activities and construction schedule, and in-depth payment procedure.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Transmit submittal items in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

W912EP-17-B-0003 SECTION 01 22 00 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Schedule of Values; G, RO

Provide a breakdown of job items into proposed pay activities. Schedule of Values will become basis for CLIN and Pay Activity data in the RMS payment data base.

1.4 JOB PAYMENT ITEMS

Payment items for the work of this contract for which contract job payments will be made are listed in the LINE ITEMS AND PRICING SCHEDULE with the unit "JOB" and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, shall be included in the listed job item most closely associated with the work involved. The job price and payment made for each item listed shall constitute full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

Progress payments for job CLINs will be made in accordance with the Payments Under Fixed-Price Construction Contracts clause of Section 00700 CONTRACT CLAUSES in Volume 1. Provide a list of pay activities, (Schedule of Values) to breakdown bid for each job CLIN. Within 20 calendar days after receiving Notice to Proceed, submit Schedule of Values for Government approval. An unbalanced Schedule of Values and Pay Activity Schedule will be returned for revision. If this contract contains either the Continuing Contracts clause or the Continuing Contracts (Alternate) clause, the Contractor should take into account the amount reserved for contract payments when preparing the construction schedule.

1.4.1 Mobilization and Demobilization (Line Item 0001)

Payment will be made for costs associated with or incidental to mobilization demobilization, weir repair and establishment of initial project management and coordination. See Clause PAYMENT FOR MOBILIZATION AND DEMOBILIZATION of Section 00700 CONTRACT CLAUSES in Volume 1.

1.4.2 Interim Mobilization (Line Item 0016)

Payment will be made for costs associated with or incidental to mobilization, weir repair, and relocation of pipeline and equipment needed to exercise option(s).

1.4.3 Turbidity Monitoring (Line Items 0003, 0010, 0018, 0025 and 0032)

Payment will be made for costs associated with or incidental to obtaining, analyzing, and reporting the results of monitoring for turbidity. See Section 01 57 25 TURBIDITY AND DISPOSAL MONITORING.

1.4.4 Environmental Species Observers (Line Items 0004, 0011, 0019, 0026 and 0033)

Payment will be made for costs associated with or incidental to endangered species observers. See Section 01 57 20 ENVIRONMENTAL PROTECTION.

W912EP-17-B-0003 SECTION 01 22 00 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.4.5 Mobilization and Demobilization for Sea Turtle Trawling and Relocation (For Hopper Dredges Only)(Line Items 0005, 0012, 0020, 0027 and 0034)

Payment will be made for costs associated with or incidental to mobilization and demobilization for sea turtle trawling and relocation (For Hopper Dredges Only). See Clause PAYMENT FOR MOBILIZATION AND DEMOBILIZATION of Section 00700 CONTRACT CLAUSES in Volume 1. Also, see Section 01 57 20 ENVIRONMENTAL PROTECTION.

1.5 UNIT PRICE PAYMENT ITEMS

Payment items for the work of this contract on which the contract unit price payments will be made are listed in the LINE ITEMS AND PRICING SCHEDULE and described below. The unit price and payment made for each item listed shall constitute full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for each of the unit price items.

Each Unit Price CLIN may be a single pay activity item or may be broken down into pay activities with smaller quantities equal to CLIN total. Contract unit price multiplied by agreed quantity is full compensation.

1.5.1 Excavation, Unclassified (Line Items 0002, 0009, 0017, 0024 and 0031)

1.5.1.1 Payment

a. Payment will be made for costs associated with or incidental to excavation, transportation, and disposal of materials; providing and maintaining access to the work site(s) and disposal area(s); noise control; debris removal; installation, bird deterrence within DMPF-3D and the Manatee Harbor upland disposal area, operation or maintenance of the electronic tracking system for surveillance of all dredging and disposal activities. See Section 35 20 23 DREDGING.

b. Insofar as consistent with the paragraph CONTINUITY OF WORK of Section 35 20 23 DREDGING, monthly partial payments will be based on approximate quantities determined by soundings or sweepings performed by the Contractor behind the dredge. The term "area designated by the Contracting Officer" as used in the CONTINUITY OF WORK paragraph, is defined as "acceptance section".

c. Hydrographic surveys for final measurement and payment and for channel clearance will be made by the Government. All surveys will be performed in accordance with USACE EM 1110-2-1003. Survey frequencies will be the same as those shown in the drawings and will remain consistent throughout the contract.

1.5.1.2 Measurement

a. The maps and/or drawings already prepared (clause CONTRACT DRAWINGS, MAPS, AND SPECIFICATIONS of Section 00700 CONTRACT CLAUSES in Volume 1) are believed to represent accurately average existing conditions, but the depths shown thereon may be verified and corrected by soundings taken before dredging. Once quantities within a specified reach or section have been determined through the use of in-place measurement, they will not be reopened except on evidence of

W912EP-17-B-0003 SECTION 01 22 00 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

collusion, fraud, or obvious error.

b. The total amount of material removed, and to be paid for under the contract, will be measured by the cubic yard in place and quantities determined by the surface to surface TIN comparison method. The volume computed shall be between the bottom surface shown by soundings taken within 3 weeks before dredging and the bottom surface shown by the soundings taken within 2 weeks after the work specified in each acceptance section indicated on the drawings has been completed. The Contractor shall give 10 days advance notice, in writing, to the Contracting Officer's Representative of the need for a pre-dredging survey or after-dredging survey for final acceptance for each acceptance section. The quantity shall include the volume within the limits of the side slopes described in subparagraph "Side Slopes" of paragraph REQUIRED DEPTH, ALLOWABLE OVERDEPTH, AND SIDE SLOPES of Section 35 20 23 DREDGING, less any deductions that may be required for misplaced material described in subparagraph "Misplaced Materials" of paragraph DISPOSAL OF EXCAVATED MATERIAL of Section 35 20 23 DREDGING.

1.5.1.3 Unit of Measure

Cubic yard.

1.5.2 Sea Turtle Trawling and Relocation (For Hopper Dredges Only)(Line Items 0006, 0013, 0021, 0028 and 0035)

1.5.2.1 Payment

Payment will be made for costs associated with or incidental to the Sea Turtle Capture Trawl Sweeping. This price shall include all costs for furnishing labor, equipment, fuel, oil, materials, and supplies required for trawl sweeping to clear and/or relocate sea turtles from in the vicinity of the dredge, and shall include the cost of reporting as specified. See Section 01 57 20 ENVIRONMENTAL PROTECTION.

1.5.2.2 Measurement

Sea Turtle Capture Trawl Sweeping will be measured for payment based upon the duration of performance on a daily basis. A day of trawl sweeping is defined as 24 hours of continuous trawling. The Contractor shall conduct captive trawl sweeping as described in Section 01 57 20 ENVIRONMENTAL PROTECTION.

1.5.2.3 Unit of Measure

Day.

1.5.3 Standby Time (Line Items 0007, 0014, 0022, 0029 and 0036)

1.5.3.1 Measurement and Payment

Standby time for dredging will be paid for each hour or part thereof that the plant is not in operation by request of the Contracting Officer. Payment will be made for costs associated with or incidental to standby of the dredge plant only upon implementation of this line item. If performance of this line item is not required or implemented per the NOTES in Section 00010A LINE ITEMS AND PRICING SCHEDULE, no payment will be made to the Contractor for this line item.

W912EP-17-B-0003 SECTION 01 22 00 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.5.3.2 Unit of Measure

Hour.

1.5.4 Bird Monitoring (Line Items 0008, 0015, 0023, 0030 and 0037)

1.5.4.1 Payment

Payment will be made for costs associated with or incidental to furnishing a Bird Monitor. See Section 01 57 20 ENVIRONMENTAL PROTECTION. Payment will be made for costs associated with or incidental to bird monitoring only upon implementation of this line item. If performance of this line item is not required or implemented per the NOTES in Section 00010A LINE ITEMS AND PRICING SCHEDULE, no payment will be made to the Contractor for this line item.

1.5.4.2 Measurement

Measurement will be made by the number of days the Bird Monitor is onsite monitoring birds during the designated monitoring period. If multiple phases of work are concurrent, payment will only be made for the Line Item associated with the Phase of work that began first. See Section 01 57 20 ENVIRONMENTAL PROTECTION.

1.5.4.3 Unit of Measure

Day.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 PAYMENT PROCEDURES

Upon receiving initial Resident Management System import file, go to "Pay Activities" and establish a link between bid breakdown schedule of values of "Pay Activities" to contract CLINs using "Schedule Activities" data entry page.

3.1.1 Requesting Progress Payment

For progress payments, ensure "Activity Schedule", "Feature Schedule", submittal register, and punchlists are all up to date. Use "Progress Payments" to "request Activity Earnings" for both "Activity Earnings" data entry page and "Other Earning". Provide hard copies of supporting invoices and quantity measurements to support all requested earnings. Ensure that sum of payment activities do not exceed contract award CLIN funding amounts, or "unbalanced" CLINs error will prevent processing the payment.

3.1.2 Options and Modification CLINS

When additional work is added by modification, existing CLINs funding amounts must be updated, or new CLINs for modification will be created. If contract has option CLINs not yet awarded, option CLINs will appear as zero dollar CLINs until option is awarded by modification. No payment may be requested for Options or Modification CLINs until contract modification has been funded and signed.

W912EP-17-B-0003 SECTION 01 22 00 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

-- End of Section --

W912EP-17-B-0003 SECTION 01 22 00 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00

ADMINISTRATIVE PROCEDURES

PART 1 GENERAL

1.1 SUMMARY 1.2 SUBMITTALS 1.3 PROJECT COORDINATION 1.3.1 Resident Management System (RMS3CM) 1.3.2 Coordination with Other Contracts 1.3.2.1 Adjacent Contractor 1.3.3 Access by Others 1.3.4 Inspections by Others 1.4 PROJECT MEETINGS 1.5 PRECONSTRUCTION CONFERENCE 1.5.1 Preconstruction Conference Minutes 1.5.2 Preconstruction Conference Submittals 1.5.2.1 Other Division 01 Submittals 1.5.2.2 Divisions 02 through 48 Submittals 1.6 PARTNERING 1.6.1 Initial Partnering Meeting 1.6.2 Partnering Regroups 1.7 NOTICE TO PROCEED 1.8 COORDINATION MEETING 1.9 PROGRESS MEETINGS 1.9.1 Progress Meeting Participants 1.10 CONTRACTOR PERFORMANCE EVALUATIONS 1.10.1 Training

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 GENERAL MEETING REQUIREMENTS 3.2 PROGRESS MEETING AGENDA

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 30 00 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 30 00

ADMINISTRATIVE PROCEDURES

PART 1 GENERAL

1.1 SUMMARY

Manage project and coordinate activities of own employees, subcontractors, suppliers and offsite fabricators. Contractor shall use computers, E-mail, and Internet resources for administrative work. Notify Contracting Officer of important meetings, schedule events and activities. Furnish labor and materials and equipment required to plan and execute project management functions and coordination. Coordinate activities and manage resources to construct project conforming to contract, on time and within budget. Related Sections are 01 32 01 PROJECT SCHEDULE, and 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Transmit submittal items in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 30 calendar days after Notice to Proceed:

SD-01 Preconstruction Submittals

List of Subcontractors

Documentation of compliance with Clauses SUBCONTRACTS (LABOR STANDARDS) and LIMITATIONS ON SUBCONTRACTING of Section 00700 CONTRACT CLAUSES in Volume 1, and, if included, paragraph LIMITATIONS ON SUBSTITUTIONS FOR CERTAIN POSITIONS AND/OR SUBCONTRACTORS of Section 00800 SPECIAL REQUIREMENTS in Volume 1. As part of the initial project schedule, submit a list of proposed subcontractors with company name, person to contact, street address, mail address, phone number, type of specialty and estimated subcontract quote.

Presentation Files; G, RO

Submit as indicated in paragraph PRECONSTRUCTION CONFERENCE below.

SD-07 Certificates

Signature Authority

Furnish a power of attorney or a notarized letter of authority from Contractor identifying local representatives authorized to sign contract documents.

W912EP-17-B-0003 SECTION 01 30 00 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Drug-Free Work Place Record

Documentation of compliance with Clause DRUG-FREE WORKPLACE of Section 00700 CONTRACT CLAUSES in Volume 1 (see subparagraphs (b)(1) through (b)(7)).

1.3 PROJECT COORDINATION

1.3.1 Resident Management System (RMS3CM)

Contractor shall use Corps of Engineers' Resident Management System (RMS3CM ) for construction information management. See Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL.

1.3.2 Coordination with Other Contracts

1.3.2.1 Adjacent Contractor

An active construction near project site may impact Contractor work (location is as shown). Coordinate activities to avoid impact to adjacent Contractors and prevent problems from adjacent contract.

1.3.3 Access by Others

Maintain access to power poles and other items owned or operated by utility companies. Coordinate with utility companies as required for line marking, hookups, and relocations as needed to perform work. Incoming electrical utilities become the responsibility of Contractor at transformers. Coordinate emergency incident response with local law enforcement and fire rescue authorities. Notify Contracting Officer in writing of coordination problems encountered affecting work.

1.3.4 Inspections by Others

During construction period, inspection or maintenance work will be performed by others within the construction limits. The Contractor will be responsible for neatly mowing all grass and vegetation (not to include established trees or other protected vegetation designated as wetland areas) within the construction limits for the duration of the contract. Areas not accessible to mowers shall be edged or trimmed neatly. Mowing or trimming shall be performed every three weeks or when vegetation exceeds twelve inches in height.

1.4 PROJECT MEETINGS

Contracting Officer requires following types of project meetings:

-- Preconstruction Conference -- Partnering Meeting -- Partnering Regroup Meetings -- Coordination Meeting -- Preparatory and Initial Phase meeting for each feature of work -- Project Progress Meetings

Project meetings are described in detail in subparts below.

W912EP-17-B-0003 SECTION 01 30 00 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.5 PRECONSTRUCTION CONFERENCE

Contracting Officer will conduct a Preconstruction Conference for this project in accordance with Clause PRECONSTRUCTION CONFERENCE of Section 00700 CONTRACT CLAUSES in Volume 1. Preconstruction Conference will be held within 30 to 60 calendar days after Notice to Proceed (NTP). (Refer to subparagraph "Preconstruction Conference Submittals" below.) Contracting Officer will notify Contractor of time, place, and agenda. Contractor shall notify key subcontractors and suppliers to attend. The Contractor shall present an audio-visual type presentation (such as a PowerPoint presentation)at the Preconstruction Conference. The presentation will be provided by the Contractor along with a verbal description to present details of the means and methods the Contractor will undertake to accomplish the construction. Following award of the contract, the Contracting Officer will provide the Contractor with an outline for the presentation within a draft agenda for the scheduled preconstruction conference. The Contractor shall submit his presentation files for review and approval of the Contracting Officer. The presentation files shall be submitted to the Contracting Officer no later than 1 week prior to the scheduled preconstruction conference. The Contracting Officer will make logistical arrangements for projection of the presentation at the preconstruction conference, but the Contractor shall also provide a laptop computer with the presentation files to be used at the preconstruction conference Contractor's presentation." Contracting Officer will discuss contract "ground rules" and general issues including:

-- Lines of Contracting Officer authority -- Lines of Contractor authority -- 00700 Contract Clauses -- 00800 Special Contract Requirements -- Contract Administration -- Progress Payment -- Correspondence Procedures -- Project Schedule -- Submittal Register -- Labor requirements -- General Site Safety

1.5.1 Preconstruction Conference Minutes

Contracting Officer will take detailed minutes of Preconstruction Conference discussions and may use an audio or video tape. Copies of typed minutes will be provided to the Contractor to review for accuracy, sign and return. Signed minutes become part of the contract file. Audio or video tapes if used will be made available for Contractor to review or copy at Area Office.

1.5.2 Preconstruction Conference Submittals

The timing of submission of submittals and completion of the Preconstruction Conference is intended to allow the Contractor and the Government adequate time to prepare for commencement of work. However, should the Contractor fail to submit required items and receive acceptance and/or approval within the times stated, the Contractor will not be permitted to commence work until these requirements have been satisfied. Any delays attributable to the Contractor's failure to comply with these pre-work requirements shall be at the Contractor's expense and may be cause for remedial action by the Contracting Officer. Submittals required

W912EP-17-B-0003 SECTION 01 30 00 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

by this Section are described in paragraph SUBMITTALS above.

1.5.2.1 Other Division 01 Submittals

The Contracting Officer reviews submitted draft plans to prepare Coordination Meeting agenda and understand Contractor procedures. Submit the following, as indicated in their respective sections, 15 to 30 calendar days after award or 30 calendar days after Notice to Proceed, whichever is later:

-- Project Schedule - See Section 01 32 01 PROJECT SCHEDULE -- Diving Plan - See Section 01 35 25 OWNER SAFETY REQUIREMENTS - DIVING -- Accident Prevention Plan - See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS -- Quality Control Plan - See Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL -- Temporary Facilities Plan - See Section 01 50 02 TEMPORARY CONSTRUCTION FACILITIES

-- Environmental Protection Plan - See Section 01 57 20 ENVIRONMENTAL PROTECTION

1.5.2.2 Divisions 02 through 48 Submittals

In addition to the above, bring submittal items for materials, workmanship, plans or events required early in project schedule which are ready for transmittal to Contracting Officer. Prepare transmittal of submittal items in accordance with Section 01 33 00 SUBMITTAL PROCEDURES.

1.6 PARTNERING

Contracting Officer wants to have a bilateral project partnership with Contractor that draws on strengths of both organizations to identify and achieve common goals. Typical partnering goals include:

-- Effective and efficient contract performance -- Project completion on time and within budget -- Construction completed according to plans and specifications -- Development of cooperative management teams -- Project success with customer (stakeholders) satisfaction -- Improved Project communication

1.6.1 Initial Partnering Meeting

Contractor, key subcontractors and suppliers shall attend a one-day project "Partnering Meeting". The Partnering Meeting is a project team building workshop facilitated by qualified persons. Contracting Officer attendees and invited persons may include:

Administrative Contracting Officer (Area Engineer) Construction Quality Assurance Representatives Jacksonville District - Construction Branch persons Jacksonville District - Engineering Division Designers Local Sponsor (Owner) - Port of Tampa

Goal of initial Partnering Meeting is to build trust, identify common goals, and understand individual project members' expectations and organizational values. Usual results include better communication between

W912EP-17-B-0003 SECTION 01 30 00 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

contract parties, shortened project learning curve and a cohesive two party contract partnership. Participants usually sign a voluntary partnering agreement generally describing mutual obligation to cooperate to achieve project goals and maintain effective communication. Contracting Officer will pay costs for workshop site rental and facilitator fees.

1.6.2 Partnering Regroups

After initial Partnering Meeting participation will be voluntary in accordance with a signed Partnering Agreement. After initial Partnering Workshop, partnering sessions will be hosted by both parties on an alternating basis with the hosting party being responsible for all costs associated with their meeting. At no time will these costs be used to change the contract price. Partnering Agreements include provisions for Contracting Officer and Contractor to request "Partnering Regroups" when needed. A "Partnering Regroup" is usually a short (4 hours - 1 day) informal partnering session where senior level Contractor and Contracting Officer project members and other interested parties review project issues of concern. Issues of conflict are reviewed, attempt to affirm common project goals and understand concerns of other partner.

1.7 NOTICE TO PROCEED

Notice to proceed (NTP) will be issued 15 to 30 calendar days after award or after all required bonds are in place, whichever is later. If the Contractor has failed to submit and receive acceptance and/or approval of specified plans, including, but not limited to, Accident Prevention Plan - Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS, Quality Control Plan - Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL, and Environmental Protection Plan - Section 01 57 20 ENVIRONMENTAL PROTECTION, or has not yet received the Contracting Officer's conditional approval to work under an interim plan, the Contractor shall not proceed with the work and shall consider the work to be suspended in accordance with the Suspension Of Work clause of the contract. While the Contractor is working under a conditionally accepted interim plan, funds may be retained from progress payments in accordance with the Payments Under Fixed-Price Construction Contracts clause of this contract until such time as the Contractor submits an acceptable plan. If the Contractor does not submit an acceptable plan within a reasonable time, as determined by the Contracting Officer, the Contracting Officer may order the Contractor to suspend work. Any suspension order issued for the Contractor's failure to submit an acceptable plan will not constitute unreasonable delay under the Suspension Of Work clause and the Contractor will not be entitled to an equitable adjustment of either performance period or contract price.

1.8 COORDINATION MEETING

Coordination Meeting is scheduled, convened and conducted by Contracting Officer after a Preconstruction Conference and prior to starting physical construction. Draft plans submitted after NOA (i.e., Quality Control Plan, Environmental Protection Plan and Accident Prevention Program) will have been reviewed. Coordination Meeting is primarily for on-site Contractor Quality Control staff, including subcontractor and supplier employees performing quality control, to meet and discuss the project in detail with Contracting Officer's Quality Assurance Representatives. Purposes of Coordination Meeting are:

W912EP-17-B-0003 SECTION 01 30 00 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

-- Achieve mutual understanding with Contractor of required Quality Control -- Jointly review submitted draft plans; resolve issues of concern -- Discuss project plans and specifications, schedule, documentation -- Establish a good working relationship between the Contractors Quality Control Staff and Quality Assurance Representatives

1.9 PROGRESS MEETINGS

Schedule, convene and preside over progress meetings as required. As project activities increase ("ramp up"), a minimum of one progress meeting per week is typical of a project of this scope. Convene additional meetings as required, or when requested by Contracting Officer. Notify persons needed to be present to discuss agenda issues. Contracting Officer may direct attendance by key Contractor suppliers, or fabricators as needed. A sample meeting agenda is provided in paragraph GENERAL MEETING REQUIREMENTS below. The Contractor shall take minutes of the meetings and distribute copies of the minutes within three working days after the meetings.

1.9.1 Progress Meeting Participants

Typical participants include:

-- Contracting Officer -- Construction Quality Assurance Representatives -- Contractor's Site Superintendent -- Contractor's Quality Control Manager -- Contractor's Safety Coordinator -- Subcontractors, as appropriate to the agenda -- Suppliers, as appropriate to the agenda -- Others as appropriate to the agenda

1.10 CONTRACTOR PERFORMANCE EVALUATIONS

Contractors are given an opportunity to provide and/or enter performance evaluation comments directly into the Contractor Performance Assessment Reporting System (CPARS). The system is a web-enabled application that supports the completion, distribution, and retrieval of contract performance evaluations. Provide to the responsible area office the name and email address of the contractor user that will be accessing CPARS.

1.10.1 Training

Contractor online training is available at the following web site: https://www.cpars.gov/allapps/cpartrng/onlinetrn.htm. Training will give the student an understanding of the Contractor Representative and Contractor Corporate Senior Management levels of access, the policies and regulations governing CPARS, and the electronic workflow with particular attention to the Contractor comment function.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 GENERAL MEETING REQUIREMENTS

See Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL for Preparatory and Initial Phase meeting checklists. Contractor

W912EP-17-B-0003 SECTION 01 30 00 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

is responsible for phase and progress meetings to include:

Meeting notification to participants Prepare agenda for meetings Use phase checklists for Preparatory and Initial Phase meetings Physical arrangements for meetings Preside at meetings Record minutes recording proceedings and decisions Copy and send minutes to: Meeting participants Project parties affected by decisions Contracting Officer (No later than 3 working days)

3.2 PROGRESS MEETING AGENDA

Modify agenda as needed for on-going work.

Review minutes from previous progress meetings Review RMS3CM Contractor Action Item Report Review work progress since previous meeting Review current definable features of work: -- Identify phases of current features of work -- Identify pending phase changes -- Identify features for discussion in next scheduled meeting Discuss problem prevention: -- Field observations -- Deficiencies and tracking -- Procedures working well -- Problems, conflicts -- Methods to improve Review construction schedule: -- Identify delays -- Discuss proposed corrective actions to regain schedule Submittals and Requests for Information (design interpretation): -- Review submittal register -- Identify submittals to expedite as required Review off-site activities: -- Fabrications -- Material and equipment delivery schedule Review Testing: -- Type, Schedule -- Received Results Review changes to construction schedule: -- Planned progress during succeeding work period -- Coordination of various schedules -- Effect of changes on construction and completion date Review site safety Discuss maintaining contract quality for materials and workmanship Discuss pending modifications, changes and substitutions Discuss other business, as appropriate

-- End of Section --

W912EP-17-B-0003 SECTION 01 30 00 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 01

PROJECT SCHEDULE

PART 1 GENERAL

1.1 SUBMITTALS 1.2 CONSTRUCTION SCHEDULES 1.2.1 RMS3CM SCHEDULES 1.2.2 Bar Chart with "S"Curve 1.2.2.1 Sample Bar Chart 1.2.2.2 Sample "S" Curve 1.3 UPDATED SCHEDULES

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 32 01 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 32 01

PROJECT SCHEDULE

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 30 calendar days after Notice to Proceed:

SD-01 Preconstruction Submittals

RMS3CM Schedules; G, RO

Bar Chart; G, RO

"S" Curve; G, RO

1.2 CONSTRUCTION SCHEDULES

Use work breakdown structure of "CLINs", "Features" and "Pay Activities". "CLINs" are Contract Line Item Numbers from bid schedule. "Features" are quality control grouping of like "Pay Activities" requiring similar quality control. "Pay Activities" are scheduled work activities or events. Most "Pay Activities" have resources (time, money, labor, material and equipment). Use "Pay Activities" with no dollars allocate to schedule administrative work activities or events.

1.2.1 RMS3CM SCHEDULES

See Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL. After receipt of Notice of Award, create "Activity Schedule" and "Feature Schedule" in RMS3CM, in accordance with the terms of FAR 52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS. Submit RMS3CM Schedules as part of initial RMS3CM export. Data can be entered manually or Contractor has option to use standard data exchange format (SDEF.txt file). Cost allocate each "Pay Activity" to an assigned CLIN. Sum of "Pay Activities" must equal CLIN totals so there is no variance. "Features" duration is early start of first "Pay Activity" to late finish date of last "Pay Activity". Primavera P6 v6.x and later versions (v7.x and v8.x) allow export of a file for conversion to standard data exchange format (SDEF.txt) file format. Primavera provides a utility that will convert the export file to an SDEF.txt file. An SDEF.txt file can then be used to directly import the Primavera schedule into RMS3CM. The Contractor shall be responsible for providing all programs and hardware necessary to prepare initial and progress schedules. The required Primavera P6 Activity Code Structure is as follows:

W912EP-17-B-0003 SECTION 01 32 01 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Field # Code Length Field Description 1 WRKP 3 Workers per day 2 RESP 4 Responsibility 3 AREA 4 Area 4 MODF 6 Modification or Claim # 5 BIDI 6 Bid Item 6 PHAS 2 Phase 7 CATW 1 Category of Work 8 FOW 20 Feature of Work

1.2.2 Bar Chart with "S"Curve

Submit the initial Bar Chart with target "S" Curve no later than 15 to 30 calendar days after award or 30 calendar days after Notice to Proceed, whichever is later. Contractor may create a manual Bar Chart and "S" curve or use computer software of his choice. Scheduling software allows for easier updates and changes. See sample Bar Chart and "S" Curve below. The Bar Chart shall include an appropriate level of detail including activities, submittals, Government review periods, material/equipment delivery, utility outages, on-site construction, inspection, testing, and closeout activities. Contractor's submissions shall follow the direction of the Contracting Officer regarding reasonable activity durations. Reasonable durations are those that allow the progress of activities to be accurately determined between payment periods. All planned durations must take into account weather and climate data, work schedules, and contract restrictions on work periods. No single on-site construction activity shall exceed 30 days in duration without further breakdown in detail.

Contractor has an option to schedule an "early finish" date with "float" until contract required completion date. Schedules with "early finish" are for the benefit of the Contractor, and the Contracting Officer may elect to continue to make balanced progress payments based on funds availability. Neither Contractor nor Contracting Officer own "float" on early finish schedules. Contractor shall not claim added costs for delay for float used. When unit price CLINs have quantity variations and impact weighted percentage of a "Pay Activity" by five percent or more, revise bar chart and "S" Curve to accurately reflect impact of variation of estimated quantities. See the next page for sample Bar Chart and "S" Curve.

W912EP-17-B-0003 SECTION 01 32 01 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.2.2.1 Sample Bar Chart

Sample Bar Chart has early finish at week 16 +/-.

Feature A CLIN1/Act 1| AAAA CLIN1/Act 2| AAAAAAAAAAAA Feature B CLIN2/Act 3| BBBBBBB CLIN2/Act 4| BBBBBBBBBBB CLIN2/Act 5| BBBBBBBBBBB Feature C CLIN3/Act 6| CCCCCCCCCCCCCC CLIN3/Act 7| CCCCCCCCCCC Feature D CLIN4/Act 8| DDDDDDDDDDDDDDDDD CLIN4/Act 9| DDDDDDDDDDDDDD |<-- Float->| CLIN4/Act 10 DDDDDD 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 TIME SCALE

1.2.2.2 Sample "S" Curve

Sample "S" curve is early finish at week 16 +/- with actual progress plotted at week 14.

% Complete 100 | +|<---- Float ---->| 95 | + + e 90 | + = Target + e 85 | a = Actual + e 80 | e = Estimated + e 75 | + e 70 | + e 65 | + e 60 | + a 55 | + a 50 | + a 45 | + + a a 40 | + a 35 | + + a 30 | + a 25 | + + a 20 | + + a a 15 | + + + a a 10 | + a a a a 5 | + + a 0 |_ + a a 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 Time Scale

1.3 UPDATED SCHEDULES

Maintain construction progress schedules submission up-to-date. Ensure submittal is updated and includes RMS3CM Schedules, Bar Charts, "S" Curves and progress narrative when requesting progress payment. Submit Bar Chart ,

W912EP-17-B-0003 SECTION 01 32 01 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

"S" Curve schedule when schedule is revised. Reflect any changes occurring since the last update.

When work is delayed by causes beyond the Contractor's control, the Contractor is obligated to notify the ACO within 10 days of the beginning of the delay. The Contractor is obligated to submit a cost and time proposal, illustrating the influence of each change or delay on the Contract Completion Date or contract required Milestone. No time extension will be granted nor delay damages paid unless a delay occurs which consumes all available Project Float, and extends the Projected Finish beyond the Contract Completion Date.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section --

W912EP-17-B-0003 SECTION 01 32 01 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

PART 1 GENERAL

1.1 SUMMARY 1.2 DEFINITIONS 1.2.1 Submittal 1.2.2 Transmittal 1.2.3 Submittal Descriptions (SD) 1.2.4 Approving Authority 1.2.5 Work 1.2.6 Contractor Reviewer 1.2.7 Primary Reviewer 1.2.8 Secondary Reviewer 1.2.9 Reviewer Codes 1.2.10 Review and Action Codes 1.2.11 Review Comments to Contractor 1.3 SUBMITTALS 1.4 SUBMITTAL CLASSIFICATION 1.4.1 Government Approved 1.4.2 Information Only 1.5 APPROVED SUBMITTALS 1.6 DISAPPROVED SUBMITTALS 1.7 WITHHOLDING OF PAYMENT 1.8 GENERAL 1.9 SUBMITTAL REGISTER 1.10 SCHEDULING 1.10.1 Avoiding Delays 1.11 TRANSMITTAL FORM (ENG FORM 4025) 1.11.1 Approving Authority Review Codes 1.12 SUBMITTAL PROCEDURES 1.12.1 Reviewing, Certifying, Approving Authority 1.12.2 Procedures 1.12.3 Number of Copies or Samples 1.12.4 Identifying Submittal Items and Transmittals 1.12.5 Submittal Format 1.12.5.1 Format for Shop Drawings 1.12.5.2 Format for Construction Drawings 1.12.5.3 Format for Computer Aided Design (CAD) Drawings 1.12.5.4 Administrative Submittal Items Format 1.12.6 Deviations 1.12.7 Considering Variations 1.12.8 Proposing Variations 1.12.9 Warranty Variations 1.12.10 Electronic Correspondence 1.13 CONTROL OF SUBMITTALS 1.14 GOVERNMENT APPROVED SUBMITTALS 1.15 INFORMATION ONLY SUBMITTALS

W912EP-17-B-0003 SECTION 01 33 00 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.16 REQUEST FOR INFORMATION (RFI) 1.17 SUBMITTAL REGISTER 1.18 STAMPS

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 33 00 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 33 00

SUBMITTAL PROCEDURES

PART 1 GENERAL

1.1 SUMMARY

This section describes submittal procedures in Jacksonville District contracts using Quality Control System submittal procedures in accordance with Section 01 45 05 DREDGING/BEACH FILL - CONTRACTOR QUALITY CONTROL. It covers submittal item identification, number of copies, review periods, quality control review, QC/QA reviewer coding, and transmittal tracking procedures using Resident Management System (RMS3CM) shared data base. Contractor shall use RMS3CM software to identify, track and transmit submittal items.

1.2 DEFINITIONS

1.2.1 Submittal

Contract Clauses "FAR 52.236-5, Material and Workmanship," paragraph (b) and "FAR 52.236-21, Specifications and Drawings for Construction," paragraphs (d), (e), and (f) apply to all "submittals."

1.2.2 Transmittal

This is a routine contract correspondence action using a transmittal form (ENG Form 4025) to send submittal items to the Government. The RMS3CM "Transmittal Log" module uses data base entry to create a hard copy of ENG Form 4025.

1.2.3 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections. Submittals are identified by SD numbers and titles as follows.

SD-01 Preconstruction Submittals

Submittals which are required prior to start of construction (work) or the start of the next major phase of the construction on a multi-phase contract, includes schedules, tabular list of data, or tabular list including location, features, or other pertinent information regarding products, materials, equipment, or components to be used in the work. Preconstruction submittals shall be submitted no later than 15-30 calendar days after award or 30 calendar days after Notice to Proceed, whichever is later.

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating

W912EP-17-B-0003 SECTION 01 33 00 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accordance with specified requirements. (Testing must have been within three years of date of contract award for the project.)

Report which includes findings of a test required to be performed by the Contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports.

Daily checklists.

Final acceptance test and operational test procedure.

SD-07 Certificates

Statements signed by responsible officials of manufacturer of product, system or material attesting that product, system or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a supplier, installer or subcontractor through Contractor, the purpose of which is to further quality of orderly progression of a portion of the work by documenting procedures, acceptability of methods or personnel qualifications.

Confined space entry permits.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

1.2.4 Approving Authority

Office authorized to approve submittal.

W912EP-17-B-0003 SECTION 01 33 00 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.2.5 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction.

1.2.6 Contractor Reviewer

Contractor employee performing quality control review on submittal items.

1.2.7 Primary Reviewer

Initial Government reviewer is usually among construction field personnel who perform quality assurance review on submittal items.

1.2.8 Secondary Reviewer

Secondary Government reviewer is usually an in-house designer or Architect/Engineer (A/E) firm hired to perform "engineering during construction". This is a submittal reviewer for design critical "G" submittal items. Secondary Reviewers may also be specialized district staffs such as safety or environmental specialists, users, or operations and maintenance reviewers. Secondary Reviewers are advisors to Approving Authority.

1.2.9 Reviewer Codes

Two and three letter codes used to identify Government primary and secondary reviewer on submittal register are as follows:

PO -- Construction Project Office RO -- Construction Resident Office AO -- Construction Area Office DO -- Jacksonville District Office AE -- Architect Engineer Contractor providing engineering during construction

1.2.10 Review and Action Codes

Reviewer code letters A,B,C,E,F,G and X are used by Contractor QC Staff and Government Primary and Secondary Reviewers to indicate approval, acceptance or rejection of a submittal item.

1.2.11 Review Comments to Contractor

ENG Form 4025, Section III is generated in Resident Management System, and contains consolidated remarks for Primary and Secondary Reviewers. "Review Comments to Contractor" will electronically update. A hard copy of ENG Form 4025, Part III is attached to a submittal item when returned.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only or as otherwise designated. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section

W912EP-17-B-0003 SECTION 01 33 00 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 30 calendar days after Notice to Proceed:

SD-01 Preconstruction Submittals

Export File; G, RO

As part of the initial project schedule, review and correct the "Submittal Register". Provide the corrected "Submittal Register" as part of first RMS3CM export file to the Government.

1.4 SUBMITTAL CLASSIFICATION

Submittals are classified as follows:

1.4.1 Government Approved

Government approval is required for extensions of design, critical materials, deviations, equipment whose compatibility with the entire system must be checked, and other items as designated by the Contracting Officer. Within the terms of the Contract Clause entitled "Specifications and Drawings for Construction," they are considered to be "shop drawings."

1.4.2 Information Only

All submittals not requiring Government approval will be for information only. "Information Only" submittal items shall be reviewed, coded and approved by the Contractor. They are not considered to be "shop drawings" within the terms of the Contract Clause referred to above.

1.5 APPROVED SUBMITTALS

The Contracting Officer's approval of submittals shall not be construed as a complete check, but will indicate only that the general method of construction, materials, detailing and other information are satisfactory. Approval will not relieve the Contractor of the responsibility for any error which may exist, as the Contractor under the Contractor Quality Control (CQC) requirements of this contract is responsible for dimensions, the design of adequate connections and details, and the satisfactory construction of all work. After submittals have been approved by the Contracting Officer, no resubmittal for the purpose of substituting materials or equipment will be considered unless accompanied by an explanation of why a substitution is necessary.

1.6 DISAPPROVED SUBMITTALS

Make all corrections required by the Contracting Officer and promptly furnish a corrected submittal in the form and number of copies specified for the initial submittal. If the Contractor considers any correction indicated on the submittals to constitute a change to the contract, a notice in accordance with the Contract Clause "Changes" shall be given promptly to the Contracting Officer.

1.7 WITHHOLDING OF PAYMENT

No payment for materials incorporated in the work will be made if required approvals have not been obtained until it is determined by the Contracting Officer that materials meet contract requirements.

W912EP-17-B-0003 SECTION 01 33 00 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.8 GENERAL

The Contractor shall make submittals as required by the specifications using the RMS3CM software "Transmittal Log". The Contracting Officer may request submittals in addition to those specified when deemed necessary to adequately describe the work covered in the respective sections. Units of weights and measures used on all submittals shall be the same as those used in the contract drawings. Each submittal shall be complete and in sufficient detail to allow ready determination of compliance with contract requirements. Prior to transmittal, all items shall be checked and approval coded by the Contractor's Quality Control (CQC) System Manager, and each item shall be stamped, signed, and dated by the CQC System Manager indicating action taken. Proposed deviations from the contract requirements shall be clearly identified. Submittals shall include items such as: Contractor's, manufacturer's, or fabricator's drawings; descriptive literature including (but not limited to) catalog cuts, diagrams, operating charts or curves; test reports; test cylinders; samples; O&M manuals (including parts list); certifications; warranties; and other such required submittals. Submittals requiring Government approval shall be scheduled and made prior to the acquisition of the material or equipment covered thereby. Samples remaining upon completion of the work shall be picked up and disposed of in accordance with manufacturer's Material Safety Data Sheets (MSDS) and in compliance with existing laws and regulations.

1.9 SUBMITTAL REGISTER

At the end of this section is a submittal register showing items of equipment and materials for which submittals are required by the specifications; this list may not be all inclusive and additional submittals may be required. The Submittal Register using RMS3CM is a shared electronic database constantly updated by both Government and Contractor. The Government will provide initial RMS3CM export file to populate the RMS3CM submittal register in electronic format. This list may not be all inclusive, and additional submittals may be required. Examine contract drawings and specifications, verify RMS3CM data, and add required submittal items. The Contractor's initial update to the submittal register shall be made prior to submission of the initial project schedule. The Contractor can print or e-mail RMS3CM generated current Submittal Register ENG Form 4288, and Transmittal Log as RMS3CM reports. Submittal and Transmittal status are updated with each RMS3CM data file exchange.

1.10 SCHEDULING

Submittals covering component items forming a system or items that are interrelated shall be scheduled to be coordinated and submitted concurrently. RMS3CM requires the Contractor to schedule and transmit submittal items from one Section together. Certifications to be submitted with drawings shall be scheduled. Schedule submittals with sufficient time to obtain a Government response prior to delivery of applicable equipment and materials, and commencement of applicable work. The Contractor assumes risk for applicable deliveries and work performed prior to receipt of a Government response to a submittal which requires no resubmission as indicated in the clause SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION of Section 00700 CONTRACT CLAUSES of Volume 1. Unless otherwise indicated in specific paragraphs governing each submittal, allow QC/QA review periods from date of receipt by Approval Authority in the schedule as follows:

W912EP-17-B-0003 SECTION 01 33 00 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Information Only - Contractor QC Review - 10 Calendar Days "G" - Government QA Review - 30 Calendar Days

The Government has the number of calendar days indicated above from the date a transmitted "G" submittal item is received to review, code and return comments. The Contractor shall resubmit disapproved submittal items (codes C, D, E, G or X) within 10 calendar days after return. No delay damages or time extensions will be allowed for time lost caused by late submittals.

1.10.1 Avoiding Delays

Notify the Contracting Officer immediately when procurement or construction delays due to submittal review are possible.

1.11 TRANSMITTAL FORM (ENG FORM 4025)

These forms are included in the RMS3CM software. Use the RMS3CM transmittal log to generate "ENG Form 4025 - Transmittal of Shop Drawings, Equipment Data, Material Samples, or Manufacturer's Certificates of Compliance" to transmit submittal items to the Government. EN Form 4025R has three sections as follows:

Section I - "Request for Approval of the Following Items" is initiated by the Contractor.

Section II - "Approval Action" combined with a review code in column "For CE Use Code" indicates submittal item acceptance or rejection by Approving Authority.

Section III - Government Review Remarks.

This form shall be properly completed using RMS3CM software to fill out all the heading blank spaces and identify each item submitted. Special care shall be exercised to ensure proper listing of the specification paragraph or sheet number of the contract drawings pertinent to the data submitted for each item.

1.11.1 Approving Authority Review Codes

The Contractor shall use RMS3CM to act as Approving Authority to code FIO submittals. The Government will use RMS3CM to prepare reviewer comments and code "G" submittal items. These comments and coding will update RMS3CM when the .RFX file update is imported by the Contractor from the RMS3CM SFTP repository. The action codes are as follows ("Resubmit" in parentheses means the Contractor is required to resubmit):

A -- Approved as submitted (Complete) B -- Approved, except as noted on drawings (Complete) C -- Approved, except as noted on drawings (Resubmit) D -- Returned by correspondence (Complete) E -- Disapproved (See Attached and Resubmit) F -- Receipt Acknowledged (Completed) G -- Other (Specify Action in Detail; Resubmittal may be required) X -- Receipt Acknowledged, does not comply (Resubmit)

W912EP-17-B-0003 SECTION 01 33 00 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.12 SUBMITTAL PROCEDURES

Submittals shall be made as follows:

1.12.1 Reviewing, Certifying, Approving Authority

The Contractor shall perform QC review of all submittal items, and certify for compliance or note submittal item is a variation. Approving authorities are as follows:

"G" - Government will approve "G" submittal items. Information Only - Contractor shall approve "Information Only" submittal items.

The Government reserves the right to perform quality assurance on an "Information Only" submittal even after it has been approved by the Contractor's Approving Authority. See paragraph INFORMATION ONLY SUBMITTALS below.

1.12.2 Procedures

The Contractor shall furnish submittals required by contract and transmit them to the Contracting Officer using ENG Form 4025 as contract transmittal form. Transmit all submittals to the address provided by the Resident Engineer prior to the Preconstruction Conference. The address may also be provided by contacting the area office indicated in Page 00010-2 of the Standard Form 1442.

1.12.3 Number of Copies or Samples

Transmit three (3) hard copies and three (3) soft copies of "G" submittal items and three (3) hard copies and three (3) soft copies of "Information Only" submittals to Contracting Officer. Each transmittal of a set of hard copy submittal items shall have a coded and signed hard copy of a RMS 3CM generated ENG Form 4025. Soft copy submittal items shall be transmitted on CD-ROM in PDF format unless otherwise approved by the Contracting Officer. Only one transmittal shall be transmitted per CD-ROM. The Contractor shall attach a signed copy of ENG Form 4025 on each CD-ROM disk case, mark the contract and transmittal numbers on each CD-ROM disk, and include a PDF of the signed ENG Form 4025 on each CD-ROM.

1.12.4 Identifying Submittal Items and Transmittals

RMS3CM creates a unique number using section number and generated number (01 30 00-X) for each submittal item. Also, RMS3CM creates a unique number for each transmittal using section number and a number assigned by the Contractor (01 33 00-XXXXX). The Contractor assigned numbers are not consecutive and may be an activity number from the procurement schedule. Attach a RMS3CM generated ENG Form 4025 to each set and copy of submittal items. Identify each sample submittal item with project title, contract number, section/submittal item number, name, address and phone number of Contractor's point of contact.

1.12.5 Submittal Format

1.12.5.1 Format for Shop Drawings

Paper copies of shop drawings shall be ANSI standard sizes A, B, C or E (8.5"x11", 11"x17", 17"x22" or 34"x44" respectively). Each drawing shall

W912EP-17-B-0003 SECTION 01 33 00 Page 9 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

have a right side margin information block similar to contract drawings with project title, contract number, contractor/supplier names, section/submittal item number, drawing title, number and date, revision date, and approval box. Units shall be the same as those in contract drawings. Dimensions shall be to the scale shown or noted as "Not to Scale" (NTS).

