Raj Vikas Chief Minister's Information System

Agenda For 23.08.2017

S.No. Issue Concerned Officials Grievances 1. GRIEVANCE ANALYSIS OF REVENUE • Revenue Department DEPARTMENT 2. SH. BANSHI LAL S/O BALWANTA RAM • Rural Development Department (NREGA) • Collector, Jodhpur 3. SH. GYARASI LAL S/O MISHRI LAL • Collector, Dausa 4. ACTION TAKEN REPORT ON DIRECTION GIVEN IN PREVIOUS RAJVIKAS VC Projects 5. CONSTRUCTION OF BYEPASS FOR VILLAGE • PWD JETHANA () • Collector, Ajmer • Revenue Department 6. CONSTRUCTION OF MINI SECRETARIAT • G.A.D. (SRIGANGANAGAR & ALWAR) • Collector, Ganganagar • Collector, Alwar 7. VAN VIHARKOTHI RESTORATION & • Forest Department CONSERVATION (DHOLPUR) • Collector, Dholpur 8. PROGRESS OF PENDING 11 HOSTELS OUT OF • Education-Secondary 186 SHARDE GIRLS HOSTELS • Collector, Pali • Collector, Banswara • Collector, Barmer • Collector, Jalore • Collector, Pratapgarh 9. PROGRESS OF PENDING 4 HOSTELSOUT OF 26 • Education-Technical WOMEN HOSTEL AT EXISTING POLYTECHNIC • Collector, Bikaner COLLEGES • Collector, Sikar • Collector, • Collector, Alwar • PWD 10. PROGRESS OF • Forest Department POKARAN-FALSOOND-BALOTRA-SIWANA • PHED WATER SUPPLY PROJECT • Collector, Jaisalmer • Collector, Barmer 11. PROGRESS OF CHAMBAL • PHED SWAIMADHOPUR-NADAUTI WATER SUPPLY • Collector, Sawai Madhopur PROJECT • Collector, Karauli 12. CONSTRUCTION OF 7NEW HOSTELS FOR SC • Social Justice & Empowerment BOYS & GIRLS Department • Collector, Jaipur • Collector, Dausa • Collector, Sawai Madhopur • Collector, Hanumangarh • UDH • PWD Programmes 13. REVIEW OF PROGRESS OF MOU OF • Industries Department RESURGENT • Collector, Ajmer • Collector, Alwar • Collector, Banswara • Collector, Baran • Collector, Barmer • Collector, Bharatpur • Collector, Bhilwara • Collector, Bikaner • Collector, Bundi • Collector, Chittorgarh • Collector, Churu • Collector, Dausa • Collector, Dholpur • Collector, Dungarpur • Collector, Ganganagar • Collector, Hanumangarh • Collector, Jaipur • Collector, Jaisalmer • Collector, Jalore • Collector, Jhalawar • Collector, Jhunjhunu • Collector, Jodhpur • Collector, Karauli • Collector, Kota • Collector, Nagaur • Collector, Pali • Collector, Pratapgarh • Collector, Rajsamand • Collector, Sawai Madhopur • Collector, Sikar • Collector, Sirohi • Collector, Tonk • Collector, 14. REVIEW OF LAND RECORD MORDNIZATION • Revenue Department PROJECT Raj Vikas Chief Minister's Information System

( 1 ) Grievance: GRIEVANCE ANALYSIS OF REVENUE DEPARTMENT

Location Rajasthan Citizen Name ALL Grievance Registration Date Grievance ID Owner Department Revenue Mobile No. Concern Department Department Revenue Department

Brief : -

Key Officials: 1 ACS,Revenue Department

Issue And Difficulties for Considerations Issues Response Status 1 Broad reasons for rejection 1. Grievances are not covered under the Fully Resolved of such huge number of rules. grievances? 2. Many grievances have not attached proper ACS,Revenue Department documents. 2 About 50% grievances are Now there is no other category at present Fully Resolved under categories others. and subject has been enlarged. Major bifurcation of these others? ACS,Revenue Department 3 645 grievances are pending Regarding pendancy regular monitoring has Fully Resolved since more than 1 year and been started for disposal of long awaited 847 pending for 6 months to grievances. 1 year. Why huge number is pending since a long time and strategy of department to resolve these within one month? ACS,Revenue Department 4 Is there any verification Verification system exists at district level. Fully Resolved process to cross check the relief to complainant? ACS,Revenue Department

Page 3 of 30 5 What is the internal Monthly/ Fortnightly monitoring has been Fully Resolved monitoring mechanism of started at state level and district level. grievances at State level and District level in department? ACS,Revenue Department

Page 4 of 30 Raj Vikas Chief Minister's Information System

( 2 ) Grievance: SH. BANSHI LAL S/O BALWANTA RAM

Location Jodhpur Citizen Name Sh. Banshi Lal S/O Balwanta Grievance Registration 21/07/2016 Ram Date Grievance ID 0716079844030 Owner Department Rural Development Mobile No. 9982131550 Concern Department Department (NREGA) Rural Development Department (NREGA), Collector, Jodhpur

