Social Safeguard Monitoring Report India: Chennai-Kanyakumari

Home , Ambathurai, Tiruppur district, Vagaikulam, Virudhunagar, Virudhunagar district

Social Safeguard Monitoring Report

Project No. 51308-001 Semestral Report February 2021

India: Chennai-Kanyakumari Industrial Corridor: Power Sector Investment Project

Prepared by Tamil Nadu Transmission Corporation Limited (TANTRANSCO), Government of Tamil Nadu for the Asian Development Bank.

This social safeguard monitoring report is a document of the borrower. The views expressed herein do not necessarily represent those of ADB's Board of Directors, Management, or staff, and may be preliminary in nature.

In preparing any country program or strategy, financing any project, or by making any designation of or reference to a particular territory or geographic area in this document, the Asian Development Bank does not intend to make any judgments as to the legal or other status of any territory or area. Monitoring Report (Social Safeguards)

Document Stage: Draft Loan Number: 3850 (IND) Project Number: 51308-001(IND) Reporting period: August 2020 to December 2020

India: Chennai-Kanyakumari Industrial Corridor Power Sector Investment Project

Prepared by: Tamil Nadu Transmission Corporation Limited (TANTRANSCO) Government of Tamil Nadu

The Monitoring Report is a document of the borrower. The views expressed herein do not necessarily represent those of ADB's Board of Directors, Management, or staff, and may be preliminary in nature.

ABBREVIATIONS

ADB – Asian Development Bank AM – Accountability Mechanism AP – Affected People CKIC – Chennai-Kanyakumari Industrial Corridor CP – Compensation Plan DC – Double Circuit

EA – Executing Agency GCC – General Construction Circle GRC – Grievance Redressal Committee GRM – Grievance Redress Mechanism IR – Involuntary Resettlement kV – Kilovolt MED – Madras Electricity Department MoP – Ministry of Power PIU – Project Implementation Unit PMU – Project Management Unit RP – Resettlement Plan RF – Resettlement Framework ROW – Right of Way SPS – Safeguard Policy Statement SS – Substation TANTRANSCO – Tamil Nadu Transmission Corporation Limited

Contents 1. INTRODUCTION 4 1.1 Background of the Project 4 1.2 Objective and Methodology of the Monitoring Report 4 1.3 Social Safeguard Categorization 5 2. PROJECT IMPLEMENTATION STATUS 6 2.1 Contract award 6 2.2 Land status and work progress in substation 6 2.3 Status of detailed survey & route approval in Transmission Lines 8 2.4 Progress of construction in Transmission Lines 13 2.5 Compensation provisions and process of compensation 16 3. SOCIAL SAFEGUARDS COMPLIANCE STATUS 20 3.1 Compliance status of Compensation Plan 20 4 INSTITUTIONAL ARRANGEMENTS AND GRIEVANCE REDRESS MECHANISM 26 4.1 Project Management Unit and Project Implementation Unit 26 4.2 Grievance Redress Mechanism 26 4.3 Grievance Redress Process and Status of Complaints Received 28 4.4 Consultation and disclosure of project information 31 4.5 Site Visit 33 5 CONCLUSION 37 6 Comments and Responses Matrix 38

ANNEXURES

Annexure 1: Maps of 230 and 110 kV Lines associated with Ottapidaram Substation 42

Annexure 2: Govt of Tamil Nadu G.O. No. 86 (Revised guidelines for compensation) 45

Annexure 3: Sample of filled MED form 48

Annexure 4: TANTRANSCO acceptance letter of operational guideline on GRM 50

Annexure 5: List of affected people received compensation 51

1. INTRODUCTION

1.1 Background of the Project

1. The proposed Chennai-Kanyakumari Industrial Corridor (CKIC) Power Sector Investment Project consists of (i) establishment of 765 kV transmission link from the southern section of CKIC (Madurai) to load centers in North (Chennai) and North Western (i.e. Coimbatore) regions of Tamil Nadu (ii) establishment of 400 kV pooling substation in southern region of CKIC (i.e. Thoothukudi) for collecting power generated from proposed upcoming power plants; and (iii) Institutional capacity building of TANTRANSCO for improved financial management and enhanced gender sensitive workplace.

2. The project is aligned with the following impact(s): industrial development and renewable energy generation in Tamil Nadu will be enhanced; the power supply to industrial demand centers in CKIC will be improved. The project has following outputs:

3. Output 1: A transmission link from the energy hub in southern CKIC to load centers in northern CKIC established. This will establish a 765 kV power transmission link between the energy generation hub in Madurai–Thoothukudi area and load centers in the western and northern parts of the state. The outputs consist of (a) Virudhunagar (765/400/230 kV, 2x1,500 megavolt ampere [MVA] and 2x500 MVA) substation; (b) 765 kV transmission lines from Virudhunagar to Coimbatore; and (c) 400 kV transmission lines to link Virudhunagar substation to several 400/230 kV pooling substations for wind and solar power plants;

4. Output 2: A pooling substation for renewable energy established in southern CKIC. This will establish a pooling substation to receive electricity generated from power plants in the Thoothukudi district. This consists of (a) Ottapidaram (400/230/110 kV, 2x315 MVA and 2x200 MVA) substation; (b) 400 kV transmission lines to connect Ottapidaram substation with several power plants; and (c) 230 kV and 110 kV transmission lines to connect Ottapidaram substation with nearby load centers.

5. Output 3: Enhanced capacity for improved financial management and gender sensitive workplace. This will be delivered through the attached technical assistance grant. This will consist of (i) strengthening the financial management capacity of the Executing Agency, particularly in reconciling intercompany balances and establishing and maintaining a comprehensive fixed asset register; (ii) supporting the Executing Agency in adopting and implementing Indian Accounting Standards; (iii) facilitating the introduction of gender sensitive workplace practices and (iv) enhancing the capacity of TANTRANSCO for monitoring the environment and social impacts of transmission projects.

6. ADB has committed a regular loan of $451.0 million to TANTRASCO from ADB’s ordinary capital resources to help finance the project. The loan was approved on 04 November 2019. The loan agreement was signed on 28 November 2019 and became effective on 17 January 2020. TANTRASCO is the executing agency (EA) of the Project.

1.2 Objective and Methodology of the Monitoring Report

7. The report captures the overall social safeguards compliance status with regard to project’s Compensation Plan (CP) and regulatory requirements. The Compensation Plan is similar to the Resettlement Plan (RP) per ADB’s Safeguard Policy Statement, 2009 (SPS). The current semi-annual monitoring report covers the project implementation status and social safeguards measures during August 2020 to January 2021.

8. The semi-annual monitoring report is based on the review of available data and information received from the respective contractors and TANTRANSCO. In addition, the report captures the observations made by the social safeguard monitoring expert during the site visit held between 21-23 December 2020.

1.3 Social Safeguard Categorization

9. The Project is categorized as ‘B’ for Involuntary Resettlement (IR) and "C" for Indigenous Peoples impacts, as per ADB’s Safeguard Policy Statement, 2009 (SPS).

2. PROJECT IMPLEMENTATION STATUS

2.1 Contract award

10. The project has 7 packages and contract for all the 7 packages has been awarded. The package number, description of package, and name of contractor against each package is given in Table 1 below.

Table 1: Packages and award of contracts

Package Description Name of contractor Contract No. status Package 7 Ottapidaram 400kV Substation & 400 Larsen & Toubro Ltd., Awarded (T-2096) kV Transmission Lines associated India with Ottapidram substation Package 2 Virudhunagar 765/400 kV AIS Megha Engineering & Awarded (T-2086) Substation Infrastructures Ltd., India Package 6 400 kV Transmission Lines Megha Engineering & Awarded (T-19) associated with Virudhunagar Infrastructures Ltd., Substation India Package 4 765 kV Transmission lines Reach 1 Kalpataru Power Awarded (T-20) associated with Virudhunagar Transmission Ltd., Substation India Package 5 765 kV Transmission lines Reach 2 KEC Intl Ltd., India Awarded (T-21) associated with Virudhunagar Substation Package 10 765 kV Transmission lines Reach 3 Transrail Lighting Ltd., Awarded (T-22) associated with Virudhunagar India Substation Package 9 230 and 110 kV Transmission Lines Transglobal Power Ltd. Awarded (T-28) associated with Ottapidaram Substation Source: TANTRANSCO Quarterly Progress Report, September 2020

2.2 Land status and work progress in substation

11. The land ownership of both Virudhunagar and Ottapidaram substation is with TANTRANSCO. The land for Virudhunagar substation has been acquired through negotiated settlement by willing buyer and willing seller mechanism. The land for Ottapidaram substation has been procured by TANTRANSCO through negotiated settlement and through mutual transfer of land from Ind Bharat to TANTRANSCO. There are no persons living or using the substation land informally and therefore there will be no affected people. The status of substation land is given in Table 2.

Table 2: Status of Substation Land

Name of the Substation Total area of Geographical Ownership of Type of land (In Ha) coordinates land Land Virudhunagar 765/400 kV AIS 91.71 East 171146 TANTRANSCO Dry Land Substation North1045715 Ottapidaram 400/230-110kV 25.59 East 175781 TANTRANSCO Black Cotton Substation North 984844 Soil Source: TANTRANSCO

12. Virudhunagar 765/400 kV AIS Substation: According to the data shared by TANTRANSCO as of 20 December 2020, site preliminary works such as site clearance and mobilization has been completed. About 84% of cutting and filling works in the site has been completed. Activities have started in the 400 kV equipment foundations, construction of control room building and compound wall. During the site visit the contractor representatives informed that the impact of COVID-19 has delayed the construction work.

Figure 1: Site of Virudhunagar 765/400 kV AIS Substation

13. Ottapidaram 400/230-110kV Substation: As per the data shared by TANTRANSCO as of 08 January 2020, preliminary works such as bush clearing of entire 64 acres has been completed. Activities are ongoing in the 400 kV equipment foundations and equipment structures. Work on 230 kV equipment foundations and 110 kV equipment foundations is almost completed. The construction work of control room building, switchyard panel room and boundary wall is ongoing.

Figure 2: Site of Ottapidaram 400/230-110kV Substation

2.3 Status of detailed survey & route approval in Transmission Lines

14. The preliminary route alignments were prepared through satellite survey data by Anna University, Tamil Nadu. Based on the GIS survey data, three alternative routes were proposed for each transmission line (Route A, Route B and Route C). The best route for each transmission line was suggested by Anna University in consultation with the field team of TANTRANSCO and taking into consideration various factors such as avoiding habitat area, avoiding crop land, avoiding forest area, avoiding settlements etc.

15. Detailed survey was undertaken along the Anna University suggested line by the respective contractors to finalise the angle points and route alignment based on the actual field condition. The status of detailed survey for the transmission lines is presented in Table 3. The revised route alignment of a transmission line, which is based on the detailed survey by contractor, was sent to TANTRANSCO for review. After the review TANTRANSCO did the route approval of the revised alignment. It is to be noted that TANTRANSCO formed an expert committee to review the proposed route alignment of 765 kV double circuit line from Virudhunagar to Coimbatore. The 765 kV line comprised of three sections. KPTL is responsible for Reach 1, KEC is responsible for Reach 2 and Transrail is in charge of Reach 3 of the line. The expert committee reviewed the route alignments of 3 sections (Reach 1, 2 and 3) and approved the route alignment with some changes. For each transmission line the below paras describe the deviations between the Anna University suggested line and the final route alignment approved by TANTRANSCO.

Table 3: Status of detailed survey in transmission lines

Sl Transmission line detail Total Detailed Detailed Remarks No. route survey survey length complete to be (km) d (In km) done (In km) 1 400 kV DC line from Kamuthi to 71.6 71.6 0 Ottapidaram 2 400 kV DC line from Udangudi to 67.9 67.9 0 Ottapidaram 3 400 kV DC line from Virudhunagar - 70.2 70.2 0 Kayathar 4 765 kV double circuit line 86.9 86.9 0 Virudhunagar - Coimbatore (Reach1) 5 765 kV double circuit line 94.0 94.0 0 Virudhunagar - Coimbatore (Reach 2) 6 765 kV double circuit line 71.4 54.8 16.6 In some stretches Virudhunagar - Coimbatore (Reach 3) detailed survey is pending due to issue created by Vivasaya Sangam parties and landowners 7A 230 kV DC line LILO of T- Sipcot 10.88 10.88 0 Kavanoor SC line to Ottapidaram SS 7B 230 kV DC line LILO of T- Sipcot 6.23 6.23 0 Savasapuram feeder to Ottapidaram 7C 110 kV DC line on DC tower from 8.95 8.95 0 LILO of TT auto-T Sipcot feeder to Ottapidaram SS 7D 110 kV SC line on DC tower from 34.41 34.41 0 proposed Ottapidaram to existing Vijayapuri SS 7E 110 kV DC line on DC tower from 3.31 3.31 0 LILO of Eppodhmvendran to Ottapidaram SS Source: TANTRANSCO

16. 400 kV DC line from Kamuthi to Ottapidaram: According to the data received from TANTRANSCO detailed survey has been completed in the entire 71.6 km line. There is no deviation between the original route alignment suggested by Anna University and the approved route alignment done by TANTRANSCO. Figure 3 shows both the Anna University route and approved route.

17. 400 kV DC line from Udangudi to Ottapidaram: Detailed survey has been completed in the entire 67.9 km line. As per the original route alignment suggested by Anna University the total length was 70 km while the total length of the approved route alignment is 67.9 km. Figure 4 shows both the Anna University route and approved route.

Figure 3: 400 kV DC line from Kamuthi to Ottapidaram

Figure 4: 400 kV DC line from Udangudi to Ottapidaram

18. 400 kV DC Line from Virudhunagar to Kayathar: As per the original route alignment suggested by Anna University the route was from Virudhunagar sub-station to Kayathar and the total length was 72 km. After the change in strategy by TANTRANSCO the approved route now connects from Virudhunagar sub-station to a common point AP 45. A newly built and

activated transmission line connects the Kayathar sub-station to Thennampatti sub-station through the common point AP 45. The total length of the approved route is 70.2 km. Due to the change in route alignment almost all the stretches of the approved route is deviated from the original route. Detailed survey completed in the entire 70.2 km line. Figure 5 shows both the Anna University route and approved route.

Figure 5: 400 kV DC line from Virudhunagar to Kayathar

19. 765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 1): Detailed survey has been completed in the entire 86.9 km line. As per the original route alignment suggested by Anna University the total length of Reach 1 was 86 km while the total length of the approved route alignment is 86.9 km. Figure 6 shows the route alignment of both the Anna University route and approved route.

Figure 6: 765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 1)

20. 765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 2): According to the data received from TANTRANSCO detailed survey has been completed in the entire 94 km line. As per the original route alignment suggested by Anna University the total length of Reach 2 was 87.7 km while the total length of the approved route alignment is 94 km. In some stretches there are major deviations between the route alignment suggested by Anna University and approved route (Refer Figure 7).

Figure 7: 765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 2) 21. 765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 3): According to the data shared by TANTRANSCO as on 19 January 2021, of the total length of 71.4 km, detailed survey completed in 54.8 km. The detailed survey is pending in the remaining section due to RoW issue created by Vivasaya Sangam parties and landowners. The contractor representatives during the discussion highlighted that “Enterupon” permission has been requested from District Collector and meeting with Superintendent of Police has been held to expediate the process of detailed survey. The route alignment of 3.74 km is on hold at CBE Gantry as the sub-station design at Coimbatore is yet to be finalized. The deviation between the route alignment suggested by Anna University and the actual approved route will be known once the detailed survey is completed in the entire line.

22. 230 and 110 kV Transmission Lines associated with Ottapidaram Substation: In this package there are five small transmission lines. According to the data received from TANTRANSCO, detailed survey has been completed in all five transmission lines (Refer Table 4 for detail). The revised route map for these lines is approved except for one line (110 kV DC line on DC tower from LILO of Eppodhmvendran to Ottapidaram SS). There is very minor deviation between the route alignment suggested by Anna University and the actual approved route for four of the five lines. The reasons for minor deviations in these lines at Gantry are due to the fact that the electrical layouts were not finalised during the Anna University survey. The Ottapidaram Substation layout and actual positioning of bays was finalised later. There is major deviation in route alignment for one line (110 kV DC line on DC tower from LILO of Eppodhmvendran to Ottapidaram SS) though in terms of distance there is minor variation. As per the original route alignment suggested by Anna University the total length of this line was 3.24 km while the total length of the revised route alignment is 3.31 km. Annexure 1 shows the route alignment of both the Anna University route and approved route of all the five lines.

2.4 Progress of construction in Transmission Lines

23. In the approved routes check survey was conducted by EPC contractors. Based on the check survey the type of towers, number of angle point and suspension towers and location of suspension towers was finalised. Table 4 gives the total number of towers, number of towers in private land and number of towers in government land for the transmission lines where check survey has been completed.

Table 4: Total towers & no. of towers in private & government land

Sl Transmission line detail Total No. of No. of Remarks No. no. of towers towers on towers on government private land land 1 400 kV double circuit line Kamuthi to 206 206 0 Ottapidaram 2 400 kV double circuit line Udangudi 200 200 0 to Ottapidaram 3 400 kV double circuit line 201 198 3 Virudhunagar - Kayathar 4 765 kV double circuit line 247 227 20 Virudhunagar - Coimbatore (Reach1) 5 765 kV double circuit line Virudhunagar - Coimbatore (Reach 268 261 7 2) 6 765 kV double circuit line 135* 130 5 *Towers as per Virudhunagar - Coimbatore (Reach approved profile 3) by EA as on 19 January 2021 7A 230 kV DC line LILO of T- Sipcot 49 NA NA As the actual Kavanoor SC line to Ottapidaram SS routes are 7B 230 kV DC line LILO of T- Sipcot 27 NA NA approved Savasapuram feeder to Ottapidaram recently by EA 7C 110 kV DC line on DC tower from 44 NA NA information is not LILO of TT auto-T Sipcot feeder to available for no. Ottapidaram SS of towers on 7D 110 kV SC line on DC tower from 149 NA NA private land and proposed Ottapidaram to existing government land. Vijayapuri SS 7E 110 kV DC line on DC tower from 16 NA NA LILO of Eppodhmvendran to Ottapidaram SS Source: TANTRANSCO 24. This is a linear project. The construction work of tower foundation and erection is ongoing. it is being implemented on piecemeal basis after taking consent from affected landowners. Stringing work has been completed in some stretches of the 400 kV DC line from Kamuthi to Ottapidaram and Udangudi to Ottapidaram. Construction work in 230 and 110 kV lines associated with Ottapidaram Substation has not commenced as the route approval was done by EA recently. Below paras gives an update of the progress of constructions for various transmission lines.

25. 400 kV DC line from Kamuthi to Ottapidaram & Udangudi to Ottapidaram: As per the latest implementation status on 08 January 2021, of the total 206 towers in Kamuthi to Ottapidaram line, foundation of 178 towers has been completed. Erection has been completed

in 173 towers. Of the 71.6 km line, stringing has been completed in 29.6 km line. In the Udangudi to Ottapidaram line, of the total 200 towers, foundation of 95 towers has been completed. The erection has been completed in 89 towers. Of the 67.9 km line, stringing has been completed in 15.7 km line. Figure 8 and 9 show the stringing of lines in the Kamuthi to Ottapidaram line.

26. 400 kV DC line from Virudhunagar to Kayathar: According to the physical progress data as on 20 December 2020, of the total 201 towers, foundation of 25 towers has been completed. Tower erection work has not commenced. During the discussion the contractor representatives mentioned that the actual route alignment was approved by TANTRANSCO in September 2020. The foundation work was also delayed due to the impact of COVID-19 and rainfall due to Northeast monsoon.

Figure 8 & 9: stringing of lines in the Kamuthi to Ottapidaram line

27. 765 kV DC line from Virudhunagar to Coimbatore (Reach 1): According to the physical progress data as on 20 December 2020, of the total 247 towers, foundation work has been completed in 112 towers and erection has been completed in 58 towers. During the discussion the contractor representatives informed that initial delay in civil work was happened due to the impact of COVID-19. In addition, construction activities were hampered due to RoW issue created by Vivasaya Sangam parties and landowners. Figure 10 shows the completion of a tower erection and Figure 11 shows a tower erection work in progress in Reach 1 line.

Figure 10: An erected tower in Reach 1 Figure 11: Tower erection work in Reach 1

28. 765 kV DC line from Virudhunagar to Coimbatore (Reach 2): As per the physical progress data as on 22 December 2020, of the total 268 towers, foundation work has been completed in 76 towers and erection has been completed in 65 towers. Stringing work has been completed in 3.8 km. During the discussion the contractor representatives informed that there was delay in civil work due to the impact of COVID-19. In addition, construction of foundation activities was hampered due to RoW issue created by Vivasaya Sangam parties and landowners. Figure 12 is the image of an erected tower on private land and Figure 13 shows an erected tower on government land in Reach 2 of 765 kV DC line.

Figure 12: Erected tower on private land (Reach 2) Figure 13: Erected tower on govt land (Reach 2)

29. 765 kV DC line from Virudhunagar to Coimbatore (Reach 3): According to the implementation status data as on 19 January 2021, of the approved 135 towers, foundation of 33 towers has been completed and erection has been completed in 14 towers. The construction of foundation is being implemented on piecemeal basis after getting the clearance from TANTRANSCO. The contractor representatives during the site visit informed that delay in construction of foundation work was happened due to the impact of COVID-19 and due to RoW issue created by Vivasaya Sangam parties and landowners.

2.5 Compensation provisions and process of compensation

30. To govern the compensation of project affected people the relevant national laws applicable to this project are: (i) The Electricity Act, 2003; (ii) The Indian Telegraph Act, 1885; and (iii) Ministry of Power's (MoP) guideline, 2015 related to compensation for transmission line. The compensation principles adopted for this project also comply with applicable laws and regulations of the Energy Department, Government of Tamil Nadu (Revised guidelines for payment of compensation towards damages in regard to RoW for transmission lines 110 kV and 230 kV lines and above).

31. MoP guidelines, 2015: The Ministry of Power, Govt. of India vide its notification dated 15th October 2015 has issued guidelines for payment of compensation for damages regarding RoW. The said guideline was adopted by Government of Tamil Nadu vide G.O. No. 63 Energy Department dated 22-11-2017 for implementation. As per the guideline the following compensation shall be paid in addition to normal tree and crop damage compensation:

. Compensation @ 85% of land value as determined by District Magistrate or any other authority based on circle rate/guideline value/Stamp Act rates for tower base area (between four legs).