1.12.5.2 Format for Construction Drawings

Construction drawings are large sized shop drawings for complex structures and systems, layout of site temporary construction (dewatering), mapping access, and land use descriptions. When required, prepare construction drawings on ANSI standard sizes C (17"x22") or E (34"x44") as directed by the Contracting Officer. The layout of construction drawings shall be as indicated in subparagraph "Format for Shop Drawings" above.

1.12.5.3 Format for Computer Aided Design (CAD) Drawings

CAD drawings may be transmitted on CD-ROM if approved by the Contracting Officer. The Contractor shall transmit the same number of CD-ROM disks as the number of hard copies required. Attach a copy of ENG Form 4025 on each CD-ROM disk case, and mark the contract and transmittal numbers on each CD-ROM disk. One paper copy of drawings shall be included with each set of CD-ROM disks transmitted.

1.12.5.4 Administrative Submittal Items Format

When an administrative submittal becomes part of the contract or project record, use 8.5"x11" pages for text and 11"x17" sheets for drawings. Use a table of contents with tabs for large submittal items. Use loose leaf binder or binder fastener to allow for disassembly, and addition of documents.

1.12.6 Deviations

Deviations are also known as "variations" from the contract requirements. Variations require Government approval, and will be considered when beneficial to the Government. An "Information Only" submittal item becomes a "G" submittal item requiring Government review and approval when a variation is proposed. When RMS3CM variation block is checked, explain why the variation should be accepted in place of the specified item in "Remarks to Government". The "Remarks to Government" will populate the ENG Form 4025R "REMARKS" block. The variation will become a modification to contract requirements if it is approved by the Contracting Officer. Approved variations may require adjustments to contract price for increased (basic change document) or decreased (Government's credit) costs, and construction time. The Government reserves the right to rescind inadvertent approval of submittals containing unnoted deviations.

1.12.7 Considering Variations

Discuss proposed variations with the Contracting Officer prior to submission. Ensure function and quality requirements are met. Submit proposed variation as a Value Engineering Change Proposal (VECP) if it is likely to result in lower cost. See the clause VALUE ENGINEERING - CONSTRUCTION of Section 00700 CONTRACT CLAUSES of Volume 1.

W912EP-17-B-0003 SECTION 01 33 00 Page 10 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.12.8 Proposing Variations

Use RMS3CM Transmittal Log to identify submittal items as variations. In "Remarks to Government", describe what the proposed variation is, how it differs from the contract, and why it is desirable and beneficial to the Government. Include estimate of cost savings if lower cost is a benefit.

1.12.9 Warranty Variations

Use the RMS3CM transmittal log "Remarks to Government" to warrant that the variation submitted for approval will be compatible with other work if incorporated.

1.12.10 Electronic Correspondence

All correspondence and contract related documents shall be submitted in searchable Adobe Portable File format (PDF) with the only exceptions being those stated at the end of this paragraph. Any documents that require signature shall be submitted in PDF format with signature. Minimum scan quality shall be 150 dpi. The Contracting Officer will discuss electronic correspondence procedures at Preconstruction and Coordination Meetings. These procedures may include sending files by e-mail, submitting on electronic media such as compact disks, a Contractor provided FTP site, a website indicated by the Contracting Officer at the Preconstruction Conference, or other methods approved by the Contracting Officer. The Contractor shall be responsible for the cost of the electronic media. Examples of correspondence and contract related documents that must be submitted in PDF format include, but are not limited to, Contractor serial letters, notifications to Contracting Officer, requests for equitable adjustment, change requests, claims, Contract Modifications (SF 30), QC Reports, RFIs, pay requests, meeting minutes, insurance certificates, schedules, shop drawings, submittals and ENG 4025 transmittal forms and supporting data. QC Reports will include all required attachments including QC Test Reports. Both a hard copy and a PDF file of the signed QC Report including required attachments shall be submitted daily. In addition, one month after the end of each month all QC Reports for the month shall be combined into one PDF and submitted. Submit copies of correspondence to other businesses, entities, or agencies such as "Notices to Mariners", permit required reports, and other contract related documents in PDF format. Include signatures if applicable for final versions of scanned contracts. All correspondence and contract related documents shall also be submitted in hard copy form, in the quantities and with the requirements listed in these documents, unless the Contractor obtains a waiver from the Contracting Officer. E-mail correspondence and payroll documentation do not have to be provided in PDF format.

1.13 CONTROL OF SUBMITTALS

The Contractor shall carefully control his procurement operations to ensure that each individual submittal is made on or before the Contractor scheduled submittal date shown on the approved "Submittal Register."

1.14 GOVERNMENT APPROVED SUBMITTALS

Upon completion of review of submittals requiring Government approval, the submittals will be identified as having received approval by being so stamped and dated. Two (2) copies of the submittal will be retained by the Contracting Officer and one (1) copy of the submittal will be returned to the Contractor.

W912EP-17-B-0003 SECTION 01 33 00 Page 11 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.15 INFORMATION ONLY SUBMITTALS

Normally submittals for information only are approved by the Contractor's approving authority. The Government will notify the Contractor if the submittal has received an "F" action code, and the submittal will not be returned. Approval of the Contracting Officer is not required on information only submittals. Submittal items found not to comply with contract requirements will be given an "X" action code, returned to the Contractor, and shall require resubmittal by the Contractor as a "G" submittal item. The Government reserves the right to require the Contractor to resubmit any item found not to comply with the contract. This does not relieve the Contractor from the obligation to furnish material conforming to the plans and specifications; will not prevent the Contracting Officer from requiring removal and replacement of nonconforming material incorporated in the work; and does not relieve the Contractor of the requirement to furnish samples for testing by the Government laboratory or for check testing by the Government in those instances where the technical specifications so prescribe.

1.16 REQUEST FOR INFORMATION (RFI)

Requests for Information are not submittal items. They are time sensitive Quality Control related correspondence. See Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL.

1.17 SUBMITTAL REGISTER

The Submittal Register is appended after the end of this section.

1.18 STAMPS

Stamps used by the Contractor on the submittal data to certify that the submittal meets contract requirements shall be similar to the following (see next page):

W912EP-17-B-0003 SECTION 01 33 00 Page 12 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

______| CONTRACTOR | | | | (Firm Name) | | | | | | | | _____ Approved | | | | | | _____ Approved with corrections as noted on submittal data and/or | | attached sheets(s). | | | | | | | | SIGNATURE: ______| | | | TITLE: ______| | | | DATE: ______| | | |______|

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section --

W912EP-17-B-0003 SECTION 01 33 00 Page 13 SUBMITTAL REGISTER CONTRACT NO.

TITLE AND LOCATION CONTRACTOR Tampa Hbr M/D 32-Ft Pr & Manatee Hbr M/D 40-Ft Pr

CONTRACTOR: CONTRACTOR APPROVING AUTHORITY G SCHEDULE DATES ACTION O V T C T R L A A O A N S R A A C S S C C T M S P I A T T I I P A F / I I V T E R I E O DATE FWD O MAILED I T C A C N TO APPR N TO T A G # A R AUTH/ CONTR/ Y L S R T E C C E DESCRIPTION A I V APPROVAL MATERIAL O DATE DATE RCD DATE FWD DATE RCD O DATE DATE RCD N N C P O W NEEDED NEEDED D OF FROM TO OTHER FROM OTH D OF FRM APPR O O T ITEM SUBMITTED H N R SUBMIT BY BY E ACTION CONTR REVIEWER REVIEWER E ACTION AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r) 01 22 00 SD-01 Preconstruction Submittals Schedule of Values G RO 01 30 00 SD-01 Preconstruction Submittals List of Subcontractors Presentation Files G, RO Submit as indicated in paragraph PRECONSTRUCTION CONFERENCE below. SD-07 Certificates Signature Authority Drug-Free Work Place Record 01 32 01 SD-01 Preconstruction Submittals RMS3CM Schedules 1.2.1 G RO Bar Chart 1.2.2 G RO 'S' Curve 1.2.2 G RO 01 33 00 SD-01 Preconstruction Submittals Export File G RO 01 35 25 SD-01 Preconstruction Submittals Dive Operations Plan G RO SD-07 Certificates Dive Personnel Qualifications G RO 01 35 26 SD-01 Preconstruction Submittals Accident Prevention Plan (APP) 1.6 G DO Activity Hazard Analysis (AHA) 1.7 G DO Crane Critical Lift Plan 1.6.1 G DO Safe Access Plan 3.1.1 G DO

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 1 OF 5 PAGES SUBMITTAL REGISTER CONTRACT NO.

TITLE AND LOCATION CONTRACTOR Tampa Hbr M/D 32-Ft Pr & Manatee Hbr M/D 40-Ft Pr

CONTRACTOR: CONTRACTOR APPROVING AUTHORITY G SCHEDULE DATES ACTION O V T C T R L A A O A N S R A A C S S C C T M S P I A T T I I P A F / I I V T E R I E O DATE FWD O MAILED I T C A C N TO APPR N TO T A G # A R AUTH/ CONTR/ Y L S R T E C C E DESCRIPTION A I V APPROVAL MATERIAL O DATE DATE RCD DATE FWD DATE RCD O DATE DATE RCD N N C P O W NEEDED NEEDED D OF FROM TO OTHER FROM OTH D OF FRM APPR O O T ITEM SUBMITTED H N R SUBMIT BY BY E ACTION CONTR REVIEWER REVIEWER E ACTION AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r) 01 35 26 Safe Access Plan 3.1.1 G DO SD-02 Shop Drawings Standard Lift Plan (SLP) 1.6.1 G DO SD-06 Test Reports Notifications and Reports 1.11 Accident Reports 1.11.1 Crane Reports 1.11.2 SD-07 Certificates Confined Space Entry Permit 1.8 Hot work permit 1.8 License Certificates 1.13 Crane Operators 1.5.2.4 G DO Third Party Certification of 1.11.4 Barge-Mounted Mobile Cranes Certificate of Compliance 1.11.3 01 45 05 SD-01 Preconstruction Submittals Quality Control Plan G RO SD-07 Certificates Letter of Authority Personnel Qualifications G RO 01 50 02 SD-01 Preconstruction Submittals Mobilization/Demobilization Plan SD-02 Shop Drawings Contractor's Temporary Facilities 3.4 Temporary Electric Drawings 01 57 20 SD-01 Preconstruction Submittals

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 2 OF 5 PAGES SUBMITTAL REGISTER CONTRACT NO.

TITLE AND LOCATION CONTRACTOR Tampa Hbr M/D 32-Ft Pr & Manatee Hbr M/D 40-Ft Pr

CONTRACTOR: CONTRACTOR APPROVING AUTHORITY G SCHEDULE DATES ACTION O V T C T R L A A O A N S R A A C S S C C T M S P I A T T I I P A F / I I V T E R I E O DATE FWD O MAILED I T C A C N TO APPR N TO T A G # A R AUTH/ CONTR/ Y L S R T E C C E DESCRIPTION A I V APPROVAL MATERIAL O DATE DATE RCD DATE FWD DATE RCD O DATE DATE RCD N N C P O W NEEDED NEEDED D OF FROM TO OTHER FROM OTH D OF FRM APPR O O T ITEM SUBMITTED H N R SUBMIT BY BY E ACTION CONTR REVIEWER REVIEWER E ACTION AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r) 01 57 20 Environmental Protection Plan G DO SD-02 Shop Drawings Turtle Deflector Device G DO Daily Logs/Summary Of Bird G DO Nesting Monitoring Weekly Logs/Summary Of Bird G DO Nesting Monitoring SD-07 Certificates Bird Monitoring Qualifications G DO Manatee Observer Qualifications G DO Endangered Species Observer G DO and Trawl Supervisor Qualifications (For Hopper Dredges Only) SD-11 Closeout Submittals Logs/Final Summary Report Project Environmental Summary Sheet Trawl Sweeping Daily Logs 01 57 25 SD-03 Product Data Calibration Standard SD-06 Test Reports Turbidity Monitoring 35 20 23 SD-01 Preconstruction Submittals Notice of Intent to Dredge Relocation of Navigation Aids

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 3 OF 5 PAGES SUBMITTAL REGISTER CONTRACT NO.

TITLE AND LOCATION CONTRACTOR Tampa Hbr M/D 32-Ft Pr & Manatee Hbr M/D 40-Ft Pr

CONTRACTOR: CONTRACTOR APPROVING AUTHORITY G SCHEDULE DATES ACTION O V T C T R L A A O A N S R A A C S S C C T M S P I A T T I I P A F / I I V T E R I E O DATE FWD O MAILED I T C A C N TO APPR N TO T A G # A R AUTH/ CONTR/ Y L S R T E C C E DESCRIPTION A I V APPROVAL MATERIAL O DATE DATE RCD DATE FWD DATE RCD O DATE DATE RCD N N C P O W NEEDED NEEDED D OF FROM TO OTHER FROM OTH D OF FRM APPR O O T ITEM SUBMITTED H N R SUBMIT BY BY E ACTION CONTR REVIEWER REVIEWER E ACTION AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r) 35 20 23 Dredge Pumpout Capacity SD-02 Shop Drawings Drag Bar G RO Acceptance Sections Plan G RO SD-07 Certificates Historical Period Shipwreck Sites 1.7 Surveys Daily/Monthly Report of Operations Misplaced Material Declaration of Inspection for 1.10 Refueling 35 20 26 SD-01 Preconstruction Submittals Dredge Plant Instrumentation Plan G, SAM-OP-J Contractor Quality Control Plan G RO SD-06 Test Reports Data Appropriately Archived G RO e-mail SD-07 Certificates Letter of National Dredging G RO Quality Management Program Certification 35 20 28 SD-01 Preconstruction Submittals

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 4 OF 5 PAGES SUBMITTAL REGISTER CONTRACT NO.

TITLE AND LOCATION CONTRACTOR Tampa Hbr M/D 32-Ft Pr & Manatee Hbr M/D 40-Ft Pr

CONTRACTOR: CONTRACTOR APPROVING AUTHORITY G SCHEDULE DATES ACTION O V T C T R L A A O A N S R A A C S S C C T M S P I A T T I I P A F / I I V T E R I E O DATE FWD O MAILED I T C A C N TO APPR N TO T A G # A R AUTH/ CONTR/ Y L S R T E C C E DESCRIPTION A I V APPROVAL MATERIAL O DATE DATE RCD DATE FWD DATE RCD O DATE DATE RCD N N C P O W NEEDED NEEDED D OF FROM TO OTHER FROM OTH D OF FRM APPR O O T ITEM SUBMITTED H N R SUBMIT BY BY E ACTION CONTR REVIEWER REVIEWER E ACTION AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r) 35 20 28 Dredge Plant Instrumentation Plan Revisions or Addendum G, SAM-OP-J Contactor Quality Control Plan, G RO section 3.2.5 SD-07 Certificates Letter of National Dredging G RO Quality Management Program Certification SD-06 Test Reports Data Appropriately Archived G RO e-mail, section 3.2.11

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 5 OF 5 PAGES Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 35 25

OWNER SAFETY REQUIREMENTS - DIVING

PART 1 GENERAL

1.1 SUMMARY 1.1.1 Related Section 1.2 REFERENCES 1.3 SAFETY AND HEALTH REQUIREMENTS MANUAL 1.4 DEFINITIONS 1.5 SUBMITTALS 1.6 DIVE PLAN 1.6.1 Dive Plan Reviewer 1.7 MEETINGS 1.7.1 Phase Meetings

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 EMERGENCY MEDICAL TREATMENT 3.2 DIVING OPERATIONS 3.2.1 Dive Operations Execution

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 35 25 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 35 25

OWNER SAFETY REQUIREMENTS - DIVING

PART 1 GENERAL

1.1 SUMMARY

Section covers job specific underwater diving requirements and dive safety.

1.1.1 Related Section

Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 Safety and Health Requirements Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910.1030 Bloodborne pathogens

1.3 SAFETY AND HEALTH REQUIREMENTS MANUAL

EM 385-1-1 is available at the web site indicated in paragraph REGULATORY REQUIREMENTS of Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS. One copy will be provided to Contractor at a Preconstruction Conference (refer to Section 01 30 00 ADMINISTRATIVE PROCEDURES.

1.4 DEFINITIONS

Use definitions found in EM 385-1-1 in transmitted dive plan submittal items.

Dive Supervisor - A person with specialized training or experience in Dive safety.

1.5 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 30 calendar days after Notice to Proceed:

W912EP-17-B-0003 SECTION 01 35 25 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SD-01 Preconstruction Submittals

Dive Operations Plan; G, RO

Refer to paragraphs DIVE PLAN, DIVING OPERATIONS, and DIVE OPERATIONS below.

SD-07 Certificates

Dive Personnel Qualifications; G, RO

Qualifications, and training certificates of dive personnel. "Annual" diver physicals shall conform to the requirements of EM 385-1-1. Contractor shall submit only a statement from a licensed physician that states the diver is "Fit To Dive". Submitted physician statement shall contain at a minimum the diver name, examination date, physician's name, physician's signature, physicians' medical license number, and physicians telephone number. The signing physician shall be an MD or an OD. Submitted statement shall NOT contain divers Personal Health Information (PHI) or Personal Identification Information (PII).

First Aid (FA), Cardiopulmonary Resuscitation (CPR) & Emergency Oxygen System (EO2) training shall be in accordance with the EM 385-1-1, Section 03.A.05 and all applicable OSHA regulations. FA, CPR & EO2 training are required to be Hands-on training. Online training will "NOT" be accepted. Proof of Hands-on training shall be provided within this submittal.

Blood-Bourne Pathogen (BBP) Program and "Annual" Training shall comply with the EM 385-1-1 and OSHA 29 CFR 1910.1030, as well as all other applicable regulations. Proof of BBP Program and "Annual" Training shall be provided within this submittal.

1.6 DIVE PLAN

Dive plan shall address all requirements of Section DIVING OPERATIONS of EM 385-1-1. See paragraph DIVE OPERATIONS below. An approved Dive Plan and Safe Practices Manual is required on all projects with work on, or over water; see paragraph DIVING OPERATIONS below.

1.6.1 Dive Plan Reviewer

Dive Plans shall be submitted by Contractor to Contracting Officer in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Dive Operations Plans are "District Office (DO)" secondary reviewed by Jacksonville District Diving Coordinator or an Alternate. The names and contract information of the Diving Coordinator and Alternate(s) will be provided at the Preconstruction Conference. When a transmittal with a Dive Plan submittal item is delivered to Resident Engineer, send a copy directly to:

Delivery/Mailing Address: U.S. Army Corps of Engineers - Jacksonville District ATTN: CESAJ-CD-Q (Diving Coordinator) 701 San Marco Blvd Jacksonville, FL 32207-8175

W912EP-17-B-0003 SECTION 01 35 25 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.7 MEETINGS

1.7.1 Phase Meetings

Each Dive shall be treated as a "definable feature of work" in accordance with accepted Quality Control Plan. Perform a Preparatory and Initial Phase meeting for all Dives.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 EMERGENCY MEDICAL TREATMENT

Arrange with local authorities for emergency dive medical response, treatment and evacuation to medical facility and nearest hyperbaric chamber. Provide map with route directions to nearest hospital and hyperbaric chamber in dive plan Emergency Management Plan required by EM 385-1-1.

3.2 DIVING OPERATIONS

Submit a Dive Operations Plan when work is performed on or over water. No matter if a dive is actually planned or only required as a contingency (i.e., most dredging projects) submit a Diving Operations Plan for Contracting Officer's approval. Dive Operations Plan shall cover all requirements in Section DIVING OPERATIONS of EM 385-1-1. Dive Operations Plan consists of a "Safe Practices Manual" describing Contractor's diving program and a "Dive Plan" describing site specific information of proposed dive or contingency dive. Safe Practices Manual, Dive Plan and revisions shall have cover sheets signed and dated by Contractor. When diving is subcontracted, cover sheets shall also be signed and dated by diving contractor's principal or authorized representative.

3.2.1 Dive Operations Execution

Execute dives in accordance with approved Dive Operations Plan submittal; Section DIVING OPERATIONS of EM 385-1-1. Contractor shall submit completed daily dive logs at the end of each dive day. Daily dive logs shall be submitted with the daily quality control report and provided to the District Dive Coordinator or authorized representative upon request. Contractor shall use COE form ENG 4615 and ENG 4616 to record daily diving activities.

-- End of Section --

W912EP-17-B-0003 SECTION 01 35 25 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 35 26

GOVERNMENTAL SAFETY REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES 1.2 DEFINITIONS 1.3 SUBMITTALS 1.4 REGULATORY REQUIREMENTS 1.5 SITE QUALIFICATIONS, DUTIES AND MEETINGS 1.5.1 Safety Personnel Training 1.5.2 Personnel Qualifications 1.5.2.1 Site Safety and Health Officer (SSHO) 1.5.2.1.1 Contractor Quality Control (QC) Person 1.5.2.2 Dredging Requirements 1.5.2.2.1 SSHO Staffing 1.5.2.2.2 SSHO Requirements 1.5.2.2.3 Designated Representative (DR) Requirements 1.5.2.2.4 Safety Personnel Training Requirements 1.5.2.3 Qualified Person for Confined Space Entry 1.5.2.4 Crane Operators 1.5.3 Personnel Duties 1.5.3.1 Site Safety and Health Officer (SSHO) 1.5.4 Meetings 1.5.4.1 Preconstruction Conference 1.5.4.2 Safety Meetings 1.6 ACCIDENT PREVENTION PLAN (APP) 1.6.1 EM 385-1-1 Contents 1.7 ACTIVITY HAZARD ANALYSIS (AHA) 1.8 DISPLAY OF SAFETY INFORMATION 1.9 SITE SAFETY REFERENCE MATERIALS 1.10 EMERGENCY MEDICAL TREATMENT 1.11 NOTIFICATIONS and REPORTS 1.11.1 Accident Reports 1.11.2 Crane Reports 1.11.3 Certificate of Compliance 1.11.4 Third Party Certification of Barge-Mounted Mobile Cranes 1.12 HOT WORK 1.13 RADIATION SAFETY REQUIREMENTS 1.14 FACILITY OCCUPANCY CLOSURE 1.15 SEVERE STORM PLAN 1.16 CONFINED SPACE ENTRY REQUIREMENTS.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 CONSTRUCTION AND OTHER WORK

W912EP-17-B-0003 SECTION 01 35 26 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.1.1 Safe Access to Dredge and Associated Floating Plant 3.1.2 Hazardous Material Exclusions 3.1.3 Unforeseen Hazardous Material 3.2 PRE-OUTAGE COORDINATION MEETING 3.3 CONTROL OF HAZARDOUS ENERGY (LOCKOUT/TAGOUT) 3.4 FALL HAZARD PROTECTION AND PREVENTION PROGRAM 3.4.1 Training 3.4.2 Fall Protection Equipment and Systems 3.4.2.1 Personal Fall Arrest Equipment 3.4.3 Fall Protection for Roofing Work 3.4.4 Horizontal Lifelines 3.4.5 Guardrails and Safety Nets 3.4.6 Rescue and Evacuation Procedures 3.5 SCAFFOLDING 3.6 EQUIPMENT 3.6.1 Material Handling Equipment 3.6.2 Load Handling Equipment (LHE) 3.6.3 Equipment and Mechanized Equipment 3.6.4 Use of Explosives 3.7 EXCAVATIONS 3.7.1 Utility Locations 3.7.2 Utility Location Verification 3.7.3 Utilities Within and Under Concrete, Bituminous Asphalt, and Other Impervious Surfaces 3.8 ELECTRICAL 3.8.1 Conduct of Electrical Work 3.8.2 Portable Extension Cords, Generators and Tools 3.9 WORK IN CONFINED SPACES

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 35 26 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 35 26

GOVERNMENTAL SAFETY REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AMERICAN NATIONAL STANDARDS INSTITUTE (ANSI/ASSE)

ANSI/ASSE A10.32 (2013) Fall Protection

ANSI/ASSE A10.34 (2001; R 2012) Protection of the Public on or Adjacent to Construction Sites

ANSI/ASSE Z359.1 (2007) Safety Requirements for Personal Fall Arrest Systems, Subsystems and Components

AMERICAN NATIONAL STANDARDS INSTITUTE/AMERICAN SOCIETY OF MECHANICAL ENGINEERS (ANSI/ASME)

ANSI/ASME B30.22 (2010) Articulating Boom Cranes

ANSI/ASME B30.3 (2009) Tower Cranes

ANSI/ASME B30.5 (2007) Mobile and Locomotive Cranes

ANSI/ASME B30.8 (2010) Floating Cranes and Floating Derricks

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 10 (2013) Standard for Portable Fire Extinguishers

NFPA 241 (2013) Standard for Safeguarding Construction, Alteration, and Demolition Operations

NFPA 306 (2009) Standard for Control of Gas Hazards on Vessels

NFPA 51B (2009; TIA 09-1) Standard for Fire Prevention During Welding, Cutting, and Other Hot Work

NFPA 70 (2015) National Electrical Code

NFPA 70E (2015) Standard for Electrical Safety in the Workplace

W912EP-17-B-0003 SECTION 01 35 26 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 Safety and Health Requirements Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910 Occupational Safety and Health Standards

29 CFR 1910.146 Permit-required Confined Spaces

29 CFR 1910.147 Control of Hazardous Energy (Lock Out/Tag Out)

29 CFR 1915 Confined and Enclosed Spaces and Other Dangerous Atmospheres in Shipyard Employment

29 CFR 1919 Gear Certification

29 CFR 1926 Safety and Health Regulations for Construction

29 CFR 1926 Subpart AA Construction Work in Confined Spaces

29 CFR 1926.1400 Cranes & Derricks in Construction

29 CFR 1926.500 Fall Protection

29 CFR 1926.1427 Operator Qualification and Certification, Cranes and Derricks in Construction

CPL 2.100 (1995) Application of the Permit-Required Confined Spaces (PRCS) Standards, 29 CFR 1910.146

1.2 DEFINITIONS

a. Competent Person for Fall Protection. A person who is capable of identifying hazardous or dangerous conditions in the personal fall arrest system or any component thereof, as well as their application and use with related equipment, and has the authority to take prompt corrective measures to eliminate the hazards of falling.

b. High Visibility Accident. Any mishap which may generate publicity or high visibility.

c. Medical Treatment. Treatment administered by a physician or by registered professional personnel under the standing orders of a physician. Medical treatment does not include first aid treatment even through provided by a physician or registered personnel.

d. Operating Envelope. The area surrounding any crane. Inside this "envelope" is the crane, the operator, riggers and crane walkers, gear between the hook and the load, the load and the crane's supporting structure (ground, rail, etc.).

e. Person for Fall Protection. A person with a recognized degree or professional certificate, and with extensive knowledge, training and experience in the field of fall protection; who is capable of

W912EP-17-B-0003 SECTION 01 35 26 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

performing design, analysis, and evaluation of fall protection systems and equipment.

f. Recordable Injuries or Illnesses. Any work-related injury or illness that results in:

(1) Death, regardless of the time between the injury and death, or the length of the illness;

(2) Days away from work (any time lost after day of injury/illness onset);

(3) Restricted work;

(4) Transfer to another job;

(5) Medical treatment beyond first aid;

(6) Loss of consciousness; or

(7) A significant injury or illness diagnosed by a physician or other licensed health care professional, even if it did not result in (1) through (6) above.

g. "USACE" property and equipment specified in USACE EM 385-1-1 should be interpreted as Government property and equipment.

h. Load Handling Equipment (LHE) Accident. A LHE accident occurs when any one or more of the six elements in the operation envelope fails to perform correctly during operation, including operation during maintenance or testing resulting in personnel injury or death; material or equipment damage; dropped load; derailment; two-blocking; overload; and/or collision, including unplanned contact between the load, crane, and/or other objects. A dropped load, derailment, two-blocking, overload and collision are considered an accident even though no material damage or injury occurs. A component failure is not considered an accident solely due to material or equipment damage unless the component failure results in damage to other components.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 30 calendar days after Notice to Proceed:

SD-01 Preconstruction Submittals

Accident Prevention Plan (APP); G, DO

*Activity Hazard Analysis (AHA); G, DO

*Crane Critical Lift Plan; G, DO

*Note: Only for activities required to start work. Remaining AHA's shall be submitted in accordance with paragraph ACTIVITY

W912EP-17-B-0003 SECTION 01 35 26 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

HAZARD ANALYSIS (AHA) below. Remaining Crane Critical Lift Plans shall be submitted in accordance with paragraph ACCIDENT PREVENTION PLAN (APP) below.

Safe Access Plan; G, DO

SD-02 Shop Drawings

Standard Lift Plan (SLP); G, DO

SD-06 Test Reports

Notifications and Reports

Submit reports as their incidence occurs, in accordance with the requirements of the paragraph, "Notifications and Reports."

Accident Reports

Crane Reports

SD-07 Certificates

Confined Space Entry Permit

Hot work permit

License Certificates

Proof of qualification for Crane Operators; G, DO

Third Party Certification of Barge-Mounted Mobile Cranes

Certificate of Compliance (Crane)

Submit one copy of each permit/certificate attached to each Daily Quality Control Report.

1.4 REGULATORY REQUIREMENTS

In addition to the detailed requirements included in the provisions of this contract, comply with the most recent edition of USACE EM 385-1-1, and all Federal, State, and local laws, ordinances, criteria, rules and regulations. Submit matters of interpretation of standards to the appropriate administrative agency for resolution before starting work. Where the requirements of this specification, applicable laws, criteria, ordinances, regulations, and referenced documents vary, the most stringent requirements govern. The most recent USACE EM 385-1-1 can be viewed at http://www.publications.usace.army.mil/USACEPublications/EngineerManuals.aspx.

1.5 SITE QUALIFICATIONS, DUTIES AND MEETINGS

1.5.1 Safety Personnel Training

a. The 30-hour OSHA Construction Course will not substitute nor qualify any personnel in meeting the competent or qualified person training or work requirements. On-line 30-hour OSHA Construction Course will be accepted to meet training requirements as outlined in the USACE EM 385-1-1 and/or as an OSHA Authorized Online Outreach

W912EP-17-B-0003 SECTION 01 35 26 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Training Provider.

b. Additional training, experience, hands-on and practical knowledge are required to meet the competent and qualified person requirements in various work activities, fall protection, scaffolding, excavation, trenching, confined space, hazardous communications/hazardous materials, LOCKOUT/TAGOUT (LOTO), respiratory protection, hearing protection, steel erection, spills, lead abatement, asbestos, blasting, critical lifts, and additional work activities listed in the EM 385-1-1. Verification of training will be required and submitted with the Accident Prevention Plan.

1.5.2 Personnel Qualifications

1.5.2.1 Site Safety and Health Officer (SSHO)

The contractor shall provide a Safety oversight team that includes a minimum of one (1) Qualified Person at each project site to function as the Safety and Health Officer (SSHO). The SSHO shall be at the work site at all times, unless specified differently in the contract, to perform safety and occupational health management, surveillance, inspections, and safety enforcement for the Contractor, and their training, experience, and qualifications shall be as required by EM 385-1-1 paragraph 01.A.17 and all associated sub-paragraphs. The SSHO shall maintain competency through having taken 8 hours of documented formal, on-line, or self-study safety and health related coursework per year, at least for the past 4 years (32 Hours of training in the last 4 Years).

The utilization of a Designated Representative (DR) as identified and outlined in EM 385-1-1, 01.A.17, is typically utilized. A Competent/Qualified Person shall be provided for all of the hazards identified in the Contractor's Safety and Health Program in accordance with the accepted Accident Prevention Plan, and shall be on-site at all times when the work that presents the hazards associated with their professional expertise is being performed. The credentials of the Competent/Qualified Persons(s) shall be approved by the Contracting Officer in consultation with the Safety Office.

The Competent/Qualified Person may be the SSHO provided the person meets all the requirements for both SSHO and Competent/Qualified Person.

1.5.2.1.1 Contractor Quality Control (QC) Person

The Contractor Quality Control Person cannot be the SSHO on this project, even though the QC has safety inspection responsibilities as part of the QC duties.

1.5.2.2 Dredging Requirements

1.5.2.2.1 SSHO Staffing

a. Dredging contracts may include several project sites; this contract will require a minimum of one full time SSHO(s) assigned per project site. SSHO may be collateral duty in specific conditions listed below.

b. Example of one dredging project site is reflected in each of the following:

(1) a mechanical dredge, tug(s) and scow(s), scow route, and material

W912EP-17-B-0003 SECTION 01 35 26 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

placement site; or

(2) a hydraulic pipeline dredge, attendant plant, and material placement site; or,

(3) a hopper dredge (include land-based material placement site - if applicable.)

c. Individual dredging project sites with work force less than 8 employees, the SSHO may be a collateral duty, with the same responsibilities of a full time SSHO.

d. Hopper dredges with USCG-Documented crews may designate an officer as a collateral-duty SSHO instead of having a full-time SSHO if the officer meets the SSHO training and experience requirements.

1.5.2.2.2 SSHO Requirements

a. In addition to requirements stated elsewhere in this specification, the SSHO shall be present at the project site, located so they have full mobility and reasonable access to all major work operations, for at least one shift in each 24 hour period when work is being done. The SSHO, or Alternate SSHO, shall be available during all shifts for immediate verbal consultation and notification, either by phone or radio. The SSHO shall be a full-time, dedicated position, except as noted above. The SSHO shall report to a senior project (or corporate) officials.

b. The SSHO shall inspect all work areas and operations during initial set-up and at least monthly observe and provide personal oversight on each shift during dredging operations for projects with many work sites, more often for those with less work sites.

c. For projects with multiple shifts or when SSHO is temporarily off-site, an Alternate SSHO will be assigned to ensure SSHO coverage for the project at all times work activities are conducted. The Alternate SSHO must meet the same requirements and assume the responsibilities of the project SSHO. The Alternate SSHO position may be a collateral duty.

d. If the SSHO is off-site for a period longer than 24 hours, a qualified replacement SSHO shall be provided and shall fulfill the same roles and responsibilities as the primary/initial SSHO.

1.5.2.2.3 Designated Representative (DR) Requirements

a. Designated Representatives (DR) are collateral duty safety personnel, with safety duties in addition to their full-time occupation, and support and supplement the SSHO efforts in managing, implementing and enforcing the Contractor's Safety and Health Program. DRs shall be individual(s) with work oversight responsibilities, such as masters, mates, fill foremen, and superintendents. DRs should not be positions requiring continuous mechanical or equipment operations, such as equipment operators.

b. A DR shall be appointed for all remote work locations more than 45 minutes' travel time from the SSHO's duty location, typically including dredged material placement sites, towing and scow operations, and other operations.

W912EP-17-B-0003 SECTION 01 35 26 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

c. The DRs will perform safety program tasks as designated by the SSHO and report safety findings to the SSHO/Alternate SSHO. The SSHO shall document results of safety findings and provide information for inclusion in the CQC reports to the Government Representative.

1.5.2.2.4 Safety Personnel Training Requirements

a. The SSHO, Alternate SSHO, and Designated Representatives for dredging contracts shall take either the OSHA 30-hour Construction Safety Course or an equivalent 30 hours of formal safety and health training covering the subjects of the OSHA 30-hour Course (see EM 385-1-1 Appendix A, paragraph 3.d(3)) applicable to dredging work and given by qualified instructors.

b. The SSHOs shall also have taken 8 hours of formal classroom or online safety and health related coursework in the past four (4) years. Hours spent as an instructor in such courses will be considered the same as attending them, but each course only gets credit once (ie. Instructing a 1-hour asbestos awareness course 5 times in the past 4 years provides one hour credit for training). SSHOs shall maintain competency through having taken 8 hours of documented formal, on-line, or self-study safety and health related coursework every year. Examples of continuing education activities that meet this requirement are writing an article, teaching a class, reading/writing professional articles, attendance/participation in professional societies/meetings, etc.

c. The SSHO, Alternate SSHO, and Designated Representatives shall have a minimum of three years' continuous experience within the past 5 years in supervising/ managing dredging, marine or land-based construction, work managing safety programs or processes, or conducting hazard analyses and developing controls in activities or environments with similar hazards. This is in lieu of the construction experience required by paragraph 01.A.17.b, EM 385-1-1.

1.5.2.3 Qualified Person for Confined Space Entry

Provide a "Qualified Person" to supervise the entry into each confined space. That individual must meet the requirements and definition of Qualified Person as contained in EM 385-1-1.

If the work involves marine operations that handle combustible or hazardous materials, this person shall have the ability to understand and follow through on the air sampling, PPE, and instructions of a Marine Chemist, Coast Guard authorized persons, or Certified Industrial Hygienist. All confined space and enclosed space work shall comply with NFPA 306, OSHA 29 CFR 1915, Subpart B, "Confined and Enclosed Spaces and Other Dangerous Atmospheres in Shipyard Employment" or as applicable, 1910.147 for general industry and per 29 CFR 1926 Subpart AA for construction industry..

1.5.2.4 Crane Operators

Meet the crane operators requirements in USACE EM 385-1-1, Section 16, and 29 CFR 1926.1427. In addition, for lifting devices (not including those exempted by EM 385-1-1) rated 2,000 pounds or more, mobile cranes with Original Manufacturer (OEM) rated capacity of 50,000 pounds or greater, designate crane operators qualified by a source that qualifies crane

W912EP-17-B-0003 SECTION 01 35 26 Page 9 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

operators (i.e., union, a government agency, or an organization that tests and qualifies crane operators). Provide proof of current qualifications. Conduct a review of all licenses, training, certifications and the medical certifications required by EM 385-1-1, Paragraph 16.B.05, every 30 days. Document and maintain a record of each review. Make this review a part of the APP.

1.5.3 Personnel Duties

1.5.3.1 Site Safety and Health Officer (SSHO)

The SSHO shall have no duties other than those related to managing the safety program. The SSHO shall:

a. Conduct daily safety and health inspections and maintain a written log which includes area/operation inspected, date of inspection, identified hazards, recommended corrective actions, estimated and actual dates of corrections. Attach safety inspection logs to the Contractors' daily quality control report.

b. Conduct mishap investigations and complete required reports. Maintain the OSHA Form 300 and Daily Production reports for prime and sub-contractors.

c. Maintain applicable safety reference material on the job site.

d. Attend the pre-construction conference, pre-work meetings including preparatory inspection meeting, and periodic in-progress meetings.

e. Implement and enforce accepted APPS and AHAs.

f. Maintain a safety and health deficiency tracking system that monitors outstanding deficiencies until resolution. Post a list of unresolved safety and health deficiencies on the safety bulletin board.

g. Ensure sub-contractor compliance with safety and health requirements.

h. Maintain a list of hazardous chemicals on site and their material safety data sheets.

i. Track and review all licenses, training, certifications and medical evaluations shall be conducted every 30 days. These inspections are to be documented and maintained for record. This requirement shall be part of the Accident Prevention Plan submittal.

j. Report any mishaps involving crane operations to the Government Designated Authority (GDA) and USACE Safety Office immediately. All crane operations mishap information must be completed, reviewed and forwarded to the USACE Safety Officer within 4 hours of the incident.

k. Smoking or tobacco use on USACE worksite shall be in designated areas only.

l. Perform a daily safety meeting for all activities on the day prior to beginning work, and record meeting on the daily QC report.

m. Above ground storage tank (AST) shall be coordinated with the local fire department. Any permit or paperwork required shall be documented and provided to the GDA.

W912EP-17-B-0003 SECTION 01 35 26 Page 10 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

n. Lightning protection/detection devices are required on all LHE, cranes and cranework.

o. Perform Project Site Safety Trend Analysis: The Site Safety Health Officer (SSHO), Project Manager (PM) and Supervisor(s) shall review and analyze all records, deficiencies and documentation pertaining to the safety and health program. This review will be conducted on a monthly basis and will focus on hazard and injury analysis, and recognition of developing trends. Trend analysis will identify recurring accidents and near-miss incidents resulting in or potentially involving injury, illness, or property damage. The analysis will also recognize repeatedly identified hazards or violations needing corrective actions to establish what plan component(s) is (are) failing that allows the hazard(s) to exist. The SSHO will provide information and recommendations for corrective measures to all contract management personnel for the trends identified in the project template. Employees will be made aware of the developing trends and hazard exposures as they are recognized. Employees will be solicited and contacted to encourage their inputs in mitigating and reversing any identified trends. Trends of accidents or hazard recurrences will be a focal point for pro-active corrective actions and employee training. Employee training records will be reviewed quarterly to ensure an adequate and effective training program is being accomplished and maintained. Follow-up with employees will be accomplished periodically to establish training retention, effective implementation or additional information needed to update the recognized trends. Meetings shall be documented, including the date, persons in attendance, subjects discussed, and names of individual(s) who conducted the meeting. Documentation shall be maintained and copies furnished to the GDA on request.

Failure to perform the above duties will result in dismissal of the superintendent, QC Manager, and/or SSHO, and a project work stoppage. The project work stoppage will remain in effect pending approval of a suitable replacement.

1.5.4 Meetings

1.5.4.1 Preconstruction Conference

a. Contractor representatives who have a responsibility or significant role in accident prevention on the project shall attend the preconstruction conference. This includes the project superintendent, site safety and health officer, quality control supervisor, or any other assigned safety and health professionals who participated in the development of the APP (including the Activity Hazard Analyses (AHAs) and special plans, program and procedures associated with it).

b. Discuss the details of the submitted APP to include incorporated plans, programs, procedures and a listing of anticipated AHAs that will be developed and implemented during the performance of the contract. This list of proposed AHAs will be reviewed at the conference and an agreement will be reached between the Contractor and the Contracting Officer's representative as to which phases will require an analysis. In addition, establish a schedule for the preparation, submittal, review, and acceptance of AHAs to preclude project delays.

W912EP-17-B-0003 SECTION 01 35 26 Page 11 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

c. Deficiencies in the submitted APP will be brought to the attention of the Contractor at the preconstruction conference, and the Contractor shall revise the plan to correct deficiencies and re-submit it for acceptance. Do not begin work until there is an accepted APP.

1.5.4.2 Safety Meetings

Conduct and document meetings as required by EM 385-1-1. Attach minutes showing contract title, signatures of attendees and a list of topics discussed to the Contractors' daily quality control report.

1.6 ACCIDENT PREVENTION PLAN (APP)

Use a qualified person to prepare the written site-specific APP. Prepare the APP in accordance with the format and requirements of USACE EM 385-1-1 and as supplemented herein. Cover all paragraph and subparagraph elements in USACE EM 385-1-1, Appendix A, "Minimum Basic Outline for Accident Prevention Plan". Specific requirements for some of the APP elements are described below. The APP shall be job-specific and address any unusual or unique aspects of the project or activity for which it is written. The APP shall interface with the Contractor's overall safety and health program. Include any portions of the Contractor's overall safety and health program referenced in the APP in the applicable APP element and made site-specific. The Government considers the Prime Contractor to be the "controlling authority" for all work site safety and health of the subcontractors. Contractors are responsible for informing their subcontractors of the safety provisions under the terms of the contract and the penalties for noncompliance, coordinating the work to prevent one craft from interfering with or creating hazardous working conditions for other crafts, and inspecting subcontractor operations to ensure that accident prevention responsibilities are being carried out. The APP shall be signed by the person and firm (senior person) preparing the APP, the Contractor, the on-site superintendent, the designated site safety and health officer, the Contractor Quality control Manager, and any designated CSP or CIH.

Submit the APP to the Contracting Officer no later than 15 to 30 calendar days after award or 30 calendar days after Notice to Proceed, whichever is later. Work cannot proceed without an accepted APP.

Once accepted by the Contracting Officer, the APP and attachments will be enforced as part of the contract. Disregarding the provisions of this contract or the accepted APP will be cause for stopping of work, at the discretion of the Contracting Officer, until the matter has been rectified.

Once work begins, changes to the accepted APP shall be made with the knowledge and concurrence of the Contracting Officer, project superintendent, SSHO and quality control manager. Should any severe hazard exposure, i.e. imminent danger, become evident, stop work in the area, secure the area, and develop a plan to remove the exposure and control the hazard. Notify the Contracting Officer within 24 hours of discovery. Eliminate/remove the hazard. In the interim, take all necessary action to restore and maintain safe working conditions in order to safeguard onsite personnel, visitors, the public (as defined by ANSI/ASSE A10.34,) and the environment.

All certifications and/or training certificates will be reviewed by SAJ-SO to include third party training certificates. All third party training will be reviewed and verified. Training certifications for the third

W912EP-17-B-0003 SECTION 01 35 26 Page 12 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

party trainer shall be provided. These documents shall be submitted in the Accident Prevention Plan (APP) and the AHA prior to work activity commencing.

Copies of the accepted plan will be maintained at the Contracting Officer's office and at the job site. Continuously reviewed and amended the APP, as necessary, throughout the life of the contract. Incorporate unusual or high-hazard activities not identified in the original APP as they are discovered. The activities shall be detailed and outlined in the APP and AHAs. Qualified person credentials on each safety office activity shall be submitted the Safety Office for review.