Brief : - • Complainant had worked in MGNREGA for serving drinking water. • Muster Roll nos. are 4645, 5479, 6241, 7127 and 7938 in village-NokhraBhatiyan, GP- NokhraBhatiyan, Block-Bap, Dist-Jodhpur. • Whenever, complainant visited office of BDO, he was replied that SITE is locked. • He has not been paid for this work yet

Key Officials: 1 Secretary,Rural Development Department (NREGA) 2 Collector, Jodhpur

Issue And Difficulties for Considerations Issues Response Status 1 The grievance was District Collector/DPC has instructed all Fully Resolved transferred between officials periodically for taking necessary X.En.,ZilaParishad, Jodhpur action in all such pending matters and as far and BDO, Baap and Phalodi as issues related to MGNREGA monthly for a number of times. What review meetings were taken in which delayed was the Collector's payment of labour and material were intervention in the matter? examined and concern were directed to take Collector, Jodhpur necessary action. FTO has been generated on 18-08-2017. 2 Why has the person not The work on which the person worked was Fully Resolved been paid due amount after closed on MIS without making payment to all more than year? workers worked on it and therefore the Secretary,Rural payment order could not be generated. Now Development Department the Fund Transfer Order issued to make (NREGA) payment to the incumbent.

Page 5 of 30 3 Why has the person not The concern gram panchayat in which the Fully Resolved been paid due amount after concerned work pertains, was shifted from more than year? PS Bap to PS Phalodi. Thereafter ownership Collector, Jodhpur of the matter was not taken by both the BDO and this resulted in delay of nearly seven month. 4 What action has been taken Then BDOs of concerned Block "Baap" and Fully Resolved against officials responsible "Phalodi" has been charge sheeted. for delay? Secretary,Rural Development Department (NREGA) 5 What action has been taken Charge sheet has been issued against Fully Resolved against officials responsible concerned BDO's of PS Bap and PS for delay? Phalodi. Collector, Jodhpur

Page 6 of 30 Raj Vikas Chief Minister's Information System

( 3 ) Grievance: SH. GYARASI LAL S/O MISHRI LAL

Location Dausa Citizen Name Sh. Gyarasi Lal S/O Mishri Lal Grievance Registration 02/02/2017 Date Grievance ID 02172762120486 Owner Department Collector, Dausa Mobile No. 9700000000 Concern Department Collector, Dausa

Brief : - Removal of encroachment on Temple land and pond land & encroachment on land of passage way in village Jhhera, Tehsil & Dist. Dausa.

Key Officials: 1 Collector, Dausa

Issue And Difficulties for Considerations Issues Response Status 1 The grievance was allocated Reminders on 1st March and 3rd May, 2017 Fully Resolved from Collector, Dausa to have been given to tehsildar on portal. Tehsildar, Dausa. But after 6 Show cause notice has been issued to months Tehsildar, Dausa officiating tehsildar for disciplinary action as again sending Collector for he failed to upload report properly on necessary action. What was Sampark portal. the Collector's intervention in the matter? Collector, Dausa 2 Why has encroachment on Encroachment has been removed from pond Fully Resolved this land not removed yet land, charagaha land and land of passage Collector, Dausa way on 08th March, 2017. Encroachment from temple land has been removed on 19.08.2017.

Page 7 of 30 Raj Vikas Chief Minister's Information System

( 4 ) Grievance: ACTION TAKEN REPORT ON DIRECTION GIVEN IN PREVIOUS RAJVIKAS VC

Location Citizen Name Grievance Registration Date Grievance ID Owner Department Planning Mobile No. Concern Department Department

Brief : -

Key Officials: 1 Collector, Ajmer 2 Collector, Alwar 3 Collector, Banswara 4 Collector, Baran 5 Collector, Barmer 6 Collector, Bharatpur 7 Collector, Bhilwara 8 Collector, Bikaner 9 Collector, Bundi 10 Collector, Chittorgarh 11 Collector, Churu 12 Collector, Dausa 13 Collector, Dholpur 14 Collector, Dungarpur 15 Collector, Ganganagar 16 Collector, Hanumangarh 17 Collector, Jaipur 18 Collector, Jaisalmer 19 Collector, Jalore 20 Collector, Jhalawar 21 Collector, Jhunjhunu 22 Collector, Jodhpur 23 Collector, Karauli 24 Collector, Kota 25 Collector, Nagaur 26 Collector, Pali 27 Collector, Pratapgarh 28 Collector, Rajsamand 29 Collector, Sawai Madhopur 30 Collector, Sikar 31 Collector, Sirohi