. Compensation towards diminution of land value in the width of Right of Way (RoW) Corridor, due to laying of transmission line subject to maximum of 15% of land value as determined based on circle rate/guideline value/Stamp Act rates.

32. The Government of Tamil Nadu issued orders stating that only in the case of acquiring Right of Way for transmission lines through private negotiation, which will avoid unnecessary litigation for enhanced compensation, the negotiated value of the land may be determined as per the Revenue and Disaster Management Department, which can then be adopted as the basis of compensation for such Right of Way. This was adopted by Government of Tamil Nadu vide Letter No. 41/A/2018, Energy Department dated 16-05-2018 for implementation.

33. G.O. (Ms) No. 86 (Revised guidelines for payment of compensation): In the Government of Tamil Nadu order (G.O. (Ms) No. 86) dated 30-10-2019 guidelines issued for payment of compensation towards damages in regard to RoW for transmission lines 110 kV and 230 kV lines and above. The Government issued the following orders:

1. For the tower base area, the existing provision of 85% shall be enhanced to 100% of assessed land value as per above procedure. 2. For diminution of land value for stringing corridor area (RoW) the existing provision of 15% shall be enhanced to 20% of assessed land value as per above procedure. 3. Rs. 50,000/- is fixed as minimum payable amount for tower base area for first 3 cents, if the assessed land value is less than Rs. 50,000/-. 4. Rs. 10,000/- may be fixed for every additional one cent or part thereof, if the tower base area exceeds 3 cents and this would be added to the minimum payable amount for tower base area.

The guideline also mentions the method of calculation of the assessed value if the 100% assessed value for tower base area is more than the amount calculated as per point 3 and 4 above. Refer Annexure 2 for the detailed guidelines of G.O. (Ms) No. 86 (Revised guidelines for payment of compensation).

34. The provisions of the G.O. (Ms) No. 86 are being implemented for this project for the land compensation of tower base area and land compensation of corridor area (RoW). The compensation amount for crop and tree is based on the rate determined by the Department of Agriculture and Department of Horticulture.

35. Process of Compensation: The affected landowner (people) of the tower base is identified through the local people and verified through the village administrative officer (VAO). After the identification, the Assistant Engineer/Assistant Executive Engineer undertakes consultation with the affected landowner. During the one-to-one consultation, information on the project, compensation provision for affected land, trees and crops are given to affected landowner. After the consent of affected landowner, detailed assessment of affected land, tree and crops is done in the presence of TANTRANSCO official and district revenue official. Work on tower foundation has commenced after taking consent from affected landowners. The particulars of the detailed assessment are filled in the Madras Electricity Department (MED) form issued to affected landowner. The signature of the land owner in the filled MED form is taken before the processing of compensation. The contractor provides the compensation amount in cheque to the affected landowner on behalf of TANTRANSCO. Later TANTRANSCO reimburse the compensation amount to the contractor. A similar process is followed for the compensation of crop and tree for tower foundation and erection and compensation of land, crop and tree for stringing in corridor area (RoW). Sample of filled MED forms are attached in Annexure 3.

36. Status of Compensation payment: Table 5 provides the summary of status of compensation payment per type of compensation for various transmission lines. Figure 14 and 15 show evidence of compensation cheques received by the affected people.

Figure 14: Cheques for compensation received by the affected people (Reach 1)

Figure 15: Cheques for compensation received by the affected people (Reach 2)

37. A format (spreadsheet) has been prepared and circulated to all the EPC contractors to record the data contained in the MED form (affected asset and compensation data). Annexure 5 contains the database of the compensation data of the affected people who have received the compensation during the reporting period.

Table 5: Status of compensation per type of compensation for various transmission lines

Name of Component Compensation Type No. of APs Total Total APs APs transmission line for which APs Compensate compensat Not compensat Compe d Paid (In ed during Compe ion nsated Rupees) Reporting nsated initiated Period

400 kV DC line from Tower foundation Land & crop compensation 194 174 1,02,54,135 174 20 Kamuthi to Approach way during foundation Crop compensation 42 35 7,95,646 35 7 Ottapidaram Tower Erection Crop compensation 26 13 4,73,883 13 13 Stringing (completed in 29.6 km) Crop & tree compensation 0 0 0 0 0 Corridor (RoW) Land compensation 0 0 0 0 0 400 kV DC line from Tower foundation Land & crop compensation 58 39 48,90,170 39 19 Udangudi to Approach way during foundation Land & crop compensation 23 5 1,14,600 5 18 Ottapidaram Tower Erection Crop compensation 8 1 59,150 1 7 Stringing (completed in 15.7 km) Crop & tree compensation 8 1 30,100 1 7 Corridor (RoW) Land compensation 0 0 0 0 0 400 kV DC Line from Tower foundation Land & crop compensation 31 12 9,18,500 12 19 Virudhunagar to Kayathar 765 kV DC Line from Tower foundation Land & crop compensation 131 111 1,33,60,668 111 20 Virudhunagar to Tower erection Crop compensation 91 36 11,20,895 36 55 Coimbatore (Reach 1) 765 kV DC Tower foundation land & crop compensation 109 95 1,76,57,213 95 14 Transmission Line Tower erection crop compensation 19 15 4,28,478 15 4 from Virudhunagar to Stringing (completed in 3.8 km) Crop & tree compensation 5 5 94,923 5 0 Coimbatore (Reach 2) Corridor (RoW) Land compensation 7 6 13,36,771 6 1 765 kV DC Tower foundation Land & crop compensation 33 33 79,22,394 33 0 Transmission Line Tower erection Crop compensation 14 4 1,35,097 4 10 from Virudhunagar to Coimbatore (Reach 3) Source: TANTRANSCO

3. SOCIAL SAFEGUARDS COMPLIANCE STATUS

3.1 Compliance status of Compensation Plan

38. The draft compensation plan (RP) was prepared in 2018 and was disclosed in July 2019. The status of compliance of the compensation plan is mentioned in Table 6.

Table 6: Compliance status of CP

Sl. Type of Definition of Entitlement Details Compliance status No Losses/Impac Entitled ts Persons/Household s) 1 Land affected Titled owner Compensation • Land value to be determined Being complied by tower base up to 85% of based on circle rate/ Guideline (between four land value by the concerned District The Government of Tamil Nadu legs) Magistrate/ or any other issued orders stating that in the authority Value / Stamp Act case of acquiring Right of Way for Rates. transmission lines through private • 85% of land value will be negotiation, which will avoid provided as per the MoP unnecessary litigation for enhanced Guidelines compensation, the negotiated value of the land may be determined as per the Revenue and Disaster Management Department, which can then be adopted as the basis of compensation for such Right of Way. This was adopted by Government of Tamil Nadu vide Letter No. 41/A/2018, Energy Department dated 16-05-2018 for implementation. Refer Annexure 2 for the detailed guidelines.

Sl. Type of Definition of Entitlement Details Compliance status No Losses/Impac Entitled ts Persons/Household s)

In the Government of Tamil Nadu order (G.O. (Ms) No. 86) dated 30- 10-2019 guidelines issued for payment of compensation towards damages in regard to RoW for transmission lines 110 kV and 230 kV lines and above. Refer Annexure 2 for the detailed guidelines. As per the provision in G.O. (Ms) No. 86, for the tower base area (between four legs) the existing provision of 85% shall be enhanced to 100% of assessed land value.

In the project 100% of the assessed land value is provided as land compensation for land affected by tower base. Refer Annexure 5 for the compensation payment of the affected people.

2 Land in the Titled owner Compensation • Land value to be determined by Being complied width of Right up to 15% of the concerned District of Way (RoW) land value Magistrate/ or any other The Government of Tamil Nadu corridor due to authority based on circle rate/ issued orders stating that in the laying of Guideline Value / Stamp Act case of acquiring Right of Way for transmission Rates. transmission lines through private line negotiation, which will avoid unnecessary litigation for enhanced

Sl. Type of Definition of Entitlement Details Compliance status No Losses/Impac Entitled ts Persons/Household s) • Up to 15% of the land value will compensation, the negotiated value be paid as per the MoP of the land may be determined as Guidelines. per the Revenue and Disaster Management Department, which can then be adopted as the basis of compensation for such Right of Way. This was adopted by Government of Tamil Nadu vide Letter No. 41/A/2018, Energy Department dated 16-05-2018 for implementation. Refer Annexure 2 for the detailed guidelines.

In the Government of Tamil Nadu order (G.O. (Ms) No. 86) dated 30- 10-2019 guidelines issued for payment of compensation towards damages in regard to RoW for transmission lines 110 kV and 230 kV lines and above. Refer Annexure 2 for the detailed guidelines. As per the provision in G.O. (Ms) No. 86, for diminution of land value for stringing corridor area (RoW) the existing provision of 15% shall be enhanced to 20% of assessed land value.

In the project 20% of the assessed land value is provided as land compensation for land in the width

Sl. Type of Definition of Entitlement Details Compliance status No Losses/Impac Entitled ts Persons/Household s) RoW corridor due to laying of transmission line. Refer Annexure 5 for the compensation paid to the affected people.

3 Loss of crops All affected Compensation • Compensation at market value Being complied for the households at market value to be computed with assistance following (titled holders, of agriculture department. The loss of standing crops under Impacts: share-croppers, • Advance notice to APs to the tower base; approach way 1. Crops lease holders and harvest crops. during tower foundation and under the non-titled • In case of standing crops, cash erection work; loss of crop in the tower base households) compensation at current market vicinity during the tower erection 2. Crops in the cost to be calculated of mature and stringing work; and loss of crop width of the crops based on average in the RoW corridor is measured RoW production. and recorded in the MED form. 3. Construction related impacts The compensation amount at on crops if market value of crop is computed occur beyond as per the rate determined by the the width of Department of Agriculture. RoW Crop compensation at market value is given to the affected people for loss of standing crops under the tower base, approach way during tower foundation and erection work and loss of crop in the vicinity during the tower erection and stringing work. Refer Annexure 5 for the compensation paid to the affected people.

Sl. Type of Definition of Entitlement Details Compliance status No Losses/Impac Entitled ts Persons/Household s)

4 1. Trees under All affected Compensation • Compensation at market value Being complied the tower base households at market value to be computed with assistance 2. Trees in the (titled holders and of horticulture department. The loss of trees under the tower width of the non-titled holders) • For fruit bearing trees base; approach way during tower RoW compensation at average fruit foundation and erection work; loss 3. Construction production for next productive of trees in the vicinity during the related impacts years to be computed at current tower erection and stringing work; on Trees if market value. and loss of trees in the RoW occur beyond • For timber trees compensation corridor is measured and recorded the width of at market cost based on type of in the MED form. RoW trees. • Timber will be retained by the The compensation amount at owner. market value of tree is computed as per the rate determined by the Department of Horticulture.

Tree compensation at market value is given to the affected people for loss of trees under the tower base, approach way during tower foundation and erection work, loss of tree in the vicinity during the tower erection and stringing work and loss of trees in the RoW corridor. Refer Annexure 5 for the compensation paid to the affected people.

Sl. Type of Definition of Entitlement Details Compliance status No Losses/Impac Entitled ts Persons/Household s)

5 Other All affected Compensation • Compensation at market value Will be complied unexpected households at market value as assessed by the concerned damages authority. (if found) during construction 6 Impacts on Vulnerable affected Vulnerability • Vulnerable affected persons will Will be complied vulnerable households such as assistance to be given priority by the households households headed be considered contractor while engaging for Vulnerable affected households, if by women, physically in kind temporary jobs (where feasible) any, will be identified during the handicapped/disable during construction. data collection by respective d family, and below • Multiple vulnerability will be contractors. The data collection of poverty line as considered as one unit for the vulnerable affected households certified by local vulnerable assistance. has started in January 2021. authority 7 Unanticipated All affected persons Unforeseen Will be complied impacts impacts will be documented and mitigated based on the principles agreed upon in the Compensation Plan and ADBs SPS 2009.

4 INSTITUTIONAL ARRANGEMENTS AND GRIEVANCE REDRESS MECHANISM

4.1 Project Management Unit and Project Implementation Unit

39. The Department of Energy, Tamil Nadu has the overall responsibility for ensuring the project implementation on behalf of Government of Tamil Nadu. Tamil Nadu Transmission Corporation Limited (TANTRANSCO), the state-owned transmission utility, serves as the executing agency (EA) and implementing agency (IA) for implementation of the ADB-financed project. The Government of India channel the ADB loan proceeds to the Government of Tamil Nadu, which then on-lend those funds to TANTRANSCO. The Government of Tamil Nadu provide counterpart funds available to TANTRANSCO as equity investments to augment TANTRANSCO’s capital base.

40. TANTRASCO has existing Project Management Unit (PMU)/Project Implementation Unit (PIU) for the implementation of the proposed project. The PMU at headquarter consists of a technical team and a financial team. The technical team is headed by Director /Transmission project and supported by Chief Engineers and Superintending Engineers. The financial team is headed by Director/Finance and supported by Chief Financial Controller and Financial Controllers.

41. The execution of project at site level is supported by PIU at Madurai and Coimbatore headed by Chief Engineer Transmission project-II, Trichy. The PIU at Madurai consists of a team headed by Superintending Engineer/GCC/Madurai and supported by Executive Engineer/C/765kV /TP Virudhunagar and Executive Engineer/TLC/Tirunelveli. The PIU at Coimbatore is headed by Superintending Engineer/GCC/Coimbatore and supported by Executive Engineer/TLC/Coimbatore.

42. TANTRANSCO is responsible for ensuring compliance with the loan covenants with regard to social safeguards. The PMU is responsible for preparation, planning, and monitoring of the implementation of CP/RP and grievance redress during various phases of the project cycle. In addition, the PMU is responsible for preparation and submission of semi-annual social monitoring reports to ADB.

43. The PIUs at Madurai and Coimbatore are responsible for supervision of the implementation of CP/RP by the EPC contractors. Relevant line departments at the district level are also involved to assist the PIUs in the CP/RP implementation. In addition, the PIUs and relevant district level officials are responsible for assessment and approval of compensation payment in accordance with the entitlement matrix of the CP/RP; ensuring of timely reimbursement of compensation payment made by the contractors; conduct periodic consultations with the affected people; and share required data and information for preparation of semi-annual social monitoring reports.

4.2 Grievance Redress Mechanism

44. Grievance Redress Mechanism (GRM) is an integral and important mechanism for addressing/resolving the concerns and grievances of project affected people. The grievances may include concerns of affected people arising out of implementation of the project, implementation of the Compensation Plan for resettlement impacts as well as adverse

environmental impacts. The Grievance Redressal Committee (GRC) is expected to resolve the concerns and grievances of the affected people during the project cycle. 1. The scope of the GRM is:

. To examine all kinds of concerns or grievances arising out of implementation of the project, including concerns relating to the resettlement compensation, environmental concerns or adverse project impacts, and to resolve such grievances in a transparent manner.

. GRC will not deal with matters pending in the courts of law. . For the GRM, only members of GRC, affected people and/or representatives of affected people will be allowed to participate in the meetings and consultations for 1 grievance redressal. . Decision of the GRC will be communicated to the aggrieved in writing/E-MAIL.

45. Grievances can be initially and informally handled at the site-level. The site level consultation with potential affected parties, TANTRANSCO and contractor can take place in an informal setting and no written records are required to be maintained. If the affected person is not satisfied with the remedial measures proposed by the contractor, he/she can make a formal representation to the GRM. The complaint can relate to either compensation payment or environmental issues.

46. The GRC has been formed by TANTRANSCO in June 2020. An operational guideline on functioning of GRM (GRC) has been developed in consultation with TANTRANSCO which describes the procedures and mechanism for the smooth operation of the GRM and GRC. The procedures have been updated in response to implementation experience and reflects a revised GRC membership and process that is designed to better reflect social norms and community leadership preferences. The operational guideline on GRM (GRC) has been accepted by TANTRASCO. The copy of the acceptance letter is attached in Annexure 4.

47. The GRM consists of two levels. The first level is handled by a GRC established at the General Construction Circle (GCC) level. The second level GRC is established at the project level and is headed by the Chief Engineer (Trichy).

48. The members of the GRC at first level (GCC level) are: Superintending Engineer in respective GCC and a contractor’s representative. During the grievance redressal, the affected people can invite an elected representative of village panchayat/urban ward2 from the his/her village/urban ward to ensure that the interest of the affected people is duly protected as per the extant compensation notification issued as per relevant Government Order.

49. The second level GRM is at project level. The GRC at project level is the appellate authority and will be responsible to address the unresolved complaints from the GCC (first) level. The members of the GRC at project level consist of Chief Engineer/Transmission

1 Informal resolution of grievances before entry into the GRM and all other forms of stakeholder consultation and participation are governed by applicable provisions in the project Initial Environmental Examination [see sections on ‘Consultation and Participation’] and Resettlement Plan [see sections on ‘Future Consultation Strategy’ and ‘Disclosure’]. 2 In Tamil Nadu, village panchayat is the first level of local governance in the rural area and urban ward of City/Municipality/Town forms the first level of local governance in urban area. Under the Tamil Nadu Panchayats Act, 1994, the President of the village panchayat is the elected representative of the village panchayat. Similarly, as per the amended Tamil Nadu District Municipalities Act, 1920, the ward Councillor is the elected representative of the ward of a Municipal Corporation/ Municipality/Town.

Projects-II/Trichy; Chief Financial Controller/TANTRANSCO; and Superintending Engineer/Civil-I/Transmission. Acting as the Chairman of GRC, the Chief Engineer/Transmission Projects-II/Trichy reviews the complaints coming directly to him from any other sources (ADB, affected people, TANTRASCO head quarter) and assign the complaints to the relevant GCC for the redressal. In case it is not addressed at first and second level GRC, the second level GRC can refer the matter to the District Magistrate.

4.3 Grievance Redress Process and Status of Complaints Received

50. The GRC Chairman reviews the complaints coming to him from various sources (directly from affected people, ADB, unresolved complaints from the first level). The GRC Chairman reviews the incoming complaints and associated documents and records and constitute the GRC panel for redressal. The affected people (petitioner) is contacted by the office of Chief Engineer for an amicable solution of the grievance of the affected people. The petitioner is invited to the office of GRC Chairman for discussion. If needed, the committee Chairman conduct an inspection or consultation at the site of the affected party by a TANTRANSCO official assigned for the purpose. The inspection of the site or any other consultation is done with the presence of aggrieved AP and/or a representative nominated by the aggrieved AP. The field inspection report is signed by the TANTRANSCO official and the petitioner. Box 1 shows a field inspection report. Once the grievance is addressed, an action taken report (ATR) is prepared by the GRC Chairman.

Box 1: A field inspection report prepared by TANTRANSCO official

51. During the reporting period from August to December 2020, a total of 8 complaints received from the project affected people. There are 7 individual complaints and one complaint from a group of villagers. All the 7 individual complaints were received by the ADB. As per the procedure ADB forwarded these complaints to the GRC chief for further action. Table 7 provides the details of the complaints received and the status of complaints.

Table 7: Details of complaints received

Sl Transmission Name & address Survey Date Main issue Action taken from Status of No. Line details of complainant no./Patta of complaints TANTRANSCO the no com Complaint plaint 1 Virudhunagar- Sasikumar 333/2 10- Information on Joint inspection held Closed Coimbatore Kalimuthu, 08-20 compensation with petitioner on 765KV DC line Village- amount in the 19.08.2020. It was (Reach 2) Kallimandhaiyam mentioned land found that line is not Ottanchathiram passing through the Taluk, Dindigul petitioner’s land. 2 Virudhunagar- Selvadurai V, 713/2A & 13 - Information on Joint inspection held Closed Coimbatore Village- 1149/3 08-20 whether line is with petitioner on 765KV DC line Kallimandhaiyam passing through the 19.08.2020. It was (Reach 2) Ottanchathiram field or not. If found that line is not Taluk, Dindigul passing information passing through the on compensation petitioner’s land. details. 3 Virudhunagar- S THANGARAJU, 647 24- Information on Joint inspection held Closed Coimbatore Ponnivadi 08-20 whether line is with petitioner on 765KV DC line village, passing through the 26.08.2020. It was (Reach 3) Dharapuram field or not. If found that line is not Taluk, Tiruppur passing information passing through the on compensation petitioner’s land. details. 4 Vanjimarimuthu 511/14 04- Information on Joint inspection held Closed Virudhunagar- K, 09-20 whether line is with petitioner on Coimbatore Kallimanthayam passing through the 05.09.2020. It was 765KV DC line village, field or not. If found that line is not (Reach 2) Oddanchatram passing information passing through the taluk, Dindigul on compensation petitioner’s land. details. 5 Virudhunagar- Lalith Vignesh, 188/1A 03- The petitioner said On 27 October 20, Closed Coimbatore Padiyur village, 08-20 his land is getting GRC Chief informed 765KV DC line Kangeyam Taluk, affected by the to petitioner that (Reach 3) Tiruppur route of the route alignment transmission line. in the relevant He made a request stretch is under to change the finalisation. After alignment. finalisation, further development will be communicated. On 18 January 21, the

petitioner informed that his grievance has been addressed by TANTRANSCO. 6 Virudhunagar- Moorthy, 188/2 23- The petitioner said On 30 September, Closed Coimbatore Padiyur village, 08-20 his land is getting GRC Chief 765KV DC line Kangeyam Taluk, affected by the communicated to (Reach 3) Tiruppur transmission line. the petitioner that He made a request after the completion to change the of detailed survey in alignment. the stretch further development will be communicated. On 18 January 21, the petitioner informed that his grievance has been addressed by TANTRANSCO. 7 Virudhunagar- M.Raja, 189/2 24- The petitioner said On 30 September Closed Coimbatore Padiyur village, 08-20 his land is getting GRC Chief informed 765KV DC line Kangeyam Taluk, affected by the to the petitioner (Reach 3) Tiruppur transmission line. that after the He made a request completion of that the line should detailed survey in avoid his land. the stretch further development will be communicated. On 18 January 21, the petitioner informed that his grievance has been addressed by TANTRANSCO. 8 Virudhunagar- Resident of 22- The residents On 12 November Closed Coimbatore Padiyur village, 10-20 expressed the TANTRANSCO 765KV DC line Kangeyam Taluk, concern that informed the (Reach 3) Tiruppur transmission line is petitioner that the passing through the revised route residential passing through buildings. Padiyur village is approved and the line does not pass over any residential building. On 9 December 20, the petitioner informed to ADB’s AM and GRM that their grievance has been resolved.