1.6.1 EM 385-1-1 Contents

a. Confined Space Entry Plan. Develop a confined and/or enclosed space entry plan in accordance with USACE EM 385-1-1, OSHA standards 29 CFR 1910, 29 CFR 1915, 29 CFR 1926, 29 CFR 1926 Subpart AA, and OSHA Directive CPL 2.100, and any other federal, state and local regulatory requirements identified in this contract. Identify the qualified person's name and qualifications, training, and experience. Delineate the qualified person's authority to direct work stoppage in the event of hazardous conditions. Include procedure for rescue by Contractor personnel and the coordination with emergency responders. Identify and provide a listing and map of all confined space(s) located on site. If there is no confined space work, include a statement that no confined space work exists and none will be created. Plan shall be submitted for review in the accident prevention plan (APP).

b. Standard Lift Plan (SLP). Within 30 calendar days after Notice to Proceed and prior to any mobilization of equipment to the project site, the Contractor shall submit a detailed lift plan outlining all equipment (including crane spreader bar, rigging, etc.) layout and procedures that will be used for lifting. The plan shall also include documentation showing that the proposed equipment and procedures are in accordance with the manufacturer's recommendation and procedure. The plan shall include all personnel and subcontractors that will be involved in the lift, their qualifications and the Contractor designated safety officer. The SLP (and all lift operations) shall be in accordance with the requirements outlines in EM 385-1-1, section 16.A.03. The Contractor is responsible for all safety associated with the lift.

c. Crane Critical Lift Plan. Prepare and sign load handling critical lift plans for lifts over 75 percent of the capacity of the crane or hoist (or lifts over 50 percent of the capacity of a barge mounted mobile crane's hoists) at any radius of lift; lifts involving more than one crane or hoist; lifts of personnel; and lifts involving non-routine rigging or operation, sensitive equipment, or unusual safety risks. Submit 30 calendar days prior to on-site work and include the requirements of USACE EM 385-1-1, paragraph 16.H. and the following:

(1) For lifts of personnel, demonstrate compliance with the requirements of 29 CFR 1926.1400.

(2) For barge mounted mobile cranes, barge stability calculations identifying barge list and trim based on anticipated loading; and load charts based on calculated list and trim. The

W912EP-17-B-0003 SECTION 01 35 26 Page 13 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

amount of list and trim shall be within the crane manufacturer's requirements. Submit a job specific Naval Architecture Survey for review by the Safety Office.

(3) For installation of Articulated Concrete Block Mattress (ACBM), the Contractor shall submit a detailed lift plan outlining all equipment (including crane, spreader bar, rigging, etc.), layout and procedures that will be used. The plan shall also include documentation showing that the proposed equipment and procedures are in accordance with the manufacturer's recommendations and procedures. The plan shall include all personnel and subcontractors that will be involved in the ACBM installation, their qualifications, and the Contractor's designated safety officer. The lift plan, and all lift operations, shall be in accordance with the requirements outlined in EM 385-1-1, Section 16. The Contractor is responsible for all safety associated with the installation of ACBM.

1.7 ACTIVITY HAZARD ANALYSIS (AHA)

The Activity Hazard Analysis (AHA) format shall be in accordance with USACE EM 385-1-1, Section 1. Submit the AHA for review at least 30 calendar days prior to the start of each phase. Format subsequent AHAs as amendments to the APP. The analysis should be used during daily inspections to ensure the implementation and effectiveness of the activity's safety and health controls.

The AHA list will be reviewed periodically (at least monthly) at the Contractor supervisory safety meeting and updated as necessary when procedures, scheduling, or hazards change.

Develop the activity hazard analyses using the project schedule as the basis for the activities performed. Any activities listed on the project schedule will require an AHA. The AHA for each activity shall be prepared by personnel qualified for that activity. The AHAs will be developed by the Contractor, supplier or subcontractor and provided to the prime contractor for submittal to the Contracting Officer.

1.8 DISPLAY OF SAFETY INFORMATION

Within one calendar day after commencement of work, erect a safety bulletin board at the job site. Where size, duration, or logistics of project do not facilitate a bulletin board, an alternative method, acceptable to the Contracting Officer, that is accessible and includes all mandatory information for employee and visitor review, shall be deemed as meeting the requirement for a bulletin board. Include and maintain information on safety bulletin board as required by EM 385-1-1, section 01.A.07. Additional items required to be posted include:

a. Confined space entry permit.

b. Hot work permit.

1.9 SITE SAFETY REFERENCE MATERIALS

Maintain safety-related references applicable to the project, including those listed in the article "References." Maintain applicable equipment manufacturer's manuals.

W912EP-17-B-0003 SECTION 01 35 26 Page 14 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.10 EMERGENCY MEDICAL TREATMENT

Contractors will arrange for their own emergency medical treatment. Government has no responsibility to provide emergency medical treatment.

1.11 NOTIFICATIONS and REPORTS

1.11.1 Accident Reports

Conduct an accident investigation for recordable injuries and illnesses, for Medical Treatment defined in paragraph DEFINITIONS, property damage accidents resulting in at least $5,000 in damages, and near misses as defined in EM 385-1-1, to establish the root cause(s) of the accident. Complete the applicable USACE Accident Report Form 3394, and provide the report to the Contracting Officer within 5 calendar day(s) of the accident. The Contracting Officer will provide copies of any required or special forms. Any mishap involving crane operations will be reported to the GDA and SAJ-SO office immediately. All crane operation mishaps information shall be completed, reviewed and forwarded to SAJ-SO within four (4) hours of the incident. The incident shall be documented in the Contractor's Significant Incident Report (CSIR). Provide to the SO a crane and/or rigging incident/accident notification form within 24 hours of the incident. Do not proceed with crane operations until cause is determined and corrective actions have been implemented to the satisfaction of the Contracting Officer. All "near misses" shall be reported to SAJ-SO and investigated. A preliminary action notification (PAN) shall be forwarded to SAJ-SO.

1.11.2 Crane Reports

Submit crane inspection reports required in accordance with USACE EM 385-1-1, and as specified herein with Daily Reports of Inspections.

1.11.3 Certificate of Compliance

Provide a Certificate of Compliance for each crane entering an activity under this contract). State within the certificate that the crane and rigging gear meet applicable OSHA regulations (with the Contractor citing which OSHA regulations are applicable, e.g., cranes used in construction, demolition, or maintenance comply with 29 CFR 1926 and USACE EM 385-1-1 Section 16. Certify on the Certificate of Compliance that the crane operator(s) is qualified and trained in the operation of the crane to be used. For cranes at DOD activities in foreign countries, certify that the crane and rigging gear conform to the appropriate host country safety standards. Also certify that all of its crane operators working on the DOD activity have been trained in the proper use of all safety devices (e.g., anti-two block devices). Post certifications on the crane.

1.11.4 Third Party Certification of Barge-Mounted Mobile Cranes

Certify barge-mounted mobile cranes in accordance with 29 CFR 1919 by an OSHA accredited person.

1.12 HOT WORK

Submit permits required by state and local laws and regulations prior to performing "Hot Work". The Contractor shall provide at least two (2) twenty (20) pound 4A:20 BC rated extinguishers for normal "Hot Work". All extinguishers shall have current inspection tagged, approved safety pin

W912EP-17-B-0003 SECTION 01 35 26 Page 15 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

and tamper resistant seal. It is also mandatory to have a designated FIRE WATCH for any "Hot Work" done at this activity. The Fire Watch shall be trained in accordance with NFPA 51B and remain on-site for a minimum of 60 minutes after completion of the task or as specified on hot work permits.

Obtain services from a NFPA Certified Marine Chemist for "HOT WORK" within or around flammable materials (such as fuel systems, welding/cutting on fuel pipes) or confined spaces (such as sewer wet wells, manholes, vaults, etc.) that have the potential for flammable or explosive atmospheres.

1.13 RADIATION SAFETY REQUIREMENTS

License Certificates for radiation materials and equipment shall be submitted to the Contracting Officer and Radiation Safety Office (RSO) for all specialized and licensed material and equipment that could cause fatal harm to construction personnel or to the construction project.

1.14 FACILITY OCCUPANCY CLOSURE

Streets, walks, and other facilities occupied and used by the Government shall not be closed or obstructed without written permission from the Contracting Officer.

1.15 SEVERE STORM PLAN

The Contractor shall submit, as part of the Accident Prevent Plan, a Severe Storm Plan, which fulfills all the requirements of Paragraph 19.A.03, USACE EM 385-1-1.

1.16 CONFINED SPACE ENTRY REQUIREMENTS.

Contractors entering and working in confined spaces while performing general industry work are required to follow the requirements of OSHA 29 CFR 1926 and comply with the requirements in Section 34 of EM 385-1-1, OSHA 29 CFR 1910, OSHA 29 CFR 1910.146, and OSHA 29 CFR 1926 Subpart AA. All confined space areas are shall be identified. The confined space plan/program shall include a detailed listing and a location map of all the identified confined spaces and shall be submitted for review in the Accident Prevention Plan (APP).

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 CONSTRUCTION AND OTHER WORK

Comply with USACE EM 385-1-1, NFPA 70, NFPA 70E, NFPA 241, the APP, the AHA, Federal and State OSHA regulations, and other related submittals and activity fire and safety regulations. The most stringent standard prevails.

PPE is governed in all areas by the nature of the work the employee is performing. Use personal hearing protection at all times in designated noise hazardous areas or when performing noise hazardous tasks. Safety glasses must be carried/available on each person.

Mandatory PPE includes:

a. Hard Hat

W912EP-17-B-0003 SECTION 01 35 26 Page 16 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

b. Appropriate Safety Boots

c. Reflective Vests

d. Eye and Hearing Protection

3.1.1 Safe Access to Dredge and Associated Floating Plant

a. Safe access to and from the dredge and all associated floating plant shall be in strict accordance with the requirements of Paragraph 19.B of EM 385-1-1. Prior to commencement of work, the Contractor shall submit for acceptance a safe access plan. The plan shall designate all means of access and outline how access, including emergency access, compliant with Paragraph 19.B of EM 385-1-1 will be provided. The safe access plan shall be submitted prior to the preconstruction conference. Illuminations shall be provided in accordance with Section 07 of EM 385-1-1.

b. At locations where floating plant may be moored at docks/wharfs designed for seagoing vessels, gangways shall be provided. The gangways shall be capable of accommodating the complete tidal range including surge. Gangways shall be installed in accordance with Paragraph 19.B.01.d of EM 385-1-1, and shall be provided with guardrails in accordance with Paragraph 21.B.02 of EM 385-1-1.

c. Access to hopper dredges for all visitors shall occur when the dredge is loaded or pumped down.

3.1.2 Hazardous Material Exclusions

Notwithstanding any other hazardous material used in this contract, radioactive materials or instruments capable of producing ionizing/non-ionizing radiation (with the exception of radioactive material and devices used in accordance with USACE EM 385-1-1 such as nuclear density meters for compaction testing and laboratory equipment with radioactive sources) as well as materials which contain asbestos, mercury or polychlorinated biphenyls, di-isocynates, lead-based paint are prohibited. The Contracting Officer, upon written request by the Contractor, may consider exceptions to the use of any of the above excluded materials. Low mercury lamps used within fluorescent lighting fixtures are allowed as an exception without further Contracting Officer approval.

3.1.3 Unforeseen Hazardous Material

The design should have identified materials such as PCB, lead paint, and friable and non-friable asbestos and other OSHA regulated chemicals (i.e. 29 CFR Part 1910.1000). If additional material, not indicated, that may be hazardous to human health upon disturbance during construction operations is encountered, stop that portion of work and notify the Contracting Officer immediately. Within 14 calendar days the Government will determine if the material is hazardous. If material is not hazardous or poses no danger, the Government will direct the Contractor to proceed without change. If material is hazardous and handling of the material is necessary to accomplish the work, the Government will issue a modification pursuant to "FAR 52.243-4, Changes" and "FAR 52.236-2, Differing Site Conditions."

W912EP-17-B-0003 SECTION 01 35 26 Page 17 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.2 PRE-OUTAGE COORDINATION MEETING

Apply for utility outages at least 10 days in advance. As a minimum, the request should include the location of the outage, utilities being affected, duration of outage and any necessary sketches. Special requirements for electrical outage requests are contained elsewhere in this specification section. Once approved, and prior to beginning work on the utility system requiring shut down, attend a pre-outage coordination meeting with the Contracting Officer and the Public Utilities representative to review the scope of work and the lock-out/tag-out procedures for worker protection. No work will be performed on energized electrical circuits unless proof is provided that no other means exist.

3.3 CONTROL OF HAZARDOUS ENERGY (LOCKOUT/TAGOUT)

The Contractor is required to review, ensure that each employee is familiar with, and comply with all areas of the LOTO program referenced in EM 385-1-1, Section 12. Additionally, the Contractor must meet all OSHA requirements of 29 CFR 1910.147. The complete Accident Prevention Plan must include electrical, mechanical and mechanized equipment to include all construction heavy equipment, power tools, batteries, etc. The Contractor's LOTO program shall be submitted with the Accident Prevention Plan.

3.4 FALL HAZARD PROTECTION AND PREVENTION PROGRAM

Establish a fall protection and prevention program, for the protection of all employees exposed to fall hazards. Within the program include company policy, identify responsibilities, education and training requirements, fall hazard identification, prevention and control measures, inspection, storage, care and maintenance of fall protection equipment and rescue and evacuation procedures.

3.4.1 Training

Institute a fall protection training program by a qualified person. As part of the Fall Hazard Protection and Prevention Program, provide training for each employee who might be exposed to fall hazards. Provide training by a qualified person for fall protection in accordance with USACE EM 385-1-1, Section 21.C.

3.4.2 Fall Protection Equipment and Systems

Enforce use of the fall protection equipment and systems designated for each specific work activity in the Fall Protection and Prevention Plan and/or AHA at all times when an employee is exposed to a fall hazard. Protect employees from fall hazards as specified in EM 385-1-1, Section 21. In addition to the required fall protection systems, safety skiff, personal floatation devices, life rings etc., are required when working above or next to water in accordance with USACE EM 385-1-1, Paragraphs 21.O. Personal fall arrest systems are required when working from an articulating or extendible boom, swing stages, or suspended platform. In addition, personal fall arrest systems are required when operating other equipment such as scissor lifts if the work platform is capable of being positioned outside the wheelbase. The need for tying-off in such equipment is to prevent ejection of the employee from the equipment during raising, lowering, or travel. Fall protection must comply with 29 CFR 1926.500, Subpart M, USACE EM 385-1-1 and ANSI/ASSE A10.32.

W912EP-17-B-0003 SECTION 01 35 26 Page 18 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.4.2.1 Personal Fall Arrest Equipment

Personal fall arrest equipment, systems, subsystems, and components shall meet ANSI/ASSE Z359.1. Only a full-body harness with a shock-absorbing lanyard or self-retracting lanyard is an acceptable personal fall arrest body support device. Body belts may only be used as a positioning device system (for uses such as steel reinforcing assembly and in addition to an approved fall arrest system). Harnesses shall have a fall arrest attachment affixed to the body support (usually a Dorsal D-ring) and specifically designated for attachment to the rest of the system. Only locking snap hooks and carabiners shall be used. Webbing, straps, and ropes shall be made of synthetic fiber. The maximum free fall distance when using fall arrest equipment shall not exceed 6 feet. The total fall distance and any swinging of the worker (pendulum-like motion) that can occur during a fall shall always be taken into consideration when attaching a person to a fall arrest system.

3.4.3 Fall Protection for Roofing Work

Implement fall protection controls based on the type of roof being constructed and work being performed. Evaluate the roof area to be accessed for its structural integrity including weight-bearing capabilities for the projected loading.

a. Low Sloped Roofs:

(1) For work within 6 feet of an edge, on low-slope roofs, protect personnel from falling by use of personal fall arrest systems, guardrails, or safety nets.

(2) For work greater than 6 feet from an edge, erect and install warning lines in accordance with 29 CFR 1926.500 and USACE EM 385-1-1.

b. Steep-Sloped Roofs: Work on steep-sloped roofs requires a personal fall arrest system, guardrails with toe-boards, or safety nets. This requirement also includes residential or housing type construction.

3.4.4 Horizontal Lifelines

Design, install, certify and use under the supervision of a qualified person horizontal lifelines for fall protection as part of a complete fall arrest system which maintains a safety factor of 2 (29 CFR 1926.500).

3.4.5 Guardrails and Safety Nets

Design, install and use guardrails and safety nets in accordance with EM 385-1-1 and 29 CFR 1926 Subpart M.

3.4.6 Rescue and Evacuation Procedures

When personal fall arrest systems are used, ensure that the mishap victim can self-rescue or can be rescued promptly should a fall occur. Prepare a Rescue and Evacuation Plan and include a detailed discussion of the following: methods of rescue; methods of self-rescue; equipment used; training requirement; specialized training for the rescuers; procedures for requesting rescue and medical assistance; and transportation routes to a medical facility. Include the Rescue and Evacuation Plan within the Activity Hazard Analysis (AHA) for the phase of work, in the Fall

W912EP-17-B-0003 SECTION 01 35 26 Page 19 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Protection and Prevention (FP&P) Plan, and the Accident Prevention Plan (APP).

3.5 SCAFFOLDING

Provide employees with a safe means of access to the work area on the scaffold. Climbing of any scaffold braces or supports not specifically designed for access is prohibited. Access scaffold platforms greater than 20 feet maximum in height by use of a scaffold stair system. Do not use vertical ladders commonly provided by scaffold system manufacturers for accessing scaffold platforms greater than 20 feet maximum in height. The use of an adequate gate is required. Ensure that employees are qualified to perform scaffold erection and dismantling. Do not use scaffold without the capability of supporting at least four times the maximum intended load or without appropriate fall protection as delineated in the accepted fall protection and prevention plan. Stationary scaffolds must be attached to structural building components to safeguard against tipping forward or backward. Give special care to ensure scaffold systems are not overloaded. Side brackets used to extend scaffold platforms on self-supported scaffold systems for the storage of material is prohibited. The first tie-in shall be at the height equal to 4 times the width of the smallest dimension of the scaffold base. Place work platforms on mud sills. Scaffold or work platform erectors shall have fall protection during the erection and dismantling of scaffolding or work platforms that are more than six feet. Delineate fall protection requirements when working above six feet or above dangerous operations in the Fall Protection and Prevention (FP&P) Plan and Activity Hazard Analysis (AHA) for the phase of work.

3.6 EQUIPMENT

3.6.1 Material Handling Equipment

a. Material handling equipment such as forklifts shall not be modified with work platform attachments for supporting employees unless specifically delineated in the manufacturer's printed operating instructions.

b. The use of hooks on equipment for lifting of material must be in accordance with manufacturer's printed instructions.

c. Operators of forklifts or power industrial trucks shall be licensed in accordance with OSHA.

d. All heavy equipment operators to include excavators, front-end loaders, dump trucks, and compactors shall be evaluated by a competent/qualified person prior to starting work. The SSHO will maintain all records of this training. The training plan/outline will include hazards identified in the owner's manual.

3.6.2 Load Handling Equipment (LHE)

a. Equip cranes and derricks as specified in EM 385-1-1, section 16 and in accordance with 29 CFR 1926.1427.

b. Notify the Contracting Officer 30 days in advance of any cranes entering the activity so that necessary quality assurance spot checks can be coordinated. Contractor's operator shall remain with the crane during the spot check.

W912EP-17-B-0003 SECTION 01 35 26 Page 20 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

c. Comply with the crane manufacturer's specifications and limitations for erection and operation of cranes and hoists used in support of the work. Perform erection under the supervision of a designated person (as defined in ANSI/ASME B30.5). Perform all testing in accordance with the manufacturer's recommended procedures.

d. Comply with ANSI/ASME B30.5 for mobile and locomotive cranes, ANSI/ASME B30.22 for articulating boom cranes, ANSI/ASME B30.3 for construction tower cranes, and ANSI/ASME B30.8 for floating cranes and floating derricks.

e. Under no circumstance shall a Contractor make a lift at or above 90 percent of the cranes rated capacity in any configuration.

f. When operating in the vicinity of overhead transmission lines, operators and riggers shall be alert to this special hazard and follow the requirements of USACE EM 385-1-1 Section 11 and ANSI/ASME B30.5 or ANSI/ASME B30.22 as applicable.

g. Do not use crane suspended personnel work platforms (baskets) unless the Contractor proves that using any other access to the work location would provide a greater hazard to the workers or is impossible. Do not lift personnel with a line hoist or friction crane. No other item shall be lifted with the crane while the work platform is in use (lifting a worker).

h. Inspect, maintain, and recharge portable fire extinguishers as specified in NFPA 10, Standard for Portable Fire Extinguishers.

i. All employees must keep clear of loads about to be lifted and of suspended loads.

j. Use cribbing when performing lifts on outriggers.

k. The crane hook/block must be positioned directly over the load. Side loading of the crane is prohibited.

l. A physical barricade must be positioned to prevent personnel from entering the counterweight swing (tail swing) area of the crane.

m. Certification records which include the date of inspection, signature of the person performing the inspection, and the serial number or other identifier of the crane that was inspected shall always be available for review by Contracting Officer personnel.

n. Written reports listing the load test procedures used along with any repairs or alterations performed on the crane shall be available for review by Contracting Officer personnel.

o. Certify that all crane operators have been trained in proper use of all safety devices (e.g. anti-two block devices).

p. Lightning Protection/Devices are required on all Load Handling Equipment, Cranes, Crane Work.

3.6.3 Equipment and Mechanized Equipment

a. Proof of training and qualifications for operator shall be kept on the

W912EP-17-B-0003 SECTION 01 35 26 Page 21 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

project site for review. The SSHO shall review certifications and qualifications of training for all the operators. If a competent person (CP) accomplishes training the CP certification and qualification will be approved prior to any training and/or certification of operators, all initial documentation (i.e. Training material, written test and/or driving evaluations) shall be reviewed by SSHO, Project Manager (PM), Superintendent or supervisor ensuring operators are current with training, permits and testing requirement. SSHO shall maintain a matrix and review monthly. The matrix requirements shall be forwarded to all equipment supervisors. This matrix shall have, as a minimum, the following information:

(1) Month and year. (2) Name of operator. (3) Initial date of certification. (4) Expiration date. (5) Name of trainer. (6) Medical evaluation date (if required). (7) Medical evaluation expiration date. (8) Operator equipment type certification. (9) Equipment serial number. (10) Equipment model.

Note: All documentation shall be maintained and copies furnished to the GDA upon request.

b. Manufacture specifications or owner's manual for the equipment shall be on-site and reviewed for additional safety precautions or requirements that are sometimes not identified by OSHA or USACE EM 385-1-1. Incorporate such additional safety precautions or requirements into the AHAs.

3.6.4 Use of Explosives

Explosives shall not be used or brought to the project site without prior written approval from the Contracting Officer. Such approval shall not relieve the Contractor of responsibility for injury to persons or for damage to property due to blasting operations.

Storage of explosives, when permitted on Government property, shall be only where directed and in approved storage facilities. These facilities shall be kept locked at all times except for inspection, delivery, and withdrawal of explosives.

3.7 EXCAVATIONS

Soil classification must be performed by a competent/qualified person in accordance with 29 CFR 1926 and EM 385-1-1.

3.7.1 Utility Locations

All underground utilities in the work area must be positively identified by a third party, independent, private utility locating company in addition to any station locating service and coordinated with the station utility department.

3.7.2 Utility Location Verification

Physically verify underground utility locations, including utility depth,

W912EP-17-B-0003 SECTION 01 35 26 Page 22 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

by hand digging using wood or fiberglass handled tools when any adjacent construction work is expected to come within three feet of the underground system.

3.7.3 Utilities Within and Under Concrete, Bituminous Asphalt, and Other Impervious Surfaces

Utilities located within and under concrete slabs or pier structures, bridges, parking areas, and the like, are extremely difficult to identify. Whenever contract work involves chipping, saw cutting, or core drilling through concrete, bituminous asphalt or other impervious surfaces, the existing utility location must be coordinated with station utility departments in addition to location and depth verification by a third party, independent, private locating company. The third party, independent, private locating company shall locate utility depth by use of Ground Penetrating Radar (GPR), X-ray, bore scope, or ultrasound prior to the start of demolition and construction. Outages to isolate utility systems must be used in circumstances where utilities are unable to be positively identified. The use of historical drawings does not alleviate the contractor from meeting this requirement.

3.8 ELECTRICAL

3.8.1 Conduct of Electrical Work

Underground electrical spaces must be certified safe for entry before entering to conduct work. Cables that will be cut must be positively identified and de-energized prior to performing each cut. Positive cable identification must be made prior to submitting any outage request for electrical systems. Arrangements are to be coordinated with the Contracting Officer and Station Utilities for identification. The Contracting Officer will not accept an outage request until the Contractor satisfactorily documents that the circuits have been clearly identified. Perform all high voltage cable cutting remotely using hydraulic cutting tool. When racking in or live switching of circuit breakers, no additional person other than the switch operator will be allowed in the space during the actual operation. Plan so that work near energized parts is minimized to the fullest extent possible. Use of electrical outages clear of any energized electrical sources is the preferred method. When working in energized substations, only qualified electrical workers will be permitted to enter. When work requires Contractor to work near energized circuits as defined by the NFPA 70, high voltage personnel must use personal protective equipment that includes, as a minimum, electrical hard hat, safety boots, insulating gloves with leather protective sleeves, fire retarding shirts, coveralls, face shields, and safety glasses. In addition, provide electrical arc flash protection for personnel as required by NFPA 70E. Insulating blankets, hearing protection, and switching suits may also be required, depending on the specific job and as delineated in the Contractor's AHA.

3.8.2 Portable Extension Cords, Generators and Tools

Size portable extension cords in accordance with manufacturer ratings for the tool to be powered and protected from damage. Immediately remove from service all damaged extension cords. Portable extension cords shall meet the requirements of EM 385-1-1, NFPA 70E, and OSHA electrical standards. All portable generators shall be in compliance with National Electrical Code (NFPA 70) Article 250-34. All portable energized power tools shall be connected to Ground Fault Interrupter GFI receptacles or Ground Fault

W912EP-17-B-0003 SECTION 01 35 26 Page 23 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Circuit Interrupter (GFCI). At the disposal site, portable equipment, floodlights, and work lights shall be grounded to comply with EM 385-1-1, Section 11.D.01.f. The protective ground shall be maintained during relocation unless circuits are de-energized.

3.9 WORK IN CONFINED SPACES

Comply with the requirements in Section 34 of USACE EM 385-1-1, OSHA 29 CFR 1910, OSHA 29 CFR 1910.146, OSHA Directive CPL 2.100 and OSHA 29 CFR 1926, and OSHA 29 CFR 1926 Subpart AA. Any potential for a hazard in the confined space requires a permit system to be used.

a. Entry Procedures. Prohibit entry into a confined space by personnel for any purpose, including hot work, until the qualified person has conducted appropriate tests to ensure the confined or enclosed space is safe for the work intended and that all potential hazards are controlled or eliminated and documented. (See Section 34 of USACE EM 385-1-1 for entry procedures.) All hazards pertaining to the space shall be reviewed with each employee during review of the AHA.

b. Forced air ventilation is required for all confined space entry operations and the minimum air exchange requirements must be maintained to ensure exposure to any hazardous atmosphere is kept below its action level.

c. Sewer wet wells require continuous atmosphere monitoring with audible alarm for toxic gas detection.

-- End of Section --

W912EP-17-B-0003 SECTION 01 35 26 Page 24 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 45 00

RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

PART 1 GENERAL

1.1 REFERENCES 1.2 Contract Administration 1.2.1 Correspondence and Electronic Communications 1.2.2 Other Factors 1.3 RMS SOFTWARE 1.3.1 RMS CONTRACTOR'S MODE (CM) 1.4 SYSTEM REQUIREMENTS 1.5 RELATED INFORMATION 1.5.1 RMS User Guide 1.6 CONTRACT DATABASE 1.7 DATABASE MAINTENANCE 1.7.1 Administration 1.7.1.1 Contractor Information 1.7.1.2 Subcontractor Information 1.7.1.3 Correspondence 1.7.1.4 Equipment 1.7.1.5 Management Reporting 1.7.1.6 Request For Information (RFI) 1.7.2 Finances 1.7.2.1 Pay Activity Data 1.7.2.2 Payment Requests 1.7.3 Quality Control (QC) 1.7.3.1 Daily Contractor Quality Control (CQC) Reports. 1.7.3.2 Deficiency Tracking. 1.7.3.3 QC Requirements 1.7.3.4 Three-Phase Control Meetings 1.7.3.5 Labor and Equipment Hours 1.7.3.6 Accident/Safety Reporting 1.7.3.7 Features of Work 1.7.3.8 Hazard Analysis 1.7.4 Submittal Management 1.7.5 Schedule 1.7.6 Import/Export of Data 1.8 IMPLEMENTATION 1.9 MONTHLY COORDINATION MEETING 1.10 NOTIFICATION OF NONCOMPLIANCE

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 45 00 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

W912EP-17-B-0003 SECTION 01 45 00 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 45 00

RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this section to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 Safety and Health Requirements Manual

1.2 Contract Administration

The Government will use the Resident Management System (RMS) to assist in its monitoring and administration of this contract. The Contractor uses the Government-furnished Construction Contractor Mode of RMS, referred to as RMS CS, to record, maintain, and submit various information throughout the contract period. The Contractor mode user manuals, updates, and training information can be downloaded from the RMS web site (http://rms.usace.army.mil). The joint Government-Contractor use of RMS facilitates electronic exchange of information and overall management of the contract. QCS provides the means for the Contractor to input, track, and electronically share information with the Government in the following areas:

Administration Finances Quality Control Submittal Monitoring Scheduling Import/Export of Data

1.2.1 Correspondence and Electronic Communications

For ease and speed of communications, exchange correspondence and other documents in electronic format to the maximum extent feasible between the Government and Contractor. Correspondence, pay requests and other documents comprising the official contract record are also be provided in paper format, with signatures and dates where necessary. Paper documents will govern, in the event of discrepancy with the electronic version.

1.2.2 Other Factors

Particular attention is directed to Contract Clause, "Schedules for Construction Contracts", Contract Clause, "Payments", Section 01 32 01 PROJECT SCHEDULE, Section 01 33 00 SUBMITTAL PROCEDURES, and Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL, which have a direct relationship to the reporting to be accomplished through RMS. Also, there is no separate payment for establishing and maintaining the RMS database; costs associated will be included in the contract

W912EP-17-B-0003 SECTION 01 45 00 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

pricing for the work.

1.3 RMS SOFTWARE

RMS is a Windows-based program that can be run on a Windows based PC meeting the requirements as specified in Section 1.3. The Government will make available the RMS software to the Contractor after award of the construction contract. Prior to the Pre-Construction Conference, the Contractor will be responsible to download, install and use the latest version of the RMS software from the Government's RMS Internet Website. Any program updates of RMS will be made available to the Contractor via the Government RMS Website as the updates become available.

1.3.1 RMS CONTRACTOR'S MODE (CM)

RMS Contractor's Mode or RMS CM is the replacement for Quality Control System or QCS. The database remains the same. References to RMS in this specification includes RMS CM.

1.4 SYSTEM REQUIREMENTS

The following is the minimum system configuration required to run RMS and Contractor Mode:

Minimum RMS System Requirements

Hardware

Windows-based PC 1.5 GHz 2 core or higher processor

RAM 8 GB

Hard drive disk 200 GB space for sole use by the QCS system

Monitor Screen resolution 1366 x 768

Mouse or other pointing device

Windows compatible printer Laser printer must have 4 MB+ of RAM

Connection to the Internet minimum 4 Mbs per user

Software

MS Windows Windows 7 x 64 bit (RMS requires 64 bit O/S) or newer Word Processing software Viewer for MS Word 2013, MS Excel 2013, or newer

W912EP-17-B-0003 SECTION 01 45 00 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Minimum RMS System Requirements

Microsoft.NET Framework Coordinate with Government QA Representative for free version required

Email MAPI compatible

Virus protection software Regularly upgraded with all issued manufacturer's updates and is able to detect most zero day viruses.

1.5 RELATED INFORMATION

1.5.1 RMS User Guide

After contract award, download instructions for the installation and use of RMS from the Government RMS Internet Website.

1.6 CONTRACT DATABASE

Prior to the pre-construction conference, the Government will provide the Contractor with basic contract award data to use for RMS. The Government will provide data updates to the Contractor as needed. These updates will generally consist of submittal reviews, correspondence status, Quality Assurance(QA) comments, and other administrative and QA data.

1.7 DATABASE MAINTENANCE

Establish, maintain, and update data in the RMS database throughout the duration of the contract at the Contractor's site office. Submit data updates to the Government (e.g., daily reports, submittals, RFI's, schedule updates, payment requests) using RMS. The RMS database typically includes current data on the following items:

1.7.1 Administration

1.7.1.1 Contractor Information

Contain within the database the Contractor's name, address, telephone numbers, management staff, and other required items. Within 7 calendar days of receipt of RMS software from the Government, deliver Contractor administrative data in electronic format in RMS.

1.7.1.2 Subcontractor Information

Contain within the database the name, trade, address, phone numbers, and other required information for all subcontractors. A subcontractor is listed separately for each trade to be performed. Assign each subcontractor/trade a unique Responsibility Code, provided in RMS. Within 7 calendar days of receipt of RMS software from the Government, deliver subcontractor administrative data in electronic format.

W912EP-17-B-0003 SECTION 01 45 00 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.7.1.3 Correspondence

Identify all Contractor correspondence to the Government with a serial number. Prefix correspondence initiated by the Contractor's site office with "S". Prefix letters initiated by the Contractor's home (main) office with "H". Letters are numbered starting from 0001. (e.g., H-0001 or S-0001). The Government's letters to the Contractor will be prefixed with "C".

1.7.1.4 Equipment

Contain within the Contractor's RMS database a current list of equipment planned for use or being used on the jobsite, including the most recent and planned equipment inspection dates.

1.7.1.5 Management Reporting

RMS includes a number of reports that Contractor management can use to track the status of the project. The value of these reports is reflective of the quality of the data input, and is maintained in the various sections of RMS. Among these reports are: Progress Payment Request worksheet, Quality Assurance/Quality Control (QA/QC) comments, Submittal Register Status, Three-Phase Control checklists.

1.7.1.6 Request For Information (RFI)

Exchange all Requests For Information (RFI) using the Built-in RFI generator and tracker in RMS.

1.7.2 Finances

1.7.2.1 Pay Activity Data

Include within the RMS database a list of pay activities that the Contractor develops in conjunction with the construction schedule. The sum of pay activities equals the total contract amount, including modifications. Each pay activity must be assigned to a Contract Line Item Number (CLIN). The sum of the activities equals the amount of each CLIN. The sum of all CLINs equals the contract amount.

1.7.2.2 Payment Requests

Prepare all progress payment requests using RMS. Complete the payment request worksheet, prompt payment certification, and payment invoice in RMS. Update the work completed under the contract, measured as percent or as specific quantities, at least monthly. After the update, generate a payment request report using RMS. Submit the payment request, prompt payment certification, and payment invoice with supporting data using RMS CM. If permitted by the Contracting Officer, email or a optical disc may be used. A signed paper copy of the approved payment request is also required and will govern in the event of discrepancy with the electronic version.

1.7.3 Quality Control (QC)

RMS provides a means to track implementation of the 3-phase QC Control System, prepare daily reports, identify and track deficiencies, document progress of work, and support other Contractor QC requirements. Maintain this data on a daily basis. Entered data will automatically output to the

W912EP-17-B-0003 SECTION 01 45 00 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

RMS generated daily report. Provide the Government a Contractor Quality Control (CQC) Plan within the time required in Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL. Within seven calendar days of Government acceptance, submit a RMS update reflecting the information contained in the accepted CQC Plan: schedule, pay activities, features of work, submittal register, QC requirements, and equipment list.

1.7.3.1 Daily Contractor Quality Control (CQC) Reports.

RMS includes the means to produce the Daily CQC Report. The Contractor can use other formats to record basic Quality Control(QC) data. However, the Daily CQC Report generated by RMS must be the Contractor's official report. Summarize data from any supplemental reports by the Contractor and consolidate onto the RMS-generated Daily CQC Report. Submit daily CQC Reports as required by Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL. Electronically submit reports to the Government within 24 hours after the date covered by the report. Also provide the Government a signed, printed copy of the daily CQC report.

1.7.3.2 Deficiency Tracking.

Use RMS to track deficiencies. Deficiencies identified by the Contractor will be numerically tracked using its Quality Control (QC) punch list items. Maintain a current log of its QC punch list items in the RMS database. The Government will log the deficiencies it has identified using its Quality Assurance (QA) punch list items. The Government's QA punch list items will be included in its export file to the Contractor. Regularly update the correction status of both QC and QA punch list items.

1.7.3.3 QC Requirements

Develop and maintain a complete list of QC testing and required structural and life safety special inspections required by the International Code Council (ICC), transferred and installed property, and user training requirements in RMS. Update data on these QC requirements as work progresses, and promptly provide the information to the Government via RMS.

1.7.3.4 Three-Phase Control Meetings

Maintain scheduled and actual dates and times of preparatory and initial control meetings in RMS.

1.7.3.5 Labor and Equipment Hours

Log labor and equipment exposure hours on a daily basis. The labor and equipment exposure data will be rolled up into a monthly exposure report.

1.7.3.6 Accident/Safety Reporting

The Government will issue safety comments, directions, or guidance whenever safety deficiencies are observed. The Government's safety comments will be provided via RMS CM. Regularly update the correction status of the safety comments. In addition, utilize RMS to advise the Government of any accidents occurring on the jobsite. A brief supplemental entry of an accident is not to be considered as a substitute for completion of mandatory reports, e.g., ENG Form 3394 and OSHA Form 300.

W912EP-17-B-0003 SECTION 01 45 00 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.7.3.7 Features of Work

Include a complete list of the features of work in the RMS database. A feature of work is associated with multiple pay activities. However, each pay activity (see subparagraph "Pay Activity Data" of paragraph "Finances") will only be linked to a single feature of work.

1.7.3.8 Hazard Analysis

Use RMS CM to develop a hazard analysis for each feature of work included in the CQC Plan. The Activity Hazard Analysis will include information required by EM 385-1-1, paragraph 01.A.13.

1.7.4 Submittal Management

For Design-Bid-Build contracts, the Government will provide the initial submittal register in electronic format. For Design-Build contracts, the Designer of Record (DOR) is responsible for developing the submittal register in electronic format."... or something to that effect. Thereafter, maintain a complete list of submittals, including completion of data columns. Dates when submittals are received and returned by the Government will be included. Use RMS CM to track and transmit submittals. ENG Form 4025, submittal transmittal form, and the submittal register update is produced using RMS. RMS will be used to update, store and exchange submittal registers and transmittals. In addition to requirements stated in specification 01 33 00, actual submittals are to be stored in RMS CM, with hard copies also provided. Exception will be where the Contracting Officer specifies only hard copies required, where size of document cannot be saved in RMS CM, and where samples, spare parts, color boards, and full size drawings are to be provided.

1.7.5 Schedule

Develop a construction schedule consisting of pay activities, in accordance with Section 01 32 01 PROJECT SCHEDULE. Input and maintain in the RMS database the schedule either manually or by using the Standard Data Exchange Format (SDEF) (see Section 01 32 01 PROJECT SCHEDULE). Include with each pay request the updated schedule. Provide electronic copies of transmittals.

1.7.6 Import/Export of Data

RMS includes the ability to import schedule data using SDEF.

1.8 IMPLEMENTATION

Use of RMS CM as described in the preceding paragraphs is mandatory. Ensure that sufficient resources are available to maintain contract data within the RMS CM system. RMS CM is an integral part of the Contractor's management of quality control.

1.9 MONTHLY COORDINATION MEETING

Update the RMS CM database each workday. At least monthly, generate and submit a schedule update. At least one week prior to submittal, meet with the Government representative to review the planned progress payment data submission for errors and omissions.

Make required corrections prior to Government acceptance of the export

W912EP-17-B-0003 SECTION 01 45 00 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

file and progress payment request. Payment requests accompanied by incomplete or incorrect data submittals will not be accepted. The Government will not process progress payments until all required corrections are processed.

1.10 NOTIFICATION OF NONCOMPLIANCE

The Contracting Officer will notify the Contractor of any detected noncompliance with the requirements of this specification. Take immediate corrective action after receipt of such notice. Such notice, when delivered to the Contractor at the work site, will be deemed sufficient for the purpose of notification.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section --

W912EP-17-B-0003 SECTION 01 45 00 Page 9 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 45 05

DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL

PART 1 GENERAL

1.1 RESIDENT MANAGEMENT SYSTEM (RMS3CM) 1.1.1 Help Support 1.2 DEFINITIONS 1.2.1 Project Manager/Superintendent 1.2.2 Quality Control System Manager 1.2.3 Safety Officer 1.2.4 Endangered Species Monitor 1.2.5 Qualified Scheduler 1.3 REFERENCES 1.4 SUBMITTALS

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 GENERAL 3.2 QUALITY CONTROL PLAN 3.2.1 General 3.2.1.1 CQC Plan Resubmittal 3.2.1.2 Failure 3.2.2 Content of the CQC Plan 3.2.3 Acceptance of Plan 3.2.4 Notification of Changes 3.3 COORDINATION MEETING 3.4 QUALITY CONTROL ORGANIZATION 3.4.1 General 3.4.2 CQC System Manager 3.4.3 Qualified Scheduler 3.4.4 CQM-C Training Requirement 3.4.5 Surveyor 3.4.6 Organizational Changes 3.5 SUBMITTALS AND DELIVERABLES 3.6 CONTROL 3.6.1 Preparatory Phase 3.6.2 Initial Phase 3.6.3 Follow-up Phase 3.6.4 Additional Preparatory and Initial Phases 3.7 TESTS/TESTING PROCEDURE 3.8 COMPLETION INSPECTION 3.8.1 Post-Construction Measurement and Inspection 3.8.2 Pre-Final Inspection 3.8.3 Final Inspection 3.9 DOCUMENTATION

W912EP-17-B-0003 SECTION 01 45 05 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.10 NOTIFICATION OF COMPLIANCE 3.11 SAMPLE FORMS

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 45 05 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 45 05

DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL

PART 1 GENERAL

1.1 RESIDENT MANAGEMENT SYSTEM (RMS3CM)

Contractor shall use the most currently approved version of Government-furnished "RMS3CM Contractor Mode" software as indicated in Section 01 45 00 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS3CM).

1.1.1 Help Support

Contractor should contact following help phone numbers for assistance.

Step 1 - Call your Area Office RMS3CM Administrator:

Area Office RMS3CM Administrators:

North Florida - 904-232-3818 South Florida - 561-308-2116 San Juan - 787-707-6165 x3008

Step 2 - Submit a ticket via the RMS3CM support website. Tickets can be submitted at http://rmssupport.helpserve.com/Tickets/Submit.

1.2 DEFINITIONS

1.2.1 Project Manager/Superintendent

Highest level manager located onsite and responsible for dredging, disposal and related activities, including but not limited to the following: production, quality control, safety, turbidity monitoring, endangered species monitoring and environmental protection.

1.2.2 Quality Control System Manager

A person assigned duties to manage Contractor's Quality Control (CQC) system. CQC System Manager shall have written delegated authority sufficient to stop work that is not in compliance with contract.

1.2.3 Safety Officer

Person assigned responsibility for site safety management. The Safety Officer shall have no other duties. See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS.

1.2.4 Endangered Species Monitor

The person assigned for identifying regulatory protected wildlife and advising the Contractor in modifying operations to protect identified species or prevent damage to their habitat shall have acceptable qualifications and demonstrated ability. Refer to Section 01 57 20 ENVIRONMENTAL PROTECTION.

W912EP-17-B-0003 SECTION 01 45 05 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.2.5 Qualified Scheduler

Person assigned responsibility for the preparation of the schedule, all required schedule updates, and preparation of all required schedule reports.

1.3 REFERENCES

The publication(s) listed below form(s) a part of this specification to the extent referenced. The publication(s) are referred to in the text by basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

ER 1180-1-6 (1995) Construction Quality Management

Corps of Engineers publication(s) Internet location site is: http://www.publications.usace.army.mil/.

1.4 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submittals shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 30 calendar days after Notice to Proceed:

SD-01 Preconstruction Submittals

Quality Control Plan; G, RO

Refer to paragraph QUALITY CONTROL PLAN below.

SD-07 Certificates

Letter of Authority

Letter to CQC System Manager signed by an authorized Contractor official which describes responsibilities and delegates sufficient authorities to perform functions of the CQC System Manager, including authority to stop work not in compliance with contract.

Personnel Qualifications; G, RO

Submit personnel qualifications for Project Manager/Superintendent, CQC System Manager, Safety Officer, Endangered Species Monitor, in resume form.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 GENERAL

The Contractor is responsible to plan and execute quality control in accordance with ER 1180-1-6 and establish and maintain an effective

W912EP-17-B-0003 SECTION 01 45 05 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

quality control system in compliance with the Clause INSPECTION OF CONSTRUCTION of Section 00700 CONTRACT CLAUSES in Volume 1. The quality control system shall consist of plans, procedures, and organization necessary to produce an end product which complies with the contract requirements. Project Manager/Superintendent is responsible for quality of work and is subject to removal by the Contracting Officer for non-compliance with contract quality requirements. The Project Manager/Superintendent shall be on site at all times, except as otherwise approved by the Contracting Officer.

3.2 QUALITY CONTROL PLAN

3.2.1 General

No later than 15 to 30 calendar days after award or 30 calendar days after Notice to Proceed, whichever is later, submit a written CQC Plan for review and acceptance by the Contracting Officer. CQC Plan submittal will be reviewed by Contracting Officer and discussed in detail at a Coordination Meeting (see paragraph COORDINATION MEETING below). CQC Plan shall identify organization chart, personnel, procedures, control methods, instructions, tests, records, and forms to be used. Contracting Officer may accept an "interim CQC Plan" under a "conditional acceptance" for first 30 calendar days of operation. Contractor shall furnish, not later than 30 calendar days after commencement of work, an acceptable overall CQC Plan.