Page 8 of 30 32 Collector, Tonk 33 Collector, Udaipur 34 ACS,Education-Higher 35 Pr. Secretary,Energy Department 36 Secretary,Food and Civil Supplies Department 37 ACS,Forest Department 38 Pr. Secretary,Home Department 39 Pr. Secretary,Home-Police 40 Secretary,Labour & Employment Department 41 Secretary,Labour(Directorate of Employment) 42 Secretary,Labour(Directorate of Labour) 43 Secretary,Labour-ESI 44 Secretary,Labour-Factory and Boilers Department 45 Secretary,Labour-RMOL 46 Secretary,Labour-Skills, Employment and Entrepreneurship 47 Pr. Secretary,LSG 48 Pr. Secretary,PHED 49 Pr. Secretary,PWD 50 ACS,Revenue (Colonisation) Department 51 ACS,Revenue Department 52 ACS,Rural Development Department 53 ACS,Rural Development Department (NREGA) 54 ACS,Social Justice & Empowerment Department 55 ACS,Tourism Department 56 Pr. Secretary,UDH 57 Pr. Secretary,Water Resources 58 Secretary,WCD( I.C.D.S) 59 Secretary,Women Empowerment Department 60 Pr. Secretary,Medical & Health Department 61 ACS,Panchayati Raj Department

Page 9 of 30 Raj Vikas Chief Minister's Information System ( 5 ) CONSTRUCTION OF BYEPASS FOR VILLAGE JETHANA (AJMER)

Location : District- Ajmer PS- Approval Date : 24/11/2014 Project Cost : 8 Cr. Pisangan Constituency- Completion Date : Nasirabad Revised Date :

Physical progress : Nil

Brief :- Construction of Bye Pass for village Jethana in has been announced in budget 2014-15 (Para no 359.0.0). At Present heavy traffic of Shree Cement and Ambuja Cement at Ras passes through habitated portion of Jethana village, as a result accidents have occurred in Jethana village. It is necessary to divert traffic passing through Jethana village by constructing 4.4 km long Bye pass. Administrative and Financial sanction has been issued on 24-11-2014 amounting to Rs 8 Crore.

Land acquisition is in process. NIT will be floated after approval of award for land acquisition work.

Key Officials: 1 Pr. Secretary,PWD 2 Collector, Ajmer 3 ACS,Revenue Department

Issue And Difficulties for Considerations Issues Response Status 1 Administrative and There is no issue of land acquisition pending at the Fully Resolved Financial sanction was issued in Nov., 2014. government level. Why is Land acquisition pending so long? ACS,Revenue Department 2 Administrative and SDO Pisangan appointed LAO on 01.04.2015, Partially Resolved Financial sanction was issued in Nov., 2014. request sent to PWD for providing proposal as per Why is Land acquisition new rules under the new LA Act. New rules were pending so long? received on 05-10-2016. Proposals sent to Collector, Ajmer ACS-PWD on 01-11-2016 for notification. Notification issued in Government Gazette by PWD on 08.03.2017 & received on 17.07.2017. SDO/LA sent final award to collector on 31.07.2017; Collector sent award to PS-PWD for approval on 03.08.2017 letter-10505. Once funds received; award shall be disbursed in 15 days. Page 10 of 30 3 When was Collector A request was made to District Collector Ajmer vide Fully Resolved contacted by PWD for land acquisition? What SE PWD letter no 6319 dated 01-12-14 for efforts made by appointment of LA officer for LA proposed Bye Department to expedite? Pass. Pr. Secretary,PWD SDO Nasirabad was appointed as LA officer. Notification under section -11 of Rajasthan Right to Fair C& Tin LA , R& R act,2013 published in Gazette on 10 March , 2017. Award submitted to Collector Ajmer on 24-04-2017 . Award amounting of Rs 1,29,30,387/- Rs. submitted CE&As PWD on 16.08.2017 and sanction of award issued on 17.08.2018. 4 Revised completion date 1) Taking Possession of Land and Preparing Fully Resolved / timeline for the work? Pr. Secretary,PWD Detailed Project Report - 15-09-2017 2) Floating NIT and receipt of tenders - 31-10-17 3)Award of work- 10-11-2017 4) Completion of Work - 09-07-2018

Page 11 of 30 Raj Vikas Chief Minister's Information System ( 6 ) CONSTRUCTION OF MINI SECRETARIAT (SRIGANGANAGAR & ALWAR) Location : District Hq. Approval Date : Project Cost : 0 Cr. SRIGANGA NAGAR & Alwar Completion Date : Revised Date :

Physical progress : Nil

Brief :- Mini secretariat Sri-Ganganagar & Alwar is to be constructed to facilitate civilians of the district. All administration can be brought under one roof so that civilians may get rid of botherness from the different government offices situated at different places.In Sriganganagar the project has not been initiated yet. In Alwar the progress is as below.

Approval Date 21.03.2011 Completion Date 18.06.2015 Sanction Date 21.03.2011 Revise Completion Date 31.03.2017 Date of work order 05.06.2013 Total found released 85.00 Cr. Project Start Date 18.07.2013 Expenditure 59.25 Cr.

Key Officials: 1 Pr. Secretary,G.A.D. 2 Collector, Ganganagar 3 Collector, Alwar

Issue And Difficulties for Considerations Issues Response Status 1 Why have detailed According to Budget announcement No. 224 Partially Resolved proposals and maps not been finalized yet? (2010-11 ) & 211 (2014-15) a mini secretariat in Pr. Secretary,G.A.D. District Head Quarter Alwar was identified among other 11 Districts. The construction agency of Alwar Mini secretariat is UIT Alwar and the due date of completion was 31.3.17. GAD has written several letters to Collector regarding completion certificate and final expenditure but till date no reply is received from Alwar.