52. Complaint from the residents of Padiyur village: A complaint from residents of Padiyur Village was received by TANTRANSCO and Asian Development Bank (ADB)’s Accountability Mechanism, which falls in Reach 3 of the 765 KV Virudhunagar – Coimbatore transmission line. TANTRANSCO held that the villagers made the complaint on the basis of the route alignment mentioned in the Compensation Plan which was prepared in 2018 by Anna University and TANTRANSCO. In the complaint the residents expressed the concern that Anna University suggested transmission line is passing through the residential buildings and requested to change the alignment. A revised route alignment has been prepared by TANTRANSCO in consultation with Anna University and the route was approved by TANTRANSCO on 12 November 2020. TANTRASCO official informed the petitioner that in the approved route map the line is not passing over any residential buildings. On 9 December 2020, the residents of Padiyur village informed to ADB’s Accountability Mechanism and GRM that their complaint has been resolved by TANTRASCO in coordination with Asian Development Bank.

53. In order to address the complaint of resident of Padiyur village ADB had its internal discussions. An action plan has been prepared that suggests preparation of option study analysis of the 3 options/alternatives for justifying the most feasible route for the affected stretch. The option analysis report concluded and recommended that Option-2: (Route B- Approved Route prepared in November 2020 by TANTRANSCO) is the most feasible option taking into consideration social and environment features and specifically taking into consideration the number of buildings and structures, compensation and construction cost. It may be noted here that though the residents of Padiyur village have formally withdrew the complaint from the Accountability Mechanism ADB is taking the measures mentioned in the action plan to close the complaint.

4.4 Consultation and disclosure of project information

54. Consultation with affected people plays an important role during various stages of the project implementation. Consultations make people aware about the project and its potential impacts and during the process obtain the views of the people affected with regard to loss of land, assets and compensation.

55. Consultations with affected people were carried out by TANTRANSCO and contractors during the detailed survey, during determination of agreed compensation values, during disbursement of compensation and during the construction.

56. The dissemination of project information and transmission line alignment to the affected people was made by one-to-one consultation through the contractor during the detailed survey due to COVID-19 restrictions on public meetings/consultations. After the identification of affected people through the village administrative officer, TANTRANSCO officials (AE, AEE) undertook individual consultation with each affected people. During the one-to-one consultation, information on the project, compensation for affected land, trees and crops were given to affected landowner. Information regarding the provisions of G.O. (Ms) No. 86 (Revised guidelines for payment of compensation) is properly explained to the affected landowner during the consultation. After the consent of affected landowner, detailed assessment of affected land, tree and crops was done in the presence of district revenue officials and recorded in the MED form given to the affected landowner. Work on tower foundation was commenced after taking the signature of affected landowners in the MED form.

57. The updating of RP (CP) is being planned. This updating will be based on detailed design and approval of the route alignment by TANTRANSCO for various transmission lines.

Information dissemination and public consultations with the people in the approved route has commenced in transmission lines where there are major deviations from the original line (Anna University suggested line). The information on public consultations will be used for the updating of RP.

Figure 16: Consultation with the landowner of location no. 22/1 (Reach 1) for assessment of land for compensation

Figure 17: Consultation with the landowner at village Solamalayapatti, (Kamuthi to Ottapidaram 400 kV line)

58. The contractor informed the affected landowner about the tentative construction schedule on foundation work well before the commencement of work. The contractor informed the affected people about the tentative construction schedule for erection and stringing in the relevant stretches of the transmission line before the commencement of construction.

Figure 18: Meeting with landowners for foundation work at village Manthittupalayam (765 kV Reach 3)

59. The entitlement matrix in the draft Compensation Plan has been shared to the TANTRANSCO official at the GCC level and district level officials. The entitlement matrix is available with all the EPC contractors. The copy of entitlement matrix and G.O. (Ms) No. 86 (Revised guidelines for payment of compensation) is also available at the project site office of TANTRANSCO inter alia at site office of the contractor.

60. In order to avail broad support from the affected people along the transmission line corridor for smooth implementation of the project, TANTRANSCO will disclose project information in an accessible place, and in a form and language (English and Tamil) understandable to affected people.

61. Information dissemination about the existence of GRM will be done by TANTRANSCO. The information on GRC and information containing instructions on how to make a grievance should be displayed at appropriate places as deemed appropriate by the TANTRASCO official. This will ensure that affected people are aware about the existence of a GRM for the redressal of grievances, if any.

4.5 Site Visit

62. A site visit was conducted by the Safeguard TA consultants (Environment, Safety and Social Safeguard) appointed by the ADB. The site visit was held between 21 December to 23 December 2020. In addition to the visit of selected sites, the consultants held discussion with all the contractors.

63. During the discussion, the contractor representatives provided updates on implementation progress and highlighted implementation challenges. Table 7 provides the summary of the discussion with each contractor.

Table 8: Summary of discussion with contractors

Contractor Summary of the discussion held

Larsen & During the discussion the Social Safeguard Monitoring Expert briefed the contractor Toubro Ltd representatives on the data collection format for social information of affected households and formats for data collection in case of major deviation from the original route (alignment suggested by Anna University). The contractor representatives provided the physical progress of the transmission line. The consultant explained them regarding the importance of providing corridor (RoW) compensation of land, tree and crop before the stringing work and maintaining the compensation data for RoW in a separate excel sheet.

Figure 19: Discussion of consultant with L&T representatives

Megha The contractor representatives provided the physical progress of the transmission line. Engineerin The consultant informed them about the additional data collection requirement since g & the approved route is almost deviated from the route alignment suggested by Anna Infrastructu University. The contractor informed that the foundation work was delayed due to the res Ltd impact of COVID-19 and rainfall due to Northeast monsoon.

Contractor Summary of the discussion held

Figure 20: Discussion of consultant with MEIL representatives

Kalpataru During the discussion the contractor representatives informed that initial delay in civil Power work was happened due to the impact of COVID-19. In addition, construction activities Transmissi were hampered due to RoW issue created by Vivasaya Sangam parties and on Ltd landowners. The Social Safeguard Monitoring Expert briefed them on the data collection format for social information of affected households and formats for data collection in case of major deviation from the original route.

KEC The contractor representatives provided the physical progress of the transmission line. International They highlighted that the initial delay in civil work was due to the impact of COVID-19. Ltd Construction of foundation activities was also hampered due to RoW issue created by Vivasaya Sangam parties and landowners. The consultant briefed them on the data collection format for social information of affected households and formats for data collection in case of major deviation from the original route. The consultant also advised them to record the compensation data for RoW in a separate excel database.

Transrail The contractor representatives mentioned about the physical progress of the transmission line. They highlighted that in some stretches of the line detailed survey is pending due to RoW issue created by Vivasaya Sangam parties and landowners. “Enterupon” permission has been requested from District Collector and meeting with Superintendent of Police has been held to expediate the process of detailed survey. Once the detailed survey is completed in the entire line the extent of deviation from the original route will be known. The consultant explained them in detail the formats to

Contractor Summary of the discussion held

be used for social information of affected households and for major deviation from the original route.

Figure 21: Discussion of consultant with Transrail representatives

TransGlobal The contractor representatives provided updates of the five transmission lines and informed that the civil work has not been commenced. The consultant explained them in detail the formats to be used for social information of affected households and for major deviation from the original route. They were also briefed about how to record compensation data in the excel database.

64. Based on the observation made during site visit and review of physical progress and compensation data following implementation issues were identified.

. In 400 kV DC line from Kamuthi to Ottapidaram and from Udangudi to Ottapidaram stringing is already completed in some stretches of the transmission line corridor (RoW). However, the process of land compensation has not started. . The recording of compensation data for corridor (RoW) was not done in the database for corridor compensation. . There was no display of project information either in the contractor site office/ store area or along the transmission line corridor. There was no display of information regarding the GRM and instructions on how to submit grievance by the affected people.

5 CONCLUSION

65. During this reporting period, the detailed survey by respective contractors has been completed in all the transmission lines except in one line (765 kV DC line Virudhunagar - Coimbatore Reach 3). In the Reach 3 transmission line detailed survey is pending in some portions due to the issue created by Vivasaya Sangam parties and landowners. The final routes for all transmission lines have been approved except in some portions of Reach 3 of 765 kV DC line.

66. The construction work is ongoing in both the substation and in all transmission lines except in one package (Package 9: 230 and 110 kV Transmission Lines associated with Ottapidaram Substation). In the initial period, the impact of COVID-19 has delayed the construction work in the substations as well as transmission lines.

67. The construction of tower foundation and erection is ongoing and in different stages across the transmission lines. Stringing of lines is ongoing in 400 kV DC line from Kamuthi to Ottapidaram and Udangudi to Ottapidaram line. Stringing has commenced in Reach 2 of 765 kV DC line Virudhunagar – Coimbatore.

68. The provisions of the Government of Tamil Nadu G.O. (Ms) No. 86 are being implemented for this project for the land compensation of tower base area and land compensation of corridor area (RoW). As per the provision, 100% of the assessed land value is provided as land compensation for land affected by tower base and 20% for land compensation of corridor area. The compensation amount for crop and tree is based on the rate determined by the Department of Agriculture and Horticulture of Government of Tamil Nadu. The particulars of the affected land/crop/tree are filled in the Madras Electricity Department (MED) form issued to affected landowner. The contractor provides the compensation amount in cheque to the affected people and TANTRANSCO reimburse the compensation amount to the contractor.

69. The GRM consists of two levels. The first level is handled by a GRC established at the General Construction Circle (GCC) level. The second level GRC is established at the project level and is headed by the Chief Engineer (Trichy). An operational guideline on functioning of GRM has been developed in consultation with TANTRANSCO. During the reporting period from August to December 2020, a total of 8 complaints has been received from the project affected people and through the GRM all the complaints are closed.

70. Consultations with affected people were carried out by TANTRANSCO and contractors during the detailed survey, during determination of agreed compensation values, during disbursement of compensation and during the construction. The contractor has informed the affected landowner about the tentative construction schedule on foundation, erection and stringing work before the commencement of work.

71. The entitlement matrix in the draft Compensation Plan has been shared to the TANTRANSCO official at the GCC level and district level officials. The entitlement matrix is available with all the EPC contractors.

72. Based on the observation made during site visit by TRTA consultants and review of physical progress and compensation data some implementation issues were identified. These includes timely payment of land and crop/tree compensation for stringing in corridor (RoW) especially in 400 kV DC line from Kamuthi to Ottapidaram and from Udangudi to Ottapidaram; display of project information through signage including information on GRM and proper record keeping in compensation database and other formats. It is expected that TANTRANSCO will act on these areas on an urgent basis.

6 Comments and Responses Matrix

No. Comments by ADB Responses and/or Actions Taken 1 Implementation Schedule Each contractor has a bar chart for the schedule Please provide a detailed schedule of of activities for implementation. The same can be activities for each remaining project made available if required. component. Please include in this schedule an indication of when Being a linear project, the work of tower consultation activities are planned. foundation, erection and stringing is being Please supply copies disclosure implemented in stages contingent upon the statements that inform affected people clearance of the RoW. it is being implemented on about the schedule for compensation piecemeal basis after taking consent from determination, award, and construction affected landowners. For example, in a activities. Please also maintain detailed transmission line tower foundation and erection records on the actual dates of work is taken up in the location where the consent consultations and compensation of land owner is received and the MED form is payments, showing that they occurred signed. Sometimes TANTRANSCO field prior to commencement of construction engineers make a number of visits to the affected works. landowner for mutual agreement on the value of compensation. Also, sometimes the unavailability of Village Administrative Officer and other district level revenue officials delay the process of finalizing the value of land compensation. In these locations the foundation work is delayed. Due to these factors, it may not be relevant to disclose the future schedule of construction activities for the entire transmission line. The schedule of foundation work is provided to the affected people during the consultation in which the signature of affected landowner is taken in the MED form. Information on the next stage of construction is shared with the concerned people well before the start of the activity.

After the identification of affected people through the VAO, TANTRANSCO/contractor undertakes individual consultation with each affected people. This is a general practice where TANTRANSCO conducts individual consultations that does not require prior information or notification. During the one-to-one consultation, information on the project and construction schedule are given to affected landowner. Information regarding the provisions of G.O. (Ms) No. 86 (Revised guidelines for payment of compensation) is properly explained to the affected landowner during the consultation.

The date of consultation regarding compensation is mentioned in the signed MED form. Work on tower foundation is commenced after taking the signature of affected landowners in the MED form.

No. Comments by ADB Responses and/or Actions Taken The actual date of compensation payment through cheque made to affected people is there in the excel database. Due to paucity of space this information is not mentioned in the Annexure on compensation data. The same can be made available on demand. 2 Ongoing Consultation The disclosure of project information, its risks, The Resettlement Plan (RP) ‘Future impacts, benefits, and implementation schedule Consultation Strategy’ commits to to the affected people is made by public continued consultation throughout the consultations or one-to-one consultation after the project cycle. In response to previous identification of the affected people and during the comments, TANTRANSCO described detailed assessment of land compensation. the consultation process in relationship During the consultation, information about the to land acquisition as: 1) obtaining compensation for affected land, trees and crops landowner consent to conduct the are given to affected landowner. detailed assessment, and 2) the responsibility of the contractor and Village level consultations are usually done during TANTRANSCO to conduct village-level the project planning on a sample basis at some discussions. Please also demonstrate sensitive places. The same will be conducted for how the project is disclosing information the deviated line for which a format for recording about the project and its risks, impacts, the public consultations were shared with the benefits, and implementation schedule. contractors during the site visit held in the last Please show that consultation is week of December 2020. The findings will be occurring: 1) prior to land acquisition and reflected in the updated Compensation Plan. construction activities, 2) during land Also, it is to further clarify that there is no land aquation and construction activities, and acquisition and physical displacement involved 3) after the conclusion of land acquisition which could have required detailed and prior and construction activities. Please also consultations. elaborate actions taken by TANTRANSCO to "ensure that Prior to construction activities, TANTRANSCO Contractor follows participatory field engineer/contractor undertakes individual approach" and clarify how the project is consultation with each affected HH and take the assured that it has not adversely consent of affected landowner to undertake affected people. detailed assessment of affected land, tree and For the noted deviations in the 765 kV crops and again do the consultation during DC Transmission Line from determination of agreed compensation values Virudhunagar to Coimbatore (Reach 2) and at the time of disbursement of compensation and the 230 and 110 kV Transmission cheque. During the construction activities Lines associated with Ottapidaram TANTRANSCO field engineer/contractor initiate Substation, please demonstrate that the discussion with affected people to discuss about project is providing adequate advanced the schedule of next stage of activities and other notice of the change to affected people. implementation issues.

The contractor through public consultation or individual discussion listens the views and opinions of affected people during the detailed survey. The route alignment is finalized to ensure that the adverse impact of the project is minimal to people.

For the noted deviations in the 765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 2) and 400 kV DC line from Virudhunagar to Kayathar, the concerned

No. Comments by ADB Responses and/or Actions Taken contractor has undertaken public consultations with affected people on a sample basis along both side of the revised route to capture the views and concerns of the affected people. The findings of the public consultations will be shared in the updated Compensation Plan. 3 Involuntary Resettlement Survey Status The anticipated number of affected households For each component, please summarize was estimated in 2018 based on the preliminary the anticipated number of affected route alignment prepared through satellite survey households estimated in advance, the data by Anna University which was just an actual number of affected households, assumption. Determining the actual number of and the status of the project in consulting affected households is an ongoing process. The with each household. process of identification of households affected by transmission line corridor (RoW) has just started. Also, identification of households affected by tower foundation is yet to commence in 230 and 110 kV Transmission Lines associated with Ottapidaram Substation as the routes were approved recently. The total number of affected households will be shared once the process of identification is completed and the same will be mentioned in the final updated Compensation Plan. 4 Resettlement Survey Data No Response Required. In comments on the previous SMR, ADB requested documentation showing that the project is maintaining structured and auditable data on affected assets. Thank you for supplying this information in Annexure 5. 5 Compensation Rate Determination The guideline value for land in Tamil Nadu is Please elaborate how TANTRANSCO updated every year which is fixed by the revenue determines the market value while department keeping in consideration multiple assessing the land restrictions value factors. As mentioned in draft Compensation under tower and footings. Please provide Plan, TANTRANSCO takes into account the rates schedules from revenue guideline value while assessing the land departments and show how these rates restrictions value under tower footings. are applied against values from the household asset inventory. Please clarify The provisions of Government of Tamil Nadu how the project is ensuring land G.O. (Ms) No. 86 are being followed for the land valuation at market rate is equivalent to compensation of tower base area and land replacement value. Please supply compensation of corridor area (RoW). The G.O. evidence of contractor receipts to (Ms) No. 86, mentioned in Annexure 2 of SMR, TANTRANSCO. Please also assess detailed out the steps for determining the value of whether actual compensation amounts land compensation. The compensation amount for each component are on-track with RP for crop and tree is based on the rate determined cost estimates. by the Department of Agriculture and Horticulture of Government of Tamil Nadu.

The project provides 100% of the guideline value as land compensation for land affected by tower base where as the provision as per the entitlement matrix of draft compensation plan was

No. Comments by ADB Responses and/or Actions Taken 85%. The project provides 20% of the guideline value for land compensation of corridor area where as the provision was 15% in the entitlement matrix of the draft compensation plan. This means TANTRANSCO is paying more than the provision as set out in the entitlement matrix. Additionally, the land is restored to its previous use.

The contractor provides the agreed compensation amount in cheque to the affected landowner on behalf of TANTRANSCO. Later TANTRANSCO reimburse the compensation amount to the contractor. As the evidence of payment, the cheque number is mentioned in the compensation database given in Annexure 5 of the report.

The RP cost estimates were done in 2018 and were based on the anticipated number of affected households. Since the number of actual affected household will vary from 2018 RP estimate the actual compensation amount may vary. Determining the actual number of affected households is an ongoing process and the actual RP cost can be estimated after the agreed compensation amount for all the affected HH is known. The SMR will keep the record of compensation cost for each monitoring period and will be summed up at the end once the entire process is completed. This is because of the nature of the project, which is linear and no permanent land acquisition is involved. 6 Grievance Redress During the reporting period from August to Please provide a log of grievances December 2020, a total of 8 complaints received tracking how many complaints were from the project affected people. There are 7 received during the reporting period, individual complaints and one complaint from a classify the types of complaints, and group of villagers. The status of grievance report on the status of grievance resolution for each complaint is mentioned in resolution for each. Indicate which were Table number 7 of the SMR. minor, and which, if any, were escalated to GRC. Also indicate whether they All the complaints were escalated to project level were resolved at GRC level 1 or 2, and GRC and were resolved by the project level GRC whether the resolution was satisfactory under the chairmanship of Chief Engineer, Trichy. to all stakeholders. The petitioners were satisfied with the resolution of the grievance.

ANNEXURE 1: Maps of 230 and 110 kV Lines associated with Ottapidaram Substation

Figure 22: 230 kV DC line LILO of T- Sipcot Kavanoor SC line to Ottapidaram SS (Anna University route and approved route)

Figure 23: 230 kV DC line LILO of T- Sipcot Savasapuram feeder to Ottapidaram (Anna University route and approved route)

Figure 24: 110 kV DC line on DC tower from LILO of TT auto-T Sipcot feeder to Ottapidaram (Anna University route and approved route)

Figure 25: 110 kV SC line on DC tower from proposed Ottapidaram to existing Vijayapuri SS (Anna University route and approved route)

Figure 26: 110 kV DC line on DC tower from LILO of Eppodhmvendran to Ottapidaram SS (Anna University route and approved route)

ANNEXURE 2: Government of Tamil Nadu G.O. (Ms) No. 86 (Revised guidelines for payment of compensation)

ANNEXURE 3: Sample of filled MED form

ANNEXURE 4: TANTRANSCO Acceptance letter of operational guideline on GRM

ANNEXURE 5: List of affected people received compensation in various Transmission lines

400 kV DC line from Kamuthi to Ottapidaram

Foundation: Virudhunagar Portion

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque/ Status of No No./Loc. landowner assessment no./Patta legs in value for crop tion value Compensat DD No. payment . No. no. affected land for affected ion land compensat crop ion (Rs) 1 16/2 Thiru. C.Murugan Foundation Keelkudi, 195/2 4 Legs 60,300 Maize 17,600 77,900 548229 Issued Aruppukottai & Dist - Virudhunagar 2 17/1 M/s. ORBIT Foundation Keelkudi, 283/4 4 Legs 66,400 Maize 17,600 84,000 548230 Issued HOMES PVT LTD Aruppukottai & Dist - Virudhunagar 3 17/2 Thiru. V.Subburaj Foundation Thimmanatha puram, 315/1C 2 Legs 30,150 Chilli 9,488 39,638 548237 Issued Kamuthi & Dist - Ramanathapuram 4 17/3 Thiru. Foundation Thimmanatha puram, 309/7A 4 Legs 60,300 Chilli 21,348 81,648 548231 Issued P.Kannayiram Kamuthi & Dist - Ramanathapuram 5 18/0 Tmy. A.Alagammal Foundation Thimmanatha puram, 274/2A 4 Legs 62,700 Chilli 21,348 84,048 548238 Issued Kamuthi & Dist - Ramanathapuram 6 18/3 Thiru. S.Muthuraj Foundation Thimmanatha puram, 242/5D 4 Legs 15,075 Black 891 15,966 548239 Issued Kamuthi & Gram Dist - Ramanathapuram 7 19/0 Thiru. P.Dharmar Foundation Thimmanatha puram, 226/3A 1 Leg 17,507 Chilli 5,218 22,725 548232 Issued Kamuthi & Dist - Ramanathapuram 8 20/1 Tmy. Laskhmi.M Foundation Thimmanatha puram, 142/6 4 Legs 60,300 Chilli 21,348 81,648 548233 Issued Kamuthi & Dist - Ramanathapuram 9 22/2 Thiru. K.Selvaraj Foundation P.M.Puram, Kamuthi & 69/2C 4 Legs 60,300 Chilli 46,491 1,06,791 548240 Issued Dist - Ramanathapuram

10 22/3 Thiru. Jeyaraman Foundation P.M.Puram, Kamuthi & 68/3B 4 Legs 66,400 Chilli 21,348 87,748 548241 Issued Dist - Ramanathapuram

11 23/2 Thiru. O.Sankar Foundation P.M.Puram, Kamuthi & 314/1A 4 Legs 60,300 Chilli 21,348 81,648 548234 Issued Ramu Dist - Ramanathapuram

12 23/3 Thiru. Aditya Foundation P.M.Puram, Kamuthi & 332/2 4 Legs 60,300 Cotton 10,008 70,308 548242 Issued Vardhan Agarwal Dist - Ramanathapuram