3.2.1.1 CQC Plan Resubmittal

No construction will be allowed to start until an "interim CQC Plan" is "conditionally accepted". When an "interim CQC Plan" is "conditionally accepted", revise and resubmit overall project CQC Plan for Contracting Officer's acceptance. When Contractor is working under an "interim CQC Plan", until Contractor submits an acceptable final CQC Plan, Contracting Officer may retain funds from progress payments in accordance with Clause PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS of Section 00700 CONTRACT CLAUSES in Volume 1. When no acceptable CQC Plan is resubmitted within a reasonable time, as determined by Contracting Officer, Contracting Officer may order Contractor to stop work until such time as a CQC Plan is accepted. Such a directed stop work order shall not be considered a suspension of work under Clause SUSPENSION OF WORK of Section 00700 CONTRACT CLAUSES in Volume 1. No pay or construction period adjustments will be allowed as a result of a directed stop work order based on Contractor inability to plan quality control in a manner acceptable to Contracting Officer.

3.2.1.2 Failure

Failure to comply with above requirements within time prescribed will be considered a condition endangering contract performance and may be considered grounds for termination of contract in accordance with Clause DEFAULT (FIXED-PRICE CONSTRUCTION) of Section 00700 CONTRACT CLAUSES in Volume 1.

3.2.2 Content of the CQC Plan

a. Describe Quality Control Organization: Include an organization chart with lines of authority and reporting. See Section 01 57 20 ENVIRONMENTAL PROTECTION for Endangered Species Monitor qualifications.

W912EP-17-B-0003 SECTION 01 45 05 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

b. Definable Features of Work: Provide a list to be agreed upon during the Coordination Meeting.

c. Qualifications: Names, qualifications (in resume format), duties, responsibilities, and authorities of each person assigned a CQC function. If included, see paragraph LIMITATIONS ON SUBSTITUTIONS FOR CERTAIN POSITIONS AND/OR SUBCONTRACTORS of Section 00800 SPECIAL REQUIREMENTS in Volume 1.

d. Letter of Authority: Copy of letter of authority to CQC System Manager. The CQC System Manager shall issue letters of direction to other quality control staff describing duties, authorities, and responsibilities.

e. Submittal Control: Procedures for scheduling, reviewing, certifying, and managing submittals. These procedures shall be in accordance with Section 01 33 00 SUBMITTAL PROCEDURES.

f. Testing: Control, verification, turbidity monitoring, and field testing procedures. Provide a list of specific instruments and tests. Provide information including work being tested, test frequency, and identify who (Contractor, Subcontractor) is responsible for each test. COE certified laboratory facilities will be approved by the Contracting Officer).

g. Three Phase Control: Procedures to implement three phase quality control and inspection system. Procedures to plan and document preparatory, initial, and follow-up control phases.

h. Deficiency Tracking: Procedures for tracking construction deficiencies from identification and steps for acceptable corrective action. Establish procedures to verify that deficiencies have been corrected and document correction.

i. Reports and Forms: Reporting procedures, including proposed reporting formats and sample forms.

j. Table of Contents: Pages of QC plan shall be numbered, including appendices. Table of contents shall be provided. Sections of the plan and all appendices shall be indexed in the table of contents.

3.2.3 Acceptance of Plan

"Conditional acceptance" of the Contractor's interim CQC Plan is required prior to starting dredging or other construction activities. Contracting Officer's acceptance is conditional and is contingent on satisfactory performance during construction. The Contracting Officer reserves the right to require the Contractor to make changes in his CQC Plan and construction operations, including removal of personnel.

3.2.4 Notification of Changes

Notify Contracting Officer in writing a minimum of 30 calendar days prior to proposed personnel or CQC Plan procedure changes. Proposed changes are subject to Contracting Officer acceptance.

W912EP-17-B-0003 SECTION 01 45 05 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.3 COORDINATION MEETING

Refer to Section 01 30 00 ADMINISTRATIVE PROCEDURES. Contracting Officer will schedule a Coordination Meeting where Contractor personnel and Contracting Officer personnel will develop a mutual understanding of how Contractor's Quality Control works with Contracting Officer's Quality Assurance. CQC Plan will be discussed in detail, including forms for recording CQC operations, control activities, testing, and administration of the system for both onsite and offsite work. Contractor quality control for production, measurement and payment, safety, turbidity monitoring, plant and equipment location, monitoring, endangered species monitoring, environmental protection and supervision by Quality Control personnel will be discussed. Meeting minutes will be prepared by Contracting Officer and signed by Contractor and Contracting Officer. The minutes shall become a part of the contract file. There may be occasions when subsequent conferences will be called by either party to reconfirm mutual understandings and/or address deficiencies in the CQC system, or procedures requiring corrective action.

3.4 QUALITY CONTROL ORGANIZATION

3.4.1 General

CQC organization shall have a CQC System Manager and sufficient number of additional qualified personnel to ensure contract quality control for workmanship and materials, including safety and environmental protection compliance. Designate Safety Officer and qualified Endangered Species Monitor who shall serve as a member of CQC staff. Provide office space, computer hardware and software, filing systems and other resources as necessary to maintain an effective CQC organization. CQC organization shall be responsible to maintain documentation and records onsite, unless approved by the Contracting Officer.

3.4.2 CQC System Manager

The Contractor shall identify an individual, employed by Contractor, within onsite organization who shall be responsible for CQC management. CQC System Manager shall have authority to act in all CQC matters for the Contractor. CQC System Manager shall be an experienced dredging or construction person with a minimum of 3 years in similar work. Identify an alternate person to serve as CQC System Manager during actual CQC System Manager's absences. Designated alternate shall be a construction person with a minimum three years experience on similar projects and shall meet CQM-C Training requirement below. CQC System Manager or a designated alternate shall be onsite during construction. CQC System Manager shall have no other duties assigned. CQC System Manager shall report to management level above Superintendent.

3.4.3 Qualified Scheduler

Provide a Qualified Scheduler who will be responsible for the preparation of the schedule and all required updating and preparation of reports. The Qualified Scheduler shall be part of the QC Staff. The resume of the Qualified Scheduler shall be provided as part of the QC Plan for Government review and acceptance. The scheduler shall be experienced in scheduling and have previously developed, created, and maintained at least 2 electronic schedules for projects similar in nature and complexity to this project. The scheduler shall be experienced in the use of scheduling software that meets the requirements this contract and is used by the

W912EP-17-B-0003 SECTION 01 45 05 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Contractor.

3.4.4 CQM-C Training Requirement

CQC System Manager shall have completed U.S. Army Corps of Engineers (COE) course "Construction Quality Management for Contractors" (CQM-C) within the previous five years. A completion certificate from any Corps District or Naval Facilities Command is acceptable. In event proposed CQC System Manager has not completed CQM-C training, he or she shall complete the CQM-C course prior to commencement of work. The Contractor will not be permitted to commence work until these training requirements have been satisfied. Any delays attributable to the Contractor's failure to comply with these pre-work requirements shall be at the Contractor's expense and may be cause for remedial action by the Contracting Officer. Information regarding CQM-C course can be obtained by contacting Chief, Quality Assurance Branch at 904-232-1128.

3.4.5 Surveyor

Survey, topographic survey, and hydrographic survey shall be performed by persons working under direct supervision of a Professional Surveyor and Mapper (PSM) registered in the State of Florida. PSM shall certify field notes, computations, and other records relating to quantity survey.

3.4.6 Organizational Changes

When CQC staff changes are needed, revise CQC Organization Chart in CQC Plan to reflect changes and submit the changes to Contracting Officer for acceptance.

3.5 SUBMITTALS AND DELIVERABLES

Submittals shall be prepared and transmitted as specified in Section 01 33 00 SUBMITTAL PROCEDURES. CQC organization shall certify submittals comply with contract requirements. Items delivered to Contracting Officer shall be controlled, packaged, transported and stored in a manner to prevent damage or loss.

3.6 CONTROL

Contractor's Quality Control is the means by which Contractor ensures construction, including that of subcontractors, complies with contract. Conduct Preparatory Phase and Initial Phase meetings for each definable feature of work (refer to Section 01 30 00 ADMINISTRATIVE PROCEDURES). Acceptance sections will be determined at the Preconstruction Conference by agreement between the Contracting Officer and the Contractor. Perform three phases of control for each definable feature of work as follows:

3.6.1 Preparatory Phase

This phase shall be performed prior to beginning work on each definable feature of work. Notify Contracting Officer at least 24 hours in advance of beginning Preparatory Control Phase. Ensure proposed plans, activity hazard analyses, permits and submittals, are approved and copies are onsite. Conduct a Preparatory Phase meeting headed by CQC System Manager and attended by Superintendent, other CQC personnel, and foreman responsible for supervising workmanship for definable feature of work. Document Preparatory Phase actions using "Preparatory Phase Checklist" and meeting minutes prepared by CQC System Manager. Preparatory Phase

W912EP-17-B-0003 SECTION 01 45 05 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

checklist is in the RMS3CM software. Attach checklist and minutes to Contractor's Quality Control (CQC) report. Preparatory Phase actions include:

a. Review each paragraph of specifications. Make copies available for use by Contracting Officers personnel and Contractor CQC staff at Preparatory Phase meeting. Maintain copies available until final acceptance of the work.

b. Review of contract drawings.

c. Check to assure that plant and/or equipment have been inspected, tested, submitted, and approved.

d. Review provisions that have been made to provide required quality control inspection and testing.

e. Examine work area to assure required preliminary work is complete and in compliance with contract.

f. Review of activity hazard analysis to assure safety requirements are met.

g. Discuss procedures for controlling quality of work. Document construction tolerances and workmanship standards for that feature of work.

h. Check to ensure that portion of CQC Plan for new work to be performed has been accepted by Contracting Officer.

i. Check that previous work or acceptance sections required to start new work have been completed.

j. Review requirements under permits, environmental protection and protection of environmental species.

k. Discuss initial control phase (workmanship).

3.6.2 Initial Phase

Notify Contracting Officer at least 24 hours in advance of beginning the Initial Phase. Initial Phase is workmanship oriented and shall be accomplished at beginning physical work on each acceptance section. Document "Initial Phase Meeting" using an Initial Phase Checklist and attach the checklist and meeting minutes to the Contractor's Quality Control (CQC) Report. Initial Phase actions include:

a. Check preliminary work to ensure that it complies with contract. Review minutes of preparatory meeting.

b. Verify adequacy of turbidity monitoring and survey control to ensure contract compliance. Verify required inspection and testing.

c. Establish level of workmanship and verify that it meets minimum acceptable contract workmanship standards and review allowable tolerances.

d. Resolve all differences.

W912EP-17-B-0003 SECTION 01 45 05 Page 9 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

e. Check safety to include compliance with and upgrading of the safety plan and activity hazard analysis. Review activity analysis with each worker.

f. Initial phase shall be repeated for new crews working onsite and when contract workmanship quality standards are not being met.

3.6.3 Follow-up Phase

Follow-up Phase consists of daily checks performed to quality control activities, including surveying and testing, to provide continuous compliance with contract requirements. Record inspection and checking results in CQC documentation. Record both quality control activities, plant and equipment performance on Report of Operations. Report of Operations forms are in the RMS3CM software. Complete follow-up checks and inspections and correct deficiencies prior to starting acceptance sections which may be affected by deficient work.

3.6.4 Additional Preparatory and Initial Phases

Additional preparatory and initial phases shall be conducted on same definable features of work when: quality of on-going work is unacceptable; there are changes in applicable CQC staff, production supervision, or work crews; work on a definable feature is resumed after a period of inactivity; or, when other problems develop.

3.7 TESTS/TESTING PROCEDURE

Perform specified tests using required monitoring instrumentation or tests to verify control measures are adequate, and provide an end product conforming to contract. When requested, Contractor shall furnish Contracting Officer duplicate samples of test specimens for possible testing by Contracting Officer. The Contractor shall perform the following activities and record and provide the following data:

a. Verify that testing standard or procedures comply with contract requirements.

b. Verify that facilities, instruments, and testing equipment are available and comply with testing standards.

c. Check test instrument calibration data against certified standards.

d. Verify that recording forms and test identification control number system, including all of the test documentation requirements, have been prepared.

e. Results of tests and monitoring instruments, both passing and failing, shall be recorded and reported in the daily QC Report for date taken. Results of the test shall include test values and instrument readings for both passing and failing tests. An information copy of tests performed by an offsite or commercial test facility shall be provided directly to the Contracting Officer. Failure to submit timely test reports or maintain adequate monitoring testing may result in nonpayment for related work performed.

W912EP-17-B-0003 SECTION 01 45 05 Page 10 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.8 COMPLETION INSPECTION

3.8.1 Post-Construction Measurement and Inspection

Near end of work on each acceptance section notify Contracting Officer to conduct post-construction survey and inspection to ensure contract conformance. Submit certified survey data and correct contract drawings to show as-built information. Notify Contracting Officer to schedule a joint inspection of each acceptance section once deficiencies have been corrected.

3.8.2 Pre-Final Inspection

Near completion of project Contracting Officer and Contractor will conduct a Pre-Final Inspection. In addition to completion of quantity survey, Contracting Officer will inspect for demobilization of temporary facilities and cleanup of staging areas used to ensure contract conformance. Contracting Officer will perform Pre-Final Inspection to verify work is complete and ready for Owner acceptance. Contracting Officer Pre-Final Inspection may result in additional work to be done. Contractor's CQC System Manager shall ensure items are corrected before notifying Contracting Officer so that a Final Inspection with the Customer can be scheduled. Any items noted on Pre-Final Inspection shall be corrected in a timely manner. Pre-Final Inspection and deficiency corrections shall be accomplished within project completion period.

3.8.3 Final Inspection

Final Inspection will be scheduled by Contracting Officer based upon results of Pre-Final Inspection. Contractor will notify the Contracting Officer in writing when ready for Final Inspection and propose a date for the Final Inspection. Contractor shall include a statement in the notification assuring the Contracting Officer that deficiencies will be corrected and the work will be acceptable by the date proposed for Final Inspection. The Contracting Officer will schedule the Final Inspection within 14 working days of Contractor's notification. The Contracting Officer will notify Owner or Sponsor to attend a Final Inspection. Contractor, Project Manager/Superintendent, and CQC System Manager shall attend the Final Inspection. In addition to Contracting Officer and Owner or Sponsor, persons from local government or other agencies may attend. Contractor's failure to have contract work completed for this inspection will be cause for Contracting Officer to bill the Contractor for Contracting Officer's additional inspection cost in accordance with the Clause INSPECTION OF CONSTRUCTION of Section 00700 CONTRACT CLAUSES in Volume 1.

3.9 DOCUMENTATION

Maintain current records as required in Sections 01 57 20 ENVIRONMENTAL PROTECTION, 01 57 25 TURBIDITY AND DISPOSAL MONITORING, and 35 20 23 DREDGING. Document quality control activities and that tests have been performed using Daily Report of Dredge Operations and Daily Quality Control Reports. Daily Quality Control Report shall be prepared in RMS3CM and a signed completed report with attachments shall be provided daily. The report shall include the following information:

a. Contractor/subcontractor and their areas of responsibility.

b. Equipment with hours worked, idle, or down for repair.

W912EP-17-B-0003 SECTION 01 45 05 Page 11 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

c. Work performed each day, giving location, description, and by whom. When Network Analysis (NAS) is used, identify each phase of work performed each day by NAS activity number.

d. Testing and control activities performed with results and references to specifications or drawings requirements. Identify control phase (Preparatory, Initial, Follow-up). List deficiencies noted, along with corrective action.

e. Quantity of materials received at the site with statement as to acceptability, storage, and reference to specifications or drawings requirements.

f. Submittals and deliverables reviewed, with contract reference, by whom, and action taken.

g. Offsite surveillance activities, including actions taken.

h. Job safety evaluations stating what was checked, results, and instructions or corrective actions.

i. Instructions given or received and conflicts in plans or specifications.

j. Contractor's verification statement.

Describe trades working on the project; number of personnel working; weather conditions encountered; and delays encountered. Records shall cover both conforming and deficient work and shall include a statement that equipment and materials incorporated into work and workmanship comply with contract. The original records shall be furnished to the Contracting Officer daily within 24 hours after the date covered by report. A CQC daily report is required for each contract day, including days on which no work is performed. On days when no work is performed, the daily report shall document weather and note possible effects on restarting work. All contract calendar days shall be accounted for. CQC System Manager or alternate shall sign and date reports. CQC System Manager's daily reports shall include copies of test reports, meeting minutes, safety inspections and issues, inspector notes, copies of reports prepared by other quality control personnel, minutes to Preparatory Phase meetings held, minutes to Initial Phase meetings held, Final Follow-up inspection results, and any other documentation of construction progress or issues. The daily reports shall also include a record of the Follow-up Phase checks performed on each definable feature of work each day, problems discovered, and corrective actions taken. The Contracting Officer may stipulate the narrative titles in the QC daily reports.

3.10 NOTIFICATION OF COMPLIANCE

The Contracting Officer shall notify the Contractor of noncompliance with contract requirements, and take corrective action immediately after receipt of noncompliance notification. Any Contractor personnel notified at the work site is sufficient for the purpose of Contractor notification. If the Contractor fails to comply within 1 calendar day, the Contracting Officer may issue an order stopping all or part of work until satisfactory corrective action has been taken. Such stop orders shall not be made a basis of a Contractor's claim for time extension or other damages.

W912EP-17-B-0003 SECTION 01 45 05 Page 12 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.11 SAMPLE FORMS

The Contracting Officer's Representative will instruct the Contractor in the preparation of these forms during the Preconstruction Conference as specified in Section 01 30 00 ADMINISTRATIVE PROCEDURES. See paragraph RESIDENT MANAGEMENT SYSTEM (RMS3CM) above for construction forms to be completed in the RMS3CM program.

-- End of Section --

W912EP-17-B-0003 SECTION 01 45 05 Page 13 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 50 02

TEMPORARY CONSTRUCTION FACILITIES

PART 1 GENERAL

1.1 SUMMARY 1.2 REFERENCES 1.3 SUBMITTALS 1.4 EXISTING UTILITIES 1.4.1 Water 1.4.2 Electricity 1.5 BRIDGE-TO-BRIDGE COMMUNICATION

PART 2 PRODUCTS

2.1 CONSTRUCTION PROJECT SIGNS

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS 3.1.1 Identification of Employees 3.1.2 Onsite Information 3.2 AVAILABILITY AND USE OF UTILITY SERVICES 3.3 BULLETIN BOARD, PROJECT SIGN, AND PROJECT SAFETY SIGN 3.3.1 Bulletin Board 3.3.2 Project and Safety Signs 3.4 CONTRACTOR'S TEMPORARY FACILITIES 3.4.1 Contractor Field Office 3.4.2 Appearance of Trailer(s) 3.4.3 Waste Storage 3.4.4 Fuel Storage and Fueling Operations 3.5 VISITORS 3.6 ACCOMMODATIONS AND MEALS FOR INSPECTORS 3.7 CLEANUP 3.8 RESTORATION 3.9 CONSTRUCTION FORMS AND DETAILS

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 50 02 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 50 02

TEMPORARY CONSTRUCTION FACILITIES

PART 1 GENERAL

1.1 SUMMARY

In addition to Construction Facilities, this Section covers the following facilities which the Contractor may choose to use:

Temporary Utilities Construction Aids Vehicular Access and Parking Project Identification

See Section 01 57 20 ENVIRONMENTAL PROTECTION for requirements including silt control, trailer placement, fueling restrictions, dust control, solid waste, and cleanup. Upon completion of project, clean up and restore area in accordance with Clause CLEANING UP of Section 00700 CONTRACT CLAUSES in Volume 1.

a. Construction Facilities include, but are not limited to, the following:

(1) Contractor Offices (2) Information Bulletin Board (3) Material and Equipment Storage Area (4) Fueling Area (5) Debris Container (dumpster) (6) Construction Signage to include Project Sign; Safety Sign; and, Construction Warning Signs

b. Temporary Utilities include, but are not limited to, the following:

(1) Water (2) Electric (3) Sewage (4) Communications (i) Telephone (ii) Internet (T-1 line with 1.5 MBS or higher speed) (5) Lighting

1.2 REFERENCES

The publications listed below form a part of this specification to extent referenced. The publications are referred to in text by basic designation only.

INSTITUTE OF ELECTRICAL AND ELECTRONICS ENGINEERS (IEEE)

IEEE C2 (2012; Errata 2012; INT 1-4 2012; INT 5 2013) National Electrical Safety Code

W912EP-17-B-0003 SECTION 01 50 02 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (2015) National Electrical Code

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 Safety and Health Requirements Manual

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 20 calendar days after award or 5 calendar days after Notice to Proceed, whichever is later.

SD-01 Preconstruction Submittals

Mobilization/Demobilization Plan

Plan shall include, but not be limited to, the following:

a. Mobilization Requirements:

(1) Methods, equipment and materials (2) Connection of utilities (3) Placement of site facilities and temporary controls (4) Construction of facilities (5) Staging and access areas photo documentation of existing conditions

b. Demobilization Requirements (methods, equipment and materials required to clean-up and restore site at project conclusion):

(1) Collection, recycle and disposal of solid waste (2) Contract-generated material (3) Utility disconnection (4) Removal of Contractor facilities (5) Repair and restoration of site (i.e., fences, roads, or permanent facilities)

SD-02 Shop Drawings

Contractor's Temporary Facilities

General layout sketch of temporary site facilities shall include, but not be limited to, the following:

a. Trailer locations b. Parking areas c. Material storage d. Equipment lay down area e. Areas for gravel f. Fuel areas g. Supplemental or other staging area h. Temporary well, water supply

W912EP-17-B-0003 SECTION 01 50 02 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

i. Septic field or holding tanks, port-a-lets j. Contaminated water handling k. Concrete cleaning area and methods of disposal l. Fences -- location and dimensions, entrance and exit points, and details of installation m. Utilities (poles, connections and services) n. Explosives storage

Temporary Electric Drawings

Electricity supply and lighting - from transformer source sketch layout locations, fixtures, and materials, to include outdoor lighting as described in subparagraph "Electric Power" below.

1.4 EXISTING UTILITIES

The Contractor is responsible for investigating the availability of utilities at the project site. Contractor shall provide potable water, sanitary sewer, electricity from transformer, communications and optional utilities the Contractor may require at the project site. Provide T-1 or equivalent connectivity capable internet services with 1.5 MBS minimum speed and wireless capabilities to the Contractor's Field Office complex.

1.4.1 Water

In addition to the above, the Contractor shall provide and maintain at his own expense an adequate supply of water for his use for construction, and to install and maintain necessary supply connections and piping for same, but only at such locations and in such manner as may be approved by the Contracting Officer. The Contractor shall also provide and maintain his own temporary toilet and washing facilities. Toilet and washing facilities shall be installed and maintained in a location approved by the Contracting Officer. Refer to paragraph AVAILABILITY AND USE OF UTILITY SERVICES below.

1.4.2 Electricity

In addition to the above, all electric current required by the Contractor shall be furnished at his own expense. All temporary lines will be furnished, installed, connected, and maintained by the Contractor in a workmanlike manner satisfactory to the Contracting Officer and shall be removed by the Contractor in like manner at his expense prior to completion of the construction. Refer to paragraph AVAILABILITY AND USE OF UTILITY SERVICES below.

1.5 BRIDGE-TO-BRIDGE COMMUNICATION

In order that radio communication may be made with passing vessels, all dredges/marine equipment engaged in work under this contract shall be equipped with bridge-to-bridge radio telephone equipment. The radio equipment shall operate on a single channel very high frequency (VHF), FM, on a frequency of 156.55 MC per second with low power output having a communication range of approximately ten miles. The frequency has been approved by the Federal Communications Commission. Channels #13 and #16 must be monitored at all times.

W912EP-17-B-0003 SECTION 01 50 02 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

PART 2 PRODUCTS

2.1 CONSTRUCTION PROJECT SIGNS

Refer to paragraph BULLETIN BOARD, PROJECT SIGN, AND PROJECT SAFETY SIGN below and the web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below.

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.1.1 Identification of Employees

The Contractor shall be responsible for furnishing to each employee, and for requiring each employee engaged on the work to display, identification as approved and directed by the Contracting officer. Prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of any employee. When required, the Contractor shall obtain and provide fingerprints of persons employed on the project. Contractor and subcontractor personnel shall wear identifying markings on hard hats clearly identifying the company for whom the employee works.

3.1.2 Onsite Information

Keep copy of contract drawings, specifications, and other contract documents at Contractor's Office onsite, available for use at all times.

3.2 AVAILABILITY AND USE OF UTILITY SERVICES

Install temporary facilities and utilities in accordance with IEEE C2, EM 385-1-1, NFPA 70. Obtain necessary construction, building, zoning, or soil erosion and sediment control approvals required by local authorities and utility companies. Equip trailer(s) with wind tie downs in accordance with local wind and building code requirements.

3.3 BULLETIN BOARD, PROJECT SIGN, AND PROJECT SAFETY SIGN

3.3.1 Bulletin Board

Immediately upon beginning of work, the Contractor shall provide a weatherproof glass-covered bulletin board not less than 36 by 48 inches in size for displaying the Equal Employment Opportunity poster, a copy of the wage decision contained in the contract, Wage Rate Information poster, and other information approved by the Contracting Officer. The bulletin board shall be located at the project site in a conspicuous place easily accessible to all employees, as approved by the Contracting Officer. Legible copies of the aforementioned data shall be displayed until work is completed. Upon completion of work the bulletin board shall be removed by and remain the property of the Contractor.

3.3.2 Project and Safety Signs

The requirements for the signs, their content, and location shall be as indicated on the web site provided in paragraph CONSTRUCTION FORMS AND DETAILS below. The signs shall be erected within 15 days after receipt of the Notice to Proceed. The data required by the safety sign shall be corrected daily, with light colored metallic or non-metallic numerals.

W912EP-17-B-0003 SECTION 01 50 02 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

The Safety Scoreboard sign shall be used on board the dredge in lieu of the safety performance sign. Upon completion of the project, the signs shall be removed from the site.

3.4 CONTRACTOR'S TEMPORARY FACILITIES

The Contractor's field offices, staging areas, stockpile storage, and temporary buildings shall be placed in areas in accordance with Section 01 57 20 ENVIRONMENTAL PROTECTION. Temporary movement or relocation of Contractor facilities shall be made when approved by the Contracting Officer.

3.4.1 Contractor Field Office

Provide on-site field office of sufficient size and staff capability to manage project activities. Provide communications and computer capabilities to manage the work, including implementing RMS, facsimile, electronic mail, reproduction, to track schedule and cost. Contractor's field office should include a conference area with table and chairs to accommodate a minimum of 8 people. Provide minimum T-1 capable internet services (1.5 MBS or higher speed) and wireless capabilities to the field office facilities/compound to facilitate RMS, Sharepoint (file transfer) and visitor usage. Provide a lockable room with electrical outlets and adequate lighting within the contractor's facilities/compound for the sole use of the contracting officer and/or representatives. Room shall have minimum dimensions of 8' x 8' and shall be furnished with 2 office desks and chairs, one 4-drawer file cabinet, and access to potable water and restroom facilities.

3.4.2 Appearance of Trailer(s)

Trailer(s), if used, shall be clean, neat exterior appearance and in good repair. Trailer(s) requiring exterior painting or maintenance will not be allowed on site until determined satisfactory by Contracting Officer.

3.4.3 Waste Storage

Provide dumpsters or suitable debris containers. Prevent windblown trash; cover as needed. Dispose of offsite when needed. Refer to Section 01 57 20ENVIRONMENTAL PROTECTION.

3.4.4 Fuel Storage and Fueling Operations

Refer to Section 01 57 20 ENVIRONMENTAL PROTECTION. Provide light when fueling at night.

3.5 VISITORS

No visitors will be allowed on site without knowledge of Contractor and permission of Contracting Officer. Direct visitors to report upon arrival to Contractor's Field Office for site safety and accident prevention briefing. Provide visitors appropriate protective equipment (i.e., ear plugs, safety glasses, etc.).

3.6 ACCOMMODATIONS AND MEALS FOR INSPECTORS

a. The Contractor shall furnish regularly to inspectors, for office purposes, a suitable separate room on board the dredge or other craft

W912EP-17-B-0003 SECTION 01 50 02 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

upon which they are employed or, if not available thereon, shall furnish suitable alternate accommodations ashore at a location approved by the Contracting Officer, and furnish suitable transportation between the alternate accommodations and the dredge or other craft upon which they are employed.

b. If the Contractor maintains on this work an establishment for the subsistence of the Contractor's own employees, the Contractor shall, when required, furnish to inspectors employed on the work, and to all Government agents who may visit the work on official business, meals of a quality satisfactory to the Contracting Officer. The meals furnished will be paid for by the Government employees at a rate no greater than the JTR meal rate per person for the county in which work is performed.

3.7 CLEANUP

Construction debris, waste materials, packaging material and the like shall be removed from the work site daily. Any dirt or mud which is tracked onto paved or surfaced roadways shall be cleaned away. Materials resulting from demolition activities which are salvageable shall be stored within the fenced area described above or at the supplemental storage area. Stored material not in trailers, whether new or salvaged, shall be neatly stacked when stored. Refer to Section 01 57 20 ENVIRONMENTAL PROTECTION for solid waste and post construction cleanup.

3.8 RESTORATION

Areas used by the Contractor for the storage of equipment or material, or other use, shall be restored to the original or better condition. Gravel used to traverse grassed areas shall be removed and the area restored to its original condition, including top soil and seeding as necessary.

3.9 CONSTRUCTION FORMS AND DETAILS

See the "Construction Forms & Details" module at the following web address: http://www.saj.usace.army.mil/About/DivisionsOffices/Engineering/DesignBranch /SpecificationsSection.aspx.

-- End of Section --

W912EP-17-B-0003 SECTION 01 50 02 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 57 20

ENVIRONMENTAL PROTECTION

PART 1 GENERAL

1.1 SCOPE 1.2 ENVIRONMENTAL LAWS, REGULATIONS AND DOCUMENTS 1.2.1 Miscellaneous Environmental Laws And Regulations 1.2.2 NEPA Reference 1.3 REFERENCES 1.4 QUALITY CONTROL 1.5 PERMITS AND AUTHORIZATIONS 1.6 SUBMITTALS 1.7 SUBCONTRACTORS 1.8 NOTIFICATION 1.9 CONTRACTOR PERSONNEL QUALIFICATIONS IN POLLUTION CONTROL

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 PROTECTION OF ENVIRONMENTAL RESOURCES 3.1.1 General Project Environmental Design and Installation Criteria 3.1.1.1 Sewage-Based Systems Environmental Design and Installation Criteria 3.1.2 Protection of Land Resources 3.1.2.1 Work Area Limits 3.1.2.2 Contractor Facilities and Other Work Areas 3.1.2.3 Solid Wastes 3.1.2.4 Fuel, Oil, and Lubricants 3.1.2.5 Hazardous Waste 3.1.2.6 Hazardous Materials 3.1.2.7 Disposal of Other Materials 3.1.3 Preservation and Recovery of Historic, Archeological, and Cultural Resources 3.1.3.1 Applicable Law 3.1.3.2 Known Resources 3.1.3.3 Inadvertent Discoveries 3.1.3.4 Claims for Downtime due to Inadvertent Discoveries 3.1.4 Protection of Water Resources 3.1.4.1 Washing and Curing Water 3.1.4.2 Monitoring of Water Areas 3.1.4.3 Turbidity 3.1.4.4 Oil, Fuel, and Hazardous Substance Spill Prevention and Mitigation 3.1.5 Protection of Fish and Wildlife Resources 3.1.5.1 Endangered Species Protection 3.1.5.2 Endangered Species Observers (Hopper Dredge Only)

W912EP-17-B-0003 SECTION 01 57 20 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.1.5.3 Manatee, Sea Turtle, Smalltooth Sawfish and Whale Sighting Reports 3.1.5.4 Disposition of Endangered or Threatened Species Carcasses 3.1.5.5 Report Submission 3.1.5.6 Hopper Dredge Equipment 3.1.5.7 Sea Turtle Trawling and Relocation (For Hopper Dredges Only) 3.1.5.8 Protection of Migratory Bird Species (Alafia River Only) 3.1.5.9 Protection of Migratory Bird Species (Manatee Harbor Only) 3.1.6 Seagrass Protection Measures 3.1.7 Protection of Air Resources 3.1.7.1 Particulates 3.1.7.2 Odors 3.1.8 Protection of Sound Intrusions 3.2 POSTCONSTRUCTION CLEANUP 3.3 PRESERVATION AND RESTORATION OF LANDSCAPE AND MARINE VEGETATION DAMAGES 3.4 INVASIVE AND NUISANCE SPECIES 3.4.1 Prevention of Invasive and Nuisance Species Transfer 3.4.2 Invasive and Nuisance Species Reporting 3.5 MAINTENANCE OF POLLUTION CONTROL FACILITIES 3.6 CONSTRUCTION FORMS AND DETAILS

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 57 20 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 57 20

ENVIRONMENTAL PROTECTION

PART 1 GENERAL

1.1 SCOPE

This Section covers prevention of environmental damage as the result of construction operations under this contract and for those measures set forth in other Technical Requirements of these specifications. For the purpose of this specification, environmental damage is defined as the presence of hazardous, physical, chemical, or biological elements or agents which adversely affect human health or welfare; unfavorably alter ecological balances; affect other species, biological communities, or ecosystems; or degrade the quality of the environment for aesthetic, cultural, and/or historical purposes. The control of environmental damage requires consideration of land, water, and air, and includes management of visual aesthetics, noise, solid waste, radiant energy and radioactive materials, as well as other pollutants.

1.2 ENVIRONMENTAL LAWS, REGULATIONS AND DOCUMENTS

1.2.1 Miscellaneous Environmental Laws And Regulations

There are numerous environmental laws and regulations. At the Federal level, the applicable laws and regulations include compliance with the Clean Water Act (CWA); Clean Air Act (CAA); Coastal Zone Management Act (CZMA); Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA); Endangered Species Act (ESA); Fish and Wildlife Coordination Act (FWCA); Marine Protection, Research, and Sanctuaries Act (MPRSA); Magnuson-Stevens Fishery Conservation and Management Act (MSFCMA); National Environmental Policy Act (NEPA); National Historic Preservation Act (NHPA); National Pollution Discharge Elimination System (NPDES); Research and Sanctuaries Act; Native American Graves Protection and Repatriation Act (NAGPRA); Resource Conservation and Recovery Act (RCRA); Rivers and Harbors Act (R&H); Safe Drinking Water Act (SDWA); Toxic Substance Control Act (TSCA); Wild and Scenic Rivers Act (WSRA); Federal Insecticide, Fungicide, and Rodenticide Act (FIFRA); Marine Mammal Protection Act (MMPA); Migratory Bird Treaty Act; Code of Federal Regulations (CFRs); Executive Orders; and, Environmental Protection Agency (EPA) requirements.

1.2.2 NEPA Reference

Commitments made in the NEPA document have been incorporated into these specifications. The NEPA document can be found at the following website: http://www.saj.usace.army.mil/About/Divisions-Offices/Planning/Environmental-Branch/ Environmental-Documents/

1.3 REFERENCES

Any publication listed below forms a part of this specification to the extent referenced. Publications are referred to in the text by basic designation only.

W912EP-17-B-0003 SECTION 01 57 20 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 1110-1-1003 (1996) NAVSTAR Global Positioning System Surveying

1.4 QUALITY CONTROL

The Contractor shall establish and maintain quality control for environmental protection of all items set forth herein. The Contractor shall record on daily quality control reports or attachments thereto, any problems in complying with laws, regulations and ordinances, and corrective action taken.

1.5 PERMITS AND AUTHORIZATIONS

The Contractor shall comply with all requirements under the terms and conditions set out in the following permit(s) and authorization(s) obtained by the Corps of Engineers listed below.

a. Tampa Harbor: Florida Department of Environmental Protection Permit No. 0157891-011-EM; effective 9/12/2006; expires on 4/7/2021.

b. Manatee Harbor: FDEP Exemption No. 983480-010-BE effective 8/12/13

The above permits indicate issuing agency approval of work required by this contract. Permits and environmental compliance documents, including Environmental Compliance Matrix (ECM) defining roles and responsibilities, are available at the following web address: http://www.saj.usace.army.mil/About/Divisions-Offices/Planning/Environmental-Branch/ Environmental-Compliance/

The Contractor shall obtain and comply with the requirements of all other permits or licenses required for construction of this project in accordance with the Clause PERMITS AND RESPONSIBILITIES of Section 00700 CONTRACT CLAUSES in Volume 1.

1.6 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 30 calendar days after Notice to Proceed:

SD-01 Preconstruction Submittals

Environmental Protection Plan; G, DO

No later than 30 calendar days after Notice to Proceed, the Contractor shall submit an Environmental Protection Plan for review and acceptance by the Contracting Officer. The Government will consider an interim plan for the first 30 days of operations. However, the Contractor shall furnish an acceptable final plan no later than 30 calendar days after receipt of Notice

W912EP-17-B-0003 SECTION 01 57 20 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

to Proceed. Acceptance of the Contractor's plan shall not relieve the Contractor of his responsibility for adequate and continuing control of pollutants and other environmental protection measures. Acceptance of the plan is conditional and predicated on satisfactory performance during construction. The Government reserves the right to require the Contractor to make changes to the Environmental Protection Plan or operations if the Contracting Officer determines that environmental protection requirements are not being met. No physical work at the site shall begin prior to acceptance of the Contractor's plan or an interim plan covering the work to be performed. The Environmental Protection Plan shall include but not be limited to the following:

a. A list of Federal, State, and local laws, regulations, and permits concerning environmental protection, pollution control, and abatement that are applicable to the Contractor's proposed operations and the requirements imposed by those laws, regulations, and permits.

b. Methods for protection of features to be preserved within authorized work areas. The Contractor shall prepare a listing of methods to protect resources needing protection, i.e., trees, shrubs, vines, grasses and ground cover, landscape features, air and water quality, fish and wildlife, soil, historical, archeological, and cultural resources.

c. Procedures to be implemented to provide the required environmental protection and to comply with the applicable laws and regulations. The Contractor shall provide written assurance that immediate corrective action will be taken to correct pollution of the environment due to accident, natural causes, or failure to follow the procedures set out in accordance with the environmental protection plan.

d. A permit or license for and the location of the solid waste disposal area.

e. Drawings showing locations of any proposed temporary excavations or embankments for haul roads, stream crossing, material storage areas, structures, sanitary facilities, and stockpiles of excess or spoil materials.

f. Environmental monitoring plans for the job site, including land, water, air, and noise monitoring.

g. Traffic control plan.

h. Methods of protecting surface and ground water during construction activities.

i. Spill prevention. The Contractor shall specify all potentially hazardous substances to be used on the job site and intended actions to prevent accidental or intentional introduction of such materials into the air, ground, water, wetlands, or drainage areas. The plan shall specify the Contractor's provisions to be taken to meet Federal, State, and local laws and regulations regarding labeling, storage, removal, transport, and disposal of potentially hazardous substances.

W912EP-17-B-0003 SECTION 01 57 20 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

j. Spill contingency plan for hazardous, toxic, or petroleum material.

k. Work area plan showing the proposed activity in each portion of the area and identifying the areas of limited use or nonuse. Plan should include measures for marking the limits of use areas.

l. A statement as to the person who shall be responsible for implementation of the Environmental Protection Plan. The Contractor personnel responsible shall report directly to the Contractor's top management and shall have the authority to act for the Contractor in all environmental protection matters.

m. Recycling and Waste Management Plan. Executive Order 12873 of 20 October 1993 requires a number of considerations in planning a project. Fallen trees should not be burned or buried. Mulching, composting, and other uses for trees should be considered. Also, recovery of metals at the job site, including aluminum cans, should be considered with proceeds to be retained by the Contractor. Non-Federal recycling and waste minimization efforts shall also be incorporated into this plan.

n. Turbidity Monitoring Plan. A statement as to the person who shall be responsible for turbidity monitoring and reporting to be performed. Method of turbidity monitoring and reporting that will be performed. The turbidity monitoring requirements of any special areas such as outstanding Florida waters.

o. Operational plan to achieve protection of sea turtles during hopper dredge(s) operation.

p. Construction activities shall be conducted in a manner as not to impact migratory birds or induce their nesting.

q. Migratory Bird Protection Plan. The Contractor shall include in the Environmental Protection Plan a detailed plan for protecting migratory birds in the project area. The project site, especially DMMA 3-D, is important migratory bird nesting habitat, and experiences high densities of both common and rare bird species. All species utilizing this site for nesting are protected under the Migratory Bird Treaty Act (MBTA). The nesting season is generally between March 1 and September 15 in this region; however, migratory birds and their eggs are protected at all times of the year pursuant to the MBTA. Since construction may occur during the nesting season, the Contractor will be responsible for ensuring that migratory birds are not impacted during construction. As mentioned in subparagraph "Protection of Fish and Wildlife Resources" below, delays in work due to the presence of migratory birds or their nests shall not be compensable. The Migratory Bird Protection Plan shall include the following components:

(1) Proposal for managing project activities to prevent the creation of suitable nesting habitat in the active conservation area prior to and during the nesting season;

(2) Measures to be implemented by the Contractor prior to nesting season to deter birds from nesting in areas where

W912EP-17-B-0003 SECTION 01 57 20 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

construction is anticipated to occur during nesting season;

(3) Monitoring protocol during construction, including names and qualifications of the proposed bird monitors;

(4) Steps that will be followed to address any unintentional take of migratory birds, should that occur. Construction activities shall be conducted in a manner so as not to impact migratory birds or their eggs.

r. Invasive and Nuisance Species Transfer Prevention Plan

SD-02 Shop Drawings

Turtle Deflector Device; G, DO

If the Contractor proposes to use a hopper dredge for this work, detail drawings shall be submitted showing the proposed device and its attachment to the Contractor's equipment no later than 30 calendar days after Notice to Proceed. Contractor's drawings to be submitted shall include the approach angle for any and all depths to be dredged during this contract. A copy of the approved drawings and calculations shall be available on the vessel during the life of this contract. No dredging work shall be allowed to commence until approval of the installed turtle deflector device.

Daily Logs/Summary Of Bird Nesting Monitoring; G, DO

Contractor shall submit as specified, daily logs of bird monitoring activities detailing the current bird activity on the island, ongoing nesting, and nesting success during the nesting season.

Weekly Logs/Summary Of Bird Nesting Monitoring; G, DO

Contractor shall submit minimum weekly uploads of seabird and shorebird nesting count data using specific procedures outlined in the Florida Fish and Wildlife Conservation Commission Breeding Bird Protocol (BBP). Data collected using this protocol will be required to be uploaded to the Florida Shorebird Database (FSD) using the online website www.FL.ShorebirdDatabase.org, and to be submitted to the Contracting Officer in electronic pdf file format on a weekly basis.

SD-07 Certificates

Bird Monitoring Qualifications; G, DO

Prior to the Preconstruction Conference, the Contractor shall furnish the qualifications of the bird monitor(s) to the Contracting Officer for approval. The Contractor shall furnish an approved plan prior to the issuance of NTP. These qualifications shall also be included as part of the Migratory Bird Protection Plan in the Environmental Protection Plan. Appropriate qualifications for bird monitors shall be a demonstrated ability to find and identify bird species, nesting behavior, nests, and eggs. Monitors shall have extensive knowledge of species' nesting habitat requirements (specifically beach-nesting bird species, including all nesting sea and shorebird species found in Florida,)

W912EP-17-B-0003 SECTION 01 57 20 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

general and nesting behavior characteristics, nests and eggs, and a knowledge of habitat requirements and experience implementing a variety of methods to deter birds from nesting, and experience working as a migratory bird monitor for construction projects. In addition, references shall be provided to verify non-educational experience. The qualifications shall be submitted on the Bird Monitoring Qualification Sheet (See Construction Forms & Details module indicated in paragraph CONSTRUCTION FORMS AND DETAILS below). The Contracting Officer shall consult with and coordinate all monitoring plans and activities with the USACE designated biologist.

Manatee Observer Qualifications (Clamshell Only); G, DO

No later than 30 calendar days after Notice to Proceed, the Contractor shall furnish to the Contracting Officer for approval, the qualifications of the manatee observer. Appropriate qualifications for manatee observer shall be demonstrated experience monitoring manatees and their behaviors in association with in-water construction projects.

Endangered Species Observer and Trawl Supervisor Qualifications (For Hopper Dredges Only); G, DO

No later than 30 calendar days after Notice to Proceed, the Contractor shall furnish to the Contracting Officer for approval, the names of the endangered species observer-biologists (ESOs) to perform the monitoring for this contract. Only pre-approved ESOs by NMFS are to monitor threatened/endangered species takes by hopper dredges. A pre-approved list of ESOs can be obtained by contacting NOAA Fisheries' Northeast Region, Protected Resources Division at 978-282-8460.

SD-11 Closeout Submittals

Logs/Final Summary Report

Contractor shall submit as specified, logs and final summary report of sightings and incidents with endangered species.

Project Environmental Summary Sheet

Contractor shall submit within 30 calendar days following completion of the project, a written report of the absence or occurrence of environmental incidents. In addition, for construction activities whose anticipated duration is more than one calendar year, the Contractor shall complete a sheet each May 31st (plus/minus 14 days).

Trawl Sweeping Daily Logs

Within 30 calendar days following completion of work, the Contractor shall submit the Trawl Sweeping Daily Logs.

1.7 SUBCONTRACTORS

Assurance of compliance with this section by subcontractors shall be the responsibility of the Contractor.

W912EP-17-B-0003 SECTION 01 57 20 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.8 NOTIFICATION

The Contracting Officer will notify the Contractor in writing of any observed noncompliance with the aforementioned Federal, State, or local laws or regulations, permits and other elements of the Contractor's environmental protection plan. The Contractor shall, after receipt of such notice, inform the Contracting Officer of proposed corrective action and take such action as may be approved. If the Contractor fails to comply promptly, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No time extensions shall be granted or costs or damages allowed to the Contractor for any such suspension.