Page 12 of 30 2 Why have detailed There were no Govt. land available for mini Partially Resolved proposals and maps not been finalized yet? secretariat at District HQ So the project was Collector, Ganganagar proposed on existing land of Collectorate,SP office and Jail and intimated to Govt. Jail authorities denied for shifting the jail So It was not possible to construct Mini secretariat at the proposed site. As discussed with the in charge secretary ,Mini Secretariat building was proposed in old sugar mill campus and proposals regarding land and construction of building was submitted to Finance Dept GOR.

3 Why have detailed Detailed Proposals and Maps has been finalized and Partially Resolved proposals and maps not been finalized yet? RCC Work has been completed for Ground and Collector, Alwar Three Floors. 4 Has the required land for Yes , Land has been located in old sugar mill Partially Resolved the project been located? campus at Sri ganganagar and are under Collector, Ganganagar consideration of the govt.

5 Has the required land for Work is under progress over the finalized Land Near Partially Resolved the project been located? Bhawani Top Circle. But due to shortfall of budget Collector, Alwar the work has been presently put on hold. 6 What efforts have been GAD has written several letters to Collectors Partially Resolved made by Department to expedite? Ganganagar. Pr. Secretary,G.A.D. 7 Revised completion date Nill Unresolved / timeline for the work? Pr. Secretary,G.A.D.

Page 13 of 30 Raj Vikas Chief Minister's Information System ( 7 ) VAN VIHARKOTHI RESTORATION & CONSERVATION (DHOLPUR) Location : Dholpur Approval Date : Project Cost : 5.61 Cr. Completion Date : Revised Date :

Physical progress : Nil

Brief :- Van Vihar Kothi is building inside the Van Vihar Sanctuary. A restoration plan has been prepared but funding has not received. Project is now being converted to PPP mode.

Key Officials: 1 ACS,Forest Department 2 Collector, Dholpur 3 ACS,Finance Department

Issue And Difficulties for Considerations Issues Response Status 1 Restoration & 1. Finance Department refused funding (25.06.2017) Partially Resolved Conservation work amounting to Rs. 1 Cr. hence decision taken to implement the project on was announced in PPP mode (23.06.2017) Budget 2014-15. Why is 2. Work order given to PDCOR for PPP mode it pending so long? Reasons for delay and operationalization (28.07.2017) cost escalation (if any). 3. PPP mode bid preparation under progress. ACS,Forest Department 2 Restoration & 1. Consultant M/S Abha Narayan Lamba, Partially Resolved Conservation work amounting to Rs. 1 Cr. has raised estimated cost of Rs 589.66 lac for was announced in renovation and conservation of Van Vihar Kothi, Budget 2014-15. Why is which was raised to tourism department. it pending so long? Reasons for delay and 2. Fund requirement was further shared with finance cost escalation (if any). department. Collector, Dholpur 3. Finance department has refused the funding hence decision was taken to implement the project on PPP mode on 23.06.17. 4. Work order was given to PDCOR for PPP mode operationalization on 28.07.17 5. PPP mode bid preparation is under progress.

Page 14 of 30 3 Strategy for early The Project is proposed to be done on PPP Mode. Partially Resolved commencement and completion of the PD COR is finalising the bid for selection of partners. project? ACS,Forest Department

Page 15 of 30 Raj Vikas Chief Minister's Information System ( 8 ) PROGRESS OF PENDING 11 HOSTELS OUT OF 186 SHARDE GIRLS HOSTELS Location : 186 Educationally Approval Date : 05/12/2014 Project Cost : 112.24 Cr. backward Blocks Completion Date : 31/03/2017 Revised Date : 31/12/2017

Physical progress : 94.09%

Brief :- Construction of 186 Girls Hostels in all 186 EBB's in Rajasthan have been sanctioned in previous years. 149+26=175 Girls Hostels have been completed and all are in running position. 11 Girls Hostels construction work is under progress.In budget announcement 2016-17(Para 150), the sanction of 47.88 crore provided to upgrade the hostels up to 100 capacity. Up-gradation 49 Girls Hostel works are under progress.

Key Officials: 1 Secretary,Education-Secondary 2 Collector, Pali 3 Collector, Banswara 4 Collector, Barmer 5 Collector, Jalore 6 Collector, Pratapgarh

Issue And Difficulties for Considerations Issues Response Status 1 Works of Girls Hostel Inquiry at 2 different levels is pending. The Unresolved Raipur, Jaitaran & Sojat are delayed due to committee constituted by District Collector Pali under inquiry against direction of RAMSA,Jaipur will give its report by 19th contractor. Status of the August,2017. Inquiry by ACB, as informed by Add. inquiry and pending at which level? SP, Pali, shall be completed shortly and it's report Collector, Pali will be submitted to their headquarter. 2 Slow progress has been 2 Hostels have been made functional, For the Fully Resolved reported in 8 hostels. What action has been remaining notices issued & financial penalty has initiated and efforts been imposed on the contractors for delay. made to expedite? Presently work is ongoing. Secretary,Education-S econdary 3 Slow progress has been As per DPC RMSA work of Girls Hostel Sajjangarh Partially Resolved reported in 8 hostels. What action has been is being done slowly by contractor. As per initiated and efforts agreement penalty of Rs 5.28 Lakhs has been made to expedite? imposed. Tentatively work will be completed by Oct Collector, Banswara 2017.