13 9/1 Thiru. Foundation Mudhalnadu, Kamuthi& Dist 326/4 1 Leg Chilli 22,771 22,771 549642 Issued Thinnayaramoorthi - Ramanathapuram

14 10/0 Thiru. Foundation Mudhalnadu, Kamuthi 334/1C 2 Legs 34,050 Coconu 36,000 75,387 549644 Issued Poominathan.K & Dist - Ramanathapuram t Tree

Chilli 5,337

15 10/0 Thiru. Foundation Mudhalnadu, Kamuthi 334/1D 2 Legs 34,050 Chilli 16,604 50,654 549645 Issued Muniyasamy.M & Dist - Ramanathapuram

16 10/1 Thiru. S.Sakthivel Foundation Mudhalnadu, Kamuthi 351/9 4 Legs 60,300 Chilli 14,825 75,125 549646 Issued & Dist - Ramanathapuram

17 10/2 Thiru. Foundation Mudhalnadu, Kamuthi 358/5B 1 Leg 15,075 Coconu 60,000 92,865 549616 Issued Karuppasamy.P & Dist - Ramanathapuram t Tree

Chilli 17,790

18 11/0 Thiru. Foundation Purasalur, Aruppukottai & 359/7 2 Legs 31,350 Chilli 3,558 34,908 549619 Issued Thangasamy.M Dist - Virudhunagar

19 11/0 Thiru. Kasi.K Foundation Purasalur, Aruppukottai & 365/4 1 Leg Chilli 21,348 21,348 549620 Issued Dist - Virudhunagar

20 11/2 Tmy. Rasammal.T Foundation Purasalur, Aruppukottai & 277/27 4 Legs 60,300 Chilli 11,860 72,160 549621 Issued Dist - Virudhunagar

21 14/2 Tmy. Foundation Kallakari, Aruppukottai & 38/8 2 Legs 30,150 Chilli 7,116 37,266 549648 Issued P.Vadivelammal Dist - Virudhunagar

22 14/2 Thiru. Foundation Kallakari, Aruppukottai & 46/7B 2 Legs 30,150 Chilli 7,116 37,266 549623 Issued K.Muthuramalinga Dist - Virudhunagar m

23 15/0 Thiru. Foundation Keelkudi, 101/12B 4 Legs 62,700 Chilli 29,057 91,757 549625 Issued Kilavarajan.R Aruppukottai & Dist - Virudhunagar

24 15/2 M/s. Orbit Projects Foundation Keelkudi, 293/5B 1 Leg 16,600 16,600 549626 Issued Private Limited Aruppukottai & Dist - Virudhunagar

25 16/1 M/s. Natural Plast Foundation Keelkudi,Aruppukottai & 193/19 4 Legs 60,300 Chilli 5,337 65,637 549650 Issued Private Limited Dist - Virudhunagar

26 16/4 M/s. Govinddham Foundation Keelkudi, 309/1 3 Legs 45,225 Chilli 5,337 50,562 549627 Issued Vinimay Private Aruppukottai & Limited Dist - Virudhunagar

27 16/5 Thiru. P.Moorthi Foundation Keelkudi, 293/8 3 Legs 45,225 Chilli 14,825 60,050 549628 Issued Aruppukottai & Dist - Virudhunagar

28 17/2 M/s. Virudhunagar Foundation Keelkudi, 282/9 2 Legs 30,150 Maize 3,080 33,230 549629 Issued Biocrops Private Aruppukottai & Limited Dist - Virudhunagar

29 17/4 Thiru. S.Sivan Foundation Thimmanatha puram, 330/3B 4 Legs 60,300 Chilli 29,057 89,357 549651 Issued Kamuthi & Dist - Ramanathapuram

30 18/1 Thiru. Ganapathi.K Foundation Thimmanatha puram, 262/4 4 Legs 60,300 Chilli 9,488 69,788 549652 Issued Kamuthi & Dist - Ramanathapuram

31 18/2 Thiru. Foundation Thimmanatha puram, 243/2A 3 Legs 45,225 Chilli 27,041 72,266 549630 Issued Nanthakumar.R Kamuthi & Dist - Ramanathapuram

32 18/2 Thiru. Foundation Thimmanatha puram, 265/3B 1 Leg Chilli 12,334 12,334 549752 Issued P.Muthukrishnan Kamuthi & Dist - Ramanathapuram

33 18/3 Thiru. Ashok Foundation Thimmanatha puram, 242/4B 1 Leg Chilli 15,655 15,655 549653 Issued kumar.R Kamuthi & Dist - Ramanathapuram

34 18/3 Thiru. Foundation Thimmanatha puram, 242/5E1 2 Legs 30,150 Coconu 60,000 1,02,010 549654 Issued Mayakrishnan.K Kamuthi & t Tree Dist - Ramanathapuram Chilli 11,860

35 19/0 Thiru. G.Rajendran Foundation Thimmanatha puram, 237/2 3 Legs 52,575 Chilli 17,790 70,365 549655 Issued Kamuthi & Dist - Ramanathapuram

36 20/0 Thiru. Palani Foundation Thimmanatha puram, 184/4B 2 Legs 35,050 Chilli 14,825 49,875 549656 Issued Murugan.S Kamuthi & Dist - Ramanathapuram

37 20/3 Tmy. Foundation Thimmanatha puram, 128/3B 4 Legs 60,300 Chilli 29,057 89,357 549631 Issued Muneeswari.M Kamuthi & Dist - Ramanathapuram

38 20/4 Thiru. M.Rajaram Foundation Thimmanatha puram, 82/1C 1 Leg Chilli 14,825 14,825 549712 Issued Muthandi Kamuthi & Dist - Ramanathapuram

39 20/4 Thiru. Palraj.G Foundation Thimmanatha puram, 87/1B 3 Legs 45,225 Chilli 14,825 60,050 549632 Issued Kamuthi & Dist - Ramanathapuram

40 21/0 Thiru. Foundation Thimmanatha puram, 80/1B 4 Legs 62,700 Chilli 9,488 72,188 549633 Issued U.Soundrapandiya Kamuthi & n Dist - Ramanathapuram

41 21/1 Thiru. Foundation P.M.Puram, Kamuthi & 136/6 4 Legs 60,300 Chilli 19,925 80,225 549634 Issued R.Perumalsamy Dist - Ramanathapuram

42 21/2 Thiru. Sathoor Foundation P.M.Puram, Kamuthi & 98/2 3 Legs 45,225 Chilli 16,604 61,829 549635 Issued Sankar.T Dist - Ramanathapuram

43 21/2 Thiru. Foundation P.M.Puram, Kamuthi & 100/3 1 Leg 15,075 Chilli 14,825 29,900 549636 Issued K.Kondakkalan Dist - Ramanathapuram

44 22/4 Tmy. K.Malliga Foundation P.M.Puram, Kamuthi & 62/4 4 Legs 66,400 Chilli 5,337 71,737 549713 Issued Dist - Ramanathapuram

45 23/1 Tmy. P.Indra Foundation P.M.Puram, Kamuthi & 310/1A 2 Legs 30,150 Chilli 5,337 35,487 549637 Issued Dist - Ramanathapuram

46 24/2 Thiru. U.Lingaraj Foundation Chinnoor, Vilathikulam 170/6 4 Legs 60,300 Chilli 14,825 75,125 549638 Issued & Dist - Tuticorin

47 9/0 Tmy. Foundation Kamuthi Town, Kamuthi 785/3A 1 Leg 34,125 Chilli 5,337 49,462 059581 Issued Kasiyammal.T & Dist - Ramanathapuram

Neem 10,000 Tree

9/0 Thiru. Anumantha Foundation Kamuthi Town, Kamuthi 786/1C 3 Legs 1,02,375 Chilli 17,790 1,50,165 059582 Issued Krishnan & Dist - Ramanathapuram 48 Neem 30,000 Tree

49 10/2 Thiru. Kennedy Foundation Mudhalnadu, Kamuthi 359/1B 1 Leg 15,075 15,075 059589 Issued Murugan.P & Dist - Ramanathapuram

50 10/2 Thiru. Foundation Mudhalnadu, Kamuthi 377/6 2 Legs 30,150 Chilli 28,464 58,614 059590 Issued V.Subramanaian & Dist - Ramanathapuram

51 10/3 Thiru. Foundation Mudhalnadu, Kamuthi 357/2B 4 Legs 60,300 Neem 10,000 70,300 059591 Issued V.Subramanaian & Dist - Ramanathapuram Tree

52 10/4 Thiru. Kennedy Foundation Seemanendal, Kamuthi & 64/5B 4 Legs 66,400 66,400 059594 Issued Murugan.P.S/o Dist - Ramanathapuram Ponnusamy Thevar

53 10/6 Thiru. Nallusamy.K Foundation Seemanendal, Kamuthi & 52/1B, 4 Legs 60,300 Onion 26,685 86,985 059595 Issued Dist - Ramanathapuram 13/1B3B

54 10/7 Thiru. Kasinatha Foundation Seemanendal, Kamuthi & 72/1A19 3 Legs 45,225 45,225 059596 Issued Thevar.N Dist - Ramanathapuram

55 11/1 Thiru. M.Marimutu Foundation Purasalur, Aruppukottai & 363/2A 2 Legs Chilli 21,348 21,348 059601 Issued Dist - Virudhunagar

56 11/1 Thiru. Foundation Purasalur, Aruppukottai & 364/3B 2 Legs 33,200 Palm 2,000 35,200 059602 Issued Ramalingam.T Dist - Virudhunagar Tree

57 12/0 Tmy. Jaya Rani.B Foundation Purasalur, Aruppukottai & 337/7B 4 Legs 70,100 70,100 059623 Issued Dist - Virudhunagar

58 12A/0 Tmy. Foundation Purasalur, Aruppukottai & 332/9B 4 Legs 1,92,600 1,92,600 059624 Issued M.Poochendu Dist - Virudhunagar

59 13/0 Thiru. Dharmaraj.C Foundation Purasalur, Aruppukottai & 274/2 4 Legs 2,43,700 2,43,700 059625 Issued Dist - Virudhunagar

60 14/1 Thiru. Foundation Kallakari, Aruppukottai & 35/2 4 Legs 60,300 Palm 8,000 68,300 059608 Issued Ponnusamy.G Dist - Virudhunagar Tree

61 14/4 Thiru. Muthu Foundation Kallakari, Aruppukottai & 90/9B 4 Legs 60,300 Neem 40,000 1,36,354 059628 Issued Ramalingam.P Dist - Virudhunagar Tree

Chilli 36,054

62 14/5 Thiru. Marimuthu.N Foundation Kallakari, Aruppukottai & 88/9B 2 Legs 30,150 Chilli 11,860 42,010 059642 Issued Dist - Virudhunagar

63 14/7 Thiru. Foundation Kallakari, Aruppukottai & 96/5A 4 Legs 60,300 Palm 8,000 68,300 059612 Issued Ponnusamy.G Dist - Virudhunagar Tree

64 15/0 Thiru. Kalimuthu.L Foundation Keelkudi, 101/9 2 Legs 31,350 31,350 059631 Issued Aruppukottai & Dist - Virudhunagar

65 15/1 Thiru. Foundation Keelkudi,Aruppukottai & 104/1A 2 Legs 33,200 Onion 8,895 42,095 059633 Issued M.M.Asirvatham Dist - Virudhunagar

66 15/2 Thiru. Foundation Keelkudi, 107/1C 3 Legs 49,800 Neem 10,000 59,800 059613 Issued K.Samuththiram Aruppukottai & Tree Dist - Virudhunagar

67 17/0 Thiru. Sethu Foundation Keelkudi, 289/3C 1 Leg 15,675 Chilli 7,116 22,791 059615 Issued Pandi.P Aruppukottai & Dist - Virudhunagar

68 17/0 Thiru. A.Perumal Foundation Keelkudi, 289/5 3 Legs 47,025 Neem 10,000 57,025 059616 Issued Aruppukottai & Tree Dist - Virudhunagar

69 20/0 Thiru. Perumal.M Foundation Thimmanatha puram, 180/3 2 Legs 35,050 Chilli 14,825 49,875 059637 Issued Kamuthi & Dist - Ramanathapuram

70 21/3 Thiru. Irulappa Foundation P.M.Puram, Kamuthi & 87/1B 4 Legs 60,300 Neem 15,000 75,300 059617 Issued Pandian.P Dist - Ramanathapuram Tree

71 22/0 Thiru. Gandhi.R Foundation P.M.Puram, Kamuthi & 86/2 4 Legs 68,100 Chilli 21,348 89,448 059618 Issued Dist - Ramanathapuram

72 23/0 Thiru. Ramakkal.S Foundation P.M.Puram, Kamuthi & 291/3 4 Legs 62,700 Neem 25,000 98,611 059638 Issued Dist - Ramanathapuram Tree

Chilli 10,911

73 23/1 Thiru. Foundation P.M.Puram, Kamuthi & 311/1 2 Legs 30,150 Neem 15,000 45,150 059619 Issued G.Athinarayanan Dist - Ramanathapuram Tree

74 24/0 Thiru. Foundation P.M.Puram, Kamuthi & 325 4 Legs 68,100 Neem 15,000 83,100 059620 Issued Gnanasekaran.T Dist - Ramanathapuram Tree

75 25/0 Thiru. Foundation Enamvadamala puram, 130/3A 4 Legs 70,100 Neem 15,000 85,100 059636 Issued R.Sivaprammahari Vilathikulam & Tree Dist - Tuticorin

Foundation: Tirunelveli Portion

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensat Total Cheque/ Status of No No./Lo landowner assessment no./Patta legs in Agreed crop ion value Compensa DD No. payment . c. No. no. affected value for for affected tion land land crop compensat ion (Rs)

1 25/1 Thiru. V. Foundation Inam vadamalapuram, 115/1 3 Legs 49,800 511078 Issued Manmathan Vilathikulam & 49,800 Dist -Tuticorin

2 25/1 Tmy. B. Foundation Inam vadamalapuram, 116/1 1 leg 16,600 511079 Issued Ramalakshmi Vilathikulam & 16,600 Dist -Tuticorin

3 25/2 Thiru. Foundation Inam vadamalapuram, 84/3 4 Legs 60,300 511080 Issued P.Paramasivan Vilathikulam & 60,300 Dist -Tuticorin

4 25/3 Tmy. Foundation Inam vadamalapuram, 82/3 4 Legs 60,300 511081 Issued G.Gandhimathi Vilathikulam & 60,300 Dist -Tuticorin

5 25/4 Thiru. Foundation Inam vadamalapuram, 58/1 2 Legs 30,150 511082 Issued K.Thangapandi Vilathikulam & 30,150 Dist -Tuticorin

6 25/4 Thiru. Foundation Inam vadamalapuram, 58/2 2 Legs 30,150 511083 Issued K.Veerasingam Vilathikulam & 30,150 Dist -Tuticorin

7 25/5 Tmy. Foundation Inam vadamalapuram, 63/1 4 Legs 60,300 511084 Issued R.Rathnamala Vilathikulam & 60,300 Dist -Tuticorin

8 26/0 Tmy. Foundation Inam vadamalapuram, 67/1A 4 Legs 62,700 511085 Issued R.Rathnamala Vilathikulam & 62,700 Dist -Tuticorin

9 26/1 Thiru. A.Murugan Foundation Sundarapachaiyapuram, 34/2 3 Legs 45,225 511086 Issued Vilathikulam & 45,225 Dist - Tuticorin

10 26/1 Tmy. A.Ramakkal Foundation Sundarapachaiyapuram, 55/3 1 leg 15,075 511087 Issued Vilathikulam & 15,075 Dist - Tuticorin

11 26/4 Tmy. Foundation Sundarapachaiyapuram, 24/1 4 Legs 60,300 511088 Issued K.Gnanasundari Vilathikulam & 60,300 Dist - Tuticorin

12 26/2 Thiru. Tharmaraj Foundation Sundarapachaiyapuram, 59/1 3 Legs 45,225 511090 Issued Vilathikulam & 45,225 Dist - Tuticorin

13 26/2 Thiru. P.Rajaram Foundation Sundarapachaiyapuram, 60/2B 1 leg 15,075 511091 Issued Vilathikulam & 15,075 Dist - Tuticorin

14 26/3 Tmy. V.Rajeshwari Foundation Sundarapachaiyapuram, 33/1 1 leg 15,075 Maize 549589 Issued Vilathikulam & 13,200 28,275 Dist - Tuticorin

15 26/3 Thiru. A.Murugan Foundation Sundarapachaiyapuram, 54/4 3 Legs 45,225 511093 Issued Vilathikulam & 45,225 Dist - Tuticorin

16 26/5 Thiru. P.Kumaravel Foundation Ramachandrapuram, 5/6A 4 Legs 66,400 511094 Issued Vilathikulam & 66,400 Dist - Tuticorin

17 27/1 Thiru. L.Perumal Foundation Keelavilathikulam - II, 249/2A2 4 Legs 60,300 511095 Issued Rediar Vilathikulam & & 60,300 Dist - Tuticorin

18 27/2 Thiru. Foundation Keelavilathikulam - II, 191/1 1 leg 15,075 511096 Issued K.Sennappan Vilathikulam & & 15,075 Dist - Tuticorin

19 27/3 Thiru. Foundation Keelavilathikulam - II, 187/2B 1 leg 16,600 511097 Issued S.Perumalsamy Vilathikulam & & 16,600 Dist - Tuticorin

20 27/4 Thiru. P.Parthipan Foundation Keelavilathikulam - II, 184/1C 4 Legs 60,300 511098 Issued Vilathikulam & & 60,300 Dist - Tuticorin

21 27/5 Tmy. Foundation Keelavilathikulam - II, 254/3C 1 leg 15,075 511099 Issued P.Perumalakkal Vilathikulam & & 15,075 Dist - Tuticorin

22 27/5 Thiru. Ganesan Foundation Keelavilathikulam - II, 255/3 3 Legs 45,225 511100 Issued Vilathikulam & & 45,225 Dist - Tuticorin

23 28/4 Thiru. Lakshmana Foundation Keelavilathikulam - I, 523/ 4 Legs 60,300 511171 Issued Perumal.P Vilathikulam & & 1C2A 60,300 Dist - Tuticorin

24 29/0 Tmy. Foundation Keelavilathikulam - I, 513/1B 4 Legs 62,700 511172 Issued R.Karuppayee Vilathikulam & & 62,700 Dist - Tuticorin

25 29/1 Thiru. A.Ayyavoo Foundation Keelavilathikulam - I, 592/4B 4 Legs 60,300 511173 Issued Alais Shanmugam Vilathikulam & & 60,300 Dist - Tuticorin

26 29/2 Tmy. A.Gnanapoo Foundation Keelavilathikulam - I, 594/1 4 Legs 60,300 511174 Issued Vilathikulam & & 60,300 Dist - Tuticorin

27 29/4 Thiru. P.Saravanan Foundation Keelavilathikulam - I, 623/3A 2 Legs 30,150 511175 Issued Vilathikulam & & 30,150 Dist - Tuticorin

28 30/0 Thiru. Jeyaraj Foundation Keelavilathikulam - I, 624/1B 4 Legs 76,500 511176 Issued premkumar.J Vilathikulam & & 76,500 Dist - Tuticorin

29 43/1 Thiru. Foundation Marthandampatti, 49/5 4 Legs 60,300 Maize 511177 Issued M.Periyaswamy Vilathikulam & & 10,200 70,500 Dist - Tuticorin

30 43/2 Thiru. P.Nagarajan Foundation Marthandampatti, 99/1A 2 Legs 30,150 Maize 40,350 511178 Issued Vilathikulam & & 10,200 Dist - Tuticorin

31 43/2 Tmy. Foundation Marthandampatti, 102/2A 2 Legs 30,150 Maize 37,350 511179 Issued S.Shanmugalaksh Vilathikulam & & 7,200 mi Dist - Tuticorin

32 43/3 Thiru. M.Perumal Foundation Marthandampatti, 96/2B 4 Legs 60,300 Palm 93,300 511180 Issued Vilathikulam & & Tree 15,000 Dist - Tuticorin

Maize 18,000

33 43/4 Tmy. Foundation Sakkammal Puram, 397/2 4 Legs 60,300 60,300 511182 Issued Parameshwari.S Vilathikulam & Dist - Tuticorin

34 44/0 Thiru. Foundation Sakkammal Puram, 57/1 4 Legs 62,700 62,700 511183 Issued S.P.C.Subbiah Vilathikulam & Dist - Tuticorin

35 44/2 Thiru. Rajakumar.S Foundation Veerapandiyapuram, 8/2 4 Legs 60,300 60,300 511184 Issued Vilathikulam & Dist - Tuticorin

36 44/3 Tmy. Foundation Veerapandiyapuram, 26/9A 3 Legs 45,225 511185 Issued Shanmugalakshmi. Vilathikulam & 45,225 K Dist - Tuticorin

37 44/4 Thiru. Foundation Veerapandiyapuram, 53/3A 3 Legs 49,800 511186 Issued Ramachandran.K Vilathikulam & 49,800 Dist - Tuticorin

38 45/0 Tmy. Foundation Veerapandiyapuram, 63/2 4 Legs 62,700 511187 Issued M.Kamatchiammal Vilathikulam & 62,700 Dist - Tuticorin

39 27/0 Thiru. S.Sridhar Foundation Keelavilathikulam - II, 139/2B 4 Legs 62,700 549554 Issued Vilathikulam & 62,700 Dist - Tuticorin

40 27/3 Thiru. Sethuram.P Foundation Keelavilathikulam - II, 189/3 3 Legs 49,800 549492 Issued Vilathikulam & 49,800 Dist - Tuticorin

41 28/0 Thiru. Foundation Keelavilathikulam - II, 263/1A2 4 Legs 62,700 549542 Issued K.Lakshmanaperu Vilathikulam & 62,700 mal Dist - Tuticorin

42 28/1 Tmy. Foundation Keelavilathikulam - II, 263/4 2 Legs 30,150 549543 Issued R.Padmanathan Vilathikulam & 30,150 Dist - Tuticorin

43 29/4 Thiru. Gurusamy.N Foundation Keelavilathikulam - I, 623/3B 2 Legs 30,150 549544 Issued Vilathikulam & 30,150 Dist - Tuticorin

44 30/1 Thiru. Foundation Keelavilathikulam - I, 396/1 4 Legs 60,300 Maize 549545 Issued A.Balakrishnan Vilathikulam & 9,000 69,300 Dist - Tuticorin

45 30/2 Thiru. K.Kanagaraj Foundation Vilathikulam, 399/1A1 4 Legs 60,300 549493 Issued Vilathikulam & 60,300 Dist - Tuticorin