Additionally, the Contractor shall notify the Contracting Officer, in writing, of the absence or occurrence of environmental incidents, as required on the Project Environmental Summary Sheet, copy on the first web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below. Refer to paragraph SUBMITTALS above.

1.9 CONTRACTOR PERSONNEL QUALIFICATIONS IN POLLUTION CONTROL

The Contractor's personnel shall be qualified to perform all phases of environmental protection, including methods of detecting and avoiding pollution, familiarization with pollution standards, both statutory and contractual, and careful installation and monitoring of the project to ensure adequate and continuous environmental pollution control. Quality Control and supervisory personnel shall be thoroughly knowledgeable of Federal, State, and local laws, regulations, and permits as listed in the Environmental Protection Plan submitted by the Contractor. Quality Control personnel will be identified in the Quality Control Plan submitted in accordance with Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 PROTECTION OF ENVIRONMENTAL RESOURCES

For contract work, the Contractor shall comply with all applicable Federal, State, or local laws and regulations. The environmental resources within the project boundaries and those affected outside the limits of permanent work under this contract shall be protected at least during the entire period of this contract. The Contractor shall confine activities to areas defined by the drawings and specifications. Environmental protection shall be as stated in the following subparagraphs.

3.1.1 General Project Environmental Design and Installation Criteria

Some project sites have features that shall not be impacted in any way, including cultural, historic, or archeological features. At all sites, the Contractor shall minimize disturbance to existing features at the site to the extent possible, including vegetative, topographic, and drainage pattern features. Wetland, seagrass or hardbottoms impacts (temporary access, detours, staging areas, and other work area impacts) to project sites should be avoided and may require separate permitting action. Any wetlands temporarily impacted shall have its soil restored upon project completion. Expansion of previously permitted project footprints may likewise require separate permitting action.

W912EP-17-B-0003 SECTION 01 57 20 Page 9 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

In all cases, the installation of temporary systems to aid construction shall provide for protection of the environment during handling, installing, storing, utilizing, transporting, servicing, testing, refilling, transferring, pumping, processing, removing waste products, repairing and maintaining systems and their components. Necessary protection shall also be considered that would prevent contamination of the environment from impacts to the systems caused by storm water runoff and flooding. Retrofit of temporary systems on project sites to modern environmental protection design standards shall also be considered.

In the event environmental protection measures fail, the Contractor shall implement procedures to control and correct environmental damage. The Contractor shall coordinate with the Contracting Officer if environmental protection measures fail.

3.1.1.1 Sewage-Based Systems Environmental Design and Installation Criteria

In general, there shall be no waste or debris discharges of any kind for a project unless authorized by the Contracting Officer. This shall include the Contractor's providing sufficient temporary sanitary equipment and facilities for the project. The design and/or installation of temporary or permanent sewage systems shall ensure that waters will be free of effects of sewage discharges. Applicable Federal, State, or local codes and requirements regarding sewage shall be strictly adhered to in the design, such as those of the EPA and, in the case of the State, Chapter 62-620 (Wastewater Facilities) of the FAC. Best Management Practices from the applicable agencies shall also be adhered to in the design.

3.1.2 Protection of Land Resources

Prior to the beginning of any construction, the Contractor shall identify all land resources to be preserved or avoided within the Contractor's work area. Materials displaced into uncleared areas shall be removed. The Contractor shall not remove, cut, deface, injure, or destroy land resources including trees, shrubs, vines, grasses, topsoil, and land forms without special permission from the Contracting Officer. The Contractor shall engage a qualified tree surgeon to perform all tree surgery. The Contractor shall be responsible to repair injuries to bark, trunk, branches, and roots of protected trees by dressing, cutting, and painting as specified for Class I Fine Pruning, of the National Arborist Association Pruning Standards for Shade Tree or as per State's Agricultural Extension Agency Guidelines, immediately as occurrences arise. No ropes, cables, or guys shall be fastened to or attached to any trees for anchorage unless specifically authorized. Where such special emergency use is permitted, the Contractor shall provide effective protection for land and vegetation resources at all times as defined in the following subparagraphs.

3.1.2.1 Work Area Limits

Prior to any construction, the Contractor shall mark the areas that are not required to accomplish all work to be performed under this contract. Isolated areas within the general work area which are to be saved and protected shall also be marked or fenced. The Contractor shall protect from damage all existing trees designated to remain. Protection of tree roots shall be provided against noxious materials in solution caused by run-off or spillage. Fires shall be located outside the canopy of protected trees. No materials, trailers, or equipment shall be stored

W912EP-17-B-0003 SECTION 01 57 20 Page 10 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

within the drip line of any protected tree. Monuments and markers shall be protected before construction operations commence. Where construction operations are to be conducted during darkness, the markers shall be visible. The Contractor shall convey to his personnel the purpose of marking and/or protection of all necessary objects.

3.1.2.2 Contractor Facilities and Other Work Areas

Locate facilities, staging and other work areas as indicated in Section 01 50 02 TEMPORARY CONSTRUCTION FACILITIES, and in compliance with permits listed in the paragraph PERMITS AND AUTHORIZATIONS above and obtained for performance of work. Borrow or dredge material management (DMMA) areas shall be managed to minimize erosion and to prevent sediment from entering nearby watercourses, wetlands, or lakes. Spoil areas shall be managed and controlled to limit spoil intrusion into areas designated on the drawings and to prevent erosion of soil or sediment from entering nearby watercourses, wetlands, or lakes. Spoil areas shall be developed in accordance with the grading plan indicated on the drawings. Temporary excavation and embankments for plant and/or work areas shall be controlled to protect adjacent areas from despoilment. If there is suspicion that sediment may be unsuitable for disposal at a specified location, the Contractor shall immediately take measures to contain the suspect sediment and notify the Contracting Officer.

3.1.2.3 Solid Wastes

Solid wastes (excluding clearing debris) shall be placed in containers which are emptied on a regular schedule. All handling and disposal shall be conducted to prevent contamination. Solid waste materials shall be hauled to a solid waste disposal site approved by the Contracting Officer. The Contractor shall comply with Federal, State and local regulations pertaining to the use of the solid waste disposal site.

3.1.2.4 Fuel, Oil, and Lubricants

Fuel, oil, and lubricants shall be managed so as to prevent spills and evaporation. To prevent spills, fuel dispensers shall have a 4-foot square, 16-gauge metal pan with borders banded up and welded at corners right below the bibb. Edges of the pans shall be 8-inch minimum in depth to ascertain that no contamination of the ground takes place. Pans shall be cleaned by an approved method immediately after every dispensing of fuel and wastes disposed of offsite in an approved area. Should any spilling of fuel occur, the Contractor shall immediately recover the contaminated ground and dispose of it offsite in an approved area. Petroleum waste generated shall be stored in marked corrosion-resistant containers and recycled or disposed of in accordance with 40 CFR 279, State, and local regulations.

3.1.2.5 Hazardous Waste

Hazardous wastes are defined in 40 CFR 261. The Contractor shall ensure that hazardous wastes are stored and disposed of in accordance with 40 CFR 261 and State and local regulations. The Contractor shall ensure that hazardous wastes are packed, labeled, and transported in accordance with 49 CFR 173 and State and local regulations.

3.1.2.6 Hazardous Materials

The Contractor shall ensure that hazardous materials are labeled, stored,

W912EP-17-B-0003 SECTION 01 57 20 Page 11 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

and transported in accordance with 49 CFR 173, State and local regulations.

3.1.2.7 Disposal of Other Materials

Other materials than previously discussed (Construction and Demolition, vegetative waste, etc.) shall be handled as directed by the Contracting Officer.

3.1.3 Preservation and Recovery of Historic, Archeological, and Cultural Resources

3.1.3.1 Applicable Law

A number of Federal laws require protection of cultural resources. Two laws, in particular, can be potentially involved with dredging activities: (1) the National Historic Preservation Act, as amended; and, (2) the Abandoned Shipwreck Act.

3.1.3.2 Known Resources

If known historic, archeological, and cultural resources within the Contractor's work area(s) are present, it will be designated as a "environmentally sensitive area" on the contract drawings or other documents. If so designated, the Contractor shall install protection for these resources and shall be responsible for their preservation during the contract's duration. The Contractor shall not distribute maps or other information on these resource locations except for distribution among the Contractor's staff with a "need to know" technical responsibility for protecting the resources.

3.1.3.3 Inadvertent Discoveries

If, during construction activities, the Contractor observes items that may have historic or archaeological origin, such observations shall be reported immediately to the Contracting Officer so that the appropriate Corps staff may be notified. Examples of expected historical, archaeological or cultural resources include bones, human remains, artifacts, shell, midden, charcoal, and other evidences of human activity. The Contractor shall cease all activities adjacent to the discovery that may result in the destruction of these resources and shall prevent his/her employees from further removing, or otherwise damaging, such resources. Once reported, Corps staff will initiate coordination with the appropriate federal, tribal and state agencies to determine if archaeological investigation is required. Additional work in the area of the discovery will be suspended at the site until all federal and state regulations have been successfully completed and the Corps staff members provide further directive. Project activities in the vicinity of the discovery may not resume until the Contracting Officer approves work to proceed.

The possibility of encountering submerged cultural resources is inherent in dredging and snagging operations. Such findings could include shipwrecks, shipwreck debris fields (such as steam engine parts, or wood planks and beams), anchors, ballast rock, concreted iron objects, concentrations of coal, prehistoric watercraft (such as log "dugouts"), and other structural features intact or displaced. The materials may be deeply buried in sediment, resting in shallow sediments or above them, or protruding into water. Suspected cultural materials inadvertently gathered from a water-saturated context should be kept moist by

W912EP-17-B-0003 SECTION 01 57 20 Page 12 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

re-immersion, spraying, or some other expedient means of wetting until the appropriate Corps staff provide further directives. No interviews or other contact with media shall occur without clear authorization from the Contracting Officer.

3.1.3.4 Claims for Downtime due to Inadvertent Discoveries

Upon discovery and subsequent reporting of a possible inadvertent discovery of cultural resources, the Contractor shall seek to continue work well away from, or otherwise protectively avoiding, the area of interest, or in some other manner that strives to continue productive activities in keeping with the contract. Should an inadvertent discovery be of the nature that substantial impact(s) to the work schedule are evident, such delays shall be coordinated with the Contracting Officer. Contract adjustments resulting from compliance with this paragraph shall be determined in accordance with Clause DIFFERING SITE CONDITIONS of Section 00700 CONTRACT CLAUSES in Volume 1.

3.1.4 Protection of Water Resources

The Contractor shall keep construction activities under surveillance, management, and control to avoid pollution of surface, ground waters, and wetlands. The Contractor shall plan his operation and perform all work necessary to minimize adverse impact or violation of water quality standards. Special management techniques as set out below shall be implemented to control water pollution by the listed construction activities which are included in this contract. The Contractor's construction methods shall protect wetland and surface water areas from damage due to mechanical grading, erosion, sedimentation and turbid discharges. There shall be no storage or stockpiling of equipment, tools, or materials within wetlands or along the shoreline within the littoral zone unless specifically authorized.

3.1.4.1 Washing and Curing Water

Waste waters directly derived from construction activities shall not be allowed to enter water areas. These waste waters shall be collected and placed in retention ponds where suspended materials can be settled out or the water evaporates so that pollutants are separated from the water. Analysis shall be performed and results reviewed and approved by Corps staff before water in retention ponds is discharged.

3.1.4.2 Monitoring of Water Areas

All water areas affected by construction activities shall be monitored by the Contractor.

3.1.4.3 Turbidity

The Contractor shall conduct his operations in a manner to minimize turbidity. Refer to Section 01 57 25 TURBIDITY AND DISPOSAL MONITORING for further instructions.

3.1.4.4 Oil, Fuel, and Hazardous Substance Spill Prevention and Mitigation

The Contractor shall prevent oil, fuel, or other hazardous substances from entering the air, ground, drainage, local bodies of water, or wetlands. This shall be accomplished by design and procedural controls. In the event that a spill occurs despite the design and procedural controls, the

W912EP-17-B-0003 SECTION 01 57 20 Page 13 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

following shall occur:

(1) Immediate action shall be taken to contain and cleanup any spill of oil, fuel or other hazardous substance.

(2) Spills shall be immediately reported to the Contracting Officer.

(3) Spill contingency planning shall be strictly in accordance with the criteria of 40 CFR, Part 109.

(4) To control the spread of any potential spill, absorbent materials shall be readily available and capable of absorbing the contents of the single largest tank.

(5) To control the spread of any potential spill, the Contractor shall provide a written certification of commitment of manpower, equipment, and materials required to expeditiously cleanup and dispose of spill materials.

a. Spill Preventive Systems: System design and installation requirements have been discussed at the beginning of this Section. Temporary or portable tanks shall conform to applicable Federal, State and local codes and requirements and shall not be placed where they may be affected by storm, flooding, or washout. Diversionary structures for spills shall be put in place in advance where practical. Both spill preventive systems and any deviations from associated requirements shall be approved by the Contracting Officer prior to implementation.

b. Liabilities: The Contractor shall be liable in the amounts established in 40 CFR, Part 113 when it can be shown that oil was discharged as a result of willful negligence or willful misconduct. The penalty for failure to report the discharge of oil shall be in accordance with the provision of 33 CFR, Part 153.

3.1.5 Protection of Fish and Wildlife Resources

The Contractor shall keep construction activities under surveillance, management, and control to minimize interference with, disturbance to, and damage of fish and wildlife. Species that require specific attention along with measures for their protection shall be listed in the Contractor's Environmental Protection Plan prior to the beginning of construction operation.

In the event that a threatened or endangered species is harmed as a result of construction activities, the Contractor shall cease all work and notify the Contracting Officer. The order of contact within the Corps of Engineers shall be as follows:

Order of Contact of Corps Personnel

Title Telephone Number

Corps, Inspector Onsite/After hours to be provided Area Engineer for Area Office indicated on Standard Form 1442 To be provided Chief, Environmental Branch Planning Division (CESAJ-PD-E) To be provided

W912EP-17-B-0003 SECTION 01 57 20 Page 14 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Chief, Construction Division (CESAJ-CD) To be provided

Information to be provided will be provided in the Preconstruction Conference.

3.1.5.1 Endangered Species Protection

The Contractor shall instruct all personnel associated with the project of the potential presence of manatees and sea turtles, smalltooth sawfish, dolphins and whales in the area, and the need to avoid collisions with and harming these animals. All construction personnel shall be advised that there are civil and criminal penalties for harming, harassing, or killing manatees or sea turtles, smalltooth sawfish, dolphins or whales which are protected under the Marine Turtle Protection Act, Marine Mammal Protection Act of 1972, the Endangered Species Act of 1973, and/or the Florida Manatee Sanctuary Act. The Contractor shall be held responsible for any manatee, sea turtle, or whale harmed, harassed, or killed as a result of construction activities.

a. Siltation Barriers: If siltation barriers are used, they shall be made of material in which manatees cannot become entangled, are properly secured, and are regularly monitored to avoid manatee entrapment. Barriers must not block manatee entry to or exit from essential habitat.

b. Special Operating Conditions:

(1) All vessels associated with the project shall operate at "no wake/idle" speeds at all times while in waters where the draft of the vessel provides less than a four-foot clearance from the bottom, and vessels shall follow routes of deep water whenever possible. Boats used to transport personnel shall be shallow-draft vessels, preferably of the light-displacement category, where navigational safety permits. Mooring bumpers shall be placed on all barges, tugs, and similar large vessels wherever and whenever there is a potential for manatees to be crushed between two moored vessels. The bumpers shall provide a minimum stand-off distance of four feet.

(2) If a manatee(s) is sighted within 100 yards of the project area, all appropriate precautions shall be implemented by the Contractor to ensure protection of the manatee. These precautions shall include the operation of all moving equipment no closer than 50 feet of a manatee. If a manatee is closer than 50 feet to moving equipment or the project area, the equipment shall be shut down and all construction activities shall cease within the waterway to ensure protection of the manatee. Construction activities shall not resume until the manatee has departed the project area.

(3) Manatee Monitoring (Clamshell Only): During clamshell dredging operations, a dedicated observer shall monitor for the presence of manatees. The dedicated observer shall have experience in manatee observation and be equipped with polarized sunglasses to aid in observing. Nighttime lighting of waters within and adjacent to the work area shall be illuminated, using shielded or low-pressure sodium-type lights, to a degree that allows the dedicated observer to sight any manatee on the surface

W912EP-17-B-0003 SECTION 01 57 20 Page 15 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

within 200 feet of the operation. The dredge operator shall gravity-release the clamshell bucket only at the water surface, and only after confirmation that there are no manatees within the safety distance identified in the standard construction conditions.

(4) Nighttime Manatee Monitoring (Clamshell Only) In the event clamshell dredging is used to accomplish work, the following measures will be adhered to during nighttime work:

(i) The dredge operator will gravity-release the clamshell bucket beginning at the water's surface, and only after confirmation that there are no manatees within the 50-foot safety distance.

(ii) At least two persons will be dedicated as protected marine animal observers. Dedicated observers will have appropriate qualifications and observation experience, demonstrated by a minimum of 100 hours of documented experience as an observer that has monitored marine animals during in-water dredging projects. The dedicated observers will be on site during all in-water construction activities and will advise personnel to cease operation upon sighting a manatee within 50 feet of any in-water construction.

(iii) In order to better observe manatees and marine turtles during nighttime clamshell operations, the contractor will use shielded lights to illuminate the water surface for 75 feet around the hoist line (cable attached to bucket). The light intensity will be a minimum of 54 lux (5 foot candles) at the water surface throughout this illuminated area including the edge. The contractor will have a handheld spotlight with a minimum of 10,000,000 candle power available to assist when appropriate in the detection of manatees and marine turtles immediately outside of this illuminated area. The Contractor will measure the size of the illuminated area and intensity of the specified illumination prior to commencement of the project. No night-time operations will commence or continue if one or more of these lighting parameters does not comply with the required specifications.

(iv) If the dedicated observers determine that detection of manatees during certain weather conditions (i.e., fog, rain, wind, etc.) is not possible, then dredging operations will cease until weather conditions improve and detection is again possible.

(v) All observers will maintain a daily log that details sightings, collisions, or injuries to protected marine animals, as well as project specific information such as work itinerary, weather, work shutdowns, observer shift changes, etc. In regard to manatee behavior, the observers will also log time of observation, estimated distance of manatees from the dredge, type of behavior (such as passing through, pausing in the vicinity of the project, interacting with the dredge, , tugs, etc., attraction to running or dripping water), and whether the dredge is operating at the time of observation. A final report will be written, summarizing all activities noted in the daily observer logs, the location and name of project, and the dates and times of work. The logs and the report will be submitted to Contracting

W912EP-17-B-0003 SECTION 01 57 20 Page 16 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Officer within 15 days following project completion. The Contracting Officer will then submit the report to the U.S. Fish and Wildlife Service ([email protected]) and the Florida Fish and Wildlife Conservation Commission ([email protected]) within 30 days of project completion.

(5) All takes of endangered or threatened (E&T) species shall be immediately reported to the Contracting Officer. Dredging operations shall cease each time an E&T species is taken until the Contracting Officer notifies the Contractor to resume dredging. Promptly following the take of an E&T species, the Government will perform a risk assessment which will include a review of all potential circumstances which contributed to the take, a review of the DQM data, and a physical inspection of the dredge and its operating procedures in accordance with the hopper dredge inspection checklist, project specifications and applicable biological opinions and permits. The Government, in coordination with the Contractor, will develop a risk management plan containing specific actions to minimize risk of additional take. The Government may terminate dredging if it is determined that take numbers are at or near the incidental take statement allowance or additional take jeopardizes other USACE approved regional dredging projects authorized by the South Atlantic/Gulf of Mexico Regional Biological Opinion and the risk of additional take by the project is determined to be high.

(6) If a sea turtle or sturgeon is taken by hopper dredge (dead or alive), a submittal of incident information shall be made into the Operations and Dredging Endangered Species System (ODESS).

d. Manatee Signs: Prior to commencement of construction, each vessel involved in construction activities shall display at the vessel control station or in a prominent location, visible to all employees operating the vessel, a temporary sign at least 8-1/2" x 11" reading, "CAUTION: MANATEE HABITAT/IDLE SPEED IS REQUIRED IN CONSTRUCTION AREA." In the absence of a vessel, a temporary 3' x 4' sign reading "CAUTION: MANATEE AREA" shall be posted adjacent to the issued construction permit. A second temporary sign measuring 8-1/2" x 11" reading "CAUTION: MANATEE HABITAT. EQUIPMENT MUST BE SHUTDOWN IMMEDIATELY IF A MANATEE COMES WITHIN 50 FEET OF OPERATION" shall be posted at the dredge operator control station and at a location prominently adjacent to the issued construction permit. The Contractor shall remove the signs upon completion of construction. Sample Manatee Caution Signs are on the first web site indicated in the paragraph CONSTRUCTION FORMS AND DETAILS below.

3.1.5.2 Endangered Species Observers (Hopper Dredge Only)

During dredging operations, observers approved by the National Oceanic and Atmospheric Administration - Fisheries (NOAA-Fisheries/NMFS) shall be aboard to monitor for the presence of the listed species. Observer coverage shall be 100 percent (24hr/day) and shall be conducted year round. During transit to and from the disposal area, the observer shall monitor from the bridge during daylight hours for the presence of endangered species, especially the Northern right whale, during the period December through March. During dredging operations, while dragheads are submerged, the observer shall continuously monitor the inflow and/or overflow screening for turtles and/or turtle parts and sturgeon and/or sturgeon parts. Upon completion of each load cycle, dragheads should be

W912EP-17-B-0003 SECTION 01 57 20 Page 17 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

monitored as the draghead is lifted from the sea surface and is placed on the saddle in order to assure that listed species that may be impinged within draghead are not lost and un-accounted for. Observers shall physically inspect dragheads and inflow and overflow screening/boxes for threatened and endangered species take.

a. Monitoring Reports: The results of the monitoring shall be recorded on the appropriate observation sheets and entered into the ODESS system (See Appendix A attached after the end of this Section). There is a form for each load and a form for an incident involving a listed species, specific to the species (turtles, sturgeon, etc.). Load forms will be completed regardless of whether any incidents with sturgeon (Gulf, Shortnose or Atlantic), whales, or sea turtles occur. In the event of any sea turtle or sturgeon (Gulf, Atlantic or Shortnose) take by the dredge, appropriate incident reporting forms shall be completed and entered into the ODESS system. Additionally, all specimens shall be photographed with the digital camera built into the ODESS tablet. These photographs shall be uploaded to the respective incident reports on the ODESS. Dredging of subsequent loads shall not commence until all appropriate reports are completed from the previous dredging load to ensure completeness and thoroughness of documentation associated with the incidental take Reports shall be submitted to the Corps within 24-hours of the take. Observer forms may be accessed on the web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below.

b. Digital Photographs: The Contractor shall use a digital camera embedded in the ODESS tablet, with an image resolution capability of at least 300 dpi, in order to photographically report all incidental takes, without regard to species, during dredging operations. Photos taken associated with the take shall be uploaded to the ODESS with the incident information.

3.1.5.3 Manatee, Sea Turtle, Smalltooth Sawfish and Whale Sighting Reports

Any take concerning a manatee, sturgeon, sea turtle, smalltooth sawfish or whale; or sighting of any injured or incapacitated manatees, sea turtles, or whales shall be reported immediately to the Corps of Engineers by notifying the personnel indicated in the table "Order of Contact of Corps Personnel" above.

A copy of the incidental take report shall be provided in PDF format with photographs to the Contracting Officer within 24 hours of the incident. The Contractor shall also immediately report any collision with and/or injury to a manatee to the Florida Fish and Wildlife Conservation Commission "Manatee Hotline" 1-888-404-FWCC (3922) and [email protected] as well as the U.S. Fish and Wildlife Service, Jacksonville Field Office 904-731-3336 for North Florida.

3.1.5.4 Disposition of Endangered or Threatened Species Carcasses

a. Turtles Taken by Hopper Dredge:

(1) Dead Turtles or sturgeon (regardless of species): Upon removal of carcass and/or parts from the draghead or screening, observers shall take photographs as to sufficiently document major characteristics of the carcass or parts including but not limited to dorsal, ventral, anterior, and posterior views. For all photographs taken, a backdrop shall be prepared to document the

W912EP-17-B-0003 SECTION 01 57 20 Page 18 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

dredge name, observer company name, contract title, time, date, species, load number, location of dredging, and specific location taken (draghead, screening, etc.). Carcass/parts shall also be scanned for flipper and Passive Integrated Transponder (PIT) tags. Any identified tags shall be recorded on the "ODESS Turtle Incident Form" or "ODESS Sturgeon Incident Form" (as appropriate) that is included in the ODESS Program Forms available through the ODESS tablet (or on the ODESS website if the tablet is not available). Also, fill out the ODESS Dredge Load Form and take photos for submission. Animal parts which cannot be positively identified to species, on board the dredge or barge(s) shall be preserved by the observer(s) for later identification. A tissue sample shall be collected from any lethally taken sea turtle/sturgeon and submitted under the process stated in the "Protocol for Collecting Tissue Samples from Turtles for Genetic Analysis" found in the CONSTRUCTION FORMS AND DETAILS below. All genetic samples collected shall be submitted to NMFS within 30 days of collection, and verification of submittal to NMFS shall be provided to the Administrative Contracting Officer. After all data collection is complete, the carcass/parts should be marked (spray paint works well), weighted down and disposed of, or provided to a state agency staff member, in accordance with the direction of the Contracting Officer.

(2) Live Turtles: Observer(s) shall measure, weigh, scan for PIT tags, tag (Iconnel flipper and PIT tags (if PIT tag not located during scan, and only if observer is qualified to tag using PIT tags)), and photograph any live turtle(s) incidentally taken by the dredge. Observer(s) (or their authorized representative) shall coordinate with the Contracting Officer and Environmental branch staff prior to transport. Handling of any marine turtles captured during hopper dredging shall be conducted only by persons with prior experience and training in these activities, such as a NMFS-approved marine turtle observer, or by persons who have submitted documentation to the Contracting Officer of meeting the FWC Marine Turtle Conservation Guidelines specific to stranding activities. The Contracting Officer or their designee who transport live or dead marine turtles or marine turtle parts into, out of, or within, the state of Florida will notify FWC in writing specifying the number, species of turtle, type of specimen, and the destination after transport is complete. Before transport, the Contracting Officer or their designee shall coordinate with FWC at [email protected] to determine the appropriate facility to receive live marine turtles for rehabilitation. The Contracting Officer or their designee will abide by the State of Florida's FWC Marine Turtle Conservation Guidelines (http://www.myfwc.com/media/4112794/fwc-mtconservationhandbook.pdf) specific to transport of live stranded turtles.

b. Turtles Taken by Relocation Trawler (Gulf of Mexico Only):

(1) Live Turtles: At least one (1) crewmember, who possesses the required permits for handling endangered species, experienced in sea turtle capture or is a NMFS-approved observer, shall be on board the trawler during the trawl and act as the sea turtle trawling and relocation supervisor. Only a NMFS-approved observer or observer candidate in training under the direct supervision of a NMFS-approved observer shall conduct the sampling operations of

W912EP-17-B-0003 SECTION 01 57 20 Page 19 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

tagging, measuring, weighing and collecting tissue samples from turtles. Each turtle that is captured shall be identified to species and age class (juvenile, sub-adult, adult), digitally photographed, scanned for Passive Integrated Transponder (PIT) tags, measured, tagged (Inconel flipper tag and PIT tag, if one not located by scan, and only if observer is qualified to tag using PIT tags), and released and the data recorded on the "Sea Turtle Tagging and Relocation Report" FOUND IN CONSTRUCTION FORMS AND DETAILS below. External tags shall also be noted and data recorded into the observer's log. Turtles shall be released at locations at least 3 nautical miles (nmi) away from the project area, at time intervals designated by the Sea Turtle Trawling and Relocation Supervisor who is proficient in the viable handling and relocating of sea turtles.

Weight/Size Measurements and Tissue Collection. Turtles shall be measured, tagged, and weighed when safely possible, prior to release. Turtle measurements shall be recorded and shall include, at a minimum, weight when possible, straight-line length, straight-line width, body depth, and tail length. Turtles shall be tagged with NMFS No. 681 Inconel tags in each of the front flippers and PIT tags according to NMFS protocol (found at https://www.sefsc.noaa.gov/turtles/TM_579_SEFSC_STRTM.pdf and on the ODESS website under the Information tab). Aseptic conditions shall be maintained for tags and tag attachment. A tissue sample shall be collected from any trawl captured turtle and submitted under the process stated in the "Protocol for Collecting Tissue Samples from Turtles for Genetic Analysis" found in the CONSTRUCTION FORMS AND DETAILS below. All genetic samples collected shall be submitted to NMFS within 30 days of collection, and verification of submittal to NMFS shall be provided to the Contracting Officer. The Contractor shall be responsible for obtaining permits related to trawling from the appropriate State agencies.

(2) Dead Turtles: Any turtle found dead in the nets during relocation trawling efforts shall be digitally photographed, measured, weighed (if possible), scanned for tags. The carcass should then be placed on ice and kept cold (but not frozen) as quickly as possible and the Contracting Officer shall be contacted immediately. The Contracting Officer will contact the Florida State Sea Turtle Salvage and Stranding network ([email protected]) to arrange for the carcass to be transferred for necropsy. The turtle shall be kept on ice (but not frozen) until the appropriate state agency can be contacted. If the state agency declines to recover the carcass for necropsy, the carcass shall be marked (spray paint works well), weighted down and disposed of in accordance with the direction of the Contracting Officer.

Weight/Size Measurements and Tissue Collection. Turtles shall be measured, and weighed. Measurements shall be recorded and shall include, at a minimum, weight when possible, straight-line length, straight-line width, body depth, and tail length. The Carcass shall also be scanned for flipper and Passive Integrated Transponder (PIT) tags. Any identified tags shall be recorded on the "Sea Turtle Incidental Take Form" that is included in the Endangered Species Observer Program Forms located on the web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below. A

W912EP-17-B-0003 SECTION 01 57 20 Page 20 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

tissue sample shall be collected from any lethally taken sea turtle and submitted under the process stated in the "Protocol for Collecting Tissue Samples from Turtles for Genetic Analysis" found in the CONSTRUCTION FORMS AND DETAILS below. All genetic samples collected shall be submitted to NMFS within 30 days of collection, and verification of submittal to NMFS shall be provided to the Contracting Officer. The Contractor shall be responsible for obtaining permits related to trawling from the appropriate State agencies.

3.1.5.5 Report Submission

If a hopper dredge is used, the Contractor shall submit all details regarding sea turtle and sturgeon takes in ODESS. Any incidents, including sightings, collisions with, injuries, or killing of manatees, sea turtles (not associated with a take via the dredge) or whales occurring during the contract period shall be recorded in a log that will be turned into the Contracting Officer at the end of the project. The Contractor shall maintain paper copies of all forms entered into the ODESS until the project is deemed complete by the Contracting Officer.

If a hopper dredge is not used, the Contractor shall maintain a log detailing all incidents, including sightings, collisions with, injuries, or killing of manatees, sturgeon (Gulf, Shortnose or Atlantic), sea turtles or whales occurring during the contract period. The data shall be recorded on forms provided by the Contracting Officer (sample forms are on the web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below). All data in original form shall be forwarded directly to Chief, Environmental Branch, P. O. Box 4970, Jacksonville, Florida, 32232-0019, within 10 days of collection and copies of the data shall be supplied to the Contracting Officer. Following project completion, a report summarizing the above incidents and sightings shall be submitted to the following:

Chief, Environmental Branch U.S. Army Corps of Engineers (CESAJ-PD-E) P.O. Box 4970 Jacksonville, Florida 32232-0019

Area Engineer for Area Office indicated on Standard Form 1442

U.S. Fish and Wildlife Service 7915 Baymeadows Way, Suite 200 Jacksonville, Florida 32256-7517

National Marine Fisheries Service Protected Species Management Branch 263 13th Avenue South St. Petersburg, Florida 33701

Florida Fish and Wildlife Conservation Commission Imperiled Species Management Section 620 South Meridian Street, Mail Stop 6A Tallahassee, Florida 32399-1600

3.1.5.6 Hopper Dredge Equipment

Hopper dredge dragheads shall be equipped with rigid sea turtle deflectors

W912EP-17-B-0003 SECTION 01 57 20 Page 21 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

which are rigidly attached. Deflectors shall be solid with no openings in the face. Alternative designs will be considered provided sufficient information is included indicating a particular modification is effective in minimizing potential turtle takes. Government technical staff will coordinate with NMFS on the effectiveness of this alternate design. A recommendation from Government technical staff and NMFS will be provided to the Contracting Officer for final approval or disapproval of the alternate design. The Contractor shall not presume that a decision on an alternative design will be provided during the contracting period. The Contractor's unit price shall be based on the original, solid faced deflector design. No adjustment in unit price will be made for the approval or denial of an alternate deflector design. No dredging shall be performed by a hopper dredge without an installed turtle deflector device approved by the Contracting Officer. Sample Turtle Deflector Design Details are on the first web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below.

a. Deflector Design:

(1) The leading vee-shaped portion of the deflector shall have an included angle of less than 90 degrees. Internal reinforcement shall be installed in the deflector to prevent structural failure of the device. The leading edge of the deflector shall be designed to have a plowing effect of at least 6" depth when the drag head is being operated. Appropriate instrumentation or indicator shall be used and kept in proper calibration to insure the critical "approach angle". (Information Only Note: The design "approach angle" or the angle of lower drag head pipe relative to the average sediment plane is very important to the proper operation of a deflector. If the lower drag head pipe angle in actual dredging conditions varies tremendously from the design angle of approach used in the development of the deflector, the 6" plowing effect does not occur. Therefore, every effort should be made to insure this design "approach angle" is maintained with the lower drag pipe.)

(2) If adjustable depth deflectors are installed, they shall be rigidly attached to the drag head using either a hinged aft attachment point or an aft trunnion attachment point in association with an adjustable pin front attachment point or cable front attachment point with a stop set to obtain the 6" plowing effect. This arrangement allows fine-tuning the 6" plowing effect for varying depths. After the deflector is properly adjusted there shall be NO openings between the deflector and the drag head that are more than 4" by 4".

(3) Draghead Screening: If the Contractor has the draghead(s) screened, in no case shall the screening for the draghead production opening be smaller than 8 inches by 8 inches. Pumps employed shall be sufficient to operate efficiently with this screening as a minimum.

b. In Flow Basket Design:

(1) The Contractor shall install baskets or screening over the hopper inflow(s) with no greater than 4" x 4" openings. The method selected shall depend on the construction of the dredge used and shall be approved by the Contracting Officer prior to commencement of dredging. The screening shall provide 100 percent

W912EP-17-B-0003 SECTION 01 57 20 Page 22 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

screening of the hopper inflow(s). The screens and/or baskets shall remain in place throughout the performance of the work.

(2) The Contractor shall install and maintain floodlights suitable for illumination of the baskets or screening to allow the observer to safely monitor the hopper basket(s) during non-daylight hours or other periods of poor visibility. Safe access shall be provided to the inflow baskets or screens to allow the observer to inspect for turtles, turtle parts or damage.

c. Hopper Dredge Operation:

(1) The Contractor shall operate the hopper dredge to minimize the possibility of taking sea turtles or sturgeon and to comply with the requirements stated in the Incidental Take Statement provided by the NMFS in the appropriate Biological Opinion.

(2) The turtle deflector device and inflow screens shall be maintained in operational condition for the entire dredging operation.

(3) When initiating dredging, suction through the drag heads shall be allowed just long enough to prime the pumps, then the drag heads shall be placed firmly on the bottom. When lifting the drag heads from the bottom, suction through the drag heads shall be allowed just long enough to clear the lines, and then shall cease. Pumping water through the drag heads shall cease while maneuvering or during travel to/from the disposal area. (Information Only Note: Optimal suction pipe densities and velocities occur when the deflector is operated properly. If the required dredging section includes compacted fine sands or stiff clays, a properly configured arrangement of teeth may enhance dredge efficiency which reduces total dredging hours and "turtle takes." The operation of a drag head with teeth shall be monitored for each dredged section to insure that excessive material is not forced into the suction line. When excess high-density material enters the suction line, suction velocities drop to extremely low levels causing conditions for plugging of the suction pipe. Dredge operators should configure and operate their equipment to eliminate all low level suction velocities. Pipe plugging cannot be corrected by raising the drag head off the bottom. Arrangements of teeth and/or the reconfiguration of teeth should be made during the dredging process to optimize the suction velocities.)

(4) Raising the drag head off the bottom to increase suction velocities is not acceptable. The primary adjustment for providing additional mixing water to the suction line should be through water ports. To insure that suction velocities do not drop below appropriate levels, the Contractor's personnel shall monitor production meters throughout the job and adjust primarily the number and opening sizes of water ports. Water port openings on top of the drag head or on raised stand pipes above the drag head shall be screened before they are utilized on the dredging project. If a dredge section includes sandy shoals on one end of a tract line and mud sediments on the other end of the tract line, the Contractor shall adjust the equipment to eliminate drag head pick-ups to clear the suction line.

W912EP-17-B-0003 SECTION 01 57 20 Page 23 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

(5) Near the completion of each payment section, the Contractor shall perform sufficient surveys to accurately depict those portions of the acceptance section requiring cleanup. The Contractor shall keep the drag head buried a minimum of 6 inches in the sediment at all times. Although the over depth prism is not the required dredging prism, the Contractor shall achieve the required prism by removing the material from the allowable over depth prism.

(6) During turning operations the pumps shall either be shut off or reduced in speed to the point where no suction velocity or vacuum exists.

(7) These operational procedures are intended to stress the importance of balancing the suction pipe densities and velocities in order to keep from taking sea turtles. The Contractor shall develop a written operational plan to minimize turtle takes and submit it as part of the Environmental Protection Plan.

(8) The Contractor shall comply with all requirements of this specification and the Contractor's accepted Environmental Protection Plan. The contents of this specification and the Contractor's Environmental Protection Plan shall be shared with all applicable crew members of the hopper dredge.

d. Hopper Dredge Lighting Requirements: From May 1st through October 31st, sea turtle nesting and emergence season, all lighting aboard hopper dredges and hopper dredge pumpout barges operating within three nautical miles of sea turtle nesting beaches shall be limited to the minimal lighting necessary to comply with U.S. Coast Guard and Occupational Safety and Health Administration (OSHA) requirements. All non-essential lighting on the dredge and pumpout barge shall be minimized through reduction, shielding, lowering and appropriate placement of lights to reduce potential disorientation effects on female sea turtles approaching the nesting beaches and sea turtle hatchlings heading seaward.

3.1.5.7 Sea Turtle Trawling and Relocation (For Hopper Dredges Only)

a. Sea Turtle Trawling and Relocation: Sea turtle relocation via trawling shall be conducted following the take of two sea turtles, without regard to species, and continue until the end of dredging or as directed by the Contracting Officer. The results of each trawl shall be recorded on Sea Turtle Trawling Report available from the ODESS website (http://dqm.usace.army.mil/odess/#/download). An interim trawling report shall be submitted within 24 hours after the third turtle take by the dredge. A final report shall be prepared after the completion of all trawling efforts. Both reports shall be submitted in hard copy and electronic format to the Contracting Officer, and shall summarize the results of the trawling (with all forms and including total trawling times, number of trawls and number of captures). Any turtles captured during the trawling effort shall be measured and tagged in accordance with standard biological sampling procedures with sampling data recorded on Sea Turtle Tagging and Relocation Report available from the ODESS website (http://dqm.usace.army.mil/odess/#/download). Any captured sea turtles shall be relocated from the work area no less than 3 miles away from the location recorded on the Sea Turtle Tagging and

W912EP-17-B-0003 SECTION 01 57 20 Page 24 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Relocation Report form.

b. Sea Turtle Trawling Procedures: An approved sea turtle trawling and relocation supervisor shall provide sea turtle trawl observers and nets to capture and relocate sea turtles and shall conduct any initiated sea turtle trawling. Turtles shall be captured with trawl nets to relocate them away from the project area to reduce the potential of sea turtle take. Methods and equipment shall be standardized including nets, trawling direction to tide, length of station, length of tow, and number of tows per station. Data on each tow shall be recorded using Sea Turtle Trawling Report available from the ODESS website (http://dqm.usace.army.mil/odess/#/download). The trawler shall be equipped with two 60-foot nets constructed from 8-inch mesh (stretch) fitted with mud rollers and flats as specified in Turtle Trawl Nets Specifications on the first web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below. Paired net tows shall be made for 10 to 12 hours per day or night. Trawling shall be conducted with the tidal flow using repetitive 15-30 minute (total time) tows in the channel or borrow area. Tows shall be made as close to the operating dredge as the trawler captain determines is safe. Positions at the beginning and end of each tow shall be determined from GPS Positioning equipment. Tow speed shall be recorded at the approximate midpoint of each tow. Refer to EM 1110-1-1003, paragraph 5.3 and Table 5-1, for acceptable GPS criteria.

c. Water Quality and Physical Measurements: Water temperature measurements shall be taken at the water surface each day using a laboratory thermometer or a thermometer built into the trawling vessel. Weather conditions shall be recorded from visual observations and instruments on the trawler. Weather conditions, air temperature, wind velocity and direction, sea state-wave height, and precipitation shall be recorded on the Sea Turtle Trawling Report on the second web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below. High and low tides shall be recorded.

d. Initiation of Trawling: Initiate trawling if two turtles are taken. The Contractor must initiate trawling and relocation activity in the dredging area within 8 hours of the occurrence of the take. Trawling shall continue until suspended by the Contracting Officer.

e. Approved Trawling Supervisor: Trawling shall be conducted under the supervision of a biologist approved by the NMFS. A letter of approval from NMFS shall be provided to the Contracting Officer prior to commencement of trawling.

f. Turtle Excluder Devices: Approval for trawling for sea turtles without Turtle Excluder Devices (TEDs) must be obtained from NMFS. Approval for capture and relocation of sea turtles must be obtained from the Florida Fish and Wildlife Conservation Commission (FF&WCC). Approvals must be submitted to the Contracting Officer prior to trawling.

g. Report Submission: Following completion of the project, a copy of the Contractor's log regarding sea turtles shall be forwarded to the Contracting Officer within 10 working days.

3.1.5.8 Protection of Migratory Bird Species (Alafia River Only)

The Contractor shall keep construction activities under surveillance,

W912EP-17-B-0003 SECTION 01 57 20 Page 25 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

management, and control to prevent impacts to migratory birds and their nests. All construction personnel shall be advised that migratory birds are protected by the Florida Endangered and Threatened Species Act of 1977, Title XXVIII, Chapter 372.072, and the U.S. Fish and Wildlife Service pursuant to the Migratory Bird Treaty Act of 1918 and the Endangered Species Act of 1973, as amended. The Contractor may be held responsible for harming or harassing the birds, their eggs or their nests as a result of the construction.

a. Monitoring of Construction Area: The Contractor shall conduct monitoring of the construction area as follows:

(1) All required monitoring shall be conducted by bird monitors with qualifications approved by the Contracting Officer. Transportation to and from the island, as well as any other necessary logistical support required for accomplishing the duties outlined in this section, shall be provided by the Contractor While birds are nesting on the island, the Contractor's personnel shall coordinate daily with the bird monitor(s) prior to accessing the island to avoid impacts to migratory birds that may be present on the exterior or interior portions of the island.

(2) The DMPF 3D site is subject to year round migratory bird nesting. As nesting may still be ongoing at the island in the fall months, the Contractor shall conduct a migratory bird survey prior to mobilizing equipment to the island. If any nests are found, the Contractor shall initiate surveys and continue them until all hatchlings have fledged or until otherwise directed by the Contracting Officer. In the spring, nesting surveys shall be conducted while construction activities are occurring at least once daily from March 1 through September 15, or when nesting is completed, whichever is later. The Contractor may choose to conduct surveys more often to be sure they are aware of potential nesting activity, and are able to deter nesting prior to its occurrence. Early in the season, before chicks hatch, conduct at least one survey during the hotter parts of the day (9AM to 4PM). Nest attendance is likely to be more stable at this time of day, since birds protect their eggs from the hot sun. Later in the season when eggs hatch, conduct counts during the cooler parts of the day (before 9AM and after 7PM). Chicks may be more active and more visible during this time.

(3) Bird nesting surveys shall be conducted daily over the entire site, especially any project areas that may be impacted by construction, pre-construction or operational activities.

(4) Surveys for detecting new nesting activity will be completed on a daily basis prior to movement of equipment, operation of vehicles, or other activities that could potentially cause harm to the birds or their eggs or young.

(5) Surveys should be conducted by walking the length of the project site and visually inspecting, using binoculars or spotting scope, for the presence of migratory birds exhibiting nesting behavior. If an ATV or other vehicle is needed to cover large project areas, the vehicle shall be operated at a speed <4 mph, and the bird monitor will stop at no greater than 200 yard intervals to visually inspect for nesting activity.