Page 16 of 30 4 Slow progress has been Chohtan baalika chatrawas Partially Resolved reported in 8 hostels. What action has been Ground flor has been completed, electrical work is initiated and efforts remaining. Work of first floor is in its finishing level. made to expedite? Work is delayed by constructor. Hostel is proposed Collector, Barmer to start till 30 sept 2017 Baytu baalika chatrawas Work of Ground flor and first flor is in its finishing level. Hostel is proposed to start till 31 Oct 2017 5 Slow progress has been 1-Ahore- Ground floor of the hostel is completed and Partially Resolved reported in 8 hostels. What action has been 32 girls have been shifted. 1st Floor will be initiated and efforts completed by 31-08-2017 and full hostel will be made to expedite? taken over and used from 1st week of Sept. 2017. Collector, Jalore 2-Ummedabad and Jaswantpura- Hostels construction will be completed by 30-09-2017. Mean while 22 Girls in Ummedabad and 31 Girls in Jaswantpura have been admitted and accommodated in nearby Kasturba Residential School. These girls will be shifted to the Sharde Hostel on completion in 1st week of Oct.17 6 Slow progress has been Sharde Girls Hostel Arnod has been completed and Fully Resolved reported in 8 hostels. What action has been started on 16th August, 2017. Currently, 36 girls are initiated and efforts enrolled in the Arnod hostel against 100 seats. made to expedite? Sharde Hostels in other 4 Blocks of district i.e. Collector, Pratapgarh Chhotisadri, Dhariyawad, Peepalkhunt and Pratapgarh are already in running condition. 7 Works of up-gradation of Tender Process has been completed, for 49 pending Partially Resolved 49 Girls Hostels are still pending due to retender works & 11 works have been completed. 36 work process. Status of likely to be completed from Aug. to Dec. 2017. One retender process and work will be completed by March 2018. One work timeline for Completion? Secretary,Education-S will be completed after receiving ACB enquiry econdary report.

Page 17 of 30 Raj Vikas Chief Minister's Information System ( 9 ) PROGRESS OF PENDING 4 HOSTELSOUT OF 26 WOMEN HOSTEL AT EXISTING POLYTECHNIC COLLEGES Location : 26 Existing Approval Date : 19/11/2010 Project Cost : 26 Cr. polytechnic Completion Date : 31/03/2015 Revised Date :

Physical progress : 88.50%

Brief :- Under CSS, 26 Women Hostels at existing polytechnic colleges was sanctioned with the budget of Rs. 26 crores. Out of these 26 Women Hostels, 22 are completed and 04 Women Hostels work are under progress, which will be completed soon.

Key Officials: 1 ACS,Education-Technical 2 Collector, Bikaner 3 Collector, Sikar 4 Collector, Jaipur 5 Collector, Alwar 6 Pr. Secretary,PWD

Issue And Difficulties for Considerations Issues Response Status 1 Project was sanctioned Progress report of remaining 4 Women Hostels is Partially Resolved in November, 2012. Why did department take too enclosed in prescribed format. long time to issue work order. ACS,Education-Techni cal 2 Present status of work of Progress report of remaining 4 Women Hostels is Partially Resolved remaining 4 Women Hostels due to enclosed in prescribed format. contractor.(Bikaner, Sikar, jaipur& Alwar), reasons for delay and timeline of completion? ACS,Education-Techni cal 3 Present status of work of The work of Bikaner hostel is complete and balance Fully Resolved remaining 4 Women Hostels due to three places including Bansawara shall be contractor.(Bikaner, completed by 31.12.2017. Sikar, jaipur& Alwar), reasons for delay and timeline of completion? Pr. Secretary,PWD

Page 18 of 30 4 Present status of work of Civil construction of woman hostel in Govt. Partially Resolved remaining 4 Women Hostels due to Polytechnic College completed in October 2016. contractor.(Bikaner, Minor sanitation, electricity & water supply related Sikar, jaipur& Alwar), work yet to be completed. reasons for delay and timeline of completion? Reasons- Collector, Bikaner 1. Type design was changed by college, which involved increased cost. (1Cr. to 2.5Cr.) 2. Sanction amount was released in two phases and tenders were invited accordingly. 3. Letter of credit for second phase issued after a lapse of two and a half year. Remaining/addition work will be completed by 15-09-2017.

5 Present status of work of Total Sanction Amount = Rs. 95.00 Lacs. Partially Resolved remaining 4 Women Hostels due to Total Exp. Amount = Rs. 94.08 Lacs. contractor.(Bikaner, Work upto sanction has been completed and as Sikar, jaipur& Alwar), intimated by executing agency, PWD, amount reasons for delay and timeline of completion? required to complete remaining work is Rs. 67.83 Collector, Sikar Lacs. Where as, Director Technical Education told that no more money will be allocated except Rs. 6.00 lacs (i.e. upto 100 lacs) as NHRD will not sanction amount more than 100 lacs. So now additional amount to be released from State Govt. for completion of work.