46 30/3 Tmy. Foundation Vilathikulam, 404/5 4 Legs 60,300 549515 Issued Jayalakshmi.P Vilathikulam & 60,300 Dist - Tuticorin

47 32/0 Thiru. Foundation Kuralaiyampatti, 8/2B 1 leg - Jasmin 549494 Issued Alagupandian.M Vilathikulam & e 26,400 26,400 Dist - Tuticorin

48 32/0 Thiru. Medai Foundation Kuralaiyampatti, 8/3 3 Legs 78,900 549546 Issued Chairman.M.A Vilathikulam & 78,900 Dist - Tuticorin

49 35/0 Thiru. T.Madasamy Foundation Kottanatham, 57/1D 3 Legs 90,150 Maize 549495 Issued Vilathikulam & 10,200 1,00,350 Dist - Tuticorin

50 35/0 Thiru. Foundation Kottanatham, 57/2B 1 leg 30,050 Palm 549496 Issued M.Murugesapandia Vilathikulam & Tree 20,000 50,050 n Muniyandi Dist - Tuticorin

51 36/0 Thiru. Foundation Keelavilathikulam - II, 55/4A 3 Legs 68,475 549497 Issued Chinnaappanasam Vilathikulam & 68,475 y.M Dist - Tuticorin

52 36/0 Thiru. T.Moorthy Foundation Kottanatham, 54/4C 1 leg 22,825 Cocon 549498 Issued Vilathikulam & ut tree 30,000 52,825 Dist - Tuticorin

53 36/1 Thiru. S.Rajagopal Foundation Kottanatham, 39/5B 1 leg - Maize 549499 Issued Vilathikulam & 15,600 15,600 Dist - Tuticorin

54 36/1 Tmy. R.Thayammal Foundation Kottanatham, 40/6 3 Legs 49,800 Palm 549500 Issued Vilathikulam & Tree 12,000 61,800 Dist - Tuticorin

55 36/2 Thiru. Foundation Kottanatham, 37/1A 4 Legs 60,300 549501 Issued Rajendran.S.P Vilathikulam & 60,300 Dist - Tuticorin

56 36/3 Thiru. G.Gurusamy Foundation Kottanatham, 29/6B 4 Legs 60,300 549502 Issued @ Kandasamy Vilathikulam & 60,300 Dist - Tuticorin

57 36/4 Tmy. P.Papammal Foundation Mandhikulam, 39/5 4 Legs 60,300 Palm 549548 Issued Vilathikulam & Tree 12,000 72,300 Dist - Tuticorin

58 36/5 Tmy. Foundation Mandhikulam, 37/12 2 Legs 30,150 Maize 549503 Issued Muthulakshmi.B Vilathikulam & 9,000 39,150 Dist - Tuticorin

59 37/0 Thiru. Foundation Mandhikulam, 31/9B 4 Legs 76,500 Palm 549504 Issued S.Srinivasaragavan Vilathikulam & Tree 24,000 1,00,500 sankaiah Dist - Tuticorin

60 38/0 Tmy. Helan.M Foundation Mandhikulam, 22/15A 2 Legs 38,250 Maize 549505 Issued Vilathikulam & 2,400 40,650 Dist - Tuticorin

61 38/0 Thiru. Murugan Foundation Mandhikulam, 22/15B 2 Legs 38,250 Maize 549506 Issued Vellaipandi Vilathikulam & 2,400 40,650 Dist - Tuticorin

62 38/1 Thiru. Foundation Ayan Sengalpadai, 17 4 Legs 60,300 549507 Issued Karuppasamy.K Vilathikulam & 60,300 Dist - Tuticorin

63 42/1 Thiru. Foundation Ayan Sengalpadai, 292 4 Legs 60,300 549508 Issued Madasamy.M.C Vilathikulam & 60,300 Dist - Tuticorin

64 42/2 Tmy. Jayanthi.K Foundation Marthandampatti, 71/1 2 Legs - Jasmin 549509 Issued Vilathikulam & e 36,000 36,000 Dist - Tuticorin

65 42/2 Thiru.Krishnan.S Foundation Marthandampatti, 212/2 2 Legs - Jasmin 549549 Issued Vilathikulam & e 36,000 36,000 Dist - Tuticorin

66 42/3 Tmy. Jayanthi.K Foundation Marthandampatti, 74/3 2 Legs - Jasmin 549510 Issued Vilathikulam & e 36,000 36,000 Dist - Tuticorin

67 42/4 Thiru. Foundation Marthandampatti, 78/1B1 1 leg 15,075 Maize 549511 Issued Shanmugaraj.S Vilathikulam & 3,600 18,675 Dist - Tuticorin

68 42/4 Thiru. Foundation Marthandampatti, 78/2A 3 Legs - Jasmin 549512 Issued Thavasilingam.R Vilathikulam & e 45,000 45,000 Dist - Tuticorin

69 42/5 Thiru. Foundation Marthandampatti, 86/1 2 Legs 30,150 Maize 549550 Issued Sanmugam.V Vilathikulam & 7,200 37,350 Dist - Tuticorin

70 42/5 Thiru. Velayutha Foundation Marthandampatti, 86/2 2 Legs 30,150 549513 Issued Perumal.A Vilathikulam & 30,150 Dist - Tuticorin

71 42/6 Thiru. M.Sithu reddi Foundation Marthandampatti, 91/4A 4 Legs 60,300 549514 Issued Vilathikulam & 60,300 Dist - Tuticorin

72 43/0 Tmy. M.Parvathi Foundation Marthandampatti, 52/6 1 leg 15,675 Maize 549530 Issued Vilathikulam & 2,400 18,075 Dist - Tuticorin

73 43/0 Thiru. C.Bala Foundation Marthandampatti, 54 2 Legs 31,350 Maize 549478 Issued Subramaniyan Vilathikulam & 3,600 34,950 Dist - Tuticorin

74 43/5 Thiru. Kuppa Foundation Sakkammal Puram, 391/2 4 Legs 66,400 549531 Issued Reddiyar.S Vilathikulam & 66,400 Dist - Tuticorin

75 44/1 Thiru. Foundation Veerapandiyapuram, 16/3 2 Legs 30,150 549516 Issued M.Balamurugan Vilathikulam & 30,150 Dist - Tuticorin

76 44/3 Tmy. Ovammal.P Foundation Veerapandiyapuram, 26/7 1 leg - Maize 549532 Issued Vilathikulam & 15,600 15,600 Dist - Tuticorin

77 44/4 Tmy. Foundation Veerapandiyapuram, 53/3A 1 leg - Maize 549533 Issued Murugalakshmi.T Vilathikulam & 15,600 15,600 Dist - Tuticorin

78 44/5 Thiru. Foundation Veerapandiyapuram, 59/2A 4 Legs 60,300 549534 Issued S.Pitchaimani Vilathikulam & 60,300 Dist - Tuticorin

79 45/1 Thiru. Foundation Veerapandiyapuram, 95/2 3 Legs 49,800 549479 Issued Ramasamy.K Vilathikulam & 49,800 Dist - Tuticorin

80 45/1 Thiru. Foundation Veerapandiyapuram, 96/1 1 leg - Maize 549480 Issued Venkatasubbu.S Vilathikulam & 15,600 15,600 Dist - Tuticorin

81 45/4 Thiru. Puthiavan.S Foundation MullurMuthukumarapuram, 52/1C 3 Legs 45,225 549535 Issued Ottapidaram & 45,225 Dist - Tuticorin

82 46/0 Thiru. S.Marimuthu Foundation MullurMuthukumarapuram, 18/4 2 Legs 35,050 Palm 549536 Issued Ottapidaram & Tree 25,000 60,050 Dist - Tuticorin

83 46/0 Thiru. Alagarsamy Foundation MullurMuthukumarapuram, 420/1 2 Legs 35,050 Maize 549481 Issued Reddiar.P Ottapidaram & 15,600 50,650 Dist - Tuticorin

84 46/1 Thiru. Foundation MullurMuthukumarapuram, 102/2 4 Legs 60,300 549537 Issued S.Vinaithirthan Ottapidaram & 60,300 Dist - Tuticorin

85 46/2 Thiru. P.Mookaiah Foundation MullurMuthukumarapuram, 92/1 1 leg 16,600 549482 Issued Ottapidaram & 16,600 Dist - Tuticorin

86 47/2 Thiru. Arulappan.P Foundation Chandragiri & 105/4 4 Legs 60,300 549483 Issued Ottapidaram, 60,300 Dist - Tuticorin

87 48/0 Thiru. Foundation Chandragiri & 214/1 3 Legs 68,475 549538 Issued Kadarkaraiandi.A Ottapidaram, 68,475 Dist - Tuticorin

88 48/1 Tmy. V.Ariyanachi Foundation Chandragiri & 215/4 4 Legs - Jasmin 549484 Issued Ottapidaram, e 60,000 60,000 Dist - Tuticorin

89 48/2 Tmy. Foundation Chandragiri & 221/2B 4 Legs 60,300 Maize 549485 Issued M.Petchiammal Ottapidaram, 9,000 69,300 Dist - Tuticorin

90 48/3 Thiru. P.Perumal Foundation Chandragiri & 235/2A 4 Legs 60,300 Maize 549539 Issued Ottapidaram, 9,000 69,300 Dist - Tuticorin

91 48/4 Thiru. S.Anburaj Foundation Chandragiri & 238/3 4 Legs 66,400 Maize 549486 Issued Ottapidaram, 9,000 75,400 Dist - Tuticorin

92 50/0 Tmy. Ulagammal Foundation Chandragiri & 267/1 1 leg 60,925 Palm 549487 Issued Varatharaj Ottapidaram, Tree 20,000 80,925 Dist - Tuticorin

93 50/0 Thiru. M.Gansean Foundation Chandragiri & 268/1 2 Legs 1,21,850 549517 Issued Ottapidaram, 1,21,850 Dist - Tuticorin

94 52/0 Thiru. Foundation S.Kumarapuram, 26/2A1A 4 Legs 95,300 549540 Issued S.Rajasekaran Ottapidaram & 95,300 Sithivinayagam Dist - Tuticorin

95 53/0 Tmy. Foundation S.Kumarapuram, 39/2A 4 Legs 95,400 Maize 549541 Issued G.Subbulakshmi Ottapidaram & 13,200 1,08,600 Dist - Tuticorin

96 53/1 M/s. Hibiscus Foundation S.Kumarapuram, 46/2 4 Legs 66,400 Maize 549488 Issued Enterprises LLP Ottapidaram & 9,000 75,400 Dist - Tuticorin

97 53/2 M/s. Vennila Foundation S.Kumarapuram, 68/3 4 Legs 66,400 Maize 549489 Issued Holdings Private Ottapidaram & 9,000 75,400 Limited Dist - Tuticorin

98 54/0 Thiru. Vaiyanraj.M Foundation S.Kumarapuram, 69/1 4 Legs 1,36,500 Maize 549490 Issued Ottapidaram & 13,200 1,49,700 Dist - Tuticorin

99 55/0 Tmy. Deivanai.K Foundation S.Kumarapuram, 76/1 4 Legs 1,36,500 Maize 549491 Issued Ottapidaram & 14,400 1,50,900 Dist - Tuticorin

Way Approach to Foundation: Virudhunagar Portion

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque/ Status of No No./Loc landowner assessment no./Patta legs in value for crop tion value Compensa DD No. payment . . No. no. affected land for affected tion land compensat crop ion (Rs)

1 10/0 Thiru. Malaisamy.K Way Mudhalnadu, Kamuthi 297/2B NA NA Onion 549643 Issued Approach & Dist - Ramanathapuram 21,793 21,793

2 10/0 Thiru. Vazhivittan.S Way Mudhalnadu, Kamuthi 335/2 NA NA Onion 549662 Issued Approach & Dist - Ramanathapuram 22,238 22,238

3 10/1 Tmy. Way Mudhalnadu, Kamuthi 351/6 NA NA Onion 549615 Issued N.Soundrammal Approach & Dist - Ramanathapuram 20,459 20,459

4 10/2 Thiru. K.Muthumani Way Mudhalnadu, Kamuthi 359/2 NA NA Onion 549647 Issued Approach & Dist - Ramanathapuram 28,019 28,019

5 10/3 Thiru. Way Kallakari, Aruppukottai & 377/4 NA NA Onion 549617 Issued Muthuramalingam.S Approach Dist - Virudhunagar 20,014 20,014

6 14/1 Thiru. Way Kallakari, Aruppukottai & 35/2 NA NA Onion 549622 Issued Ponnusamy.G Approach Dist - Virudhunagar 26,240 26,240

7 14/2 Tmy. Way Kallakari, Aruppukottai & 40/3 NA NA Onion 549649 Issued P.Vadivelammal Approach Dist - Virudhunagar 28,019 28,019

8 14/2 Thiru. M.Irulandi Way Kallakari, Aruppukottai & 40/2 NA NA Onion 549711 Issued Approach Dist - Virudhunagar 22,238 22,238

9 14/4 Thiru. Way Kallakari, Aruppukottai & 47/11B NA NA Onion 549624 Issued Sokkalingam.M Approach Dist - Virudhunagar 21,793 21,793

10 10/1 Thiru. Way Mudhalnadu, Kamuthi 360/1 NA NA Onion 059586 Issued Nagarathinam.S Approach & Dist - Ramanathapuram 44,831 44,831

11 10/2 Thiru. Rajendra Way Mudhalnadu, Kamuthi 358/5A, NA NA Onion 059588 Issued Prasath.N Approach & Dist - Ramanathapuram 370/7A 24,906 24,906

12 10/3 Thiru. V.Murugesan Way Mudhalnadu, Kamuthi 377/6 NA NA Chilli 059592 Issued Approach & Dist - Ramanathapuram 25,618 25,618

13 10/4 Thiru. Navin Way Seemanendal, Kamuthi & 63/6B NA NA Paddy 059593 Issued Ponmani.K Approach Dist - Ramanathapuram 4,355 23,924 NA NA Onion 19,569

14 11/0 Thiru. Rajagopal.M Way Purasalur, Aruppukottai & 356/5C NA NA Paddy 059597 Issued Approach Dist - Virudhunagar 3,992 20,003 NA NA Onion 16,011

15 11/0 - Thiru. Rajagopal.M Way Purasalur, Aruppukottai & 358/7B, NA NA Paddy 059599 Issued 11/1 Approach Dist - Virudhunagar 357/2E 4,355 24,814 NA NA Onion 20,459

16 11/2 Thiru. Way Purasalur, Aruppukottai & 364/3B NA NA Onion 059603 Issued Ramalingam.T Approach Dist - Virudhunagar 17,790 17,790

17 12/0 Thiru. Bose.V Way Purasalur, Aruppukottai & 335/14C NA NA Onion 059605 Issued Approach Dist - Virudhunagar 35,580 35,580

18 12/0 Thiru. A.Kathirvel Way Purasalur, Aruppukottai & 337/7B NA NA Onion 059606 Issued Approach Dist - Virudhunagar 22,238 22,238

19 12A/0 Tmy. Way Purasalur, Aruppukottai & 333/5 NA NA Onion 059607 Issued Subramanian.G Approach Dist - Virudhunagar 24,906 24,906

20 14/0 - Thiru. Way Kallakari, Aruppukottai & 13/5 NA NA Chilli 059626 Issued 14/1 Boominathan.S Approach Dist - Virudhunagar 24,906 24,906

21 14/4 - Thiru. Ponnaiya.S Way Kallakari, Aruppukottai & 86/1 NA NA Chilli 059627 Issued 14/3 Approach Dist - Virudhunagar 25,618 25,618

22 14/3 Thiru. Murugan.M Way Kallakari, Aruppukottai & 48/11 NA NA Chilli 059610 Issued Approach Dist - Virudhunagar 24,194 24,194

23 14/5 - Tmy. Kaliyammal.B Way Kallakari, Aruppukottai & 89/4 NA NA Chilli 059643 Issued 14/6 Approach Dist - Virudhunagar 24,906 24,906

24 14/5 - Thiru. Irulandi.M Way Kallakari, Aruppukottai & 90/8 NA NA Onion 059648 Issued 14/6 Approach Dist - Virudhunagar 22,238 22,238

25 14/4 - Thiru. N.Sattanan Way Kallakari, Aruppukottai & 49/1 NA NA Chilli 059645 Issued 14/5 Approach Dist - Virudhunagar 24,906 24,906

26 14/5 - Thiru. Muthu Way Kallakari, Aruppukottai & 102/1A NA NA Onion 059646 Issued 14/6 Ramalingam.K Approach Dist - Virudhunagar 29,354 29,354

27 14/6 Thiru. Way Kallakari, Aruppukottai & 90/7 NA NA Onion 059647 Issued Sathiyendhiran.R Approach Dist - Virudhunagar 24,906 24,906

28 14/7 Thiru. Way Kallakari, Aruppukottai & 90/5B NA NA Chilli 059630 Issued Velmurugan.S Approach Dist - Virudhunagar 27,752 27,752

29 15/0 Thiru. Way Kallakari, Aruppukottai & 101/12A NA NA Onion 059632 Issued Velmurugan.S Approach Dist - Virudhunagar 30,243 30,243

Way Approach to Foundation: Tirunelveli Portion

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque/ Status of No No./Lo landowner assessment no./Patta legs in value for crop tion value Compensat DD No. payment . c. No. no. affected land for affected ion land compensat crop ion (Rs)

1 25/1 Thiru. Way Approach Sundarapachaiyapuram, 208/3B NA NA Maize 549588 Issued A.Eswaramoorthy Vilathikulam & 10,200 10,200 Dist - Tuticorin

2 26/1 Thiru. Way Approach Sundarapachaiyapuram, 61/2 NA NA Maize 548113 Issued A.Eswaramoorthy Vilathikulam & 10,200 10,200 Dist - Tuticorin

3 26/3 Thiru. Way Approach Sundarapachaiyapuram, 34/1B NA NA Maize 511092 Issued V.Ravikannan Vilathikulam & 10,200 10,200 Dist - Tuticorin

4 43/3 Thiru. M.Perumal Way Approach Marthandampatti, 103/2B NA NA Maize 511181 Issued Vilathikulam & & 10,200 10,200 Dist - Tuticorin

5 36/0 Thiru. Way Approach Kottanatham, 55/3B NA NA Maize 549547 Issued V.Thirukanam Vilathikulam & 10,200 10,200 Dist - Tuticorin

6 43/0 Thiru. Way Approach Marthandampatti, 79/1 NA NA Maize 549477 Issued Senthilkumar.P Vilathikulam & 10,200 10,200 Dist - Tuticorin

Erection: Virudhunagar Portion

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque Status of No No./Loc landowner assessment no./Patta legs in value for crop tion value Compensati /DD No. payment . . No. no. affected land for affected on land compensat crop ion (Rs)

1 10/0 Thiru. Erection Mudhalnadu, Kamuthi 334/3B NA NA Onion 059583 Issued Pushpavalli.P & Dist - Ramanathapuram 22,238 22,238

2 10/0 Tmy. Erection Mudhalnadu, Kamuthi 332/3A NA NA Onion 059584 Issued Panchavarnam & Dist - Ramanathapuram 24,906 24,906

3 10/1 Thiru. Sakthivel.S Erection Mudhalnadu, Kamuthi 351/8A, NA NA Onion 059585 Issued & Dist - Ramanathapuram 360/2B, 41,510 41,510 360/3B, 351/10A

4 10/1 Thiru. Erection Mudhalnadu, Kamuthi 360/4 NA NA Onion 059587 Issued Nagarathinam.S & Dist - Ramanathapuram 22,238 22,238

5 11/0 Thiru. Erection Purasalur, Aruppukottai & Dist 357/3C NA NA Paddy 059598 Issued Subramanyan.T - Virudhunagar 2,540 24,778

Onion 22,238

6 11/1 Thiru. Erection Purasalur, Aruppukottai & Dist 363/5B NA NA Paddy 059600 Issued Thangasamy.M - Virudhunagar 3,629 28,535

Onion 24,906

7 11/1 Thiru. Murugan.S Erection Purasalur, Aruppukottai & Dist 363/9 NA NA Paddy 059621 Issued - Virudhunagar 2,540 24,778

Onion 22,238

8 11/2 Tmy. Rasammal.T Erection Purasalur, Aruppukottai & Dist 277/27 NA NA Onion 059622 Issued - Virudhunagar 17,790 17,790

9 12/0 Thiru. Arumugam.R Erection Purasalur, Aruppukottai & Dist 335/9 NA NA Onion 059604 Issued - Virudhunagar 22,238 22,238

10 14/1 Thiru. Irulandi.B Erection Kallakari, Aruppukottai & 35/2 NA NA Chilli 059609 Issued Dist - Virudhunagar 24,906 24,906

11 14/5 Thiru. Erection Kallakari, Aruppukottai & 88/9A NA NA Chilli 059629 Issued Alagarsamy.M Dist - Virudhunagar 35,106 35,106

12 14/5 Thiru. Irulandi.M Erection Kallakari, Aruppukottai & 88/9A NA NA Chilli 059641 Issued Dist - Virudhunagar 35,106 35,106

13 14/5 Tmy. Erection Kallakari, Aruppukottai & 107/1C NA NA Onion 059644 Issued Veeramakali.M Dist - Virudhunagar 22,238 22,238

14 14/5 Thiru. Marimuthu.P Erection Kallakari, Aruppukottai & 88/7C NA NA Chilli 059649 Issued Dist - Virudhunagar 29,057 29,057

15 14/7 Thiru. Erection Kallakari, Aruppukottai & 96/5A NA NA Onion 059611 Issued Ponnusamy.G Dist - Virudhunagar 26,685 26,685

16 15/2 Thiru. Veluchamy.S Erection Keelkudi, 107/3 NA NA Onion 059614 Issued Aruppukottai & 20,014 20,014 Dist - Virudhunagar

17 15/3 Thiru. Erection Keelkudi, 116/2C, NA NA Onion 059634 Issued Muthusamy.K Aruppukottai & 116/1B3 26,685 26,685 Dist - Virudhunagar

18 23/2 Thiru. Pothiraj.P Erection P.M.Puram, Kamuthi & 316/2B NA NA Chilli 059635 Issued Dist - Ramanathapuram 25,075 25,075

400 kV DC line from Udangudi to Ottapidaram

Foundation

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque Status of No No./Loc landowner assessment no./Patta legs in value for crop tion value Compensati /DD payment . . No. no. affected land for affected on No. land compensat crop ion (Rs)