W912EP-17-B-0003 SECTION 01 57 20 Page 26 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

(6) The bird monitor(s) shall maintain a daily log detailing monitoring and nesting activity, including a map of the island showing their locations. The bird monitor shall use the forms attached to this section to complete the daily log. These logs shall be provided via e-mail to the Contracting Officer's designated USACE Technical Representative on a daily basis. Within 30 days after completion of construction, a summary of monitoring shall be submitted to the Contracting Officer and the Environmental Branch Chief (see table "Order of Contact of Corps Personnel" above), which details bird species identified, nesting and nesting success/failure including species, number of nests created, location, number of eggs, number of chicks generated during the project and reasons for nesting success or failure, if known. The summary shall contain an appendix with all daily log sheets.

b. Nesting Activity Notification: Any nesting activity observed by the Contractor shall be reported immediately to the Contracting Officer who shall have sole authority for any work stoppages, creation of the buffer area, or restart of construction activities. In addition, notify the personnel indicated in the table "Order of Contact of Corps Personnel" above, and Nancy Douglass, FWC Regional Biologist at (863) 648-3203 or email [email protected].

c. Nesting Within Construction Area:

(1) Should nesting begin within the construction area, a temporary, 300-foot buffer shall be created around the nests and marked with signs to avoid entry. The area shall be left undisturbed until nesting is completed or terminated, and the chicks fledge. The decision to allow construction in a former nesting site will be determined by the Contracting Officer in consultation with the U.S. Fish and Wildlife Service and the FF&WCC. Access to the nesting sites by humans (except limited access when accompanied by the bird monitor or Contracting Officer), equipment or pets under control of the Contractor is prohibited.

(2) If nesting occurs within the construction area, a bulletin board shall be placed and maintained by the Contractor in the contracting shed with the location map of the construction site showing the bird nesting areas and a warning, clearly visible, stating that "BIRD NESTING AREAS ARE PROTECTED BY THE FLORIDA THREATENED AND ENDANGERED SPECIES ACT AND THE FEDERAL MIGRATORY BIRD TREATY ACT".

(3) Birds will find the top of the dike or the flat interior desirable nesting habitat. If construction activity ceases for any period of time, nesting may occur before work can resume. Any stoppage of activity could induce nesting, subsequently, construction could be altered or stopped to avoid impacting the birds. Areas which are potentially suitable for nesting can be altered to make the area undesirable. One approved method is the placement of stakes at 10- to 15-foot intervals and tie flagging between the stakes in a web fashion. This may dissuade bird nesting until construction can be resumed. In addition, the disposal area basin can be flooded prior to the beginning of nesting season to the elevation required for displacement from the disposal of dredged material in order to make the basin

W912EP-17-B-0003 SECTION 01 57 20 Page 27 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

undesirable for bird nesting.

d. Bird Monitoring Qualifications: The Contractor's Environmental Protection Plan shall contain the qualifications of the bird monitor and the steps to be taken to construct the project in such a manner as not to impact migratory birds or induce their nesting. The qualifications of the bird monitor are a demonstrated ability to identify bird species, general and nesting behavior characteristics, nests and eggs, and a knowledge of habitat requirements. In addition, references must be provided to verify non-educational experience. The qualifications shall be submitted on the Bird Monitoring Qualification Sheet.

e. Work Delay: Delays in work due to the fault of negligence of the Contractor or the Contractor's failure to comply with this specification shall not be compensable. Any adjustments to the contract performance period or price that are required as a result of compliance with this section shall be made in accordance with the Clause SUSPENSION OF WORK of Section 00700 CONTRACT CLAUSES in Volume 1.

f. Meeting Attendance: The Contractor's bird monitor shall attend the biannual Migratory Bird Protection meetings, and weekly progress meetings with USACE that occur during nesting season.

3.1.5.9 Protection of Migratory Bird Species (Manatee Harbor Only)

The Contractor shall keep construction activities under surveillance, management, and control to prevent impacts to migratory birds and their nests. All construction personnel shall be advised that migratory birds are protected by the Florida Endangered and Threatened Species Act of 1977, Title XXVIII, Chapter 372.072, and the U.S. Fish and Wildlife Service pursuant to the Migratory Bird Treaty Act of 1918 and the Endangered Species Act of 1973, as amended. The Contractor may be held responsible for harming or harassing the birds, their eggs or their nests as a result of the construction.

a. Monitoring of Construction Area: In order to meet these responsibilities, the Contractor shall conduct monitoring of the construction area beginning 1 April through 31 August, if construction activities occur during that period. Daily monitoring using the Daily Bird Monitoring Report shall be conducted during the dawn or dusk time frames by a bird monitor approved by the Contracting Officer (Caution shall be taken by the monitor to avoid disturbance to the nesting birds). The Contractor shall maintain a daily log detailing monitoring and nesting activity (not all bird species are listed). Sample monitoring report and qualification sheet are on the first web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below. Within 30 days after completion of construction, a summary of monitoring shall be submitted to the Corps detailing nesting and nesting success/failure including species, number of nests created, location, number of eggs, number of offspring generated during the project and reasons for nesting success or failure, if known.

b. Nesting Activity Notification: Any nesting activity observed by the Contractor shall be reported immediately to the Contracting Officer who shall have sole authority for any work stoppages, creation of the buffer area, or restart of construction activities.

W912EP-17-B-0003 SECTION 01 57 20 Page 28 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

c. Presence/Absence Survey: At least 3 visits must be made to each site during April-July. A 6-minute point count (variable circular plot) should be conducted between sunrise and 3 hours after or 1 hour prior to sunset. If breeding birds are encountered, nests shall be located and observed without disturbance to the nesting activity. Nests shall be marked and visited every 3-5 days to determine fate.

d. Nesting Within Construction Area:

(1) Should nesting begin within the construction area, a temporary, 300-foot buffer shall be created around the nests and marked with signs to avoid entry. The area shall be left undisturbed until nesting is completed or terminated, and the chicks fledge. The decision to allow construction in a former nesting site will be determined by the Contracting Officer in consultation with the U.S. Fish and Wildlife Service and the FF&WCC. Access to the nesting sites by humans (except limited access when accompanied by the bird monitor or Contracting Officer), equipment or pets under control of the Contractor is prohibited.

(2) If nesting occurs within the construction area, a bulletin board shall be placed and maintained by the Contractor in the contracting shed with the location map of the construction site showing the bird nesting areas and a warning, clearly visible, stating that "BIRD NESTING AREAS ARE PROTECTED BY THE FLORIDA THREATENED AND ENDANGERED SPECIES ACT AND THE FEDERAL MIGRATORY BIRD TREATY ACT".

(3) Birds will find the top of the dike or the flat interior desirable nesting habitat. Any stoppage of construction activity could induce nesting, subsequently, construction could be altered or stopped to avoid impacting the birds. Areas which are potentially suitable for nesting can be altered to make the area undesirable. One approved method is the placement of stakes at 10- to 15-foot intervals and tie flagging between the stakes in a web fashion. This may dissuade bird nesting until construction can be resumed. In addition, the disposal area basin can be flooded prior to the beginning of nesting season to the elevation required for displacement from the disposal of dredged material in order to make the basin undesirable for bird nesting.

e. Bird Monitoring Qualifications: The Contractor's Environmental Protection Plan shall contain the qualifications of the bird monitor and the steps to be taken to construct the project in such a manner as not to impact migratory birds or induce their nesting. The qualifications of the bird monitor are a demonstrated ability to identify bird species, general and nesting behavior characteristics, nests and eggs, and a knowledge of habitat requirements. In addition, references must be provided to verify non-educational experience. The qualifications shall be submitted on the Bird Monitoring Qualification Sheet.

f. Work Delay: Delays in work due to the fault of negligence of the Contractor or the Contractor's failure to comply with this specification shall not be compensable. Any adjustments to the contract performance period or price that are required as a result of compliance with this section shall be made in accordance with the Clause SUSPENSION OF WORK of Section 00700 CONTRACT CLAUSES in Volume

W912EP-17-B-0003 SECTION 01 57 20 Page 29 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.

3.1.6 Seagrass Protection Measures

a. The Contractor shall instruct all personnel associated with the project of the presence of seagrasses, especially the Federally-listed threatened Johnson's Seagrass (Halophlia johnsonii), and the need to avoid contact with seagrasses.

b. All construction personnel shall be advised that there are civil and criminal penalties for harming or destroying seagrasses, especially Johnson's Seagrass which is protected under the Endangered Species Act of 1973, as amended. The Contractor may be held responsible for any seagrasses harmed or destroyed due to construction activities.

c. The Contractor shall not anchor, place pipeline, or stage equipment in a manner that will cause any damage to seagrasses or hardbottoms. Anchoring, placing pipeline, or staging equipment shall avoid these sensitive areas. If such activities cannot be done without affecting these sensitive areas, the activities shall cease and the Contracting Officer and Chief, Environmental Branch (904-232-1665) shall be immediately notified (no later than the morning following the next working day if the incident occurs after normal working hours). Any actual or potential incident involving damage to, or disturbance of, seagrasses or hardbottoms shall be reported.

3.1.7 Protection of Air Resources

The Contractor shall keep construction activities under surveillance, management, and control to minimize pollution of air resources. All activities, equipment, processes and work operated or performed by the Contractor in accomplishing the specified construction shall be in strict accordance with the applicable air pollution standards of the State of Florida (Florida Statute, Chapter 403 and others and Chapters 200 series of the FAC) and all Federal emission and performance laws and standards, including the U.S. Environmental Protection Agency's Ambient Air Quality Standards. Information regarding Florida Statutes can be obtained from the following web site: http://www.dep.state.fl.us.

3.1.7.1 Particulates

Particulates, such as dust, shall be controlled at all times, including weekends, holidays, and hours when work is not in progress. The Contractor shall maintain excavations, stockpiles, haul roads, permanent and temporary access roads, plant sites, spoil areas, borrow areas, and work areas within or outside the project boundaries free from particulates that would cause air pollution standards to be exceeded or that would cause a hazard or nuisance. The Contractor shall have the necessary equipment and approved methods to control particulates as the work proceeds and before a problem develops.

3.1.7.2 Odors

Odors shall be controlled at all times for all construction activities.

W912EP-17-B-0003 SECTION 01 57 20 Page 30 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.1.8 Protection of Sound Intrusions

The Contractor shall keep construction activities under surveillance and control to minimize damage to the environment by noise.

3.2 POSTCONSTRUCTION CLEANUP

The Contractor shall clean up any area(s) used for construction.

3.3 PRESERVATION AND RESTORATION OF LANDSCAPE AND MARINE VEGETATION DAMAGES

The Contractor shall restore all landscape features and marine vegetation damaged or destroyed during construction operations outside the limits of the approved work areas. Such restoration shall be a part of the Environmental Protection Plan as defined in subparagraph "Environmental Protection Plan" of paragraph SUBMITTALS above. This work shall be accomplished at the Contractor's expense.

3.4 INVASIVE AND NUISANCE SPECIES

3.4.1 Prevention of Invasive and Nuisance Species Transfer

The Contractor shall thoroughly clean equipment prior to and following work on the project site to ensure that items/materials including, but not limited to, soil, vegetative debris, eggs, mollusk larvae, seeds, and vegetative propagules are not transported from a previous work location to this project site, nor transported from this project site to another location. Prevention protocols require cleaning all equipment surfaces, including but not limited to, undercarriages, tires, and sheet metal. All equipment, including but not limited to, heavy equipment, vehicles, trailers, ATV's, and chippers must be cleaned. Smaller equipment, including, but not limited to, chainsaws, loppers, shovels, and backpack sprayers, must be cleaned and inspected to ensure they are free of eggs, vegetative debris, vegetative propagules, etc. The Contractor may utilize any method accepted by the Government; common accepted methods include pressure washing and steam cleaning/washing equipment. Prevention protocols should also address clothing and personal protective equipment.

Prior to the commencement of work, the Contractor shall complete and provide an invasive and nuisance species transfer prevention plan to the Corps for approval. This plan shall be part of the Environmental Protection Plan as defined in subparagraph "Environmental Protection Plan" of paragraph SUBMITTALS (Part 1.5) above. The invasive and nuisance species transfer prevention plan shall identify specific transfer prevention procedures and designated cleaning sites/locations. Prevention protocols may vary depending upon the nature of the project site. It will be the responsibility of the Contractor to ensure all equipment coming onto and leaving the project site is inspected and not harboring materials that would spread, or potentially spread, invasive and nuisance species onto or off the project site. The Contractor shall provide a report verifying equipment brought on site was cleaned and shall provide a report verifying equipment was cleaned prior to removal from the project site.

Work delays due to the fault and/or negligence of the Contractor or the Contractor's failure to comply with this specification shall not be compensable. Any adjustments to the contract performance period or price that are required as a result of compliance with this section shall be made in accordance with the Clause SUSPENSION OF WORK of Section 00700 CONTRACT CLAUSES in Volume 1.

W912EP-17-B-0003 SECTION 01 57 20 Page 31 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.4.2 Invasive and Nuisance Species Reporting

The Contractor shall report sightings of invasive and nuisance species not identified and documented in the pre-construction condition within 24 hours. The reporting shall include the date, time, location (latitude and longitude preferred), environmental conditions, circumstances surrounding the sighting, disposition/behavior of the species, and any other notable observations. Pictures of the reported species are desirable. Reporting shall be made to the Jacksonville District Corps of Engineers Planning Division, Environmental Branch and Operations Division, Invasive Species Management Branch. Points of contact will be provided in the Preconstruction Conference.

3.5 MAINTENANCE OF POLLUTION CONTROL FACILITIES

The Contractor shall maintain all constructed facilities and pollution control facilities and devices for the duration of the contract or for that length of time construction activities create the particular pollutant.

3.6 CONSTRUCTION FORMS AND DETAILS

See the "Construction Forms & Details" module at the following web address: http://www.saj.usace.army.mil/About/Divisions-Offices/Engineering/Design-Branch/ Specifications-Section/

Also, see web site address http://dqm.usace.army.mil/odess/#/download to obtain the Sea Turtle/Post-Hopper Dredging Project Checklist, Endangered Species Observer Program Forms, Sea Turtle Tagging and Relocation Report, and Sea Turtle Trawling Report. Links to these forms are under the heading "Turtle Information".

-- End of Section --

W912EP-17-B-0003 SECTION 01 57 20 Page 32 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 57 25

TURBIDITY AND DISPOSAL MONITORING

PART 1 GENERAL

1.1 SCOPE 1.2 SUBMITTALS

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 MONITORING REQUIREMENTS 3.1.1 General 3.1.1.1 Turbidity Monitoring Equipment 3.1.2 Dredging and Disposal Locations 3.1.2.1 Frequency 3.1.2.2 Locations 3.2 TURBIDITY TESTS 3.2.1 Testing 3.2.2 Reporting 3.2.2.1 Report Contents 3.2.2.2 Notification 3.3 WORK DELAY 3.4 CONSTRUCTION FORMS AND DETAILS

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 01 57 25 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 01 57 25

TURBIDITY AND DISPOSAL MONITORING

PART 1 GENERAL

1.1 SCOPE

The work covered by this section consists of furnishing all labor, materials, and equipment, and performing all work required to obtain, analyze, and report the results of turbidity and disposal monitoring.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-03 Product Data

Calibration Standard

The Contractor shall furnish to the Contracting Officer a copy of the operating instructions and standards used in calibrating equipment used in collecting samples for turbidity.

SD-06 Test Reports

Turbidity Monitoring

All required daily turbidity test reports shall be submitted (by electronic mail in Excel format) to the Contracting Officer, within 24 hours after completion of each test.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 MONITORING REQUIREMENTS

3.1.1 General

Nearshore or inland water samples shall be obtained and analyzed for turbidity. Sampling shall be conducted in accordance with techniques described in the latest edition of "Standard Methods" published by the American Public Health Association (APHA), American Water Works Association (AWWA), and Water Pollution Control Federation (WPCF), and other current techniques recognized by the scientific community and approved by the Jacksonville District, Corps of Engineers. Samples obtained for turbidity analysis shall be analyzed within 30 minutes of collection. Samples shall be taken with a sampler obtaining samples uncontaminated by water from any other depth.

W912EP-17-B-0003 SECTION 01 57 25 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.1.1.1 Turbidity Monitoring Equipment

Monitoring required for turbidity shall be measured in Nephelometric Turbidity Units (NTU) using a standard Nephelometer. Global Positioning System (GPS) is also required to record sampling stations. The Contractor shall provide the Government with a certification, attesting to the accuracy of his testing equipment and procedure. The Contractor shall also provide the Contracting Officer with a duplicate of the standard used to calibrate his testing instrument as well as a complete set of operating instructions for the turbidity testing equipment. The Contractor and the Contracting Officer will use this standard throughout the project to maintain the calibration of the equipment.

3.1.2 Dredging and Disposal Locations

Monitoring shall occur provided sea, wind, visibility, marine traffic and other conditions allow for safe performance of the activity. The Contractor shall document all instances where turbidity monitoring within the bounds of the above parameters could not be performed. Routine monitoring shall occur at the following locations:

3.1.2.1 Frequency

a. Compliance Site Type 1 (where the mixing zone does not abut seagrass): Twice daily at least 4 hours apart during all dredging, filling or disposal operations. If overflow occurs from filling a hopper dredge, disposal barge or scow barge, then monitoring shall occur at least once during each loading event when the turbidity reaches the edge of the mixing zone.

b. Compliance Site Type 2 (where a shortened mixing zone abuts seagrass): Hourly, when visual observation indicates a turbidity plume extends into areas containing seagrasses. If overflow occurs from filling a hopper dredge, disposal barge or scow barge, them monitoring frequency shall be increased to every 30 minutes during loading and up to 30 minutes after overflow has ceased.

3.1.2.2 Locations

a. Background: At mid-depth, at least 300 meters upcurrent from the dredge, fill, or disposal site discharge point and clearly outside the influence of any turbidity generated by this project or other obvious turbidity plumes.

b. Compliance Site Type 1 - at mid-depth, at the mixing zone boundary (150 meters from the edge of the active construction within waters/wetlands or point of discharge into water/wetlands, but not beyond the edge of the nearest seagrass bed), downcurrent from the dredge or disposal site discharge point, within the densest portion of any visible turbidity plume.

c. Compliance Site Type 2 - At mid-depth, within the densest portion of any visible turbidity plume, no more than 150 meters downcurrent from the dredge, fill, or disposal site discharge point, or 1 meter within the edge of seagrass areas closest to the construction activity (whichever is less)

W912EP-17-B-0003 SECTION 01 57 25 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.2 TURBIDITY TESTS

3.2.1 Testing

Whenever there is doubt as to the adequacy of the testing or validity of the results, the Contracting Officer may direct that additional tests be performed at no additional cost to the Government.

3.2.2 Reporting

The monitoring data shall be recorded on summary forms, and as a daily QC test in the RMS system, that contain the pertinent information in the following paragraphs. Example forms are on the web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below. Other data shall be submitted in the form supplied by the laboratory chosen to do the analysis. All data shall be forwarded (electronically) to the Contracting Officer, Environmental Branch (CESAJ-PD-E), and FDEP within 7 days of collection. Electronic mail addresses of the Corps and FDEP personnel to receive these reports are provided below. Reports shall be provided in Excel Spreadsheet (.xls) files. Turbidity Teseting results shall also be logged daily into QCS.

NAME ORGANIZATION E-MAIL ADDRESS

To be determined USACE ACO To be determined To be determined CESAJ-PD-E POC To be determined JCP Compliance Officer FDEP [email protected]

Information to be determined will be provided in the Preconstruction Conference. CESAJ-PD-E POC may also be indicated in the Environmental Compliance Matrix (ECM). See Section 01 57 20 ENVIRONMENTAL PROTECTION.

3.2.2.1 Report Contents

a. Permit application number. b. A statement describing the methods used in collection, handling, storage, and quality control methods used in the analysis of the samples. c. A map indicating the sampling location and plume configuration, if any . d. A map plotting the dredge location. This map can be combined with the map indicating the sampling location. e. A statement by the individual responsible for implementation of the sampling program concerning the authenticity, precision, limits of detection, and accuracy of the data. f. Monitoring Reports. Monitoring reports shall also include the following information for each day that samples are taken: (1) Time of day and date samples were taken. (2) Depth of water body. (3) Depth of sample. (4) Antecedent weather conditions. (5) Tidal stage and direction of flow. (6) Dredge or disposal location (station location and map). (7) Water sample location. (8) Wind direction and velocity. g. A description of any factors influencing the dredging or disposal operation or the sampling program. Reports shall be furnished daily even when no sampling is conducted. When sampling is not conducted, a brief statement shall be given in the report

W912EP-17-B-0003 SECTION 01 57 25 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

explaining the reason for not conducting the sampling, such as "dredge not working due to mechanical problems" or "no sampling taken due to high seas". h. State plane coordinates (x and y) shall be provided for all sampling stations along with the coordinates of the dredge and discharge pipe and the distance between the sampling station and dredge/discharge pipe for each sampling event to demonstrate compliance with the stated sampling distances.

3.2.2.2 Notification

If turbidity exceeds background levels by more than 29 NTU, the Contractor shall immediately notify Chief, Environmental Branch at 904-232-1665 and the Contracting Officer, or on the morning of the following work day if it occurs after normal work hours. In addition, all dredging or disposal activity shall cease immediately and all measures to reduce turbidity shall be taken. Dredging or disposal shall not resume until corrective measures have been taken and turbidity has returned to acceptable levels as determined by proper testing described in subparagraph "Dredging and Disposal Locations" above.

3.3 WORK DELAY

Delays in work due to the fault or negligence of the Contractor or the Contractor's failure to comply with this specification shall not be compensable. Any adjustments to the contract performance period or price that are required as a result of compliance with this section shall be made in accordance with the provisions of the Clause SUSPENSION OF WORK of Section 00700 CONTRACT CLAUSES in Volume 1.

3.4 CONSTRUCTION FORMS AND DETAILS

See the "Construction Forms & Details" module at the following web address: http://www.saj.usace.army.mil/About/DivisionsOffices/Engineering/DesignBranch /SpecificationsSection.aspx

-- End of Section --

W912EP-17-B-0003 SECTION 01 57 25 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

SECTION 35 20 23

DREDGING

PART 1 GENERAL

1.1 SCOPE 1.2 REFERENCES 1.3 SUBMITTALS 1.4 DREDGING RESTRICTIONS 1.4.1 Order of Work 1.4.2 Transportation of Material 1.5 SPECIAL INSTRUCTIONS 1.5.1 Coordination with Concurrent Contract 1.6 PUMPING OF BILGES 1.7 HISTORICAL PERIOD SHIPWRECK SITES 1.8 UTILITY CROSSINGS 1.8.1 General 1.9 PERMITS 1.10 FUEL OIL TRANSFER OPERATIONS 1.11 SIGNAL LIGHTS 1.12 NOTICE TO MARINERS -- DREDGING CONTRACTS 1.13 FINAL CLEANUP 1.14 WORK VIOLATIONS 1.15 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SYSTEM (HOPPER DREDGES AND DUMP SCOWS) 1.15.1 System Requirements

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 NOTIFICATION OF COAST GUARD 3.1.1 Navigation Aids 3.1.2 Dredging Aids 3.2 WORK AREA 3.2.1 Access 3.2.2 Protection of Existing Waterways 3.2.3 Adjacent Property and Structures 3.2.4 Subaqueous Cable Crossings 3.3 DISPOSAL OF EXCAVATED MATERIAL 3.3.1 General 3.3.2 Upland Disposal Area 3.3.2.1 Material Placement 3.3.2.2 Maximum Height of Dredged Materials 3.3.2.3 Disposal Area Drainage 3.3.2.4 Existing Weirs 3.3.2.5 Existing Outfall Pipes 3.3.3 Barges

W912EP-17-B-0003 SECTION 35 20 23 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.3.4 Placing of Dredged Material 3.3.5 Dredge Pipelines 3.3.5.1 Dredge Discharge Pipeline 3.3.5.2 Submerged Pipeline 3.3.5.3 Floating Pipeline 3.3.6 Booster Pumps 3.3.7 Misplaced Materials 3.4 REQUIRED DEPTH, ALLOWABLE OVERDEPTH, AND SIDE SLOPES 3.4.1 Required Depth 3.4.2 Allowable Overdepth 3.4.3 Side Slopes 3.4.4 Excessive Dredging 3.4.5 Areas to be Dredged 3.4.6 Acceptance Sections 3.5 SURVEYS 3.5.1 General 3.5.2 Contractor Representative 3.5.3 Tide Data 3.5.3.1 Real Time Kinematic (RTK) GPS 3.5.3.2 Kinematic Tidal Datum 3.6 INSPECTION 3.6.1 Quality Assurance Representative (QAR) 3.6.2 Failure to Comply 3.7 FINAL EXAMINATION AND ACCEPTANCE 3.7.1 Final Examination of Work 3.7.2 Bed Leveling 3.7.3 Bed Leveling - Reporting and Documenting 3.7.4 Final Acceptance 3.8 SHOALING 3.9 CONTINUITY OF WORK 3.10 NOISE CONTROL 3.11 DREDGE CERTIFICATION 3.12 GENERAL DREDGING SAFETY REQUIREMENTS 3.12.1 Certification of Attendant and Auxiliary Plant 3.12.2 Minimum Tow-Boat Requirements 3.13 CONSTRUCTION FORMS AND DETAILS

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 35 20 23 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 35 20 23

DREDGING

PART 1 GENERAL

1.1 SCOPE

The work covered by this section consists of furnishing all labor, materials, and equipment, and performing all excavation and disposal of all material as specified herein or indicated on the drawings. This scope also includes all necessary measures for protection of the environment. Environmental protection requirements under this contract are as important to overall completion of the work as other technical aspects. Failure to meet the requirements of these specifications for environmental protection may result in work stoppages or termination for default. No part of the time lost due to any such work stoppages shall be made the subject of claims for extensions of time or for excess costs or damages by the Contractor. If the Contractor fails or refuses to promptly repair any damage caused by violation of the provisions of these specifications, the Contracting Officer may have the necessary work performed and charge the cost thereof to the Contractor.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 Safety and Health Requirements Manual

EM 1110-1-1000 (1993) Photogrammetric Mapping

EM 1110-1-1002 (1990) Survey Markers and Monumentation

EM 1110-1-1003 (1996) NAVSTAR Global Positioning System Surveying

EM 1110-1-1004 (1994) Deformation Monitoring and Control Surveying

EM 1110-1-2909 (1998; Chg 2) Geospatial Data and Systems

EM 1110-2-1003 (2013) Engineering and Design, Hydrographic Surveying

FLORIDA BOARD OF PROFESSIONAL SURVEYORS AND MAPPERS (FBPSM)

FBPSM Minimum Technical Standards, Chapters 177, 472, 61G17

W912EP-17-B-0003 SECTION 35 20 23 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

TRI-SERVICE STANDARDS (TSS)

TSS (2006) A/E/C CADD Standards

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Notice of Intent to Dredge

Prior to commencement of work on this contract, the Contractor shall notify the Commander, Seventh Coast Guard District of his intended operations to dredge and request that it be published in the Local Notice to Mariners. This notification must be given in sufficient time so that it appears in the Notice to Mariners at least two weeks prior to the commencement of this dredging operation. A copy of the notification shall be provided to the Contracting Officer.

Relocation of Navigation Aids

The Contractor shall not remove, change the location of, obstruct, willfully damage, make fast to, or interfere with any aid to navigation. Within 7 calendar days following receipt of Notice of Award, the Contractor shall notify the Commander, Seventh Coast Guard District, Miami, Florida, of his plan to dredge adjacent to any aids which require relocation to facilitate dredging. The notification shall be sent via Fax to 305-415-6757, ATTN: Mr. Gene Stratten. This notification shall be immediately followed by a formal written request with a copy to the Contracting Officer. The Contractor shall also contact the U.S. Coast Guard, 305-415-6750, for information concerning the position to which the aids will be relocated.

Dredge Pumpout Capacity

Prior to commencement of work on this contract, the Contractor shall submit to the Contracting Officer their expected maximum pump out rate in CFS and expected maximum daily dischared volume (CF) of the slurry mixture into DMPF 3D.

SD-02 Shop Drawings

Drag Bar; G, RO

Submit drawings and one photograph showing drag bar equipment used for final leveling work indicated in the paragraph FINAL EXAMINATION AND ACCEPTANCE below.

Acceptance Sections Plan; G, RO

Submit an acceptance sections plan for approval by the Government prior to commencement of work. See subparagraph

W912EP-17-B-0003 SECTION 35 20 23 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

"Acceptance Sections" in paragraph REQUIRED DEPTH, ALLOWABLE OVERDEPTH, AND SIDE SLOPES below.

SD-07 Certificates

Historical Period Shipwreck Sites

The Contractor shall immediately notify the Contracting Officer if any shipwreck, artifact, or other objects of antiquity that have scientific or historical value, or are of interest to the public, are discovered, located, and/or recovered.

Surveys

The Contractor shall give 10 days advance notice, in writing, to the Contracting Officer of the need for a pre-dredging survey or after-dredging survey for final acceptance for each acceptance section.

Daily/Monthly Report of Operations

The Contractor shall prepare on RMS and submit one (1) hard copy of the Daily Report of Operations, using either ENG Form No. 27A or ENG Form No. 4267, for each dredge and/or unloader working. This report shall be submitted on a daily basis and not in groups (groups = multi-days reports packaged together at one time). In addition to the daily report, the Contractor shall prepare a Monthly Report of Operations for each month or partial month's work on either ENG Form No. 27A or ENG Form No. 4267. The monthly report shall be submitted on or before the 7th of each month, consolidating the previous month's work. Upon completion of the job, the Contractor shall submit a consolidated job report, combining the monthly reports. The Contractor shall distribute one copy of each report to the District Engineer; ATTN: CESAJ-EN-C; U.S. Army Engineer District, Jacksonville, P.O. Box 4970; Jacksonville, Florida 32232-0019. Reports shall be submitted on a monthly basis with daily reports accompanying the monthly report and job report.

Additionally, one copy of the form(s) shall be maintained by the Contractor on the dredge(s) for the Contracting Officer's inspection purpose. Further instructions on the preparation of the reports will be furnished at the Preconstruction Conference.

Misplaced Material

The Contractor shall notify the U.S. Coast Guard Marine Safety Office of any misplaced material as stated in the Clause OBSTRUCTION OF NAVIGABLE WATERWAYS of Section 00700 CONTRACT CLAUSES in Volume 1.

Declaration of Inspection for Refueling

Refer to paragraph FUEL OIL TRANSFER OPERATIONS below for submittal.

W912EP-17-B-0003 SECTION 35 20 23 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.4 DREDGING RESTRICTIONS

1.4.1 Order of Work

There is no specific order of work for this project. The dredging performed by all dredges shall be continuous within reaches approved by the Contracting Officer.

1.4.2 Transportation of Material

Water and dredge material shall not be permitted to overflow or spill out of barges or hopper dredges during transport to the disposal site.

1.5 SPECIAL INSTRUCTIONS

1.5.1 Coordination with Concurrent Contract

Another maintenance dredging contract will begin during the execution of this contract and will also utilize upland disposal site DMPF 3-D. The Contracting Officer will determine the Contractor with the largest volumetric (CF) discharge per day into upland disposal site DMPF 3-D and shall direct this Contractor as having overall management control of DMPF 3-D. The Contracting Officer will direct the Contractor when to start and stop overall management of DMPF 3-D. While having overall management control of DMPF 3-D, the Contractor shall provide routine general inspection of DMPF 3-D for erosion, scour, and damage to the embankments; control the placement of weir riser boards and be solely responsible for meeting turbidity requirements for disposal site DMPF 3-D under this contract. The Contractor shall not hinder or impede the work of "Others" while performing routine general inspection and shall only notify the Contracting Officer or the Contracting Officer's Representative if observations of concern are noted during this routine inspection. At the direction of the Contracting Officer, the Contractor shall coordinate transferring overall management control to "Others" in a manner that does not stop or delay any dredging operations under any contracts associated with disposal into DMPF 3-D during the transition of control. The Contractor transferring overall management control shall provide written documentation at the time of transfer to the Contracting Officer and to "Others" stating that overall management control of Upland Disposal Area DMPF 3-D has been transferred from (Contractor Name) to (Receiving Entity Name) and dated Month, Day, Year & Hour.

1.6 PUMPING OF BILGES

Contractors are warned that pumping oil or bilge water containing oil into navigable waters, or into areas which would permit the oil to flow into such waters, is prohibited by Section 13 of the River and Harbor Act of 1899, approved 3 March 1899 (30 Stat. 1152; 33 U.S.C. 407). Violation of this prohibition is subject to the penalties under the referenced Acts.

1.7 HISTORICAL PERIOD SHIPWRECK SITES

If any shipwreck, artifact, or other objects of antiquity that have scientific or historical value, or are of interest to the public, are discovered, located, and/or recovered, the Contractor acknowledges that:

a. The site(s), articles, or other materials are the property of the State of Florida, with title vested in the Department of State,

W912EP-17-B-0003 SECTION 35 20 23 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Division of Historical Resource; and that,

b. Contractor shall immediately notify the Contracting Officer.

1.8 UTILITY CROSSINGS

1.8.1 General

It is the Contractor's responsibility to investigate the location of all utility crossings. The Contractor shall take precautions against damages which might result from his operations in the vicinity of the utility crossings. If any damage occurs as a result of his operations, the Contractor will be required to suspend dredging until the damage is repaired and approved by the Contracting Officer. Costs of such repairs and downtime of the dredge and attendant plant shall be at the Contractor's expense.

1.9 PERMITS

The Contractor's attention is directed to the Clause PERMITS AND RESPONSIBILITIES of Section 00700 CONTRACT CLAUSES in Volume 1 and the paragraph PERMITS AND AUTHORIZATIONS of Section 01 57 20 ENVIRONMENTAL PROTECTION.

1.10 FUEL OIL TRANSFER OPERATIONS

In accordance with U.S. Coast Guard regulations (33 CFR 156.120), couplings used in fuel oil transfer operations on any vessel with a capacity of 250 or more barrels of oil shall be either a bolted or full-threaded connection; or a quick-connect coupling approved by the Commandant; or an automatic back-pressure shutoff nozzle used to fuel the vessel. An executed fuel oil transfer (Declaration) form signed by the tanker operator shall be submitted to the Contracting Officer for each refueling operation. The U.S. Coast Guard shall also be notified prior to any refueling. A copy of the Declaration of Inspection for Refueling is on the web site indicated in the paragraph CONSTRUCTION FORMS AND DETAILS below.

1.11 SIGNAL LIGHTS

The Contractor shall display signal lights and conduct operations in accordance with the General Regulations of the Department of the Army and of the Coast Guard governing lights and day signals to be displayed by towing vessels with tows on which no signals can be displayed, vessels working on wrecks, dredges, and vessels engaged in laying cables or pipe or in submarine or bank protection operations, lights to be displayed on dredge pipe lines, and day signals to be displayed by vessels of more than 65 feet in length moored or anchored in a fairway or channel, and the passing by other vessels of floating plant working in navigable channels, as set forth in Commandant U.S. Coast Guard Instruction M16672.2, Navigation Rules: International-Inland (COMDTINST M16672.2), or 33 CFR 81 Appendix A (International) and 33 CFR 84 through 33 CFR 89 (Inland) as applicable.

1.12 NOTICE TO MARINERS -- DREDGING CONTRACTS

Should the Contractor, during operations, encounter any objects on the channel bottom which could be a hazard to navigation, the Contractor shall immediately notify the Contracting Officer as to the location of said

W912EP-17-B-0003 SECTION 35 20 23 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

object and shall provide any other pertinent information necessary for the Contracting Officer to prepare and issue a Notice to Mariners.

1.13 FINAL CLEANUP

Final cleanup, as stated in the paragraph COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK of Section 00700 CONTRACT CLAUSES in Volume 1, shall include the removal of all the Contractor's plant and equipment either for disposal or reuse. Plant and/or equipment and/or materials to be disposed of shall only be disposed in a manner and at locations approved by the Contracting Officer. Unless otherwise approved by the Contracting Officer, the Contractor will not be permitted to abandon any equipment in the disposal area or other areas adjacent to the worksite. Failure to promptly remove all plant, pipeline, equipment, and materials upon completion of the dredging will be considered a delay in the completion of the final cleanup and demobilization work. In such case, the Government will exercise its right as stated in Clause DEFAULT (FIXED-PRICE CONSTRUCTION) of Section 00700 CONTRACT CLAUSES in Volume 1 to remove any plant and/or equipment and/or materials at the Contractor's expense.

1.14 WORK VIOLATIONS

Work done in violation of these specifications or a verbal or written stop order of the Contracting Officer will be considered as unsatisfactory progress for purposes of progress payments in accordance with Clause PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS of Section 00700 CONTRACT CLAUSES in Volume 1.

1.15 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SYSTEM (HOPPER DREDGES AND DUMP SCOWS)

1.15.1 System Requirements

See Section 35 20 26 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SCOW - ULLAGE PROFILE and Section 35 20 28 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM HOPPER DREDGE. However, in the event of NDQMP System failure (not fully operational), the Contractor shall notify the Contracting Officer and continue tracking using ETS (see paragraph "Electronic Tracking System (ETS) for Ocean Disposal Vessels" below) for up to 48 hours until the NDQMP System is fully operational and in use. If, upon NDQMP System failure, the Contractor cannot use ETS or cannot use the NDQMP System within 48 hours of failure, all dredging operations for the vessel shall cease until the NDQMP System is fully operational. Any delays resulting from NDQMP System failure shall be at the Contractor's expense. When required to calculate displacement, the density of water shall be 64.0 pounds per cubic foot or its metric equivalent of 1025 kilograms per cubic meter.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 NOTIFICATION OF COAST GUARD

3.1.1 Navigation Aids

Navigation aids located within or near the areas required to be dredged will be removed, if necessary, by the U.S. Coast Guard in advance of dredging operations. The Contractor shall not remove, change the location

W912EP-17-B-0003 SECTION 35 20 23 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

of, obstruct, willfully damage, make fast to, or interfere with any aid of navigation.

3.1.2 Dredging Aids

The Contractor shall obtain approval from the U.S. Coast Guard for all buoys, dredging aid markers to be placed in the water, and dredging aid markers affixed with a light prior to the installation. Dredging aid markers and lights shall not be colored or placed in a manner that they will obstruct or be confused with navigation aids.

3.2 WORK AREA

The Contractor will be permitted to exclude the public from the work areas in the immediate vicinity of his dredging, transporting, and disposal operations including dredging, transporting, and disposal operations. Enforcement shall be the Contractor's responsibility at no additional cost to the Government. The enforcement shall be coordinated with local enforcement agencies and will be subject to approval of the Contracting Officer.

3.2.1 Access

The Contractor shall be responsible for providing and maintaining access necessary for his equipment and plant to and from the work site, mooring area, and disposal area. The Contractor shall ascertain the environmental conditions which can affect the access such as climate, winds, currents, waves, depths, shoaling, and scouring tendencies.

3.2.2 Protection of Existing Waterways

The Contractor shall conduct his operations in such a manner that material or other debris are not pushed outside of dredging limits or otherwise deposited in existing side channels, basins, docking areas, or other areas being utilized by vessels. The Contractor will be required to change his method of operations as may be required to comply with the above requirements. Should any bottom material or other debris be pushed into areas described above, as a result of the Contractor's operations, the same must be promptly removed by and at the expense of the Contractor to the satisfaction of the Contracting Officer.

3.2.3 Adjacent Property and Structures

Any damage to private or public property or structures resulting from the disposal or dredging operations shall be repaired promptly by the Contractor at his expense. Any damage to structures as a result of Contractor's negligence will result in suspension of dredging and require prompt repair at the Contractor's expense as a prerequisite to the resumption of dredging.

3.2.4 Subaqueous Cable Crossings

The Contractor shall be responsible for verifying the locations and depths of all utility crossings and take precautions against damages which might result from his operations, especially the sinking of dredge spuds and/or anchors into the channel bottom, in the vicinity of utility crossings. If any damage occurs as a result of his operations, the Contractor will be required to suspend dredging until the damage is repaired and approved by the Contracting Officer. Costs of such repairs and downtime of the dredge

W912EP-17-B-0003 SECTION 35 20 23 Page 9 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

and attendant plant shall be at the Contractor's expense.

3.3 DISPOSAL OF EXCAVATED MATERIAL

3.3.1 General

Material excavated from Manatee Harbor shall be transported and deposited in the upland disposal area designated on the drawings. The average distance to which the material will have to be transported is approximately 1.7 nautical miles and the maximum distance will be approximately 2.0 nautical miles. Material excavated from Alafia River Channel shall be transported to and deposited in disposal area DMPF 3-D (Dredge Material Placement Facility). The average distance to which the material will have to be transported is approximately 1.7 nautical miles and the maximum distance will be approximately 3.2 nautical miles.

3.3.2 Upland Disposal Area

3.3.2.1 Material Placement

Dredged material shall be placed in the disposal area at a maximum distance from the weirs to insure sufficient settling time so that the effluent will meet the turbidity requirements specified in Section 01 57 25 TURBIDITY AND DISPOSAL MONITORING. The dredged material shall be placed in the disposal area in such a manner as to not scour out or damage the crown and side slopes of the existing dikes. Damage to dikes or scouring of the crown and side slopes shall be repaired by the Contractor to their original pre-award condition at no additional cost to the Government. The Contractor shall not cut into or modify the upland disposal site dike section for any reason. In the event that the contractor excavates, cuts into, or modifies the upland disposal site dike, the dredging operations shall be immediately suspended and require prompt repair of the dike as a prerequisite to the resumption of dredging.

3.3.2.2 Maximum Height of Dredged Materials

Dredged Material and/or water in the Manatee Harbor disposal area shall not be placed higher than 2 feet below the lowest point on the dike crest. The Contractor shall use a Florida Licensed Professional Surveyor and Mapper to survey the dike crest in the Manatee Harbor disposal area to determine the location of the lowest point on the dike crest. Dredged materials and/or water in disposal area DMPF 3-D shall not be placed higher than 2.5 feet below the lowest point of the dike crest. The Contractor shall constantly monitor the water height while pumping to insure that this clearance is maintained. Materials deposited in the disposal area above the maximum height or outside the disposal area will result in suspension of dredging operations and require the removal of such materials as a prerequisite to the resumption of dredging.

Drainage of exterior areas adjacent to the diked disposal area shall not be blocked or impaired in any manner by the Contractor's operations. The Contractor shall excavate and maintain ditches necessary to prevent blocking or impairing drainage. The ditches shall be of adequate number and size to eliminate all blockage or impairment of drainage adjacent to the diked disposal area.

3.3.2.3 Disposal Area Drainage

The Contractor shall, if necessary, excavate and maintain ditches to drain

W912EP-17-B-0003 SECTION 35 20 23 Page 10 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

all low areas in the dredged material and disposal area to the weirs. The ditches shall be of adequate number and size to eliminate all ponding of water in the dredged material above the elevation of the weir invert.

3.3.2.4 Existing Weirs

a. The existing weirs shall be operated by the Contractor to control discharge of disposal area effluent during disposal and decanting operations. Riser boards for the weirs are stored on site in a secure location as shown on the drawings. Access to the riser boards will be provided by the Contracting Officer's Representative.

b. The Contractor shall install riser boards in the weirs to a crest elevation which produces an effluent quality meeting the turbidity requirements specified in Section 01 57 25 TURBIDITY AND DISPOSAL MONITORING. The Contractor shall wedge the riser boards in place and seal the end and between-board joints as needed to prevent soil slurry and turbid water from passing through the weirs.

c. Upon completion of disposal operations, all weirs shall be left in place and the Contractor shall adjust the elevations of the crests to provide for complete drainage without ponding of the disposal area for a minimum of 15 days. The elevation adjustment to the weirs shall be the same on all weirs in the disposal area. The weir's riser boards shall be removed one row at a time. The next row of boards shall not be removed until the water level is drawn down to not more than one inch above the weirs' crest. This process shall be continued until the interface with the suspended dredged material is reached. After the interface is reached, the Contractor shall continue to inspect the disposal area until completion of his/her work under this contract, and he/she shall remove another row of boards each time the material has consolidated sufficiently so that it will not flow from the disposal area. The effluent from this final drainage for eliminating ponding shall meet the applicable requirement specified in Section 01 57 20 ENVIRONMENTAL PROTECTION and/or Section 01 57 25 TURBIDITY AND DISPOSAL MONITORING. The Contractor shall provide at least hourly inspection of the weirs during final drainage of the areas and raise the weir boards if necessary to stop the effluent if it does not meet the applicable requirements. This inspection shall be at closer intervals, if necessary, during periods of rain and when the water level is approaching the interface.

3.3.2.5 Existing Outfall Pipes

The Contractor shall ensure that all weirs and outfall pipes are operational for this dredging event. The Contractor shall inspect, clean out and repair outfall pipes for safe operation of the weirs. The contractor shall inspect outfall shoreline stabilization for signs of scour and failure prior to starting dredging operations and upon completion. Repairs shall be made to return the weir systems to their intended function if necessary. The contractor shall inspect these areas during the pre-bid, disposal area site visit, estimate materials and equipment required to complete the work, and include this cost in the lump sum price for the "Mobilization and Demobilization" line item in the Line Items and Pricing Schedule (Section 00010A).

3.3.3 Barges

Water and dredged materials shall not be permitted to overflow or spill

W912EP-17-B-0003 SECTION 35 20 23 Page 11 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

out of barges or dump scows during transport to the disposal site(s). Failure to repair leaks or change the method of operation which is resulting in overflow or spillage will result in suspension of dredging operations and require prompt repair or change of operation to prevent overflow or spillage as a prerequisite to the resumption of dredging.