6 Present status of work of The matter is pending between Polytechnic Unresolved remaining 4 Women Hostels due to Department and PWD. contractor.(Bikaner, Work of Women Hostel at Polytechnic College is Sikar, jaipur& Alwar), incomplete . Project Cost initially was 100 Lac and reasons for delay and timeline of completion? completion date was 31-3-15. Total expenditure of Collector, Jaipur rs. 65.28 Lac was done upto March 2014. Only 50 Lac have been transferred to PWD so far. No construction work has been done since last 3 years. XEn PWD City III has given forecast estimate for remaining work of rs. 160.58 Lac to Chief Eng. (Building).

Page 19 of 30 7 Present status of work of Tech. Edu. Department deposited only 20 Lacs and Partially Resolved remaining 4 Women Hostels due to 6.77 Lacs to PWD Alwar against issued Sanction of contractor.(Bikaner, 95 Lacs (Year 2011-12) and 43 Lacs (Dated Sikar, jaipur& Alwar), 20.09.2013) respectively. PWD Alwar issued work reasons for delay and timeline of completion? order of 59.21 Lacs on 17.05.2011. But due to Collector, Alwar budget shortfall remaining work has been put on hold. Now after receiving remaining amount on 17.05.2017, estimate has been prepared & tender will be issued within a week. 8 Reasons for Improper The distribution of budget has been made by Chief Fully Resolved distribution of received budget to related Engineer's office as per the demand made by the divisions by Chief individual divisional office as per requirement of the Engineer (Building) work executed under the contract agreement. PWD, Jaipur? Pr. Secretary,PWD 9 For construction of 7 The excess expenditure has been incurred to make Partially Resolved women hostels expenditure was more the facility fully functional. No proper approval have than allotted budget. been processed as yet. Reasons for excess expenditure? Was there proper approval for it? Pr. Secretary,PWD 10 Why was utilization The utilization certificates have been submitted to Fully Resolved certificate not sent by PWD within prescribed the Technical Education department time to time as time limit? per the actual expenditure incurred on works against Pr. Secretary,PWD the contract agreements.

Page 20 of 30 Raj Vikas Chief Minister's Information System ( 10 ) PROGRESS OF POKARAN-FALSOOND-BALOTRA-SIWANA WATER SUPPLY PROJECT Location : Pokaran (Jaisalmer), Approval Date : Project Cost : 966.77 Cr. Baitu, Sheo, Pachpadra & Siwana Completion Date : 27/09/2015 (Barmer) Revised Date : 29/09/2018

Physical progress : 82.00%

Brief :- Pokaran Falsoond Balotra Siwana Water Supply Project proposed for benefit to 563 villages (177 villages of distt Jaisalmer & 386 villages of distt Barmer) and 3 towns (Pokaran, Balotra & Siwana). Project divide in total 7 packages (SPR -1, 2A and 2B infra work) and (SPR-3A, 3B, 4A & 4B is cluster distribution work). Package SPR-1 is complete and other 6 packages are under progress.

Key Officials: 1 Pr. Secretary,PHED 2 Collector, Jaisalmer 3 Collector, Barmer 4 ACS,Forest Department

Issue And Difficulties for Considerations Issues Response Status 1 Project was sanctioned Project delayed mainly due to delay in work of Partially Resolved in November, 2008. Time overrun by 4 years gravity trunk main in 115 Km from Pokaran to Santra & 4 months approx. Bhakri, by contractor M/s SPML. This is a vital Reason for delay? package of this project on which water supply to 106 Pr. Secretary,PHED villages of SPR 3A, 234 of SPR 4A & 152 villages and 2 towns (Balotra and Siwana) of SPR 4B, total 492 villages and 2 towns is dependent. 2 Initial cost was Rs. The reason for increased cost is due to change of Partially Resolved 966.77 cr and revised cost due to delay is Rs. design period for pipe system from 15 to 30 years, 1454.20 Cr. Responsible change in pipe policy by abandoning use of AC officer for delay? pipes, increasing assessed cost of deposit works Pr. Secretary,PHED etc. The paucity of funds also delayed execution of SPR-1. The revised cost has been got sanctioned from competent authority by producing reasons and facts; wherein individual responsibility is not reflected.

Page 21 of 30 3 The forest clearance is User Agency submitted online proposal for diversion Partially Resolved pending. Expected time line to get cleared. of 0.289 ha. forest land for Pokran Falsund Balotra ACS,Forest Siwana Lift on dated 1.08.2014. Observations Department regarding KML file, DGPS map, FRA, NFL etc. found in proposal. UA resubmitted this proposal repeatedly but compliance of observations is yet not complete. Executive Engineer was requested on 8-08-2017 to come to Office for discussion . UA came to office on dated 18.8.2017. EDS was briefed. 4 The forest clearance is Application for forest clearance submitted on Partially Resolved pending. Expected time line to get cleared. 01.08.2014, The equivalent area non forest land Pr. Secretary,PHED allotted by District Administration. Forest clearance proposal is pending with CCF, Jaipur. As discussed with Forest officers, some observations regarding mapping have been noticed and it is likely to get clearance in 3 months. Forest land is required for construction of Master Balancing Reservoir at Siwana and Ground Level Service Reservoir at Sela in the District Barmer. 5 What is the timeline for • Project of 115 Km gravity trunk main from Pokaran Partially Resolved the completion of the project? to Santra Bhakri, rescinded, from M/s SPML and Pr. Secretary,PHED balance work awarded to M/s GVPR, who has started the work. • Other packages shall be completed simultaneously by Sept 2018. • Infra of 71 villages of Distt. Jaisalmer is ready. 11 villages have been partially commissioned and balance 60 villages are likely to be commissioned by Dec-2017. (Details attached)