1 55/1 Thiru. P. Foundation Srimoolakarai, Srivaikundam & 857 4 legs Maize 549462 Issued Vanniaperumal Dist - Tuticorin 60,300 31,200 91,500

2 54A/1 Thiru. K. Manthiram Foundation Srimoolakarai, Srivaikundam & 835/2 4 legs Maize 548208 Issued Dist - Tuticorin 60,300 31,200 91,500

3 65/0 Tmy. S. Foundation Thimmarajapuram, Tuticorin & 51/2, 4 legs Maize 548209 Issued Piramuammal Dist - Tuticorin 53/3 85,600 24,600 1,10,200

4 65/6 Thiru. G. Foundation Thimmarajapuram, Tuticorin & 143/1 4 legs Maize 548189 Issued Sudalaimuthu Dist - Tuticorin 60,300 31,200 91,500

5 54A/0 Thiru. D. Foundation Srimoolakarai, Srivaikundam & 663/1 4 legs Maize 548210 Issued Venkadesan Dist - Tuticorin 68,100 76,800 1,44,900

6 58/2 Thiru. S. Foundation Chettimallanpatti, 92/1B 4 legs Maize 548190 Issued Velmurugan Srivaikundam & 60,300 33,600 93,900 Dist - Tuticorin

7 68/0 Tmy. S. Foundation Ramasamypuram, Tuticorin & 2/1 4 legs Maize 548191 Issued Muthammal Dist - Tuticorin 78,100 82,800 1,60,900

8 53/4 Foundation Srimoolakarai, Srivaikundam & 700 4 legs Maize 548192 Issued Thiru. D. Dist - Tuticorin 60,300 31,200 91,500 Venkadesan

9 54/0 Thiru. D. Foundation Srimoolakarai, Srivaikundam & 694/2 4 legs Maize 548160 Issued Venkadesan Dist - Tuticorin 68,100 78,000 1,46,100

10 71/1 Thiru. R. Foundation Umarikottai, Tuticorin & 1254/2B 4 legs Black 548193 Issued Paramasivam Dist - Tuticorin 60,300 Gram 15,540 75,840

11 66/0 Tmy. V. Foundation Ramasamypuram, Tuticorin & 211/2A 3 legs Maize 548161 Issued Shanmugathammal Dist - Tuticorin 51,075 76,800 1,27,875

12 67/1 Tmy. M. Foundation Ramasamypuram, Tuticorin & 12/2A 3 legs Black 548162 Issued Chellammal Dist - Tuticorin 49,800 Gram 18,690 92,490

Coconu t Tree 24,000

13 73/0 Thiru. K. Foundation Umarikottai, Tuticorin & 297 3 legs Green 548163 Issued Muthukrishnan Dist - Tuticorin 65,025 Gram 37,765 1,62,790

Coconu t Tree 60,000

14 72/0 Tmy. S. Foundation Umarikottai, Tuticorin & 283 2 legs Black 548194 Issued Muthammal Dist - Tuticorin 45,650 Gram 13,020 1,21,550

Spiked Millet 14,880

Coconu t Tree 48,000

15 65/7 Tmy. S. Foundation Ramasamypuram, Tuticorin & 217/4 2 legs Maize 548164 Issued Mahalakshmi Dist - Tuticorin 30,150 24,000 54,150

16 65/7 Tmy. L. Valliammal Foundation Ramasamypuram, Tuticorin & 217/6 2 legs Maize 548165 Issued Dist - Tuticorin 30,150 24,000 54,150

17 66/0 Tmy. S. Foundation Ramasamypuram, Tuticorin & 211/1 1 leg Maize 549463 Issued Valavanthal Dist - Tuticorin 17,025 26,400 43,425

18 61/1 Thiru. R. Foundation Ellainayakkanpatti, 109 4 legs Maize 548195 Issued Renganathan Srivaikundam & 66,400 46,200 1,12,600 Dist - Tuticorin

19 67/0 Thiru.R.Meenakshi Foundation Ramasamypuram, Tuticorin & 26/1 4 legs Maize 548196 Issued Sundaram Dist - Tuticorin 1,05,200 75,000 1,80,200

20 66/2 Thiru. K. Subbaih Foundation Ramasamypuram, Tuticorin & 33/3A 2 legs Maize 549464 Issued Pillai Dist - Tuticorin 30,150 31,200 61,350

21 66/2 Thiru. A. Gurusamy Foundation Ramasamypuram, Tuticorin & 36/1 2 legs Maize 548211 Issued Dist - Tuticorin 30,150 31,200 61,350

22 82/1 Tmy. S. Foundation Umarikottai, Tuticorin & 26/1 4 legs Maize 548212 Issued Shanmugathai Dist - Tuticorin 60,300 37,200 1,21,500

Coconu t Tree 24,000

23 73/0 Tmy. B. Kirubai Foundation Umarikottai, Tuticorin & 296 1 leg Spiked 548214 Issued Dist - Tuticorin 21,675 Millet 33,360 55,035

24 65/5 Tmy. A. Valliammal Foundation Thimmarajapuram, Tuticorin & 128/2A 3 legs Maize 548215 Issued Tuticorin 45,225 37,200 1,18,425

Coconu t Tree 36,000

25 61/0 Thiru. S. Foundation Ellainayakkanpatti, 118/4 2 legs Maize 548327 Issued Arunachalam Pillai Srivaikundam & 31,350 33,600 64,950 Dist - Tuticorin

26 67/1 Thiru. M. Foundation Ramasamypuram, Tuticorin & 12/3 1 leg Maize 548328 Issued Sudalaimuthu Dist - Tuticorin 16,600 14,070 30,670

27 63/0 Thiru. M. Perumal Foundation Varthagarettipatti, Tuticorin & 4/1 2 legs Maize 548330 Issued Dist - Tuticorin 96,250 72,600 1,68,850

28 75/0 Thiru. C. Ponraj Foundation Umarikottai, Tuticorin & Dist - 320/2 3 legs Black 548331 Issued Tuticorin 1,82,625 Gram 21,840 2,04,465

29 74/0 Tmy. G. Foundation Umarikottai, Tuticorin & Dist - 302/4 4 legs Black 548332 Issued Manonmani Tuticorin 2,43,500 Gram 37,590 2,81,090

30 66/1 Tmy. S. Pari Foundation Ramasamypuram, Tuticorin & 39/1B 4 legs Maize 548333 Issued Pooranam Dist - Tuticorin 60,300 36,600 1,20,900

Coconu t Tree 24,000

31 72/0 Thiru. S. Tottappan Foundation Umarikottai, Tuticorin & Dist - 284/2A 2 legs Black 548334 Issued Tuticorin 45,650 Gram 14,700 1,20,010

Green Gram 23,660

Coconu t Tree 36,000

32 71/3 Thiru. M. Foundation Umarikottai, Tuticorin & Dist - 258/2 4 legs Black 548335 Issued Muthulakshumi Tuticorin 60,300 Gram 14,280 1,22,580

Coconu t Tree 48,000

33 63/0 Tmy. P. Agnimuthu Foundation Varthagarettipatti, 1/3 1 leg Maize 549878 Issued Tuticorin & 48,125 23,400 71,525 Dist - Tuticorin

34 58/3 Thiru. P. Jeyaraj Foundation Chettimallanpatti, 65/3B 4 legs Maize 549881 Issued Srivaigundam & 60,300 37,200 1,33,500 Dist - Tuticorin Coconu t Tree 36,000

35 71/0 Thiru. J. Prashanth Foundation Umarikottai, 1258/3A 4 legs Maize 549869 Issued Immanuel Tuticorin & 1,05,200 83,400 1,88,600 Dist - Tuticorin

36 59/0 Thiru. P. Jeyaraj Foundation Chettimallanpatti, 56/1B2B 4 legs Maize 549882 Issued Srivaigundam & 1,36,500 83,400 2,19,900 Dist - Tuticorin

37 76/0 Thiru. R. Foundation Umarikottai, Tuticorin 366/2 4 legs Maize 549880 Issued Shanmugaraj & Dist - Tuticorin 1,36,500 64,800 2,01,300

38 45/0 Tmy. K. Selva Foundation Eral, Tuticorin & 421/B 4 legs Banana 549883 Issued Rajathy Dist - Tuticorin 78,000 Tree 2,85,600 3,75,600

Coconu t Tree 12,000

39 65/4 Thiru. V. Foundation Thimmarajapuram, 113/2A 4 legs Maize 549877 Issued Chelladurai Tuticorin & 60,300 37,200 1,21,500 Dist - Tuticorin Coconu t Tree 24,000

Way Approach to Foundation

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque Status of No. No./Lo landowner assessment no./Patta legs in value for crop tion value Compensati /DD payment c. No. no. affected land for affected on No. land compens crop ation (Rs)

1 71/2 - Tmy. R. Indira Way Approach Umarikottai, Tuticorin & 257/1, NA NA Maize 548213 Issued 71/3 Dist - Tuticorin 254/1 12,000 24,000

Coconut Tree 12,000

2 67/0- Thiru. R. Meenakshi Way Approach Ramasamypuram, Tuticorin & 26/1 NA NA Maize 548326 Issued 67/1 Sundaram Dist - Tuticorin 9,000 21,000

Coconut Tree 12,000

3 66/1 - Thiru. A. Gurusamy Way Approach Ramasamypuram, Tuticorin & 1/4 NA NA Maize 548329 Issued 66/2 Dist - Tuticorin 11,400 23,400

Coconut Tree 12,000

4 75/0 - Thiru. R. Way Approach Umarikottai, Tuticorin & Dist - 341/1 NA NA Maize 549873 Issued 76/0 Shanmugaraj Tuticorin 14,400 26,400

Coconut Tree 12,000

5 71/3 - Thiru. V. Veerapagu Way Approach Umarikottai, Tuticorin & Dist - 262/2 NA NA Maize 549874 Issued 72/0 Tuticorin 7,800 19,800

Coconut Tree 12,000

Crop compensation for Erection and Stringing

1 55/1 & Thiru. M. Erection & Srimoolakarai, 857 NA NA Banana 89250 89250 549871 Issued Chakkaravarthy Stringing Tree 55/1 - Srivaigundam & 55/2 Dist - Tuticorin

400 kV DC Line from Virudhunagar to Kayathar

Foundation

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque Status of No. No./Lo landowner assessment no./ legs in value for crop tion value Compen payment c. No. Patta no. affected land for affected /DD land compens crop sation No. ation (Rs)

1 13/3 Thiru. T. SENTHUR Foundation Nenmeni, Sattur (Taluk), 2 4 Legs Maize 17,000 78,500 359325 Issued Virudhunagar (District) 61,500

2 13/7 Tmy. V. RAMANI Foundation Ayyampatti, Sattur (Taluk), 14/1 4 leg Maize 21,000 82,500 359320 Issued Virudhunagar (District) 61,500

3 13/8 Thiru. G. Foundation Ayyampatti, Sattur (Taluk), 55 4 Legs Maize 21,500 83,000 359323 Issued SUBBANAICKER Virudhunagar (District) 61,500

4 13/9 Thiru. A. Foundation Ayyampatti, Sattur (Taluk), 61/4 4 Legs Maize 23,000 1,10,700 359324 Issued SANKARGANESH Virudhunagar (District) 67,700 Palmyra 20,000 h Tree

5 14/0 Tmy. S. KALPANA Foundation Uppathur, Sattur (Taluk), 126/2 2 Legs Palmyra 25,000 60,250 359321 Issued DEVI Virudhunagar (District) 35,250 h Tree

6 14/2 Tmy. V. BHARANI Foundation Uppathur, Sattur (Taluk), 250/1 4 Legs Palmyra 20,000 81,500 359322 Issued Virudhunagar (District) 61,500 h Tree

7 17/1 Foundation 2/2. 3 Legs Cotton 30,968 1,01,743 359328 Issued

Thiru. M. Ayyakottaiyur, Ettaiyapuram Palmyra 20,000 SENTHOORPANDI (Taluk), Tuticorin (District) 50,775 Tree

8 17/1 MUSILIM JAMATH Foundation Ayyakottaiyur, Ettaiyapuram 12/3A 1 Leg Maize 10,000 56,925 359329 Issued FUND (Taluk), Tuticorin (District) 16,925 Palmyra 30,000 Tree

9 17/2 Thiru. V. Foundation Ayyakottaiyur, Ettaiyapuram 15/5 2 Legs Corrom 17,064 57,814 359330 Issued BALAMURUGAN (Taluk), Tuticorin (District) 30,750 Palmyra 10,000 Tree

10 17/2 Tmy. B. Foundation Ayyakottaiyur, Ettaiyapuram 16/2 - - Cotton 15,168 15,168 359331 Issued VIJAYALAKSHMI (Taluk), Tuticorin (District)

11 18/2 Thiru. V. Foundation Urulaikudi, Ettaiyapuram 72/2C 4 Legs Palmyra 30,000 97,700 359326 Issued MURUGESAN (Taluk), Tuticorin (District) 67,700 h Tree

12 18/4 Thiru. V. Foundation Urulaikudi, Ettaiyapuram 100/1 4 Legs Palmyra 25,000 92,700 359327 Issued MURUGESAN (Taluk), Tuticorin (District) 67,700 h Tree

765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 1)

Foundation

S. Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque Status of No. Towe landowner assessment no./Patta legs in value for crop tion value compen /DD payment r no. affected land for affected No. No./L land compens crop sation oc. ation No. (Rs)

1 35/4 K Parasuraman Foundation Naduvakottai, Thirumangalam, 75/6A 4 - 0 84,200 000031 Issued Madurai. 84,200

2 22/2 P Periyasamy Foundation Kallikudi Bit - II, Kallikudi, 195/11A 4 Tapioca 95,000 000032 Issued Madurai 91,000 4,000

3 27/5 T Rajagopal Foundation kanjampatti Bit - I, Peraiyur, 255/6 4 - 0 84,200 000033 Issued Madurai. 84,200

4 36/0 A Panchavarnam Foundation Naduvakottai, Thirumangalam, 77/3 2 - 0 56,900 000034 Issued Madurai. 56,900

5 36/0 S Minnal Foundation Naduvakottai, Thirumangalam, 77/4 2 - 0 56,900 000035 Issued Madurai. 56,900

6 36/3 C Usharani Foundation Kilavaneri, Thirumangalam, 36/2C 4 - 0 91,000 000036 Issued Madurai. 91,000

7 27/6 S Anand Foundation Kenjampatti bit - I, Peraiyur, 248/3B2 4 - 0 1,05,700 000037 Issued Madurai. 1,05,700

8 20/11 A Kathar Beevi Foundation Thennamanallur, Kallikudi, 71/1B1 4 Sugarcan 1,42,200 000038 Issued Madurai 98,200 e 44,000

9 28/5 K R Sundararajan Foundation Sengapaddai Bit - I, Kallikudi, 149/2D 1 - 0 21,050 000039 Issued Madurai. 21,050

10 28/5 S Padmanaban Foundation Sengapaddai Bit - I, Kallikudi, 135/1A 1 - 0 21,050 000040 Issued Madurai. 21,050

11 27/4 S Thangamari Foundation Kallikudi Bit - II, Kallikudi, 21/5A, 3 - 0 63,150 000041 Issued Madurai 21/5B 63,150

12 28/6 G Ganesan Foundation Sengapaddai Bit - I, Kallikudi, 158/1B 1 - 0 21,050 000042 Issued Madurai. 21,050

13 28/6 K Parasuraman Foundation Sengapaddai Bit - II, Kallikudi, 180/9A 2 - 0 42,100 000043 Issued Madurai. 42,100

14 28/6 P Narayanamoorthy Foundation Sengapaddai Bit - II, Kallikudi, 180/10A 1 - 0 21,050 000044 Issued Madurai. 21,050

15 21/0 Ayyanar Vai Foundation Thennamanallur, Kallikudi, 67/1B1 2 Sugarcan 88,600 000045 Issued Madurai 66,800 e 19,800

16 30/1 S Ramasamy Foundation Sengapaddai Bit - II, Kallikudi, 125/18 2 - 0 45,500 000046 Issued Madurai. 45,500

17 29/0 K Nallammal Foundation Sengapaddai Bit - II, Kallikudi, 170/3, 3 Corn 1,07,600 000047 Issued Madurai. 133/1 90,600 17,000

18 29/0 R Kumar Pandian Foundation Sengapaddai Bit - II, Kallikudi, 170/4 1 - 0 30,200 000048 Issued Madurai. 30,200

19 20/10 T Narayanan Foundation Thennamanallur, Kallikudi, 37/11B 3 - 0 68,250 000049 Issued Madurai 68,250

20 20/10 K Muthusethupathi Foundation Thennamanallur, Kallikudi, 37/13 1 - 0 22,750 000050 Issued Madurai 22,750

21 30/0 S A Venkattaraman Foundation Sengapaddai Bit - II, Kallikudi, 134/1B 3.5 - 0 1,78,413 000051 Issued Madurai. 1,78,413

22 36/4 A Malaisamy Foundation Kilavaneri, Thirumangalam, 44/6 2 - 0 45,500 000052 Issued Madurai. 45,500

23 20/5 T Sekar Foundation Chitoor, Kallikudi, 255/3A1 4 - 0 91,000 000054 Issued Madurai 91,000

24 20/6 V Adhinarayanan Foundation Thennamanallur, Kallikudi, 108/5 2 Cotton 56,181 000055 Issued Madurai 45,500 10,681

25 20/6 G Subba Reddy Foundation Thennamanallur, Kallikudi, 108/4 2 Cotton 55,463 000056 Issued Madurai 45,500 9,963

26 20/9 M Bose Foundation Thennamanallur, Kallikudi, 84/14 4 - 0 84,100 000065 Issued Madurai 84,100

27 20/4 S Muniyarasu Foundation Chitoor, Kallikudi, 264/1C2 4 - 0 91,000 000058 Issued Madurai 91,000

29 27/0 R Sivanatham Foundation Kallikudi Bit - II, Kallikudi, 67/1 4 - 0 1,13,900 000066 Issued Madurai 1,13,900

30 27/2 R Sivanatham Foundation Kallikudi Bit - II, Kallikudi, 57/3B 4 - 0 84,100 000060 Issued Madurai 84,100

31 32/0 V Parameshwaran Foundation Naduvakottai, Thirumangalam, 82/2D 4 - 0 1,26,800 000061 Issued Madurai. 1,26,800

32 20/7 V Muthupandi Foundation Thennamanallur, Kallikudi, 93/1A1 2 Ground 51,508 000062 Issued Madurai 42,050 Nut 9,458

33 20/7 P Sangaiah Foundation Thennamanallur, Kallikudi, 110/7B 2 Cotton 51,747 000063 Issued Madurai 42,050 9,697

34 35/1 N Seetharaman Foundation Thottiyampatti Village, 2/2B 4 - 0 91,000 000070 Issued Peraiyur, Madurai. 91,000

35 15/3 R Dhivya Foundation P.Kumaralingapuram, 21/6 4 - 0 91,000 000131 Issued Virudhunagar , Virudhunagar 91,000

36 13/3 S Radhakrishanan Foundation Meesalur, Virudhunagar, 302/1 4 - 0 91,000 000087 Issued Virudhunagar. 91,000

37 13/2 A Santhanalakshmi Foundation Meesalur, Virudhunagar, 823/1,82 4 - 0 84,100 000088 Issued Virudhunagar. 3/2 84,100

38 20/1 S K S Foundation Puliyankulam, Thirumangalam, 106/7 4 Cholam 1,03,100 000067 Issued Saravanakumar Madurai 84,100 19,000

40 20/2 P Guruvammal Foundation Puliyankulam, Thirumangalam, 102/4 1 Cholam 36,525 000069 Issued Madurai 21,025 15,500

41 13/4 T Thirupathisamy Foundation Meesalur, Virudhunagar, 317/2B, 4 Guava 1,34,100 000095 Issued Virudhunagar. 316/2B, 84,100 50,000 329/0

42 12/3 S Kanagaraj Foundation Thathampatti, Virudhunagar, 13/4,14/1 4 Guava 1,41,000 000089 Issued Virudhunagar. 91,000 50,000

43 25/0 S Venkateswaran Foundation Puliyankulam, Thirumangalam, 168/16A 2 Palmyra 89,050 000117 Issued Madurai 69,050 20,000

44 25/0 M Katturajan Foundation Kallikudi Bit - II, Kallikudi, 115/11 1 Palmyra 46,525 000118 Issued Madurai 34,525 12,000

45 28/7 N K Kondasamy Foundation Sengapaddai Bit - II, Kallikudi, 177/4C 1 Cholam 39,025 000108 Issued Madurai. 21,025 18,000

46 28/1 G Nagajothi Foundation Kenjampatti bit - I, Peraiyur, 217/4B 3 Cholam 85,075 000090 Issued Madurai. 63,075 22,000

47 15/2 R Girija Foundation P.Kumaralingapuram, 23/2A,23/ 2 Cholam 62,050 000121 Issued Virudhunagar , Virudhunagar 2B 42,050 20,000

48 12/1 N Pradeepan Foundation Thathampatti, Virudhunagar, 20/3 4 Guava 1,41,000 000091 Issued Virudhunagar. 91,000 50,000

50 10/8 K Avudathayammal Foundation Thathampatti, Virudhunagar, 65/2 2 Lemon 1,25,500 000122 Issued Virudhunagar. 45,500 tree 80,000

51 10/8 K Balakrishnan Foundation Thathampatti, Virudhunagar, 66/5B 1 Tamarind 42,750 000123 Issued Virudhunagar. 22,750 Tree 20,000

52 10/8 T Ramamoorthy Foundation Thathampatti, Virudhunagar, 65/3 1 Palmyra 42,750 000124 Issued Virudhunagar. 22,750 20,000

53 49/0 P Ponnuthai Foundation Thidiyan, Usilampatti, Madurai 132/3 3 100200 Palmyra 1,56,200 000072 Issued 50,000

54 48/6 Muthupandiyammal Foundation Thidiyan, Usilampatti, Madurai 103/4C 3 Coconut 1,02,925 000073 Issued Veerapandi 66,525 tree 36,400

55 34/0 S Kanchanadevi Foundation Naduvakottai, Thirumangalam, 50/1B 2 63400 Coconut 1,56,200 000093 Issued Madurai. tree 72,800

56 34/0 M Deivendran Foundation Naduvakottai, Thirumangalam, 50/1A4 2 63400 Coconut 1,56,200 000094 Issued Madurai. tree 72,800

57 21/0 S Ramar Foundation Thennamanallur, Kallikudi, 67/5A 2 Cholam 76,300 000064 Issued Madurai 66,800 9,500