3.3.4 Placing of Dredged Material

During placement of dredged material in the disposal area, the Contractor will be required to provide constant radio contact between the dredge and the disposal area. This will enable the Contractor's personnel at the disposal area to immediately notify the dredge in the event of dike or pipeline failure. In the event of dike or pipeline failure, the dredging operations shall be immediately suspended and require prompt repair of the dike or pipeline as a prerequisite to the resumption of dredging.

3.3.5 Dredge Pipelines

3.3.5.1 Dredge Discharge Pipeline

The Contractor shall plainly mark the pipeline access routes with conspicuous stakes, targets and/or buoys to be maintained throughout the contract operations. A tight dredge discharge pipeline shall be maintained to prevent spilling of dredged material or dredge water outside of the disposal area. The Contractor shall provide and maintain radio communication between the dredge and the disposal area and the dredge and the Contracting Officer. The Contractor shall coordinate with the COR in the field on the pipeline route over and into DMPF-3D. The pipeline shall be inspected at least twice daily for leaks. Failure to immediately repair leaks in the discharge pipeline will result in suspension of dredging operations and require prompt repair of pipeline as a prerequisite to the resumption of dredging. Any damage to private or public property resulting from the Contractor's operations shall be repaired by the Contractor at his expense.

3.3.5.2 Submerged Pipeline

In the event the Contractor elects to submerge his pipeline, the pipeline shall rest on the bottom, and the top of the submerged pipeline and any anchor securing the submerged pipeline shall be no higher than the required project depth for the channel in which the submerged pipeline is placed. Should the Contractor elect to use a pipeline material which is buoyant or semi-buoyant, such as PVC pipe or similar low density materials, the Contractor shall securely anchor the pipeline to prevent the pipeline from lifting off the bottom under any conditions. The Contractor shall make daily inspections of the submerged pipeline to ensure buoyancy has not loosened the anchors. The Contractor shall remove all anchors when the submerged pipeline is removed. The location of the entire length of submerged pipeline shall be marked with signs, buoys, lights, and flags conforming to U.S. Coast Guard regulations.

3.3.5.3 Floating Pipeline

Should the Contractor's pipeline not rest on the bottom, it will be considered a floating pipeline and shall be visible on the surface and clearly marked. In no case will the Contractor's pipeline be allowed to fluctuate between the surface and the bottom, or lie partly submerged. Lights shall be installed on the floating pipeline as required in paragraph SIGNAL LIGHTS above. The lights shall be supported either by

W912EP-17-B-0003 SECTION 35 20 23 Page 12 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

buoys or by temporary piling, provided by the Contractor and approved by the Contracting Officer. Where the pipeline does not cross a navigable channel, the flashing yellow all-around lights shall be spaced not over 200 feet apart, unless closer spacing is required by U.S. Coast Guard personnel, in which case the requirements of the U.S. Coast Guard shall govern, at no additional cost to the Government.

3.3.6 Booster Pumps

Any booster pumps installed by the Contractor shall be located at least 300 feet from any residential-type building or house. Booster pumps, their prime movers, and any auxiliary equipment shall be fitted or equipped with mufflers, noise control enclosures, or other engineering noise control methods, measures, and features such that steady noise emanating from this equipment does not exceed 85 decibels on the A scale at slow response, and impulsive noise does not exceed 140 decibels. Such items shall be maintained throughout the course of the work.

3.3.7 Misplaced Materials

Materials deposited above the maximum indicated elevation or outside of the disposal area shown will require the removal of such materials at the Contractor's expense.

3.4 REQUIRED DEPTH, ALLOWABLE OVERDEPTH, AND SIDE SLOPES

3.4.1 Required Depth

The material actually removed from the designated areas to be dredged, to a depth of not more than the required depth shown on the drawings, will be estimated and paid for in accordance with the provisions contained in the subparagraphs "Measurement" and "Payment" of Section 01 22 00 MEASUREMENT AND PAYMENT.

3.4.2 Allowable Overdepth

To cover the inaccuracies of the dredging process, material actually removed from the designated areas to be dredged, to a depth below the required depth of not more than the allowable overdepth shown on the drawings, will be measured and paid for in accordance with the provisions contained in the subparagraphs "Measurement" and "Payment" of Section 01 22 00 MEASUREMENT AND PAYMENT.

3.4.3 Side Slopes

Although dredging of side slope material may be necessary to provide the required project channel dimensions (depth and width), the side slopes shown on the drawings are provided for payment purposes only. Side slopes may be formed by box cutting, step cutting, or dredging along the side slope. Material actually removed, within the limits approved by the Contracting Officer, to provide for final side slopes not flatter than that shown on the contract drawings, but not in excess of the amount originally lying above this limiting side slope, will be measured and paid for in accordance with the provisions contained in subparagraphs "Measurement" and "Payment" of Section 01 22 00 MEASUREMENT AND PAYMENT. Such amount will be estimated and paid for whether dredged in original position or by box cut dredging whereby a space is dredged below the allowable side slope plane on the bottom of the slope for upslope material capable of falling into the cut. End slopes and transition slopes will

W912EP-17-B-0003 SECTION 35 20 23 Page 13 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

not be estimated or paid for under this contract. In such cases, a 0 horizontal on 1 vertical will be used with no upslope allowance provision applied outside the required prism.

3.4.4 Excessive Dredging

It is recognized that the limits of dredging need to extend beyond the pay prism in order to remove material from within the pay prism. Therefore, the limits of active dredging may exceed the limits of the pay prism in vertical dimension as well as horizontal dimension to the extent necessary to remove material from the pay prism. Indirect impacts (sideslope sloughing, etc) may extend even beyond the limits of active dredging. Nevertheless, material taken from beyond the limits of the pay prism as described in subparagraphs "Allowable Overdepth" and "Side Slopes" above will be deducted from the total amount dredged as excessive overdepth dredging, or excessive sideslope dredging, for which payment will not be made. Nothing herein shall be construed to prevent payment for the removal of shoals performed in accordance with the applicable provisions of the paragraphs FINAL EXAMINATION AND ACCEPTANCE or SHOALING of this Section.

3.4.5 Areas to be Dredged

Based on information currently available to the Government, areas known to require dredging are depicted on the drawings as shaded areas. The actual areas to be dredged may vary from the shaded areas shown in the drawings. In order to provide the required project dimensions within and throughout the project limits shown on the drawings, the Contractor shall remove material located within the project limits as directed by the Contracting Officer, regardless of whether the material is located in a shaded area or not. Payment for all dredged material dredged from a shaded area will be made at the applicable contract unit price. Payment for all material dredged from a non-shaded area may be made at the applicable contract unit price; however, the Contractor may request an adjustment to the contract unit price in accordance with DFAR Clause 252.243-7002 REQUESTS FOR EQUITABLE ADJUSTMENT and/or FAR Clause 52.243-4 CHANGES of Section 00700 CONTRACT CLAUSES in Volume 1.

3.4.6 Acceptance Sections

For purposes of payment, the work to be done will be divided into acceptance sections. Prior to any dredging, the Contractor shall prepare and provide a proposed acceptance sections plan for approval by the Contracting Officer. Generally, the work should be divided into areas that equate to approximately 30 days of dredging or that constitute separable or definable features of work.

3.5 SURVEYS

3.5.1 General

The Contracting Officer shall be notified, in writing, 10 days in advance of the need for pre-dredging and after-dredging surveys. Surveys will be performed in accordance with the paragraph QUANTITY SURVEYS of Section 00700 CONTRACT CLAUSES in Volume 1; Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR QUALITY CONTROL; EM 1110-1-1000, EM 1110-1-1002, EM 1110-1-1003, EM 1110-1-1004, EM 1110-1-2909, and EM 1110-2-1003; FBPSM; and, TSS. A copy of the EM's can be downloaded from the following web site: http://140.194.76.129/publications/eng-manuals/. A copy of the TSS

W912EP-17-B-0003 SECTION 35 20 23 Page 14 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

can be downloaded from the following web site: https://cadbim.usace.army.mil/.

3.5.2 Contractor Representative

The Contractor or his authorized representative will be notified when soundings and/or sweepings are to be made, and will be offered the opportunity to be on board the Government survey vessel, but may decline the offer. All in-place measurement surveys and final acceptance sweep surveys will be performed by the Government. The Contractor's representative shall be fully knowledgeable in offshore construction subsurface surveying procedures, techniques, equipment, and horizontal and vertical calibration methods, and state-of-the-art horizontal and vertical accuracy limitations. The Contractor's representative may observe and review, in progress, the adequacy and accuracy of the survey for in-place payment purposes, and for the potential existence of collusion, fraud, or obvious error in the data.

3.5.3 Tide Data

3.5.3.1 Real Time Kinematic (RTK) GPS

The government will utilize RTK GPS for determining Real Time water levels (tide corrections) for measurement and payment purposes. The Contractor is responsible for providing all applicable RTK equipment for surveying and dredging operations.

3.5.3.2 Kinematic Tidal Datum

A file listing the separations between NAVD 88 and the Chart Datum (Mean Lower Low Water) will be provided to the Contractor for entry into the hydrographic survey software. The Kinematic Tidal Datum file shall be obtained from the Construction Representative prior to commencing surveying and dredging operations.

3.6 INSPECTION

3.6.1 Quality Assurance Representative (QAR)

The QAR shall be notified prior to the establishment of horizontal control work (baseline layout, ranges, station flags, shore-based control for EPS/RPS, etc.) and vertical control work (tide staff(s), upland cross sections, construction elevations top/invert, maximum/minimum elevations of dredged materials within disposal area(s), etc.), but the presence or absence of the QAR shall not relieve the Contractor of his responsibility for proper execution of the work in accordance with the specifications. The Contractor will be required:

a. To furnish, on the request of the Contracting Officer or any QAR, the use of such boats, boatmen, laborers, and material forming a part of the ordinary and usual equipment and crew of the dredging plant as may be reasonably necessary in inspecting and supervising the work.

b. To furnish, on the request of the Contracting Officer or any QAR, suitable transportation from all points on shore designated by the Contracting Officer to and from the various pieces of plant, and to and from the disposal area.

W912EP-17-B-0003 SECTION 35 20 23 Page 15 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.6.2 Failure to Comply

In conjunction with the Clause INSPECTION OF CONSTRUCTION of Section 00700 CONTRACT CLAUSES of Volume 1, should the Contractor refuse, neglect, or delay compliance with these requirements, the specific facilities may be furnished and maintained by the Contracting Officer and the cost thereof will be deducted from any amounts due or to become due the Contractor.

3.7 FINAL EXAMINATION AND ACCEPTANCE

3.7.1 Final Examination of Work

As soon as practicable and no later than two (2) weeks after the completion of the entire work or any section thereof (if the work is divided into sections) as in the opinion of the Contracting Officer will not be subject to damage by further operations under the contract, such work will be thoroughly examined at the cost and expense of the Government by sounding or by sweeping, or both, as determined by the Contracting Officer. Should any shoals, lumps, or other lack of contract depth be disclosed by this examination, the Contractor will be required to remove same by dragging the bottom in accordance with the subparagraph "Bed Leveling" below or by dredging at the contract rate of dredging.

The Contractor or his authorized representative will be notified when soundings and/or sweepings are to be made and will be permitted to accompany the survey party. When the area is found to be in a satisfactory condition, it will be accepted finally. Should more than two sounding or sweeping operations by the Government over an area be necessary by reason of work for the removal of shoals disclosed at a prior sounding or sweeping, the cost of such third and any subsequent soundings or sweeping operations will be charged against the Contractor at the rate of $5,500 per day for each day in which the Government plant is engaged in sounding or sweeping and/or is enroute to or from the site or held at or near the said site for such operation.

3.7.2 Bed Leveling

Bed leveling by dragging the bottom with a drag bar or other apparatus shall be allowed only in the designated dredging areas shown on the drawings. Dragging in areas outside of the designated dredging areas shown on the drawings is specifically prohibited without written approval of the Contracting Officer.

3.7.3 Bed Leveling - Reporting and Documenting

The contractor shall fully document all bed leveling activity including date and time for initiation and completion of bed leveling. All bed leveling activity shall be documented on the Contractor's Quality Control Report (QCR).

3.7.4 Final Acceptance

Final acceptance of the whole or a part of the work and the deductions or corrections of deductions made thereon will not be reopened after having once been made, except on evidence of collusion, fraud or obvious error, and the acceptance of a completed section shall not change the time of payment of the retained percentages of the whole or any part of the work.

W912EP-17-B-0003 SECTION 35 20 23 Page 16 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.8 SHOALING

If, before the contract is completed, shoaling occurs in any section previously accepted, including shoaling in the finished channel because of the natural lowering of the side slopes, redredging at contract price, within the limits of available funds may be done if agreeable to both the Contractor and the Contracting Officer.

3.9 CONTINUITY OF WORK

No payment will be made for work done in any area designated by the Contracting Officer until the full depth required under the contract is secured in the whole of such area, unless prevented by in-situ rock, nor will payment be made for excavation in any area not adjacent to and in prolongation of areas where full depth has been secured, except by decision of the Contracting Officer. Should any such nonadjacent area be excavated to full depth during the operations carried on under the contract, payment for all work therein may be deferred until the required depth has been made in the area intervening. The Contractor may be required to suspend dredging at any time when, for any reason, the gauges or ranges cannot be seen or properly followed.

3.10 NOISE CONTROL

All equipment and dredge/barges, boats, and tugs used on this work shall be equipped with satisfactory mufflers or other noise abatement devices. The Contractor shall conduct his operations so as to comply with all Federal, State and local laws pertaining to noise. The use of horns and whistle signals shall be held to the minimum necessary in order to ensure as quiet an operation as possible.

3.11 DREDGE CERTIFICATION

During dredging operations the Contractor's dredge shall have a current marine survey inspection certificate for the dredge to be used. The certification shall have been issued by a licensed and accredited marine surveyor within the previous 12 months. The marine surveyor must be accredited by either the National Association of Marine Surveyors or the Society of Accredited Marine Surveyors. The certifications and inspection shall be appropriate for the intended use of the plant in all locations specified in this contract.

3.12 GENERAL DREDGING SAFETY REQUIREMENTS

3.12.1 Certification of Attendant and Auxiliary Plant

In addition to the requirements of EM 385-1-1, Section 19, Subparagraph 19.A.01.b., all supporting floating plant for dredging operations (to include, but not limited to, anchor barges, deck barges, deck/work barges, tug boats, tenders, workboats, pump-out barges, derrick barges, and spider barges) shall have a current marine survey inspection certificate. The only exceptions to this requirement include pipeline support pontoons or floats and outboard skiffs under 16 feet in length. The certification shall have been issued by a licensed and accredited marine surveyor within the previous 12 months. The marine surveyor must be accredited by either the National Association of Marine Surveyors or the Society of Accredited Marine Surveyors. No attendant plant that does not have a valid certification shall be used on this contract. The certifications and inspection shall be appropriate for the intended use of the plant in all

W912EP-17-B-0003 SECTION 35 20 23 Page 17 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

locations specified in this contract. Unless the Contracting Officer decides otherwise, documentation of the inspection for each piece of plant shall be provided prior to issuance of Notice to Proceed.

3.12.2 Minimum Tow-Boat Requirements

In addition to the requirements of EM 385-1-1, Section 19, Subparagraph 19.A.03.e., when dredging with non-self propelled dredges seaward of the CRL-L or CRL-C, the contractor shall provide the following.

a. One primary towboat of adequate size and horsepower to move any and all attendendant and support plant against prevailing tides, currents, and winds during normal and severe weather conditions. The towboat shall be available within the project work area at all times.

b. A towboat(s) of adequate size and horsepower to move the dredge(s) against prevailing tides, currents, and winds during normal and severe weather conditions shall be able to mobilize to the work site, and move the dredge(s) to safe harbor with 4 to 6 hours of first notification.

3.13 CONSTRUCTION FORMS AND DETAILS

See the "Construction Forms & Details" module at the following web address: http://www.saj.usace.army.mil/About/DivisionsOffices/Engineering/DesignBranch /SpecificationsSection.aspx.

-- End of Section --

W912EP-17-B-0003 SECTION 35 20 23 Page 18 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

SECTION 35 20 26

NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SCOW - ULLAGE PROFILE

PART 1 GENERAL

1.1 DESCRIPTION 1.2 SUBMITTALS 1.3 PAYMENT 1.4 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM CERTIFICATION 1.5 DREDGE PLANT INSTRUMENTATION PLAN (DPIP)

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 SPECIFICATIONS FOR REPORTED DATA 3.1.1 Scow Name 3.1.2 Contract Number 3.1.3 Trip Number 3.1.3.1 Open Water Disposal 3.1.3.2 Offloading 3.1.3.3 Project Trip Number 3.1.4 Horizontal Positioning 3.1.5 Date and Time 3.1.6 Hull Status 3.1.6.1 Open Water Disposal 3.1.6.2 Offloading 3.1.7 Course 3.1.8 Speed 3.1.9 Heading 3.1.10 Draft 3.1.11 Displacement 3.1.12 Bin Ullage Sounding 3.1.13 Bin Volume 3.2 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SYSTEM REQUIREMENTS 3.2.1 Telemetry 3.2.2 Data Reporting Frequency 3.2.3 Data Transmission to Web Service 3.2.4 XML-Formatted Sensor Data String 3.2.5 Contractor Data Backup 3.3 PERFORMANCE REQUIREMENTS 3.4 COMPLIANCE QUALITY ASSURANCE CHECKS 3.4.1 Position Check 3.4.2 Hull Status Check 3.4.3 Draft & Displacement Check 3.4.4 Bin Ullage Sounding & Volume Check 3.5 CONTRACTOR QUALITY CONTROL 3.6 LIST OF ITEMS PROVIDED BY THE CONTRACTOR

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 35 20 26 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

W912EP-17-B-0003 SECTION 35 20 26 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 35 20 26

NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SCOW - ULLAGE PROFILE

PART 1 GENERAL

1.1 DESCRIPTION

The work under this contract requires use of the National Dredging Quality Management Program (DQM) to monitor the scow's status at all times during the contract, and manage data history.

This performance-based specification section identifies the minimum required output and precision and instrumentation requirements. The requirements may be satisfied using equipment and technical procedures selected by the Contractor.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office responsible for review of the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00, "SUBMITTAL PROCEDURES":

SD-01 Preconstruction Submittals

Dredge Plant Instrumentation Plan; G, SAM-OP-J

Contractor Quality Control Plan; G, RO

SD-06 Test Reports

Data Appropriately Archived e-mail; G, RO

SD-07 Certificates

Letter of National Dredging Quality Management Program Certification; G, RO

1.3 PAYMENT

No separate payment will be made for installation, operation and maintenance for the DQM certified system as specified herein for the duration of the dredging operations; all costs in connection therewith will be considered a subsidiary obligation of the Contractor and covered under the contract unit prices for dredging in the bidding schedule.

W912EP-17-B-0003 SECTION 35 20 26 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.4 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM CERTIFICATION

The Contractor is required to have a current certification from the DQM for the scow instrumentation system to be used under this contract. Criteria for certification shall be based on the most recent specification posted on the DQM website (http://dqm.usace.army.mil/Specifications/Index.aspx), Compliance with these criteria shall be verified by on-site quality assurance (QA) checks conducted by DQM Support Center Data Acquisition and Analysis Team, and by periodic review of the transmitted data. If a system is installed specifically for this contract, the QA checks should take place prior to any material being loaded into the scow to insure that it is capable of transmitting quality data to the DQM database or with prior approval of local district, during the first load for each scow, and subsequent loads as is necessary to verify compliance. A DQM Certification is valid for one year from the date of certification and is contingent upon the system's ability to meet the performance requirements as outlined in sections 3.3 and 3.5. If issues with data quality are not corrected within 48 hours, the system certification shall be revoked and additional QA checks by the Data Acquisition Team may be necessary.

Annual DQM Certification shall be based on:

A series of QA checks as described in section 3.4 "Compliance Quality Assurance Checks'

Verification of data acquisition and transfer (Section 3.3)

Review of the Dredge Plant Instrumentation Plan (DPIP) as described in Section 1.5

The dredging contractor shall have personnel who are familiar with the system instrumentation and who have the ability to recalibrate the sensors on site during the QA process. The dredging contractor shall coordinate pickup times and locations and provide transportation to and from any platform with a DQM system to team personnel in a timely manner. The dredging contractor shall also have on site for the QA checks a tug capable of towing the scow. As a general rule, Data Acquisition and Analysis Team personnel will come with PPE consisting of hardhats, steel toe boots, and life jackets. If additional safety equipment is needed, such as eye protection, safety harnesses, work gloves or personal location beacons, these items shall be provided to the team while on site. The Contractor shall submit a test data package to the DQM Database from the system on each scow and have it accepted by the DQM Support Center prior to scow compliance checks. The Contractor shall also submit data collected during the QA Checks from the scow monitoring system to the DQM database and the Data Acquisition Team personnel while on site. It is the dredging contractor's obligation to inform the QA team if the location designated for the QA checks has any site specific safety concerns prior to their arrival on site.

The owner or operator of the scow shall contact DQM at [email protected] on an annual basis, or at least three weeks prior to the proposed beginning of dredging, to schedule QA checks. This notification is meant to make the Data Acquisition Team aware of a target date and the contract on which the plant will be used. At least one week prior to the target date, the dredging contractor shall contact the Data Acquisition team and verbally coordinate a specific date and location. The contractor shall then follow-up this conversation with a written e-mail

W912EP-17-B-0003 SECTION 35 20 26 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

confirmation. The owner/operator shall coordinate the QA checks with all local authorities, including but not limited to, the local USACE contracting officer.

Re-certification is required for any yard work which produces modification to displacement (i.e. change in scow lines, repositioning or repainting hull marks), modification to bin volume (change in bin dimensions or addition or subtraction of structure) or changes in sensor type or location; these changes shall be reported in the sensor log section of the DPIP A system does not have to be transmitting data between jobs, however in order to retain certification during this period, the system sensors or hardware should not be disconnected or removed from the scow. If the system is powered down, calibration coefficients shall be retained.

1.5 DREDGE PLANT INSTRUMENTATION PLAN (DPIP)

The Contractor shall have a digital copy of the DPIP on file with the National DQM Support Center. The Contractor shall also maintain a copy of the DPIP on a working dredge on site which is easily accessible to government personnel at all times. This document shall describe the sensors used, configuration of the system, how sensor data will be collected, how quality control on the data will be performed, and how sensors/data reporting equipment will be calibrated and repaired if they fail. A description of computed scow specific data and how the sensor data will be transmitted to the DQM Database shall also be included. The Contractor shall submit to the DQM Support Center any addendum or modifications made to the plan, subsequent to its original submission, prior to start of work.

The DPIP shall include the following as a minimum: (DPIP must have table of content in the following order)

- Dredging Company -- Scow Point of Contact -- Telephone Number -- Email address

- Scow Monitoring System Provider -- Scow Monitoring System Point of Contact -- Telephone Number -- Email address

- Scow Name/ID

- Sensor repair, replacement, installation, modification or calibration methods

- Data reporting equipment

- Procedure for providing sensor data/computed data to DQM Database via e-mail

- System Power Supply

- System Battery Charge Method

- Documentation on how the contract number will be changed if the system is left on past the end of the contract

W912EP-17-B-0003 SECTION 35 20 26 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

- System telemetry

- Dimensioned Drawings of the Scow -- A typical plan and profile view of the scow showing: -- Bin cross sections -- Locations of required sensors referenced to: -- fore and aft perpendicular -- bin length, depth, width, zero reference -- external hull draft markings (latitudinal, longitudinal, keel) -- each other -- overall scow dimensions

- Criteria and method used to increment trip number

- Description of how the UTC time stamp is collected

- Positioning system -- brand name and specifications -- sampling rates for data acquisition (standard vs. disposal) -- scow heading instrumentation brand name and specifications -- instrument used to calculate -- any calculation done external to the instrumentation -- certificates of calibration and/or manufacturer certificates of compliance -- A description of how scow speed is determined

- Hull status -- Instrumentation brand name and specifications -- Certificates of calibration and/or manufacturer certificates of compliance -- Any calculation done external to the instrumentation -- Criteria for determining hull open/closed

- Heading -- Instrumentation brand name and specifications -- Certificates of calibration and/or manufacturer certificates of compliance -- Any calculation done external to the instrumentation -- Criteria for determining heading

- Drafts -- Instrumentation brand name and specifications -- Certificates of calibration and/or manufacturer certificates of compliance -- Any calculation done external to the instrumentation -- Criteria used to determine draft

- Displacement -- Method used by Contractor to calculate displacement based on fore and aft draft -- Tables listing (fresh and salt water) displacement as a function of draft provided by a licensed marine surveyor/ naval architect independent of the contractor. The scaling between each interval in the table is determined by the designer of the table (which is determined by the shape of the scow), however units shall be reported, at a minimum, in ft and tenths of ft for draft and long tons for displacement. -- These methods and tables must be an accurate reflection of

W912EP-17-B-0003 SECTION 35 20 26 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

the current configuration and displacement

- Bin Ullage Sounding -- Sensor brand name and specifications -- Certificates of calibration and/or manufacturer certificates of compliance -- Any calculation done external to the instrumentation -- Criteria used to determine ullage soundings

- Volume -- Method used by Contractor to calculate bin volume based on fore and aft bin ullage -- Table which lists the bin volume as a function of bin ullage soundings provided by a licensed marine surveyor/ naval architect independent of the Contractor. The scaling between each interval in the table is determined by the designer of the table (which is determined by the shape of the bin(s)), however units shall be reported in ft and tenths of ft for ullage and cubic yards for volume. -- These methods and tables must be an accurate reflection of the current configuration and volume

- Contractor Data -- Backup frequency -- Backup method -- Post processing

- Archive capability

- Documentation of: -- test methods used by the Contractor to provide quality control of data -- verification that the reported values are applicable for the sensor and application

- Quality Control Plan as per section 3.5 -- Name of Quality Control Systems Manager -- Procedures for checking collected data against known values -- Procedures for verifying telemetry is functioning

- Log of sensor performance and modifications

- Log of Contractor data backup as per section 3.2.6

Any changes to the computation methods during the contract shall be approved by the DQM Support Center prior to their implementation.

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 SPECIFICATIONS FOR REPORTED DATA

The Contractor shall provide, operate and maintain all hardware and software to meet these specifications. The Contractor shall be responsible for replacement, repair and calibration of sensors and other necessary data acquisition equipment needed to supply the required data.

Repairs shall be completed within 48 hours of any sensor failure. Upon

W912EP-17-B-0003 SECTION 35 20 26 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

completion of a repair, replacement, installation, modification or calibration the Contractor shall notify the Contracting Office's Representative (COR). The COR may request re-calibration of sensors or other hardware components at any time during the contract as deemed necessary.

The Contractor shall keep a log of sensor repair, replacement, installation, modification and calibration in the on-site copy of the DPIP. The log shall contain a three-year history of sensor maintenance to include: the time of sensor failures (and subsequent repairs), the time and results of sensor calibrations, the time of sensor replacements, and the time that backup sensor systems are initiated to provide required data. It shall also contain the name of the person responsible for the sensor work.

Sensors installed shall be capable of collecting parameters within specified accuracies and resolutions indicated in the following subsections and transmit them to the DQM Database.

With the exception of position and any value calculated, reported sensor values should represent a weighted average with the highest and lowest values not included in the calculated average for the given interval. The averaging routine used should be consistent across all event triggers. This information should be documented in the DPIP sections that say "Calculations done external to the instrumentation".

These data reporting requirements cover the collection of electronic data on a scow through the entire dredging cycle. Disposal events can consist of both open water disposal and offloading. Open water disposal is the placement of material via bottom doors or split hull. Offloading is the placement of material via either hydraulic or mechanical means.

3.1.1 Scow Name

Each scow shall be assigned a unique name that will remain constant from one dredging operation to the next.

3.1.2 Contract Number

The USACE Assigned contract number for the project will be reported.

3.1.3 Trip Number

A DQM trip number shall document the end of a disposal event for a given scow.

3.1.3.1 Open Water Disposal

The trip number will be incremented at the completion of each disposal/removal of material from the scow. Each scow shall maintain a separate trip numbering sequence - i.e. each scow will start with a trip number of 1, that will be incremented by 1 each time that scow completes a disposal. The trip number must be calculated and repeatable based on a given logic; it may not necessarily correspond to the trip number logged aboard the dredge or tug. Efforts shall be made to include logic that avoids false trip number increments, while also not allowing the routine to miss any disposal events.

W912EP-17-B-0003 SECTION 35 20 26 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.1.3.2 Offloading

The trip number will be incremented at the completion of each disposal/removal of material from the scow. Each scow shall maintain a separate trip numbering sequence - i.e. each scow will start with a trip number of 1, that will be incremented by 1 each time that scow completes a disposal. The trip number must be calculated and repeatable based on a given logic; it may not necessarily correspond to the trip number logged aboard the dredge or tug. Efforts shall be made to include logic that avoids false trip number increments, while also not allowing the routine to miss any disposal events.

3.1.3.3 Project Trip Number

A project trip number is not unique to a particular dredge plant, but is unique to a contract. Like a scow trip number the project trip number shall document the end of a disposal event. Project trip numbering will begin at number 1 at the start of the contract, and will be incremented by 1 at the completion of each disposal event or emptying of the dredge material. The trip number must be calculated and repeatable based on a given logic. Efforts shall be made to include logic that avoids false trip number increments, while also not allowing the routine to miss any disposal events.

3.1.4 Horizontal Positioning

Geographic coordinates of the vessel as indicated by the location of the GPS antenna. All locations shall be obtained using a Positioning System operating with a minimum accuracy level of 1 to 3 meters horizontal Circular Error Probable (CEP). Positions shall be reported as Latitude/Longitude WGS 84 in decimal degrees. West Longitude and South Latitude values are reported as negative.

3.1.5 Date and Time

The date and time shall be reported to the nearest second and referenced to UTC time based on a 24 hour format; yyyy-mm-dd hh:mm:ss.

3.1.6 Hull Status

Hull status is meant to reflect a condition when material could be removed or released from the scow. For this contract, hull status shall register closed prior to leaving the disposal area.

3.1.6.1 Open Water Disposal

An open split hull or open bottom door shall be indicated by reporting an "OPEN" value. A closed split hull or closed bottom door of a scow shall be indicated by reporting an "CLOSED" value. Open status shall be indicated as the bin starts to open and a closed status shall be indicated only once the bin is fully closed. For pocket scows, the Open/Closed status shall correspond to the compartment which is first to open and last to close.

3.1.6.2 Offloading

For non-dumping scows, the "OPEN" value shall indicate that the bin is in the process of being unloaded, either by pumping or mechanical means.

W912EP-17-B-0003 SECTION 35 20 26 Page 9 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.1.7 Course

Scow course-over-ground (COG)shall be provided using industry standard equipment. The Contractor shall provide scow course over ground (to the nearest whole degree) with values from 000 (true north) to 359 degrees referenced to a clockwise positive direction convention.

3.1.8 Speed

Scow speed-over-ground shall be provided in knots using industry standard equipment with a minimum accuracy of 1.0 knots and resolution to the nearest 0.1 knot.

3.1.9 Heading

Scow heading shall be provided using industry standard equipment. The scow heading shall be accurate to within 5 degrees and reported to the nearest whole degree, with values from 000 (true north) to 359 degrees referenced to a clockwise positive direction convention.

3.1.10 Draft

All reported draft measurements shall be in feet, tenths and hundredths with an accuracy of + 0.1 foot relative to observed physical draft readings. The measurements shall be reported at a resolution of two decimal places (hundredths of a foot). Reported forward draft value shall be equal to the sum of the visual forward port and starboard draft mark readings divided by 2. Reported aft draft value shall be equal to the sum of the visual aft port and starboard draft mark readings divided by 2.Forward draft, aft draft and average draft will be reported. Sensors shall be placed at an optimum location on the scow to be reflective of observed physical draft mark readings at any trim or list. The sensor value reported shall be an average of at least 10 samples per event, remove at least one maximum value and one minimum value, and average the minimum 8 remaining values. When average draft is calculated for the purpose of determining displacement, significant digits for average draft shall be maintained such that if forward draft was 0.15 and aft draft was 0.1 then the average draft would be 0.125.

3.1.11 Displacement

Scow displacement shall be reported in long tons, based on the most accurate method available for the scow. The minimum standard of accuracy for displacement is interpolation from the displacement table, based on the average draft. For this contract the density of water used to calculate displacement shall be 64.0 pounds per cubic foot or its metric equivalent of 1025 kilograms per cubic meter and shall be used for an additional interpolation between the fresh and salt water tables.

3.1.12 Bin Ullage Sounding

All reported ullage soundings shall be in feet, tenths and hundredths with an accuracy of + 0.1 foot with respect to the combing, and be representative of the forward and aft extents of the hopper as close to centerline as is possible. The measurements shall be reported at a resolution of two decimal places (hundredths of a foot). If sensors must be offset from centerline of the bin they should be offset to opposite sides of the vessel. Forward ullage, aft ullage and average ullage soundings will be reported. The sensor value reported shall be an average

W912EP-17-B-0003 SECTION 35 20 26 Page 10 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

of at least 10 samples per event, remove at least one maximum value and one minimum value, and average the minimum 8 remaining values. When average ullage is calculated for the purpose of determining hopper volume, significant digits for average ullage shall be maintained such that if forward ullage was 0.15 and aft ullage was 0.1 then the average ullage would be 0.125. Special arrangements for pocket scows may be made in consultation with the DQM support center.

3.1.13 Bin Volume

Scow bin volume shall be reported in cubic yards, based on the most accurate method available for the scow. The minimum standard of accuracy for bin volume is interpolation from the bin volume table, based on the average ullage soundings.

3.2 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SYSTEM REQUIREMENTS

Contractors DQM system shall be capable of collecting, displaying, and transmitting information to the DQM Database. The parameters which shall be reported to the DQM Database include: trip number, date and time, hull status, scow course, scow speed, scow heading, draft, displacement, ullage, and bin volume. An easily accessible, permanent visual display on the scow shall show in real time the parameters collected by the system in the same units as data submitted to the DQM database. In the event a reported parameter is calculated based on multiple sensors, the sensor values as used in the equation shall be able to be viewed in addition to the required parameter. If a hardware problem occurs, or if a part of the system is physically damaged, then the Contractor shall be responsible for repairing it within 48 hours of determination of the condition.

3.2.1 Telemetry

The Contractor may select any commercial satellite, cellular phone, or other data communications systems available, as long as it is capable of transmitting real time data, as well as enough additional band width to clear historically queued data when a connection is re-obtained. The telemetry system shall be always available and have connectivity in contract area at least 12 out of 24 hours -OR- at least 20 out of 24 hours -OR- at least 1 out of every 2 hours -OR - at least once every 24 hours, capable of transmitting all queued data. Telemetry systems must be capable of meeting these minimum reporting requirements in all operating conditions. The data transition process from the scow to the DQM database must be automated. The data may be sent from the scow directly to the DQM database or to a shore based computer. Data transmitted to the DQM Database should be raw data; any processing of the data conducted shore side shall be done using repeatable automated software or programming routine. A description of this process shall be included in the DPIP.

3.2.2 Data Reporting Frequency

Disposal activities shall be logged with high temporal and spatial resolution. Data shall be logged as a series of events. Each set of measurements (i.e. time, position, etc…) will be considered an event. All required information in section 3.1 that are not an averaged variable (i.e. draft and ullage) shall be collected within one second of reported time. Data shall be measured with sufficient frequency by the scow system to resolve the events to the accuracy specified in the following table. Any averaged variable must be collected and computed within this sampling interval. Event Types "", "Loading/Stationary" and "Offloading" and

W912EP-17-B-0003 SECTION 35 20 26 Page 11 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

"Open Water Disposal" are triggered by a time criteria; the criteria should be consistent across the "Sailing" and "Open Water Disposal" event types and should not change for the data collected on a given scow. This criterion should be documented by the contractor in the DPIP.

Event Event Event Time Position Type Event Trigger Descriptions Resolution Resolution Loading/ No change in position with hull status closed 1 minute NA Stationary An elapsed time of 1 hour since the last event No change in position with hull status open ------NONCLOSURE------In the event a scow has completed an open water disposal and transited back to a holding station without closing the hull, the sampling shall be changed to once per hour

Sailing Change in position with hull status closed 1 second +/-10 ft Time from the last sample equals 1 minutes

Open Hull status open 1 second +/-10 ft Water A position must be recorded within 1 second of Disposal the hull status going from closed to open and again within 1 second of the hull status going from open to closed The position shall be reported at any equal interval from 6 to 12 seconds. This interval shall always remain consistent for the dredge plant.

Offloading Offloading material, hull status reported as 1 second +/-10 ft open A position must be recorded within 1 minute arrival at the offload location and within one second of the material starting to be removed from scow. Time from the last sample equals 1 minute. ------STANDBY OFFLOADING----- In the event a scow is not being actively 1 minute offloaded at the offload location for a time equal to one hour, sampling interval shall be equal to once an hour.

Example: Scow is stationary for 1 hour 15 minutes, and then the scow sails to the disposal area. You should have a "Loading/Stationary" event at time zero, time 1 hour, and time 1 hour 15 minutes. Then, for Sailing, within 1 second of an elapsed time of 1 minute from the 1 hour 15 minutes event, another event occurs.

3.2.3 Data Transmission to Web Service

A Simple Object Access Protocol (SOAP) web service shall be used to report sensor data to the DQM Database. Data shall be transmitted as it is collected in real time and pushed to the DQM web service. If the web service is not available or returns an Error message, the data shall be stored in a queue and transmitted upon re-establishment of the connection,

W912EP-17-B-0003 SECTION 35 20 26 Page 12 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

starting with the oldest data in the queue and continuing until real-time transmission is restored. Delays in pushing real time data to the DQM database should not exceed four hours. Exceptions to these requirements may be granted by the DQM center on a case by case basis with consideration for considering contract specific requirements, or site specific conditions, and extreme weather events.

The web service provides synchronous or asynchronous calls to the Enqueue method, whose fields are:

Key GUID string identifying the contractor Subject Plant identification string Data Scow XML data element with one point's sensor readings

Please contact [email protected] to obtain the web service URL and the appropriate Key credentials.

Upon transmitting the Key (e.g. `12345678-90AB-CDEF-1234-567890ABCDEF`), Subject (e.g. `2099`), and Data (example in next section), the service will respond with one of the following responses.

If the Key element identifying the contractor was invalid, the service will respond with: Error: Invalid/Expired GUID

If the Plant or Data elements were incorrect (e.g. if the XML string is not well-formed SCOW_DREDGING_DATA), the service will respond with: Error: Invalid Format

If there is an error within the service itself, the service will respond with: Error: Service Unavailable

If all fields were correct, the service will respond with a SHA 256 hexadecimal checksum of the Data field, e.g.: 67DE1F8FA6989415BE817D1E3ABF6A3B761624F09AE02F5DF9FC63D15196F322

If all fields were correct, but the Key for this contractor will soon expire, the service will respond with the new key, as well as a SHA 256 hexadecimal checksum of the Data field. The new Key and the checksum will be separated by a pipe `|` character for simpler parsing, e.g.: Warning: Update GUID to FEDCBA09-8765-4321-FEDC-BA0987654321|67DE1F8FA6989415BE817D1E3ABF6A3B761624 F09AE02F5DF9FC63D15196F322

Upon receipt of the Update GUID warning above, the contractor should update the Key transmitted in further calls to the service, as the current Key will expire within a short timeframe. The new Key will be available for use immediately. After the contractor uses the new Key for the first time, the service will immediately disable the old Key.

Communication with the DQM web service can be conducted either synchronously or asynchronously. For synchronous communication the system provider's web service should wait for the results before sending the next line of XML data.

3.2.4 XML-Formatted Sensor Data String

Each scow event shall be passed as a string on one continuous line of

W912EP-17-B-0003 SECTION 35 20 26 Page 13 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

data. The example below is broken up by variable for ease of reading:

AU1994 W123BA-09-D-0087_RL01 102 34 -81.670632 41.528987 2010-08-14 10:50:15 0.0 0.0 OPEN Some more scow info, if needed

It should be noted that date values shall be formatted as follows: YYYY-MM-DD HH:MM:SS, as shown above. If for any reason a field has no value, send the enclosing XML tags with nothing between them, e.g. . The web service cannot handle a "null" value or any other indicators of no value collected.Data

3.2.5 Contractor Data Backup

The Contractor shall maintain an archive of all data sent to the DQM database during the dredging contract. The COR may require, at no increase in the contract price, that the Contractor provide a copy of these data covering specified time periods. The data shall be provided in the HTML format which would have been transmitted to the DQM database. Data submission shall be via storage medium acceptable to the COR.

At the end of the dredging contact, the Contractor shall contact the National DQM Support Center prior to discarding the data to ensure it has been appropriately archived. The Contractor shall record in a separate section at the end of the scow's on-site copy of the DPIP the following information:

a. Person who made the call b The date of the call c. The DQM representative who gave permission to discard

The same day of the phone call and prior to discarding the data, the Contractor shall submit a "Data Appropriately Archived e-mail" to the local districts Contracting Officer's Representative with the above information, and Cc: the DQM Support Center representative providing permission. In addition to the above information, also include in the e-mail:

W912EP-17-B-0003 SECTION 35 20 26 Page 14 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

d. Project name and contract number e. Scow start and end dates f. Name of the scow

3.3 PERFORMANCE REQUIREMENTS

The Contractor's DQM system shall be fully operational at the start of dredging operations and fully certified prior to moving dredge material on the contract (see section 1.4, National Dredging Quality Management Program Certification). To meet contract requirements for operability, in addition to certification, the Contractor's system shall provide a minimum an accurate data and be compliant with DPIP requirements (Section 1.5). Quality data strings are considered to be those providing accurate values for all parameters reported when operating according to the specification. Repairs necessary to restore data return compliance shall be made within 48 hours. If the Contractor fails to report required data within the specified time window for scow measurements (see Section 3.2.2 "Data Measurement Frequency" and 3.2.3 "Data Reporting"), or if the system has not received DQM certification prior to dredging; the system will be declared not in compliance, and the Contractor will be assessed liquidated damages equivalent to the additional oversight hours that would be required for Corps personnel to be on site from the first full day after the system is deemed not operational through to the time when the system is returned to fully operational status.

3.4 COMPLIANCE QUALITY ASSURANCE CHECKS

Quality assurance checks are required prior to the commencement of dredging, and at the discretion of a COR periodically throughout the duration of the contract. As part of the testing requirements, the dredging contractor shall provide the above personnel an easily accessible visual display of measurements from the scow monitoring system in the same units that are submitted to the DQM database. These measurements shall be provided in real-time on the scow or near real-time on location. The Dredging contractor shall also submit data collected during the QA checks from the scow monitoring system to the DQM database at completion of the checks. Detailed instructions for performing these checks and a spreadsheet for recording the results are available at http://dqm.usace.army.mil/Certifications/Index.aspx. Incoming data shall be periodically reviewed to assure compliance with performance requirements outlined in section 3.3.

For annual instrumentation checks and compliance monitoring, the DQM Data Acquisition Team personnel attempt to be as flexible as possible in performing their checks so as not to delay work; however, in order to expedite matters as much as possible, it is necessary that they receive the support and cooperation of the local district and dredging contractor. The dredging contractor shall coordinate pickup times and locations and provide transportation to and from any platform with a DQM certified system in a timely manner. Calibrations to the sensors should already be performed before DQM personnel arrive on site.

3.4.1 Position Check

During the QA checks, both the static position of the scow and a dynamic tracking of movement though each of the event triggers (section 3.2.2) will be monitored by an independent GPS unit. The inspector GPS data shall be compared to the data that is collected by the DQM certified system for

W912EP-17-B-0003 SECTION 35 20 26 Page 15 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

the same period. The data should be provided to the Data Acquisition Team by the system provider while onsite. The Data Acquisition Team will confirm position of the scow, verify that data collection intervals change as each of the scow event triggers change, and will check all data reporting requirements. A contractor furnished tug will be required to transport the scow during this check. Throughout the contract, the COR will periodically verify reported positions by independently measuring with other equipment to verify locations.

3.4.2 Hull Status Check

The Contracting Officer's Representative will document the angle at which the hull status sensor registers "OPEN" and "CLOSED".

3.4.3 Draft & Displacement Check

The COR shall periodically verify the accuracy of the fore and aft system reported draft values by comparing the vessel hull draft marks to the corresponding sensor readings indicated on the DQM screen. The vessel's hull draft reading shall be viewed from a contractor supplied auxiliary vessel circling the dredge. The COR shall review the difference between averaged drafts recorded by the instruments and those estimated from the draft marks to insure that the system is operating within the acceptable accuracy of approximately + 0.1 ft. in calm seas conditions. Reported draft values will be verified light, loaded, and at other intervals at the discretion of the COR. If sensors responsible for collecting draft values are not located on centerline, verification may be required under different trim and list conditions. If values are outside the acceptable range, the Contractor shall re-calibrate or repair system components as necessary. This check may be performed separately or as a part of the Water Load Test. For each system provided 5fore and aft draft, an average draft value will be calculated during the draft check, and the corresponding displacement will be verified longhand using the supplied draft/displacement tables.

3.4.4 Bin Ullage Sounding & Volume Check

The COR shall periodically check the reported bin ullage sounding using a tape measure or other distance measuring device. The Contractor shall furnish a clearly readable weighted tape, marked in tenths of a foot, capable of measuring throughout the full range of bin depth. The weight for this tape shall be a 6-inch diameter disk weighing between 2 and 3 pounds. The COR shall review the bin ullage sounding data to insure that the system is operating within acceptable accuracy (0.1 feet). Reported ullage soundings will be verified light, loaded, and at other intervals at the COR's discretion. Measurements can be taken from multiple locations along the combing or from sensor location at the COR's discretion. If values are outside the acceptable range, the Contractor shall re-calibrate or repair system components as necessary. This check may be performed separately or as a part of the Water Load Test. For each system provided fore and aft ullage sounding value, an average ullage sounding will be calculated during during the ullage check, and the corresponding bin volume will be verified longhand using the supplied bin volume tables.