Page 22 of 30 Raj Vikas Chief Minister's Information System ( 11 ) PROGRESS OF CHAMBAL SWAIMADHOPUR-NADAUTI WATER SUPPLY PROJECT Location : SawaiMadhopur, Approval Date : Project Cost : 478.91 Cr. Karauli, Gangapur city, Todabhim Completion Date : Revised Date : 31/03/2017

Physical progress : Nil

Brief :- Chambal Swai Madhopur-Nadauti Water Supply Project proposed for benefit to 3 towns (Sawai Madhopur, Karauli, Gangapur city), 109 villages and 98 habitations of Sawai Madhopur and Karauli districts.

Key Officials: 1 Pr. Secretary,PHED 2 Collector, Sawai Madhopur 3 Collector, Karauli

Issue And Difficulties for Considerations Issues Response Status 1 Completion date of The reasons for delay are: Partially Resolved Package-1 was 2.10.2008 and revised • Application for environment clearance submitted on completion date was 17.12.2004 and issued on 12.4.2010. 31.03.2017. While • CWC was requested for vetting of Design Drawing physical progress is only 71%. Reason for delay? of intake on 11.02.2011. Due to delay, decided to Pr. Secretary,PHED get vetted from IIT , approval was issued on 12.09.2012. • Works other than Intake were started on 12.01.2006. The firm carried out the works with slow pace. Work is in progress. (Detailed are attached) 2 Completion date of The work was awarded to M/s SPML Infra Ltd. by Partially Resolved Package-2 was 2.04.2016. While Addl. Chief Engineer(Project) PHED Bharatpur vide physical progress is only no. 1272-86 dated 23.9.2013 for an amount Rs. 32%. Reason for delay? 234.90 Cr, which was to be completed in 30 months Pr. Secretary,PHED i.e. by date 02.4.2016. Due to slow progress, the contractor has completed work of Rs. 69.92 Crs. upto 31.7.2017. L.D. Rs. 7.79 Cr. levied for delay.

Page 23 of 30 3 Initial cost was Rs. Initially project was sanctioned on 02.11.2004 and Partially Resolved 478.91 cr and revised cost due to delay is Rs. Package-I transmission main work was awarded to 567.0 Cr. Responsible M/s SPML Infra on 23.9.05. In year 2013, distribution officer for delay? works of 109 villages were revised as per prevailing Pr. Secretary,PHED rates of year 2013 and work related to distribution system for 109 villages was awarded. Due to preparation of estimates on the basis of prevailing rates the cost was increased in revised sanction. 4 What is the timeline for Timeline for completion: Partially Resolved the completion of the project? Package I:- Pr. Secretary,PHED i. Intake and piers - June 2018. ii. Approach bridge, pipe line, control room at river front - Aug. 2018. iii. WTP, pump house & settling tank - June 2018. iv. Pipe line from Gangapur city to Sawaimadhopur & pump house at Gangapur city - Aug. 2018. Package II:- Pipe line, pump houses, ESRs, distribution system etc. - Sept. 2018.

Page 24 of 30 Raj Vikas Chief Minister's Information System ( 12 ) CONSTRUCTION OF 7NEW HOSTELS FOR SC BOYS & GIRLS

Location : Dausa-I&II , Approval Date : 05/12/2016 Project Cost : 9 Cr. (S.Madhopur), Noher (Hanumangrah) , Completion Date : 31/12/2017 Jagatpura, Revised Date : 30/04/2018 Jamuvaramgrah, Shahpura (Ja Physical progress : Nil

Brief :- In the compliance of Budget Announcement 2016-17 Para 111, 7 New Hostels are to be constructed.

Demolition of old Girl hostel has been recommended by three member committee headed by ADM Dausa on 30.11.2016.

Demolition of old ST girls' hostel has been recommended for new construction.

Collector, Jaipur has been requested for allotment of land on 02.09.2016, 03.03.2017, 05.05.2017 & 07.06.2017.

JDA have been requested for allotment of land in Jagatpura & Jamuvaramgrah on 02.08.2016, 02.08.2017.