58 20/8 S Rajaram Foundation Thennamanallur, Kallikudi, 96/4B2 Half of Coconut 3,13,950 000083 Issued Madurai two legs 22,750 tree 2,91,200

59 20/8 V Chandarasekar Foundation Thennamanallur, Kallikudi, 96/5C Coconut 1,45,600 000084 Issued Madurai tree 1,45,600

60 20/8 M Thangamani Foundation Thennamanallur, Kallikudi, 96/6E 2 Coconut 1,18,300 000085 Issued Madurai 45,500 tree 72,800

61 20/8 S Thangamari Foundation Thennamanallur, Kallikudi, 96/6C Half of Coconut 95,550 000086 Issued Madurai two legs 22,750 tree 72,800

62 16/0 K Ramachandran Foundation Senniyapuram, Virudhunagar, 84/1A 1 Palmyra 81,700 000105 Issued Virudhunagar 31,700 50,000

63 16/0 P Subburam Foundation Senniyapuram, Virudhunagar, 84/1B 1 Palmyra 81,700 000106 Issued Virudhunagar 31,700 50,000

64 16/1 P Surakkal Foundation Senniyapuram, Virudhunagar, 74/2 3 Palmyra 1,18,250 000197 Issued Virudhunagar 68,250 50,000

65 20/0 P Geetha Foundation Puliyankulam, Thirumangalam, 341/3 4 108900 Palmyra 2,28,900 000096 Issued Madurai 1,00,000

66 15/4 S Pandiyammal Foundation Pavali, Virudhunagar, 249/2 1 Palmyra 57,750 000125 Issued Virudhunagar. 22,750 25,000

67 15/4 A Subburaj Foundation Pavali, Virudhunagar, 249/2 1 Palmyra 57,750 000126 Issued Virudhunagar. 22,750 25,000

68 15/4 G Mariammal Foundation Pavali, Virudhunagar, 249/4 1 Tamarind 42,750 000127 Issued Virudhunagar. 22,750 Tree 20,000

69 14/0 I Madasamy Foundation Meesalur, Virudhunagar, 185B/2B, 3 Coconut 3,76,550 000128 Issued Virudhunagar. 185B/1B 85,350 tree 2,91,200

70 14/0 B KalyanaKumar Foundation Meesalur, Virudhunagar, 185B/1A 1 Coconut 1,01,250 000129 Issued Virudhunagar. 2 28,450 tree 72,800

71 48/1 P Subramaniam Foundation P.Vagaikulam, 45/3C2 4 105700 Coconut 1,97,460 000074 Issued Thirumangalam, Madurai. tree 72,800

72 50/0 P Parvathi Foundation Thidiyan, Usilampatti, Madurai 132/1 4 120900 Coconut 2,16,452 000097 Issued tree 72,800

73 47/7 M Ammavasai Foundation P.Vagaikulam, 169/3A 2 Coconut 81,900 000076 Issued Thirumangalam, Madurai. 45,500 tree 36,400

74 47/6 M Paramasivam Foundation P.Vagaikulam, 166/1B 4 91000 Coconut 1,40,040 000077 Issued Thirumangalam, Madurai. tree 36,400

75 47/7 A Pandiammal Foundation P.Vagaikulam, 152/1B 1 Palmyra 47,750 000078 Issued Thirumangalam, Madurai. 22,750 25,000

76 19/1 R Dhanapandi Foundation Puliyankulam, Thirumangalam, 334/3A 4 84100 Tamarind 1,94,100 000053 Issued Madurai Tree 60,000

77 47/5 S Karuthammal Foundation Kangayanatham, 1/11 2 Coconut 78,450 000079 Issued Thirumangalam, Madurai. 42,050 tree 36,400

78 49/0 M Peyammal Foundation Thidiyan, Usilampatti, Madurai 126/3B 1 Palmyra 83,400 000080 Issued 33,400 50,000

79 36/9 V Mokkaichamy Foundation A Ammapatti, Thirumangalam 72/6B 4 84100 Palmyra 1,33,600 000081 Issued 25,000

80 47/5 M Selvam Foundation Kangayanatham, 1/16, 2 Coconut 78,450 000082 Issued Thirumangalam, Madurai. 1/13 42,050 tree 36,400

81 28/2 S Kaartick Foundation Kenjampatti bit - I, Peraiyur, 213/1A 4 - 0 84,100 000157 Issued Madurai. 84,100

82 17/2 V Rajkumar F & E Vadamalaikuruchi, 154/7 4 Makka 1,62,349 000165 Issued Virudhunagar, Virudhunagar 91,000 Cholam 71,349

83 28/4 S Sathya Meenakshi Foundation Sengapadai Bit-I, Kallikudi 133/2B 4 Makka 1,16,185 000166 Issued 84,100 Cholam 32,085

84 28/7 N R Murali Prasad Foundation Sengapadai Bit-II, Kallikudi 177/4B 3 Makka 95,840 000168 Issued (3 Pit) 63,075 Cholam 32,765

85 22/0 A Alangaran Foundation Thennamanallur, Kallikudi, 66/1A1A 4 Makka 1,70,145 000110 Issued Madurai 1,33,600 Cholam 36,545

86 23/0 G Sankarapandian Foundation Kallikudi Bit - II, Kallikudi, 170/6G 1 Coconut 68,100 000111 Issued (C Madurai 31,700 Tree 36,400 Pit)

87 23/0 R Jeyaram Reddiar Foundation Kallikudi Bit - II, Kallikudi, 170/7A 3 Coconut 1,67,900 000112 Issued (A B Madurai 95,100 Tree 72,800 D Pit)

88 23/0 M Rathinam Foundation Kallikudi Bit - II, Kallikudi, 170/5B - Makka 25,698 000113 Issued Madurai - Cholam 25,698

89 17/1 P K Sankar Raj Foundation Senniyapuram, Virudhunagar, 57/5 4 Makka 4,93,835 000098 Issued Virudhunagar 91,000 Cholam 77,835

90 47/2 P Jagadeesh Foundation Erramallampatti, 56/3 2 Cotton 1,26,562 000104 Issued (2Pits Thirumangalam, Madurai 42,050 11,712 )

91 47/2 M Kasimayan Foundation Erramallampatti, 56/3 2.0 Cotton 4,51,762 000100 Issued (2 Pit) Thirumangalam, Madurai 42,050 11,712

92 47/2 M Kasimayan Foundation Erramallampatti, 56/3 - Coconut 4,73,200 000101 Issued Thirumangalam, Madurai - Tree 4,73,200

93 47/7 C Urangapuli Foundation P.Vagaikulam, 169/3A 1.0 Coconut 59,150 000130 Issued (1Pit) Thirumangalam, Madurai. 22,750 Tree 36,400

94 2/1 S Veeraputhiran Foundation Pattampudur, 192/5B 2 Makka 71,593 000177 Issued Virudhunagar,Virudhunagar 45,500 Cholam 26,093

95 16/0 S R Selvi Foundation seeniyapuram, Virudhunagar, 84/2A 2 Palmira 1,63,400 000178 Issued (2 Pit) Virudhunagar 63,400 tree 1,00,000

96 1E/1 S MURUGAN Foundation Kovilvirarpatti, Virdhunagar 35/16 4 Cotton 1,50,593 000183 Issued 98,200 52,393

97 1E/2 P CHINNARAJ Foundation Kovilvirarpatti, Virdhunagar 33/7B 4 Cotton 1,40,816 000182 Issued 91,000 49,816

98 1H/2 SRINIVASAGAM Foundation Kottainatham, Virdhunagar 194/2A 1 Makka 50,639 000185 Issued PERIYASAMY 21,025 Cholam 29,614

99 1H/2 R VELUSAMY Foundation Kottainatham, Virdhunagar 194/3A 3 63075 Palmira 1,51,040 000184 Issued tree 25,000

100 16/2 K KALEESWARI Foundation seeniyapuram, Virdhunagar 43/1C 1 Makka 54,794 000135 Issued 24,550 Cholam 30,244

101 16/2 P MANJULA Foundation seeniyapuram, Virdhunagar 43/4 3 73650 Palmira 1,53,165 Issued tree 50,000 000134

102 26/0 K PAPPA Foundation Kallikudi Bit-2 117/12A 4 140600 Palmira 3,51,500 000120 Issued tree 1,50,000

103 61/3 N SUBASH Foundation A Pudhupatti 8-10C1C 4 Coconut 4,91,400 000140 Issued 91,000 Tree 4,00,400

104 80/3 R RAMAR Foundation ViralimayanPatti 30/6 - Jasmine 66,000 000191 Issued - 66,000

105 81/0 A POONGOTHAI Foundation ViralimayanPatti 21/8 4 126800 Coconut 2,67,257 000181 Issued Tree 1,09,200

106 82/0 IRUMPUDURAI Foundation ViralimayanPatti 150/3 1 30200 Coconut 91,600 000137 Issued Tree 36,400

107 82/0 N RATHAMAN Foundation ViralimayanPatti 150/3 1 30200 Coconut 91,600 000138 Issued Tree 36,400

108 82/0 KARUPPAYEE Foundation ViralimayanPatti 150/3 2 60400 Palmira 91,400 000136 Issued tree 6,000

109 82/1 P SUNDARAPANDI Foundation ViralimayanPatti 129/1A 4 98200 Palmira 1,66,700 000116 Issued tree 50,000

110 82/2 C.BOSE Foundation ViralimayanPatti 190/1A 2 42050 Coconut 1,41,322 000192 Issued Tree 36,400

111 82/2 P.RAMPRABHU Foundation ViralimayanPatti 190/1A 2 42050 Coconut 1,15,959 000193 Issued Tree 36,400

112 82/3 C.JEYAKODI Foundation Nadakottai , Nilakottai 182/1E 3 79275 Coconut 1,95,691 000189 Issued Tree 72,800

113 82/3 OTCHA DEVAR Foundation Nadakottai , Nilakottai 183/2A 1 Cotton 55,502 000190 Issued 26,425 29,077

114 83/0 S.BALU Foundation Nadakottai , Nilakottai 169/1B2 4 102700 Coconut 3,40,732 000188 Issued Tree 1,82,000

Erection

S. Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compe Total Cheque Status No. Tower landowner assessment legs in value for crop compen of No./Lo no./Patta affected compens nsation /DD payment c. No. no. land ation sation No. (Rs) value for affected

crop

1 22/2 P Periyasamy Erection Kallikudi Bit - II, Kallikudi, 195/11A NA NA Coconut 000142 Issued Madurai Tree 72,800 72,800

2 20/7 R Lakshmanan Erection Thennamanallur, Kallikudi, 110-1B, NA NA Makka 000143 Issued Madurai 104-6, Cholam 32,765 32,765 95-3A, 95-4B, 110-4, 101-1F

3 20/7 V Muthupandi Erection Thennamanallur, Kallikudi, 93/1A1 NA NA Palmira 000144 Issued Madurai tree 25,000 25,000

4 20/7 M Mariyappan Erection Thennamanallur, Kallikudi, 93/1B, NA NA Makka 000145 Issued Madurai 94/5A2 Cholam 9,093 9,093

5 20/7 P Pitchaiammal Erection Thennamanallur, Kallikudi, 110/7A NA NA Makka 000146 Issued Madurai Cholam 6,251 6,251

6 20/8 S Rajaram Erection Thennamanallur, Kallikudi, 94-1C2 , NA NA Coconut 000147 Issued Madurai 96-4B2, Tree 36,400 36,400 85-1J1

7 20/8 K Pitchai Erection Thennamanallur, Kallikudi, 96/4A NA NA Makka 000148 Issued Madurai Cholam 5,189 5,189

8 20/8 A Malaichamy Erection Thennamanallur, Kallikudi, 90/1 NA NA Makka 000149 Issued Madurai Cholam 7,104 7,104

9 20/9 Santhanamari Erection Thennamanallur, Kallikudi, 94-1D1, NA NA Cotton 000150 Issued Krishnan Madurai 96-5A2, 33,028 33,028 96-5A, 94-1D2

10 27/4 S Thangamari Erection Kallikudi Bit - II, Kallikudi, 21/5B NA NA Coconut 000151 Issued Madurai Tree 72,800 72,800

11 20/1 S Mookaiya Erection Puliyankulam, Thirumangalam, 106/03 NA NA Makka 000119 Issued Madurai Cholam 22,288 22,288

12 20/1 S K S Erection Puliyankulam, Thirumangalam, 106/7 NA NA Palmira 000152 Issued Saravanakumar Madurai tree 25,000 25,000

13 28/1 K Saminathan Erection Kenjampatti bit - I, Peraiyur, 212/1B1 NA NA Makka 000153 Issued Madurai. Cholam 20,237 20,237

14 28/1 C Ponnuram Erection Kenjampatti bit - I, Peraiyur, 212/2 NA NA Makka 000154 Issued Reddiar Madurai. Cholam 5,189 5,189

15 28/1 R Manikandan Erection Kenjampatti bit - I, Peraiyur, 212/6,21 NA NA Cotton 000155 Issued Madurai. 2/3 15,007 15,007

16 28/1 G Nagajothi Erection Kenjampatti bit - I, Peraiyur, 217/4B NA NA Cotton 000156 Issued Madurai. 40,759 40,759

17 27/6 S Anand Erection Kenjampatti bit - I, Peraiyur, 248/3B2 NA NA Palmira 000158 Issued Madurai. tree 75,000 75,000

18 13/2 N Ilangovan Erection Meesalur, Virudhunagar, 764/1, NA NA Makka 000160 Issued Virudhunagar. 814/2, Cholam 10,723 10,723 825/1

19 27/5 S Erection Kenjampatti bit - I, Peraiyur, 255/5A NA NA Cotton 000161 Issued Senthamaraikkanna Madurai. 20,488 20,488 n

20 27/5 S Selvaraj Erection Kenjampatti bit - I, Peraiyur, 255/6 NA NA Cotton 000162 Issued Madurai. 49,754 49,754

21 27/5 D Sethumathavan Erection Kenjampatti bit - I, Peraiyur, 16/5A NA NA Makka 000163 Issued Madurai. Cholam 16,431 16,431

22 13/3 P Rajeshwari Erection Meesalur, Virudhunagar, 322/2 NA NA Makka 000164 Issued Virudhunagar. Cholam 8,302 8,302

23 20/1 V Ramasamy Erection Sengapadai Bit-I, Kallikudi 132/1,13 NA NA Makka 000167 Issued 3/10,133/ Cholam 61,378 61,378 2A

24 28/7 N K Kondasamy Erection Sengapadai Bit-II, Kallikudi 177/4C NA NA Makka 000169 Issued Cholam 25,006 25,006

25 28/5 S Padmanaban Erection Sengapadai Bit-I, Kallikudi 135/1A NA NA Makka 000171 Issued Cholam 37,262 37,262

26 12/3 S Kanagaraj Erection Thathampatti, Virudhunagar, 13/4,14/1 NA NA Makka 000172 Issued Virudhunagar. Cholam 60,526 60,526

27 13/4 S Murugasen Erection Meesalur, Virudhunagar, 316/2A,3 NA NA Cotton 000173 Issued Virudhunagar. 17/2A 8,198 8,198

28 28/6 P Narayanamoorthy Erection sengapaddai Bit-II, Kallikudi, 180/10A NA NA Palmira 000174 Issued Madurai. tree 10,000 10,000

29 20/5 V Jeyakumar Erection Chitoor, Kallikudi, 255/3A2 NA NA Makka 000175 Issued Madurai Cholam 12,453 12,453

30 20/5 T Sekar Erection Chitoor, Kallikudi, 255/3A1 NA NA Palmira 000176 Issued Madurai tree 25,000 25,000

31 30/2 K Ganesan Erection Sengapadai Bit-II, Kallikudi 116/1A NA NA Makka 000179 Issued Cholam 22,535 22,535

32 28/6 A Balaram Erection Sengapadai Bit-II, Kallikudi 180/10C NA NA Makka 000180 Issued Cholam 7,907 7,907

33 16/0 S R SELVI Erection seeniyapuram, Virdhunagar 84/2A NA NA Palmira 000196 Issued tree 25,000 25,000

34 16/0 K Erection seeniyapuram, Virdhunagar 84/1A NA NA Makka 000196 Issued RAMACHANDRAN Cholam 70,422 70,422

35 36/0 MINNAL Erection Naduvakottai 77/4,79/1 NA NA Coconut 000187 Issued B3 Tree 72,800 72,800

36 36/0 PANCHAVARNAM Erection Naduvakottai 77/3 NA NA Coconut 000186 Issued Tree 72,800 72,800

765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 2)

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Total Crop Cheque Status of No. No./Lo landowner assessment no./Patta legs in value for crop Amount /DD payment c. No. no. affected Land No. land compens ation (Rs)

1 25/1 Thiru. A.Subramani Foundation kundalapatty,nilakotai 21/5,7,22 1 leg jasmine 000179 Issued taluk,dindigul ,23 22,750 23,780 46,530

2 25/1 Thiru. Foundation kundalapatty,nilakotai 56/3,20 & 3 legs jasmine 000180 Issued S.Pommaiyan taluk,dindigul 77/7A1 68,250 48,629 1,16,879

3 25/2 Thiru. K.Raj Foundation kundalapatty,nilakotai 16/8A1 4 legs 000181 Issued taluk,dindigul 91,000 - - 91,000

4 25/3 Thiru. T.Rajangam Foundation kundalapatty,nilakotai 70/2,3,4 2 legs jasmine 000182 Issued taluk,dindigul & 71/1 42,100 27,016 69,116

5 25/3 Thiru. R.Senthil Foundation kundalapatty,nilakotai 71/2 2 legs jasmine 000183 Issued taluk,dindigul 42,100 23,314 65,414

6 26/2 Thiru. C.Ponnuthai Foundation kundalapatty,nilakotai 315/1B,2 2 legs jasmine 000184 Issued taluk,dindigul A 42,101 25,377 67,478

7 26/2 Thiru. R.Murugan Foundation kundalapatty,nilakotai 315/1B,2 2 legs jasmine 000185 Issued taluk,dindigul A 42,100 36,021 78,121

8 26/3 Thiru. Foundation pillayarnatham,nilakotai 178/3B2 2 legs 000186 Issued A.Ramalagan taluk,dindigul 42,100 - - 42,100

9 26/3 Thiru. C.Palraj Foundation pillayarnatham,nilakotai 176 & 2 legs 000187 Issued taluk,dindigul 177/C 42,100 - - 42,100

10 26/4 Thiru. K.Pandi Foundation kalkottai,nilakotai taluk,dindigul 341/4, 4 legs 000188 Issued 342/3 84,200 - - 84,200

11 27/1 Tmty P.Mallika, Foundation pillayarnatham,nilakotai 232/1 2 legs 000189 Issued taluk,dindigul 45,500 - - 45,500

12 27/1 Thiru K. Ponpandi Foundation musuvanuthu,nilakotai 191/2 2 legs 000190 Issued taluk,dindigul 45,500 - - 45,500

13 27 A/0 Thiru Foundation pillayarnatham,nilakotai 2 legs 000191 Issued M.Palanisamy taluk,dindigul 277/1,5,7 56,890 - - 56,890 ,9

14 28A/0 Thiru Foundation pillayarnatham,nilakotai 237/1 2 legs 000192 Issued S.Ponnusamy taluk,dindigul 56,890 - - 56,890

15 29A/0 Thiru H.Vijaya Foundation pillayarnatham,nilakotai 7/3B,3D 1 leg 000193 Issued taluk,dindigul 38,800 - - 38,800

16 28/0 Thiru S.Kamalam, Foundation pillayarnatham,nilakotai 7/3C 1 leg 000194 Issued taluk,dindigul 38,800 - - 38,800

17 28A/0 Thiru M.Maharajan Foundation pillayarnatham,nilakotai 31/3B 4 legs 000195 Issued taluk,dindigul 1,40,600 - - 1,40,600

18 29/0 Thiru P.Manimuthu Foundation pullukadupatti,nilakotai 128/3D 1 leg 000196 Issued taluk,dindigul 35,150 - - 35,150

19 29/0 Thiru K.Samy Foundation pillayarnatham,nilakotai 119/1, 1 leg 000197 Issued kannu taluk,dindigul 125/1A,1 35,150 - - 35,150 25/1C

20 29/0 Thiru R.Durai Foundation pillayarnatham,nilakotai 128/3C 1 leg 000198 Issued samy, taluk,dindigul 35,150 - - 35,150

21 29/0 Tmty Andiammal Foundation pillayarnatham,nilakotai 128/3C 1 leg 000199 Issued Tamil raman, taluk,dindigul 35,150 - - 35,150

22 31A/0 Tmty T.Lakshmi Foundation silukuvarpatti,nilakotai 341/4, 1 leg jasmine 000202 Issued taluk,dindigul 342/3 50,975 16,209 67,184

23 31A/0 Thiru P.Raja Foundation silukuvarpatti,nilakotai 31/333/2 3 legs jasmine 000203 Issued taluk,dindigul A, 333/21 1,52,925 16,201 1,69,126

24 31B/1 Thiru K.Bose, Foundation silukuvarpatti,nilakotai 380,396/ 4 legs jasmine 000204 Issued taluk,dindigul 1B 98,200 - 98,200

25 31B/2 Thiru V.Sahayaraj Foundation sangarapuram,nilakotai ,431/1 3 legs jasmine 000205 Issued taluk,dindigul 73,650 - 73,650

26 31B/2 Thiru Foundation silukuvarpatti,nilakotai ,431/1 1 leg jasmine 000206 Issued A.Amaladass, taluk,dindigul 24,550 24,014 48,564

27 25/0 Tmy.Annalakshmi Foundation sitharakalnatham,nilakotai 48/2A 4 legs Amla 000269 Issued Raja taluk,dindigul 1,26,800 - 1,26,800

28 30/0 Thiru. Foundation kompukaranpatty,nilakotai 70/2C 2 legs Maize 000142 Issued P.Palanisamy, taluk,dindigul 57,000 - 57,000

29 31D/0 Thiru.Muniyandi Foundation silukavarpatti,nilakotai 37/3B 1 leg jasmine '00014 Issued Alagar, taluk,dindigul 35,125 - 35,125 3

30 31D/0 Thiru.S.Murugan, Foundation silukavarpatti,nilakotai 38/2A,46 3 legs jasmine '00014 Issued taluk,dindigul 6/1B,466/ 1,05,375 - 1,05,375 4 2

31 33A/0 Thiru.S.Mani, Foundation ammapatti,nilakotai 94/6,94/2 4 legs jasmine `00033 Issued taluk,dindigul B 1,20,900 - 1,20,900 0