3.5 CONTRACTOR QUALITY CONTROL

Dredging contractor shall designate a quality control systems manager (QCSM), who shall develop and maintain daily procedures to ensure the contractor's quality control (CQC) of the DQM system. These methods shall

W912EP-17-B-0003 SECTION 35 20 26 Page 16 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

include a procedure by which data being collected is checked against known values and telemetry is verified to be functioning. The Contractor Quality Control Plan which describes these methods and procedures shall be included in the DPIP as per section 1.5. This is the only section which shall be submitted to the local district and is a required submittal prior to the start of the contract. CQC Reports may be required at the discretion of the QAR daily. Annotations shall be made in the CQC Report documenting all actions taken on each day of work including all deficiencies found and corrective actions taken.

3.6 LIST OF ITEMS PROVIDED BY THE CONTRACTOR

DPIP Sec 1.5 Dredge Plant Instrumentation Plan

DQM SYSTEM Sensor Instrumentation Sec. 3.1 Specifications for Reported Data

SCOW DATA Event documentation Sec. 3.2.2 Data Measurement Frequency Data reports Sec. 3.2.3 Data Reporting

QA EQUIPMENT ON DREDGE Clear and accurate draft marks Ullage tape Sec. 3.4.4 Bin Ullage Sounding & Volume Check

-- End of Section --

W912EP-17-B-0003 SECTION 35 20 26 Page 17 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION TABLE OF CONTENTS

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

SECTION 35 20 28

NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM HOPPER DREDGE

PART 1 GENERAL

1.1 DESCRIPTION 1.2 SUBMITTALS 1.3 PAYMENT 1.4 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM CERTIFICATION 1.5 DREDGE PLANT INSTRUMENTATION PLAN (DPIP)

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 REQUIREMENTS FOR REPORTED DATA 3.1.1 Date and Time 3.1.2 Load Number 3.1.3 Horizontal Positioning 3.1.3.1 Vessel Horizontal Positioning 3.1.3.2 Draghead Horizontal Positioning 3.1.4 Hull status 3.1.5 Dredge Course 3.1.6 Dredge Speed 3.1.7 Dredge Heading 3.1.8 Tide 3.1.9 Draft 3.1.10 Hopper Ullage Sounding 3.1.11 Hopper Volume 3.1.12 Displacement 3.1.13 Empty Displacement 3.1.14 Draghead depths 3.1.15 Slurry Densities of Dragarms 3.1.16 Slurry Velocities of Dragarms 3.1.17 Pump RPM 3.1.18 Sea Suction Valve for Dragarm 3.1.19 Pumpout 3.1.20 Project Trip Number 3.2 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SYSTEM REQUIRMENTS 3.2.1 Computer Requirements 3.2.2 Software 3.2.3 Network Hub 3.2.4 UPS 3.2.5 Internet Access 3.2.6 Data Routing Requirements 3.2.7 Data Reporting Frequency 3.2.8 Data Format 3.2.9 Data Reporting 3.2.10 Contractor Data Backup 3.3 PERFORMANCE REQUIREMENTS

W912EP-17-B-0003 SECTION 35 20 28 Page 1 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.4 COMPLIANCE QUALITY ASSURANCE CHECKS 3.4.1 Draft & Displacement Check 3.4.2 Draghead Depth Check 3.4.3 Ullage Sounding & Volume Check 3.4.4 Position Check 3.4.5 Water Load Test 3.5 CONTRACTOR QUALITY CONTROL 3.6 LIST OF ITEMS TO BE PROVIDED BY THE CONTRACTOR

-- End of Section Table of Contents --

W912EP-17-B-0003 SECTION 35 20 28 Page 2 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

SECTION 35 20 28

NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM HOPPER DREDGE

PART 1 GENERAL

1.1 DESCRIPTION

The work under this contract requires use of the National Dredging Quality Management Program (DQM)to monitor the dredge's status at all times during the contract and manage data history.

This performance-based specification section identifies the minimum required output and precision and instrumentation requirements. The requirements may be satisfied using equipment and technical procedures selected by the Contractor.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office responsible for review of the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00, "SUBMITTAL PROCEDURES":

SD-01 Preconstruction Submittals

Dredge Plant Instrumentation Plan Revisions or Addendum; G, SAM-OP-J

Contactor Quality Control Plan, section 3.2.5; G, RO

SD-07 Certificates

Letter of National Dredging Quality Management Program Certification; G, RO

SD-06 Test Reports

Data Appropriately Archived e-mail, section 3.2.11; G, RO

1.3 PAYMENT

No separate payment will be made for installation, operation and maintenance of the DQM certified system as specified herein for the duration of the dredging operations; all costs in connection therewith shall be considered a subsidiary obligation of the Contractor and covered under the contract unit prices for dredging in the bidding schedule.

1.4 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM CERTIFICATION

The Contractor is required to have a current certification from the DQM

W912EP-17-B-0003 SECTION 35 20 28 Page 3 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

for the hopper dredge instrumentation system to be used under this contract. Criteria for certification shall be based on the most recent specification posted on the DQM website (http://dqm.usace.army.mil/Specifications/Index.aspx). Compliance with these criteria shall be verified by annual on-site quality assurance (QA) checks conducted by DQM Support Center Data Acquisition and Analysis Team, and by periodic review of the transmitted data. DQM Certification is valid for one year from the date of the annual QA checks. Certification is contingent upon the system's ability to continuously meet the performance requirements as outlined in sections 3.3 and 3.5. If issues with data quality are not corrected within 48 hours, the system certification shall be revoked and additional QA checks by the Data Acquisition Team may be necessary.

Annual DQM Certification shall be based on:

- A series of QA checks as described in section 3.4 "Compliance Quality Assurance Checks"

- Verification of data acquisition and transfer (Section 3.3)

- Review of the Dredge Plant Instrumentation Plan (DPIP) as described in Section 1.5

The Contractor shall have personnel who are familiar with the system instrumentation and who have the ability to recalibrate the sensors on site during the QA process. The dredging contractor shall coordinate pickup times and locations and provide transportation to and from any platform with a DQM system to team personnel in a timely manner. As a general rule, Data Acquisition and Analysis Team personnel will come with PPE consisting of hardhats, steel toe boots, and life jackets. If additional safety equipment is needed, such as eye protection, safety harnesses, work gloves or personal location beacons, these items shall be provided to the team while on site. It is the dredging contractor's obligation to inform the QA team if the location designated for the QA checks has any site specific safety concerns prior to their arrival on site.

The owner or operator of the hopper dredge shall contact the DQM at [email protected] on an annual basis at least three weeks prior to the certification expiration, to schedule QA checks for renewal. This notification is meant to make the Data Acquisition Team aware of a target date for the annual QA checks for the dredge. At least one week prior to the target date, the Contractor shall contact the Data Acquisition team and verbally coordinate a specific date and time. The contractor shall then follow-up this conversation with a written e-mail confirmation. The owner/operator shall coordinate the QA checks with all local authorities, including but not limited to, the local USACE contracting officer.

Re-certification is required for any yard work which produces modification to displacement (i.e. change in dredge lines, repositioning or repainting hull marks), modification to bin volume (change in bin dimensions or addition or subtraction of structure) or changes in sensor type or location; these changes shall be reported in the sensor log section of the DPIP. A system does not have to be transmitting data between jobs, however in order to retain its certification during this period, the system sensors or hardware should not be disconnected or removed from the dredge. If the system is powered down, calibration coefficients shall be retained.

W912EP-17-B-0003 SECTION 35 20 28 Page 4 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

1.5 DREDGE PLANT INSTRUMENTATION PLAN (DPIP)

The Contractor shall have a digital copy of the DPIP on file with the National DQM Support Center. The Contractor shall also maintain a copy of the DPIP on the dredge while working on site which is easily accessible to government personnel at all times. This document shall describe the sensors used, configuration of the system, how sensor data will be collected, how quality control on the data will be performed, and how sensors/data reporting equipment will be calibrated and repaired if they fail. A description of computed dredge specific data and how the sensor data will be transmitted to the DQM Database will also be included. The Contractor shall submit to the DQM Support Center any addendum or modifications made to the plan, subsequent to its original submission, prior to start of work.

The DPIP shall include the following as a minimum: (DPIP must have table of contents in the following order and tabs separating sections)

Cover Page

-- Dredge Name -- Date -- Photo of plant

Table of Contents

- Dredge Contacts

Dredging Company -- Dredge Point of Contact on-site -- Phone Number -- Email address

Dredge Monitoring System Provider -- Dredge Monitoring System Point of Contact -- Telephone Number -- Email address

New Page

- Table of dredge characteristics --Dimensions of dredge --Dimensions of hopper --Method of disposal --Capacity --Minimum and maximum digging depth --Minimum and maximum drafts and displacements --RPM and velocity range --ID of suction and discharge pipes

New Page

- Sensor data collection method

-- Any averaging -- Route from sensor to DQM computer -- Internet connection type and provider

W912EP-17-B-0003 SECTION 35 20 28 Page 5 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

- Sensor descriptions, locations and calibration methods

Positioning system

-- Brand name, model and accuracy -- Any calculation done external to the instrumentation -- Sensor location with referenced dimensions

Dredge heading instrumentation

-- Brand name, model and accuracy -- Any calculation done external to the instrumentation

Hull status

--Brand name, model and accuracy --Any calculation done external to the instrumentation --Sensor location with referenced dimensions --Calibration procedure

Draft

--Brand name, model and accuracy --Any calculation done external to the instrumentation --Sensor location with referenced dimensions --Calibration procedure

Ullage

--Brand name, model and accuracy --Any calculation done external to the instrumentation --Sensor location with referenced dimensions --Calibration procedure

Dragarm depths

--Brand name, model and accuracy --Any calculation done external to the instrumentation --Sensor location with referenced dimensions --Calibration procedure

Density

--Brand name, model and accuracy --Any calculation done external to the instrumentation --Sensor location with referenced dimensions including pipe diameter --Calibration procedure

Velocity

--Brand name, model and accuracy --Any calculation done external to the instrumentation --Sensor location with referenced dimensions including pipe diameter --Calibration procedure

Pump RPM

W912EP-17-B-0003 SECTION 35 20 28 Page 6 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

--Brand name, model and accuracy --Any calculation done external to the instrumentation --Sensor location with referenced dimensions --Calibration procedure

Pumpout (if instrumented)

--Brand name, model and accuracy --Any calculation done external to the instrumentation --Sensor location with referenced dimensions --Calibration procedure

- Calculated Parameters

Displacement

--Method used by Contractor to calculate displacement --Tables listing (fresh and salt water) displacement as a function of draft in feet and tenths of feet

Hopper Volume

--Method used by Contractor to calculate hopper volume --Table listing the hopper volume as a function of hopper ullage in feet and tenths of feet --Description of datum for ullage sounding measurements

Drag Head Position

--Method used by Contractor to calculate drag head position

Load number

--Method used to increment load number

- Quality Control

Description of Contractors quality control process Log of sensor calibrations, repairs and modifications

- Appendices

Hydrostatic curves

Certified Displacement and Volume Tables

Legible dimensioned drawings of the dredge with units in feet

--A typical plan of the dredge showing: ---Overall dredge and hopper dimensions ---Locations of required sensors referenced to uniform longitudinal and transverse reference points ---Distance between the draft sensors ---Distance between the ullage sensors ---Dimensions of dragarm

--A profile view of the dredge showing:

W912EP-17-B-0003 SECTION 35 20 28 Page 7 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

---Overall dredge and hopper dimensions ---Distance between draft sensors and draftmarks ---Locations of required sensors referenced to uniform vertical and longitudinal reference points --Typical vessel cross section through the hopper

Sensor manuals and certificates of calibration

Any changes to the computation methods shall be approved by the National Dredging Quality Management Program Support Center prior to their implementation.

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION

3.1 REQUIREMENTS FOR REPORTED DATA

The Contractor shall provide, operate and maintain all hardware and software to meet these specifications. The Contractor shall be responsible for replacement, repair and calibration of sensors and other necessary data acquisition equipment needed to supply the required data.

Repairs shall be completed within 48 hours of any sensor failure. Upon completion of a repair, replacement, installation, modification or calibration, the Contractor shall notify the Contracting Officer's Representative (COR). The COR may request re-calibration of sensors or other hardware components at any time during the contract as deemed necessary.

The Contractor shall keep a log of sensor repair, replacement, installation, modification and calibration in the dredge's onboard copy of the DPIP. The log shall contain a three-year history of sensor maintenance to include: the time of sensor failures (and subsequent repairs), the time and results of sensor calibrations, the time of sensor replacements, and the time that backup sensor systems are initiated to provide required data. It shall also contain the name of the person responsible for the sensor work.

Sensors installed shall be capable of collecting parameters within specified accuracies and resolutions indicated in the following subsections and transmit them to the DQM Database.

Reported sensor values for ullage, draft and draghead depth should represent a weighted average with the highest and lowest values not included in the calculated average for the given interval. This information should be documented in the DPIP sections that say "Calculations done external to the instrumentation".

3.1.1 Date and Time

The date and time shall be reported to the nearest second and referenced to UTC time based on a 24 hour format; mm/dd/yyyy hh:mm:ss. This reported time shall be such that it cannot be modified in any computer. One possible solution is to use the time reported by the GPS in the NMEA string.

W912EP-17-B-0003 SECTION 35 20 28 Page 8 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.1.2 Load Number

A load number shall document the end of a disposal event. Load numbering will begin at number 1 at the start of the contract, and will be incremented by 1 at the completion of each disposal event or emptying of the hopper. Whenever possible, the load number shall be calculated off of the sensors aboard the dredge, and shall be a mathematically repeatable routine. Efforts shall be made to include logic that avoids false load number increments while also not allowing the routine to miss any disposal event. If manual incrementing of the load number is in place, extra attention should be paid to this value in the contractor's quality control process (section 3.5).

3.1.3 Horizontal Positioning

All locations shall be obtained using a Positioning System operating with a minimum accuracy level of 1 to 3 meters horizontal Circular Error Probable (CEP). Positions shall be reported as Latitude/Longitude WGS 84 in decimal degrees. West Longitude and South Latitude values are reported as negative.

3.1.3.1 Vessel Horizontal Positioning

Geographic coordinates of the vessel as indicated by the location of the GPS antenna.

3.1.3.2 Draghead Horizontal Positioning

Geographic coordinates of the heel on centerline of the draghead(s). Any offset calculations from the GPS antenna should be described in the DPIP.

3.1.4 Hull status

Open/closed status of the hopper dredge, corresponding to the split/non-split condition of a split hull hopper dredge shall be monitored. For dredges with hopper doors, the status of a single door that is the first opened during normal disposal operations may be monitored. An "OPEN" value shall indicate the hopper door is open, or in the case of split hull dredges, the hull is split. A "CLOSED" value indicates the hopper doors are closed, or in the case of split hull dredges, the hull is not split. For this contract, hull status shall register closed prior to leaving the disposal area.

3.1.5 Dredge Course

Dredge course-over-ground (COG) shall be provided using industry standard equipment. The Contractor shall provide dredge course over ground to the nearest whole degree with values from 000 (true north) to 359 degrees referenced to a clockwise positive direction convention.

3.1.6 Dredge Speed

Dredge speed-over-ground shall be provided in knots using industry standard equipment with a minimum accuracy of 1 knot and resolution to the nearest 0.1 knot.

3.1.7 Dredge Heading

Dredge heading shall be provided using industry standard equipment. The

W912EP-17-B-0003 SECTION 35 20 28 Page 9 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

dredge heading shall be accurate to within 5 degrees and reported to the nearest whole degree, with values from 000 (true north) to 359 degrees referenced to a clockwise positive direction convention.

3.1.8 Tide

Tide data shall be obtained using appropriate equipment to give the water level with an accuracy of +/- 0.1 feet and a resolution of 0.01 feet. Tide values above project datum described in the dredging specification shall be entered with a positive sign, those below with a negative sign.

3.1.9 Draft

All reported draft measurements shall be in feet, tenths and hundredths with an accuracy of +/- 0.1 foot, relative to observed physical draft readings. The measurements shall be reported at a resolution of two decimal places (hundredths of a foot). Reported forward draft value shall be equal to the sum of the visual forward port and starboard draft mark readings divided by 2. Reported aft draft value shall be equal to the sum of the visual aft port and starboard draft mark readings divided by 2. Forward draft, aft draft and average draft will be reported. Sensors shall be placed at an optimum location on the vessel to be reflective of observed physical draft mark readings at any trim or list. The sensor value reported shall be n average of at least 10 samples per event, remove at least one maximum value and one minimum value, and average the minimum 8 remaining values. When average draft is calculated for the purpose of determining displacement, significant digits for average draft shall be maintained such that if forward draft was 0.15 and aft draft was 0.1 then the average draft would be 0.125.

3.1.10 Hopper Ullage Sounding

All reported ullage soundings shall be in feet, tenths and hundredths with an accuracy of +/- 0.1 foot with respect to the combing, and be representative of the forward and aft extents of the hopper as close to centerline as is possible. The measurements shall be reported at a resolution of two decimal places (hundredths of a foot). Forward ullage and aft ullage soundings will be reported. Sensors should be mounted so as to avoid discharge flume turbulence, foam and any structure that could produce sidelobe errors. If sensors must be offset from centerline of the hopper they should be offset to opposite sides of the vessel. If more than one fore or one aft sensor is used, they shall be placed near the corners of the hopper and the average value of the fore sensors and the average value of the aft sensors shall be reported The sensor value reported shall be an average of at least 10 samples per event, remove at least one maximum value and one minimum value, and average the minimum 8 remaining values. When average ullage is calculated for the purpose of determining hopper volume, significant digits for average ullage shall be maintained such that if forward ullage was 0.15 and aft ullage was 0.1 then the average ullage would be 0.125.

3.1.11 Hopper Volume

Hopper volume shall be reported in cubic yards, based on the most accurate method available for the dredge. The minimum standard of accuracy for hopper volume is interpolation from the certified hopper volume table, based on the average fore and aft ullage soundings.

W912EP-17-B-0003 SECTION 35 20 28 Page 10 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

3.1.12 Displacement

Dredge displacement shall be reported in long tons, based on the most accurate method available for the dredge. The minimum standard of accuracy for displacement is interpolation from the displacement table, based on the average draft. For this contract the density of water used to calculate displacement shall be 64.0 pounds per cubic foot or its metric equivalent of 1025 kilograms per cubic meter and shall be used for an additional interpolation between the fresh and salt water tables.

3.1.13 Empty Displacement

Empty displacement shall be reported in long tons, and shall be the lightship value of the dredge, or the weight of the dredge with no material in the hopper, adjusted for fuel and water consumption.

3.1.14 Draghead depths

Draghead depths shall be reported with an accuracy of +/- 0.5 feet and a resolution to the nearest 0.1 feet as measured from the surface of the water with no tidal adjustments. Minimum accuracies are conditional to relatively calm water. The sensor value reported shall be an average of at least 10 samples per event, remove at least one maximum value and one minimum value, and average the minimum 8 remaining values.

3.1.15 Slurry Densities of Dragarms

A density metering device, calibrated according to the manufacturer's specifications, shall be used to record the slurry density of each dragarm to the nearest 0.0001 g/cc with an accuracy of +/- 0.001g/cc. If the manufacture does not specify a frequency of re-calibration, calibration shall be conducted prior to commencement of work.

3.1.16 Slurry Velocities of Dragarms

A flow metering device, calibrated according to the manufacturer's specifications, shall be used to record the slurry velocity of each dragarm to the nearest 0.0001 fps with an accuracy of +/- 0.001 fps. If the manufacture does not specify a frequency of re-calibration, calibration shall be conducted prior to commencement of work. The slurry velocity shall be measured in the same pipeline inside diameter as that used for the slurry density measurement.

3.1.17 Pump RPM

Pump RPM shall be measured with the highest level of accuracy that is standard on the vessel operational displays, either at the bridge, at the drag tenders controls, or in the engine room. Dredges with multiple pumps per side shall report RPM for the pump that best describes the dredging process (typically the outboard pump). If requirements of section 3.1.19 are determined based on pump RPM, then that value shall be reported.

3.1.18 Sea Suction Valve for Dragarm

If sea suction can be taken to bypass suction through the draghead, the sea suction location and valve status will be reported. The status of the valve will change from "closed" to "open" when the valve starts to open and will register "closed" when the valve is fully closed. When applicable, the state of the latch will be reported as "true" or "false".

W912EP-17-B-0003 SECTION 35 20 28 Page 11 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

The sea suction location shall be reported in a standard non-changing name string or no more than 20 characters. These field values will always occur in the XML string as a set. The DQM system can only accommodate up to 4 unique sea suction locations. Suggested options for the naming convention can be found in the Example dataset in section 3.2.9, "Data Format".

3.1.19 Pumpout

When the hopper dredge is being pumped out, a "True" value shall be reported; when it is not, a "False" value shall be reported. The only permissible values are "TRUE" and "FALSE".

3.1.20 Project Trip Number

A project trip number is not unique to a particular dredge plant, but is unique to a contract. Like a load number the project trip number shall document the end of a disposal event. Project trip numbering will begin at number 1 at the start of the contract, and will be incremented by 1 at the completion of each disposal event or emptying of the dredge material. Whenever possible, the project trip number shall be calculated off of the sensors aboard the dredge, and shall be a mathematically repeatable routine. Efforts shall be made to include logic that avoids false load number increments while also not allowing the routine to miss any disposal event. If manual incrementing of the load number is in place, extra attention shall be paid to this value in the contractor's quality control process (section 3.5).

3.2 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SYSTEM REQUIRMENTS

Contractors DQM system shall be capable of collecting, displaying, and transmitting information to the DQM Database. The applicable parameters from section 3.1 shall be recorded as events locally and continually transmitted to the DQM Database anytime an internet connection is available. The Dredge shall be equipped with a DQM computer system consisting of a computer, monitor, keyboard, mouse, data modem, UPS, and network hub. The computer system shall be a standalone system, exclusive to the DQM monitoring system, and will have USACE DQM software installed on it. If a hardware problem occurs, or if a part of the system is physically damaged, then the Contractor shall be responsible for repairing it within 48 hours of determination of the condition.

3.2.1 Computer Requirements

The Contractor shall provide a dedicated on-board computer for use by the Dredging Quality Management system. This computer shall run the Corps' software and receive data from the Contractor's data reporting interface. This computer must meet or exceed the following performance specifications:

CPU: Intel or AMD processor with a (non-overclocked) clock speed of at least 3 gigahertz (GHz) Hard drive: 250 gigabytes (GB); internal RAM: 2 gigabytes Ethernet adapter: 10 or 100 megabit (Mbit) internal network card with an RJ-45 connector Video adapter: Must support resolution of 1024x768 at 16 bit color depth Keyboard: Standard 101-key

W912EP-17-B-0003 SECTION 35 20 28 Page 12 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

Mouse: Standard 2-button mouse Monitor: 17 inch viewable display; must support 1024x768 resolution at 16 bit color depth CD-ROM drive: 16X read speed/8X write speed Ports: 2 free Serial ports with standard 9-pin connectors; 1 free USB port Other hardware: Category 5 (Cat-5) cable with standard RJ-45 plugs connecting the network adapter to the network hub; one spare cable

Contractor shall install a fully-licensed copy of Windows 7 Professional Operating System on the computer specified above. Contractor shall also install any necessary manufacturer-provided drivers for the installed hardware.

This computer shall be located and oriented to allow data entry and data viewing, as well as to provide access to data ports for connection of external hardware. Location and orientation shall be subject to Contracting Officer's Representative's approval.

3.2.2 Software

The DQM computer's primary function is to transmit data to the DQM shore side database. No other software which conflicts with this function shall be installed on this computer. The DQM computer will also have the USACE provided DQMOBS (Dredge Quality Management Onboard Software) installed on it by DQM personnel.

3.2.3 Network Hub

The DQM computer shall communicate via IEEE 802.3 Ethernet and the TCP/IP networking protocol. The Contractor shall provide a network hub to allow the temporary addition of the Contracting Officer's representative's portable computer to the computer network. The hub shall provide a minimum of four RJ-45 ports that support Category 5 (Cat-5) cable with standard RJ-45 plugs connecting the network adapter to the network hub; one spare cable shall be available on site to plug into the network hub.

3.2.4 UPS

The Contractor shall supply an Uninterruptible Power Supply (UPS) for the computer and networking equipment. The UPS shall provide backup power at 1kVA for a minimum of 10 minutes. The UPS shall interface to the DQM computer to communicate UPS status. The Contractor shall ensure that sufficient power outlets are available to run all specified equipment.

3.2.5 Internet Access

The Contractor shall maintain an internet connection capable of transmitting real time data to the DQM Server and supporting remote access, as well as enough additional band width to clear historically queued data when a connection is re-obtained. The telemetry system shall be always available and have connectivity in contract area. The Contractor shall acquire and install all necessary hardware and software to make the internet connection available for data transmission to the DQM web service. The hardware and software must be configured to allow the USACE DQM center remote access to this computer. Coordination between the dredging company's IT and DQM support may be required in order to

W912EP-17-B-0003 SECTION 35 20 28 Page 13 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

configure remote access though any security, firewall, router, and telemetry systems. Telemetry systems must be capable of meeting these minimum reporting requirements in all operating conditions.

3.2.6 Data Routing Requirements

Onboard sensors shall continually monitor dredge conditions, operations and efficiency and route this information into the shipboard dredge-specific system computer (DSS) to assist in guiding dredge operations. Portions of this Contractor-collected information shall be routed to the DQM computer on a real-time basis. Standard sensor data shall be sent to the DQM computer via an RS 232 9600 or 19200-baud serial interface. The serial interface shall be configured as 8 bits no parity and no flow control.

3.2.7 Data Reporting Frequency

Data shall be logged as a series of events. Each event will consist of a data set containing dredge information as per section 3.1. Each set of measurements (i.e. time, position, etc…) will be considered an event. All required information in section 3.1 that are not an averaged variable (i.E. draft and ullage) shall be collected within one second of the reported time. A data string for an event shall be sent to the DQM computer every 6 to 12 seconds, and this interval shall remain constant throughout the contract; data strings shall never be transmitted more frequently than once per every 5 seconds. Any averaged variable must be collected and computed within this sampling interval.

3.2.8 Data Format

Data shall be reported as an Extensible Markup Language (W3C standard XML 1.0) document as indicated below. Line breaks and spaces are added for readability, but the carriage return, line feed character combination is only added to delineate records (HOPPER_DREDGING_DATA tag) for actual data transmission.

{?xml version="1.0"?} {HOPPER_DREDGING_DATA version = "2.0"} {DREDGE_NAME} string32 {/DREDGE_NAME} {HOPPER_DATA_RECORD} {DATE_TIME} time date string {/DATE_TIME} {LOAD_NUMBER} integer string {/LOAD_NUMBER} {VESSEL_X coord_type="LL"} floating point string {/VESSEL_X} {VESSEL_Y coord_type="LL"} floating point string {/VESSEL_Y} {PORT_DRAG_X coord_type="LL"} floating point string {/PORT_DRAG_X} {PORT_DRAG_Y coord_type="LL"} floating point string {/PORT_DRAG_Y} {STBD_DRAG_X coord_type="LL"} floating point string {/STBD_DRAG_X} {STBD_DRAG_Y coord_type="LL"} floating point string {/STBD_DRAG_Y} {HULL_STATUS} OPEN/CLOSED string {/HULL_STATUS} {VESSEL_COURSE} floating point string {VESSEL_COURSE} {VESSEL_SPEED} floating point string {/VESSEL_SPEED} {VESSEL_HEADING} floating point string {/VESSEL_HEADING} {TIDE} floating point string {/TIDE}

W912EP-17-B-0003 SECTION 35 20 28 Page 14 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

{DRAFT_FORE} floating point string {/DRAFT_FORE} {DRAFT_AFT} floating point string {/DRAFT_AFT} {ULLAGE_FORE} floating point string {/ULLAGE_FORE} {ULLAGE_AFT} floating point string {/ULLAGE_AFT} {HOPPER_VOLUME} floating point string {/HOPPER_VOLUME} {DISPLACEMENT} floating point string {/DISPLACEMENT} {EMPTY_DISPLACEMENT} floating point string {/EMPTY_DISPLACEMENT} {DRAGHEAD_DEPTH_PORT} floating point string {/DRAGHEAD_DEPTH_PORT} {DRAGHEAD_DEPTH_STBD} floating point string {/DRAGHEAD_DEPTH_STBD} {PORT_DENSITY} floating point string {/PORT_DENSITY} {STBD_DENSITY} floating point string {/STBD_DENSITY} {PORT_VELOCITY} floating point string {/PORT_VELOCITY} {STBD_VELOCITY} floating point string {/STBD_VELOCITY} {PUMP_RPM_PORT} floating point string {/PUMP_RPM_PORT} {PUMP_RPM_STBD} floating point string {/PUMP_RPM_STBD} {VALVE_1_LOCATION} string 32 {VALVE_1_LOCATION} {VALVE_1_STATUS} open/closed {/VALVE_1_STATUS} {VALVE_1_LATCHED} true/false {/VALVE_1_LATCHED} {VALVE_2_LOCATION} string32 {/VALVE_2_LOCATION} {VALVE_2_STATUS} open/closed {/VALVE_2_STATUS} {VALVE_2_LATCHED} true/false {/VALVE_2_LATCHED} {VALVE_3_LOCATION} string32 {/VALVE_3_LOCATION} {VALVE_3_STATUS} open/closed {/VALVE_3_STATUS} {VALVE_3_LATCHED} true/false {/VALVE_3_LATCHED} {VALVE_4_LOCATION} string32 {/VALVE_4_LOCATION} {VALVE_4_STATUS} open/closed {/VALVE_4_STATUS} {VALVE_4_LATCHED} true/false {/VALVE_4_LATCHED} {PUMP_OUT_ON} true/false/unknown string {/PUMP_OUT_ON} {PROJECT_TRIP_NUMBER} integer string {/PROJECT_TRIP_NUMBER} {/HOPPER_DATA_RECORD}

{/HOPPER_DREDGING_DATA} Carriage return - ASCII value 13 Line Feed - ASCII value 10

Example

{?xml version="1.0"?} {HOPPER_DREDGING_DATA version = "2.0"} {DREDGE_NAME}Essayons{/DREDGE_NAME} {HOPPER_DATA_RECORD} {DATE_TIME}04/11/2002 13:12:05{/DATE_TIME} {LOAD_NUMBER}102{/LOAD_NUMBER} {VESSEL_X coord_type="LL"}-80.123333{/VESSEL_X} {VESSEL_Y coord_type="LL"}10.123345{/VESSEL_Y} {PORT_DRAG_X coord_type="LL"}-80.1233371{/PORT_DRAG_X} {PORT_DRAG_Y coord_type="LL"}10.12335{/PORT_DRAG_Y} {STBD_DRAG_X coord_type="LL"}-80.123339{/STBD_DRAG_X} {STBD_DRAG_Y coord_type="LL"}10.123347{/STBD_DRAG_Y} {HULL_STATUS}CLOSED{/HULL_STATUS} {VESSEL_COURSE}258{/VESSEL_COURSE} {VESSEL_SPEED}3.4{/VESSEL_SPEED} {VESSEL_HEADING}302{/VESSEL_HEADING} {TIDE}-0.1{/TIDE} {DRAFT_FORE}10.05{/DRAFT_FORE} {DRAFT_AFT}15.13{/DRAFT_AFT}

W912EP-17-B-0003 SECTION 35 20 28 Page 15 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

{ULLAGE_FORE}10.11{/ULLAGE_FORE} {ULLAGE_AFT}10.22{/ULLAGE_AFT} {HOPPER_VOLUME}2555.2{/HOPPER_VOLUME} {DISPLACEMENT}4444.1{/DISPLACEMENT} {EMPTY_DISPLACEMENT}2345.0{/EMPTY_DISPLACEMENT} {DRAGHEAD_DEPTH_PORT}55.10{/DRAGHEAD_DEPTH_PORT} {DRAGHEAD_DEPTH_STBD}53.21{/DRAGHEAD_DEPTH_STBD {PORT_DENSITY}1.02{/PORT_DENSITY} {STBD_DENSITY}1.03{/STBD_DENSITY} {PORT_VELOCITY}22.1{/PORT_VELOCITY} {VALVE_4_LATCHED} false{/VALVE_4_LATCHED} {PUMP_OUT_ON}false{/PUMP_OUT_ON} {/HOPPER_DATA_RECORD} {/HOPPER_DREDGING_DATA} {cr} {lf} {DREDGE_NAME}Essayons{/DREDGE_NAME} {HOPPER_DATA_RECORD} {DATE_TIME}04/11/2002 13:12:10{/DATE_TIME} {LOAD_NUMBER}102{/LOAD_NUMBER} {VESSEL_X coord_type="LL"}-80.123334{/VESSEL_X} {VESSEL_Y coord_type="LL"}10.123346{/VESSEL_Y} {PORT_DRAG_X coord_type="LL"}-80.1233372{/PORT_DRAG_X} {PORT_DRAG_Y coord_type="LL"}10.12336{/PORT_DRAG_Y} {STBD_DRAG_X coord_type="LL"}-80.123340{/STBD_DRAG_X} {STBD_DRAG_Y coord_type="LL"}10.123348{/STBD_DRAG_Y} {HULL_STATUS}CLOSED{/HULL_STATUS} {VESSEL_COURSE}259{/VESSEL_COURSE} {VESSEL_SPEED}3.5{/VESSEL_SPEED} {VESSEL_HEADING}300{/VESSEL_HEADING} {TIDE}-0.1{/TIDE} {DRAFT_FORE}10.00{/DRAFT_FORE} {DRAFT_AFT}15.15{/DRAFT_AFT} {ULLAGE_FORE}10.15{/ULLAGE_FORE} {ULLAGE_AFT}10.20{/ULLAGE_AFT} {HOPPER_VOLUME}2555.5{/HOPPER_VOLUME} {DISPLACEMENT}4444.0{/DISPLACEMENT} {EMPTY_DISPLACEMENT}2345.0{/EMPTY_DISPLACEMENT} {DRAGHEAD_DEPTH_PORT}55.15{/DRAGHEAD_DEPTH_PORT} {DRAGHEAD_DEPTH_STBD}53.19{/DRAGHEAD_DEPTH_STBD {PORT_DENSITY}1.00{/PORT_DENSITY} {STBD_DENSITY}1.01{/STBD_DENSITY} {PORT_VELOCITY}22.5{/PORT_VELOCITY} {VALVE_3_LATCHED}false{/VALVE_3_LATCHED} {VALVE_4_LOCATION}Starboard Sea Chest{/VALVE_4_LOCATION} {VALVE_4_STATUS}open {/VALVE_4_STATUS} {VALVE_4_LATCHED} false{/VALVE_4_LATCHED} {PUMP_OUT_ON}false{/PUMP_OUT_ON} {PROJECT_TRIP_NUMBER} 102 {/PROJECT_TRIP_NUMBER} {/HOPPER_DATA_RECORD} {/HOPPER_DREDGING_DATA} {cr} {lf}

3.2.9 Data Reporting

The system shall transmit correctly formatted event data XML strings to the DQM Database continuously from mobilization until the last USACE post-dredging survey has been accepted. If the internet connection

W912EP-17-B-0003 SECTION 35 20 28 Page 16 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

(section 3.2.6) is non-operable, manual backups from the dredge computer of the XML data string which would have been transmitted to the DQM computer over the serial connection shall be performed for each day the device is inoperable and submitted to the DQM center within 48 hours. This submission does not replace the requirement of correcting the issue affecting automatic transmission of data. In the event of data transfer, transmission, or hardware failure; a manually recorded disposal log shall be maintained. It shall consist of a series of events. These events are: start of dredging, end of dredging, pre-disposal and post-disposal events. Each event shall include: time stamp (GMT), position (Latitude and Longitude WGS84), draft, ullage, volume and displacement. Disposal logs shall be submitted on a daily basis to the Contracting Officer's Representative during the time when the system is not operational.

3.2.10 Contractor Data Backup

The Contractor shall maintain an archive of all data sent to the DQM computer during the dredging contract. The COR may require, at no increase in the contract price, that the Contractor provide a copy of these data covering specified time periods. The data shall be provided in the XML format which would have been transmitted to the DQM computer. There shall be no line breaks between the parameters; each record string shall be on separate line. Naming convention for the files shall be {dredgename}_{StartYYYYMMddhhmmss}_{EndYYYYMMddhhmmss}.txt . Data submission shall be via storage medium acceptable to the COR.

At the end of the dredging contact, the Contractor shall contact the National DQM Support Center prior to discarding the data to ensure it has been appropriately archived. The Contractor shall record in a separate section at the end of the dredge's on-board copy of the DPIP the following information:

a. Person who made the call b. The date of the call c. The DQM representative who gave permission to discard

The same day of the phone call and prior to discarding the data, the Contractor shall submit a "Data Appropriately Archived e-mail" to the local districts Contracting Officer's Representative with the above information, and Cc: the DQM Support Center representative providing permission. In addition to the above information, also include in the e-mail:

d. Project name and contract number e. Dredge start and end dates f. Name of hopper dredge

3.3 PERFORMANCE REQUIREMENTS

The Contractor's DQM system shall be fully operational at the start of dredging operations and fully certified prior to moving dredge material on the contract (see Section 1.4, National Dredging Quality Management Program Certification). To meet contract requirements for operability, in addition to certification, the Contractor's system shall provide an accurate data string return and be compliant with hardware requirements (Section 3.2). Quality data strings are considered to be those providing accurate values for all parameters reported when operating according to the specification. Repairs necessary to restore data return compliance shall be made within 48 hours. If the Contractor fails to report required

W912EP-17-B-0003 SECTION 35 20 28 Page 17 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

data within the specified time window for dredge measurements (see Sections 3.2.7 "Data Measurement Frequency" and 3.2.9 "Data Reporting"); the system will be declared not fully operational, and the Contractor will be assessed liquidated damages equivalent to the additional oversight hours that would be required for Corps personnel to be on site from the first full day after the system is deemed not operational through to the time when the system is returned to fully operational status.

3.4 COMPLIANCE QUALITY ASSURANCE CHECKS

Quality assurance checks are required prior to the commencement of dredging, and at the discretion of a COR periodically throughout the duration of the contract. Detailed instructions for performing these checks and a spreadsheet for recording the results are available at http://dqm.usace.army.mil/Certifications/Index.aspx . Incoming data shall be periodically reviewed to assure compliance with performance requirements outlined in section 3.3. In addition to making sure the data received meets the reporting requirements outlined in the sub sections under section 3.1, a more detailed description of some of the quality assurance methods are outlined below.

For annual instrumentation checks and compliance monitoring, the DQM Data Acquisition Team personnel attempt to be as flexible as possible in performing their checks so as not to delay work; however, in order to expedite matters as much as possible, it is necessary that they receive the support and cooperation of the local district and dredging contractor. The dredging contractor shall coordinate pickup times and locations and provide transportation to and from any platform with a DQM certified system in a timely manner. Calibrations to the sensors should already be performed before DQM personnel arrive on site.

3.4.1 Draft & Displacement Check

The COR shall periodically verify the accuracy of the fore and aft system reported draft values by comparing the vessel hull draft marks to the corresponding sensor readings indicated on the DQM screen. The vessel's hull draft reading shall be viewed from a contractor supplied auxiliary vessel circling the dredge. The COR shall review the difference between averaged drafts recorded by the instruments and those estimated from the draft marks to insure that the system is operating within the acceptable accuracy of approximately +/- 0.1 ft. in calm seas conditions. Reported draft values will be verified light, loaded, and at other intervals at the inspector's discretion. If sensors responsible for collecting draft values are not located on centerline, verification may be required under different trim and list conditions. If values are outside the acceptable range, the Contractor shall re-calibrate or repair system components as necessary. This check may be performed separately or as a part of the Water Load Test. For each system provided fore and aft draft, an average draft value will be calculated during the draft check, and the corresponding displacement will be verified longhand using the supplied draft/displacement tables.

3.4.2 Draghead Depth Check

The COR may require periodic calibration checks of the reported draghead depth using manual means such as tape measures or sounding lines to directly measure draghead depth. The Contractor shall furnish a steel tape, chain, or wire with clearly visible flags/tags placed at 1 foot

W912EP-17-B-0003 SECTION 35 20 28 Page 18 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

increments within the operational range of the dragarm. These devices shall be capable of measuring the depth below the water surface to the lowest fixed point of each draghead (often the heel) with sufficient length to measure 5 feet more than the maximum project depth. Pressure sensors may be used to verify calibration of the draghead sensors only in areas where current flow past the vessel/dragarm cannot be reduced sufficiently to allow safe handling of manual measuring devices. Pressure sensors, used for this purpose shall be vented pressure gages and shall be subjected to an annual manufacturer's calibration. Prior to the dragarm depth check, the sensor shall be checked at a known depth, and may be required to be zeroed at this point according to manufacturer's specifications. Care shall be taken not to kink the cable or restrict the vent during deployment.

The COR shall review the draghead depth data to insure that the system is operating within acceptable accuracy, and may direct the Contractor to re-calibrate or repair system components as necessary. If a bubbler type system is used, weekly calibration of the draghead sensors is recommended, as they are sensitive to environmental conditions.

3.4.3 Ullage Sounding & Volume Check

The COR shall periodically check the reported hopper ullage sounding using a tape measure or other distance measuring device. The Contractor shall furnish a clearly readable weighted tape, marked in tenths of a foot, capable of measuring throughout the full range of hopper depth. The weight for this tape shall be a 6-inch diameter disk weighing between 2 and 3 pounds. The COR shall review the hopper dredge ullage sounding data to insure that the system is operating within acceptable accuracy (0.1 feet). Reported ullage soundings will be verified light, loaded, and at other intervals at the COR's discretion. Measurements can be taken from multiple locations along the combing or from sensor location at the COR's discretion. If values are outside the acceptable range, the Contractor shall re-calibrate or repair system components as necessary. This check may be performed separately or as a part of the Water Load Test. For each sensor provided fore and aft ullage sounding value, an average ullage sounding value will be calculated during the ullage sounding check, and the corresponding volume will be verified longhand using the supplied hopper volume tables.

3.4.4 Position Check

During the QA checks the reported position of the dredge will be verified by comparison with readings from a handheld GPS receiver. Throughout the contract, the COR will periodically take readings from an independent GPS to verify locations.

3.4.5 Water Load Test

Water Tests shall consist of pumping the hopper dredge out to its lowest level and then filling it to capacity with water, taking ullage and draft measurements at both levels to determine hopper dredge volume and displacement. The objective of the water test is to validate the dredge's reported displacement and hopper volumes. If the results of the water test indicate that the system is not operating within acceptable accuracy, the Contractor shall correct the deficiencies causing the error, and repeat the water test until the results are acceptable.

The Contractor shall provide a handheld refractometer with automatic

W912EP-17-B-0003 SECTION 35 20 28 Page 19 Tampa Harbor Maintenance Dredging 32-Foot Project, Alafia River Channel & Turning Basin Manatee Harbor Maintenance Dredging 40-Foot Project, Entrance Channel & Turning Basin

temperature compensation to measure the hopper dredge water specific gravity during water tests. The refractometer shall be capable of measuring the hopper dredge water specific gravity with a resolution of 0.001 and minimum accuracy of +/- 0.001. The Contractor shall also provide a water-sampling device to retrieve a sufficient volume of water from various depths in the hopper dredge to accurately determine specific gravity with the refractometer, and a sufficient volume of deionized water for calibration of the device.

3.5 CONTRACTOR QUALITY CONTROL

Dredging contractor shall designate a quality control systems manager (QCSM), who shall develop and maintain daily procedures to ensure the contractor's quality control (CQC) of the DQM system. These methods shall include a procedure by which data being collected is checked against known values, telemetry is verified to be functioning, and the DQM computer is verified to be on and the DQMOBS is running. The Contractor Quality Control Plan which describes these methods and procedures shall be included in the DPIP as per section 1.5 Table of Contents, item 27. This is the only section which shall be submitted to the local district and is a required submittal prior to the start of the contract. CQC Reports may be required at the discretion of the QAR daily. Annotations shall be made in the CQC Report documenting all actions taken on each day of work including all deficiencies found and corrective actions taken.

3.6 LIST OF ITEMS TO BE PROVIDED BY THE CONTRACTOR

DPIP Sec 1.5 Dredge Plant Instrumentation Plan

DQM SYSTEM Sensor Instrumentation Sec. 3.1 Specifications for Reported Data DQM Computer Sec. 3.2 National Dredging Quality Management System Requirements

DREDGE DATA Event documentation Sec. 3.2.9 Data Reporting Dredge Data Backups Sec. 3.2.10 Contractor Data Backups

QA EQUIPMENT ON DREDGE Ullage tape Sec. 3.4.3 Ullage Sounding & Volume Check Dragarm depth chain Sec. 3.4.2 Draghead Depth Check Refractometer -measuring in grams/cubic centimeter with a resolution of 0.001 and a minimum accuracy of +/- 0.001 with calibration water Sec. 3.4.5 Water Load Test Water sampling device Sec. 3.4.5 Water Load Test

-- End of Section --

W912EP-17-B-0003 SECTION 35 20 28 Page 20