Key Officials: 1 ACS,Social Justice & Empowerment Department 2 Collector, Jaipur 3 Collector, Dausa 4 Collector, Sawai Madhopur 5 Collector, Hanumangarh 6 ACS,UDH 7 Pr. Secretary,PWD

Issue And Difficulties for Considerations Issues Response Status

Page 25 of 30 1 Reasons for delay in 1-JDA has sent complete proposal for allotment of Unresolved allotment of lands for Jagatpura & 2798.61 Sqm. land for S.C. Boys Hostel to State Jamuvaramgarh hostels Govt. on 25-07-17. Case is being referred back to in Jaipur are pending. JDA for examination of the proposals again to ACS,UDH assess the actual requirement of land keeping in view the DPR/construction plan. 2-Land has been identified in Jamvaramgarh. Matter will be placed before the LPC(Land & Property Committee) of JDA on 22-08-17.

2 Reasons for delay in The matter is related to JDA . As per report of JDA Partially Resolved allotment of lands for Jagatpura & for Jagatpura Hostel decision has been taken in LPC Jamuvaramgarh hostels meeting dated 22-3-2013 for allotment of land area in Jaipur are pending. 2798.61 sq mtrs. in Om Sai Sirdipuram scheme at Collector, Jaipur residential reserve price. Matter sent to UDH for approval of free of cost. For Jamwaramgarh hostel land identified in Khasra N. 576 in Village Jamwaramgarh . Matter will be presented in next LPC Meeting dated 22-8-17 3 The hostel is proposed Hostel being demolished is also for SC category Fully Resolved for SC category but in Dausa old ST girl's (Girls). Currently, hostel is being run at rented hostel is being building in Dausa. demolished. What are the arrangements for old ST girls' hostlers? Collector, Dausa 4 Timeline of construction For construction of Two Hostels at Dausa, sanction Partially Resolved of these hostels. ACS,Social Justice & has been issued, work will be started by PWD soon. Empowerment For hostels at Khandar and Nohar, work has been Department started by PWD. Time line for completion of construction work has been assigned as 30.4.2018. For Hostel at Shahpura district administration has recently allotted old School Building which requires repair. For Jamwa Ramgarh land allotment is in process at the level of JDA and for Jagatpura pending at the level of UDH for free allotment

Page 26 of 30 5 Timeline of construction Time line of construction of these hostels as under:- Fully Resolved of these hostels. Pr. Secretary,PWD 1. Jhunjhunu 2 nos- 31.10.2017 2. Salumber 1 no. - 31.12.2017 3. Noher and Khandar 2 nos. 31.03.2018 4- Dausa 1 no. 30.04.2018 5- Alwar 1 no.- 8 month from date of allotment of land .

Page 27 of 30 Raj Vikas Chief Minister's Information System ( 13 ) REVIEW OF PROGRESS OF MOU OF RESURGENT RAJASTHAN

Brief :- The summit was held on 19th and 20th November, 2015 at Jaipur.

Total 295 MoUs of expected investment of Rs. 3.2 lac cr were signed.

2.39 lac new employment opportunities expected.

Key Officials: 1 Commissioner,Industries-B.I.P. 2 ACS,Industries Department

Issue And Difficulties for Considerations Issues Response Status 1 Out of total 470 cases 56 have been implemented. The progress of implementation is very slow. ACS,Industries Department 2 Out of 470 cases 141 have been dropped. Reasons? ACS,Industries Department 3 Out of 470 cases 107 cases are under implementation and 48 are pending for approval. Reasons for delay? ACS,Industries Department

Page 28 of 30 Raj Vikas Chief Minister's Information System ( 14 ) REVIEW OF LAND RECORD MORDNIZATION PROJECT

Brief :- National Land Records Modernization Programme (NLRMP) with the ultimate goal of ushering in the system of conclusive titles with title guarantee in the country.

Components of the programme are computerization of land records including mutations, digitization of maps and integration of textual and spatial data, survey/ resurvey and updation of all survey and settlement records, computerization of registration and its integration with the land records maintenance system, development of core Geospatial Information Systems and capacity building.

Key Officials: 1 ACS,Revenue Department

Issue And Difficulties for Considerations Issues Response Status 1 Jamabandi data of 1456 Jamabandi data for 46444 out of 47900 villages has Partially Resolved villages are still not computerized. Reasons been computerized and a copy of Record of Rights and action plan of fully (RoR or Khata) can be obtained from website computerization of http://apnakhata.raj.nic.in. Work is under progress. Jamabandi data. ACS,Revenue Department 2 Only 5 tehsils have been 5 more model Tehsils are likely to get notified by Partially Resolved notified as ONLINE. Action Plan to online all 31-08-2017 and remaining 23 by 30-10-2017. the tehsils. ACS,Revenue Department 3 Till date 12988 map 12988 map sheets have been completely updated Partially Resolved sheets have been completely updated with with Tarmeem and digitized and for 26344 map Tarmeem and digitized. sheets work is final stages. It is targeted that all Total 1,24,000 maps will digitization of existing 124000 maps will be be digitized by 31.12.2017. Reasons for completed 100 percent by 31-12-2017. slow progress and action plan? ACS,Revenue Department

Page 29 of 30 4 Establishment work of Work in 49 Tehsils has been completed, is in Partially Resolved modern record rooms in 205 tehsils in under progress in 205 Tehsils and has not started in 60 progress. When will the Tehsils for want of suitable space. Effort are on for work complete and what rest. is the action plan for 60 tehsils where suitable place is still unavailable? ACS,Revenue Department

Page 30 of 30