32 40/1 Thiru.P.Killachia Foundation jampuduraikottai,nilakotai 385/3 4 legs jasmine `00034 Issued Gounder taluk,dindigul 1,25,500 - 1,25,500 0

33 40A/0 Thiru.R.K.Ramasa Foundation jampuduraikottai,nilakotai 373/2 4 legs sapota `00024 Issued my taluk,dindigul 1,02,600 - 1,02,600 3

34 26/0 Tmty.C.Panjavarna Foundation jampuduraikottai,nilakotai 324/3 4 legs lemon 000121 Issued m, taluk,dindigul 1,09,000 tree - 1,09,000

35 28/0 Thiru. Foundation pillayarnatham,nilakotai 7/5A 2 legs sapota 000331 Issued R.Ramakrishnan taluk,dindigul 77,550 - 77,550

36 29/2 Thiru. R.Sudhagar, Foundation koovanuthu,nilakotai 70/2C 4 legs lemon 000122 Issued taluk,dindigul - tree - -

37 30/0 Thiru. A.Pandi, Foundation musuvanuthu,nilakotai 70/4 2 legs maize 000014 Issued taluk,dindigul 57,000 - 57,000 5

38 30A/0 Thiru. Foundation koovanuthu,nilakotai 207/7C; 2 legs maize 000146 Issued R.Ramasamy, taluk,dindigul 207/8B 57,000 - 57,000

39 30A/0 Thiru.R.Alagarsam Foundation koovanuthu,nilakotai 207/7A 1 leg maize 000147 Issued y, taluk,dindigul 207/8B 28,500 - 28,500

40 30A/0 Thiru. R.Chandran, Foundation koovanuthu,nilakotai 207/8A 1 leg maize 000148 Issued taluk,dindigul 28,500 - 28,500

41 31C/0 Thiru.S.Thangaraj, Foundation silukavarpatti,nilakotai 426/15B, 4 legs jasmine 000149 Issued taluk,dindigul 15F,15I 1,08,900 - 1,08,900

42 31E/0 Thiru.S.Soundara Foundation silukavarpatti,nilakotai 70/3 3 legs maize 000150 Issued Pandiyan, taluk,dindigul 1,05,450 - 1,05,450

43 32A/0 Thiru.S.Arockia Foundation ammapatti,nilakotai 166/13A, 2 legs maize 000247 Issued Durai, taluk,dindigul 13B, 56,850 - 56,850 13C,9A,9 B,9C

44 33/0 Thiru.K.Sivasamy, Foundation nariyuthu,nilakotai 109-6C 2 legs jasmine 000151 Issued (A&B taluk,dindigul 1,06,900 34,492 1,41,392 PIT)

45 33/1 Thiru.K.Sivasamy, Foundation nariyuthu,nilakotai 99-19B 1 leg jasmine 000152 Issued (A taluk,dindigul 56,400 37,504 93,904 PIT)

46 33/1 Thiru.V.K.Murugan, Foundation nariyuthu,nilakotai 98/9A,9C 2 legs 000153 Issued (B & D taluk,dindigul 1,52,800 - - 1,52,800 PIT)

47 33/1 Thiru.M.Michal Foundation nariyuthu,nilakotai 99/4A1 1 leg jasmine 000154 Issued (C Maria Arokiam, taluk,dindigul 71,400 23,999 95,399 PIT)

48 32/2 Thiru.A.SANTIAGU Foundation KODAI ROAD, 169/12 2 legs jasmine 000246 Issued NILAKOTTAI(TK), DINDIGUL 1,62,051 13,480 1,75,531

49 32/2 Thiru.G.MOSES Foundation AMMAPATTI, 169/9B 2 legs jasmine 000245 Issued MARIYA DOSS NILAKOTTAI(TK), DINDIGUL 1,67,051 10,784 1,77,835

50 41/0 Thiru. Foundation JAMBUDURAI KOTTAI, 401/6 4 legs 000302 Issued K.NAGARAJAN KODAI ROAD VIA 4,70,800 - - 4,70,800 NILAKOTTAI, DINDIGUL

51 32A/0 THIRU.B.NAGARA Foundation MAVUTHANPATI, 166/15 2 legs cholam 000299 Issued JAN NILAKOTTAI, DINDIGUL. 1,76,900 2,045 1,78,945

52 32A/1 THIRU.V.NAGARA Foundation MAVUDAMPATTI, 130/5,13 3 legs Thuvarai 000244 Issued JAN NILAKOTTAI, 0/7 2,63,075 2,465 2,65,540 DINDIGUL.

53 34/0 THIRU.A.AMBURO Foundation NARIYUTHU, 9/6 4 legs BroadBe 000130 Issued SE SILUKKUVARPATTI, 4,73,800 ans 3,771 4,77,571 DINDIGUL.

54 37/0 TMY.M.PAPPATHI Foundation KOLINGIPATTI, 559/2A 4 legs jasmine 000131 Issued AND FOUR NILAKOTTAI, 4,33,800 34,491 4,68,291 OTHERS DINDIGUL.

55 50/1 THIRU.V.PANDI Foundation AMBATHURAI, 585/2B 2 legs Maize 000132 Issued BALASAMUDRAM, 3,01,450 3,010 3,04,460 DINDIGUL.

56 50/1 THIRU.C.SELVAR Foundation NADUPATTI, 585/2C 1 leg jasmine 000133 Issued AJ AMBATHURAI, 1,02,725 23,755 1,26,480 DINDIGUL.

57 50/1 THIRU.C.SELVAR Foundation SEVAL SARAGU, 598/1A 1 leg jasmine 000134 Issued AJ AMBATHURAI, 92,725 33,107 1,25,832 DINDIGUL.

58 59/0 THIRU.M.KARUPP Foundation VEERAKKAL, 307/10A 4 legs Maize 000259 Issued AIAH DINDIGUL. 3,20,800 3,756 3,24,556

59 60/3 THIRU.R.RITAMA Foundation PILLAYARNATHAM, 948/3 4 legs Maize 000258 Issued RY, PITHALAIPATTI, 2,44,100 3,110 2,47,210 DINDIGUL.

60 61/0 THIRU.M.RATHIN Foundation MALAYAGOUNDANPATTI, 949/3 4 legs Maize 000266 Issued AM NILAKOTTAI, 3,49,500 1,806 3,51,306 DINDIGUL.

61 40A/0 THIRU.R.K.RAMA Foundation NILAKOTTAI, 373/2 4 legs 000163 Issued SAMY JAMBUTHURAIKOTTAI, 4,40,000 - - 4,40,000 DINDIGUL

62 40A/0 THIRU.R.K.RAMA Foundation NILAKOTTAI, 373/2 4 legs 000164 Issued SAMY JAMBUTHURAIKOTTAI, 4,25,000 - - 4,25,000 DINDIGUL

63 40A/0 THIRU.R.K.RAMA Foundation NILAKOTTAI, 373/2 4 legs 000165 Issued SAMY JAMBUTHURAIKOTTAI, 4,40,000 - - 4,40,000 DINDIGUL

64 40A/0 THIRU.R.K.RAMA Foundation NILAKOTTAI, 373/2 4 legs 000166 Issued SAMY JAMBUTHURAIKOTTAI, 4,40,000 - - 4,40,000 DINDIGUL

65 40A/0 THIRU.R.K.RAMA Foundation NILAKOTTAI, 373/2 4 legs 000167 Issued SAMY JAMBUTHURAIKOTTAI, 4,00,000 - - 4,00,000 DINDIGUL

66 32B/0 THIRU.S.PALANIC Foundation NARIYUTHU,DINDIGUL 122/2A 1 leg 000354 Issued HAMI 1,33,389 - - 1,33,389

67 33B/0 THIRU.M.DURAIC Foundation ORUTHATTU, NILAKOTTAI, 12/6C 2 legs 000160 Issued HAMY DINDIGUL DISTRICT. 3,63,587 - - 3,63,587

68 33B/0 THIRU.M.THANGA Foundation THIMMARASANAICKANUR, 12/6C 2 legs jasmine 000161 Issued PPANDI, ANDIPATTI,THENI. 1,90,000 7,189 1,97,189

69 51/1 THIRU.G.DEVARA Foundation CHINNALAPATTI, 548/1A1 4 legs jasmine 000123 Issued J CHINNALAPTTI, 4,14,300 37,552 4,51,852 SIVALSARAGU, DINDIGUL.

70 63/1 THIRU.D.CHARLE Foundation PALAYAKANNIVADI, 927/2 4 legs Maize 000124 Issued S KASAVANAMPATTI, 3,93,000 7,060 4,00,060 DINDIGUL.

71 63/3 THIRU.SRINIVASA Foundation KONUR,KONNOOR, 927/2 4 legs Maize 000155 Issued N RAMASAMY KASAVANUMPATTI, 2,83,750 4,445 2,88,195 DINDIGUL.

72 64/0 THIRU.T.THIRUM Foundation NARI MEEDU,MADURAI. 927/2 4 legs Maize 000157 Issued ALAISAMY 2,27,700 5,430 2,33,130

73 64/1 THIRU.M.GANAPA Foundation GONOR, 927/2 4 legs Maize 000159 Issued THI KASAVANAMPATTI, 1,69,100 4,445 1,73,545 DINDIGUL..

74 47/0 TMY.K.PONNAMM Foundation PACHAMALAYANKOTTAI 134/1 4 legs maize 000308 Issued AL DINDIGUL 4,33,000 5,925 4,38,925

75 53/0 TIRU.ARUMUKAM Foundation , 446/5B2 4 legs 000309 Issued .T.S VIRUGAMBAKKAM,CHENNAI 4,80,000 - - 4,80,000

76 53/0 TIRU.ARUMUKAM Foundation , 446/5B2 4 legs 000312 Issued .T.S VIRUGAMBAKKAM,CHENNAI 4,80,000 - - 4,80,000

77 63/0 THIRU.A.MARIYA Foundation KARISALPATTI, 130/5,13 4 legs maize 000279 Issued FRANCIS PALAYAKANNIVADI, 0/7 3,70,900 8,000 3,78,900 DINDIGUL

78 64/6 TMY.NALAYINI Foundation ,KRISHNASAMI PILLAI 456/4 4 legs Roja 000278 Issued NAVANEETHA LANE,DINDIGUL 2,97,100 2,106 2,99,206 KRISHNAN

79 64/8 THIRU.R.MURUG Foundation KELATHIPPAMPATTI, 188/5 2 legs maize 000272 Issued AN KASAVANAMPATTI, 2,75,450 1,850 2,77,300 DINDIGUL

80 64/8 THIRU.P.RAMESH Foundation KEELA THIPPAMPATTI, 188/6 2 legs jasmine 000273 Issued KASAVANAMPATTI, 98,950 12,946 1,11,896 DINDIGUL.

81 41/0 Thiru. Foundation JAMBUDURAI KOTTAI, 401/6 4 legs 000307 Issued K.NAGARAJAN NILAKOTTAI, DINDIGUL 1,00,000 - - 1,00,000

82 41/0 Thiru. Foundation JAMBUDURAI KOTTAI, 401/6 4 legs 000306 Issued K.NAGARAJAN NILAKOTTAI, DINDIGUL 4,65,000 - - 4,65,000

83 41/0 Thiru. Foundation JAMBUDURAI KOTTAI, 401/6 4 legs 000305 Issued K.NAGARAJAN NILAKOTTAI, DINDIGUL 4,88,000 - - 4,88,000

84 41/0 Thiru. Foundation JAMBUDURAI KOTTAI, 401/6 4 legs 000304 Issued K.NAGARAJAN NILAKOTTAI, DINDIGUL 4,88,000 - - 4,88,000

85 41/0 Thiru. Foundation JAMBUDURAI KOTTAI, 401/6 4 legs 000303 Issued K.NAGARAJAN NILAKOTTAI, DINDIGUL 4,88,000 - - 4,88,000

86 49/0 THIRU.N.MURUG Foundation KURUMPAPATTI, 610/4 4 legs jasmine 000327 Issued A KRISHNAN AMBATHURAI, DINDIGUL. 4,63,925 16,177 4,80,102

100

87 53/0 Thiru.Arulanantha Foundation Seevalsaragu, Attur 000329 issued m 1,41,480 1,41,480

88 23/0 Tmty.M.Ranimari Foundation MALAYAGOUNDANPATTI, 000332 issued Fathima NILAKOTTAI, 1,76,705 1,76,705 DINDIGUL.

89 23/0 Tmty.M.Ranimari Foundation MALAYAGOUNDANPATTI, 000333 issued Fathima NILAKOTTAI, 3,39,500 3,39,500 DINDIGUL.

90 51/4 Tiru Foundation Seevalsaragu, Attur 454/2C1 4 legs Sappota 000347 issued S.SIVAKUMAR 37,208 - 37,208

91 54/0 Tmty. BHAVANI Foundation Seevalsaragu, Attur 76/2A Maize 000348 issued GANESAN 56,900 - 56,900

92 54/0 Tiru M.Arokiyam Foundation Seevalsaragu, Attur 76/2B1 Jasmine 000349 issued 56,900 - 56,900

93 54/0 Tiru M.Arokiyam Foundation Seevalsaragu, Attur 76/2B1 Gova 000350 issued 2,00,000 2,00,000

94 39/1 Tiru Foundation JAMBUDURAI KOTTAI, 39/8 2 legs coconut 000362 issued R.Ganeshkumar NILAKOTTAI, DINDIGUL 42,050 tree - 42,050

95 39/1 Tmty .Mariya Foundation JAMBUDURAI KOTTAI, 40/2 2 legs Sappota 000363 issued Arokiyam NILAKOTTAI, DINDIGUL 42,050 - 42,050

Erection

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compe Total Cheque Status No No./Loc landowner assessment no./Patta legs in value for crop compen of . . No. no. affected compens nsation /DD No. payme land ation sation nt (Rs) value for affected

crop

101

1 25/2 Thiru.AP.Murugan, ERECTION kundalapatti,nilakotai 16,6B NA NA jasmine 30,363 30,363 000221 Issued taluk,dindigul

2 31A/0 Thiru. A.Maria Sami ERECTION silukavarpatti,nilakotai 338/3C; NA NA jasmine 6,000 6,000 000251 Issued Muthu, taluk,dindigul 341/7B; 338/3D; 162/2A1

3 31A/0 Tmy.A.Mathalai ERECTION silukavarpatti,nilakotai 2535(333 NA NA jasmine 10,080 10,080 '000252 Issued mery taluk,dindigul ,335) 333/2B; 335/1

4 31A/0 Thiru.A.Santhiyagu, ERECTION silukavarpatti,nilakotai 333/8E; NA NA jasmine 14,399 14,399 '000253 Issued taluk,dindigul 334/1B

5 25/3 Thiru.T.Rajangam ERECTION nariyuthu,nilakotai 41/2A NA NA maize `000270 Issued taluk,dindigul 1,535 1,535

6 31A/0 Thiru.A.Saveriyar, ERECTION koovanuthu,nilakotai 337/2B1; NA NA jasmine 000254 Issued taluk,dindigul 338/3A; 5,392 5,392 338/3E

7 25/1 THIRU.S.POMMAI ERECTION KUNDALAPATTI, 56/3 NA NA Maize 2,045 2,045 000242 Issued YAN SIRUNAICKEN PATTI, SITHARGAL NATHAM, DINDIGUL

8 31A/0 THIRU.P.RAJA ERECTION SILUKKUVARPATTI, 333/2A,3 NA NA jasmine 12,606 12,606 000256 Issued NILAKOTTAI, 33/2I DINDIGUL

9 31A/0 TMY.T.LAKSHMI ERECTION SILUKKUVARPATTI, 342/3 NA NA Maize 901 901 000255 Issued NILAKOTTAI, DINDIGUL

10 26-Apr THIRU.K.PANDI ERECTION KALKOTTAI, NILAKKOTTAI, 192/2,21 NA NA maize 11,855 11,855 000294 Issued DINDIGUL-624 219. 6/4,217/4

102

11 33B/0 THIRU.K.BALUCH ERECTION KATTUNAYAKKANPATTI, 12/6D NA NA jasmine 16,177 16,177 000300 Issued AMI ORUTHATTU PO, NARIYUTHU,DINDIGUL.

12 33B/0 THIRU.M.VELLAIC ERECTION KATTUNAYAKKANPATTI, 12/6E NA NA jasmine 13,480 13,480 000301 Issued HAMY ORUTHATTU PO, NARIYUTHU,DINDIGUL.

13 62/0 Tmy.Johncy Rani ERECTION ,KASAVANAMPATTI, 927/3 NA NA Cholam 000328 issued DINDIGUL. 8,645.00 8,645.00

14 36/0 Tmy.R.Chinnaponni ERECTION ,Jammuduraikottai,nilakottai 385/4 NA NA lemon 000342 issued tree 1,20,000 1,20,000.

15 39/1 Tiru Ramakrishnan ERECTION JAMBUDURAI KOTTAI, 39/8 NA NA Guava 175000 175000 000364 issued NILAKOTTAI, DINDIGUL

Stringing

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensat Total Cheque/ Status of No No./Lo landowner assessment no./Patta legs in value for crop ion value compensat DD No. payment . c. No. no. affected Land for affected ion land compens crop ation (Rs)

1 28/0- THIRU.K.SENTHIL STRINGING PILLAIYARNATHAM, 7/2B 0 000280 Issued 28A/0 KANIAN, NILAKKOTTAI, DINDIGUL- 4,55,000 4,55,000 624 219.

2 30/0 - THIRU.A.PANDI STRINGING KOMBUKARANPATTY, 68/8C 0 jasmine 21,593 1,04,107 000281 Issued 30A/0 DINDIGUL 82,514

3 30/0 - TMY.S.YEERAMM STRINGING KUVANUTHU, NILAKOTTAI, 206/1 0 jasmine 21,593 3,08,300 000282 Issued 30A/1 AL DINDIGUL. 2,86,707

4 30/0 - THIRU.A.ALAGAR STRINGING KOOVANUTHU, 206/2 0 jasmine 15,108 1,55,715 000283 Issued 30A/2 SAMY NILAKOTTAI, DINDIGUL. 1,40,607

103

5 30/0 - TMY.G.CHANDRA STRINGING KOOVANUTHU, 68/6A 0 jasmine 17,270 3,07,188 000284 Issued 30A/3 NILAKOTTAI, DINDIGUL. 2,89,918

6 30/0 - THIRU.S.NATARAJ STRINGING KOOVANUTHU, 68/5 0 jasmine 19,359 1,01,384 000286 Issued 30A/4 AN NILAKOTTAI, DINDIGUL. 82,025

765 kV DC Transmission Line from Virudhunagar to Coimbatore (Reach 3)

Foundation

S. Tower Name of affected Stage of Village, Survey No. of Agreed Type of Compensa Total Cheque/ Status of N No./Loc landowner assessment no./Patta legs in value for crop tion value compensati DD No. payment o. . No. Taluk & District no. affected Land for affected on land compens crop ation (Rs)

1 15/1 K. KANDASAMY Foundation Village - 1460/3 4 1,10,760 1,10,760 000919 Issued Sankarandampalayam, Taluk - Dharapuram, District - Tiruppur

2 16/3 V. PALANISAMY Foundation Village - Vadugapalayam, 879/2A 4 120520 Drum 203856 3,24,376 000918 Issued Taluk - Dharapuram, District - Sticks , Tiruppur Tamirend, Palm , Chilly

3 34/5 S.VELUSAMY Foundation Village - Uthiyur, Taluk - 204/1 4 110850 1,10,850 001068 Issued Kangayam, District - Tiruppur

4 34/6 SAMIAPPA GR N Foundation Village -Uthiyur, Taluk - 9/1 4 130880 - 1,30,880 001067 Issued Kangayam , District - Tiruppur

5 24/1 THANGARAJ PR Foundation Village -Pongandural, Taluk - 516/ A2 4 110760 Tomato, 202388 3,13,148 000932 Issued Dharapuram, District - Drum Tiruppur Sticks , Palm Chilly

104

6 24/0 S NAGARAJ Foundation Village -Pongandural, Taluk - 523/1 1 9767 Tomato, 168533 1,78,300 000933 Issued Dharapuram, District - Drum Tiruppur Sticks , Palm

7 24/0 G SATHYA Foundation Village -Pongandural, Taluk - 522/11 2 130619 Tomato, 156409 2,87,028 000934 Issued Dharapuram, Distrct - Tiruppur Drum Sticks , Palm Chilli

8 19/1 SUBRAMANIAN K Foundation Village - 990/4,& 4 110760 Drum 226432 3,37,192 000938 Issued Sankarandampalayam, Taluk - 990/5 Sticks , Dharapuram, District - Tamirend, Tiruppur Palm , Ground Nut

9 19/2 MADA Foundation Village - 995 4 120520 Ground 208432 3,28,952 000942 Issued SOUNTHFRA Sangarandampalayam ,Taluk- Nut, PANDIAN P Dharapuram, Tiruppur district Tamirend, Palm

10 34/2 CHINNAKARUPPA Foundation Village -Muthalapalayam, 200/1 4 110850 1,10,850 001069 Issued NAN I Taluk - Kangayam , District - Tiruppur

11 24/2 DURAISAMI S Foundation Village -Muthalapalayam, 568 2 83104 Drum 90997 1,74,101 000949 Issued Taluk - Kangayam , District - Sticks , Tiruppur Ground Nut, Cholam, Palm , Chilly

12 19/0 DURAISAMY P Foundation Village - 945/2 3 168554 Ground 351091 5,19,645 000950 Issued Sangarandampalayam ,Taluk- Nut , Dharapuram, Tiruppur district Tamirend, Drumstick, Palm , Chilly

105

13 24/0 S K Foundation Village -Pongandural, Taluk - 523/2 1 37157 Palm , 90669 1,27,826 000955 Issued BALASUBRAMANI Dharapuram , District - Chilly AM Tiruppur

14 19A/0 S.G.SETHURAJES Foundation Village - Sirukinar, Taluk - 1015 4 131020 1,31,020 000959 Issued WARAN Dharapuram , District - Tiruppur

15 21A/1 S.K.GANESH Foundation Village -Sirukinar, Taluk 927 4 120520 Drumstick , 243302 3,63,822 000961 Issued - Dharapuram Tamirend, Palm , Chilly

16 22/0 M Foundation Village -Pongandural, Taluk - 920 4 161270 Tomato , 320466 4,81,736 000963 Issued MANICKAKRISHNA Dharapuram , District - Tamirend, SAMY Tiruppur Palm , Chilly

17 25/0 S Foundation Village -Muthalapalayam, 560 4 145740 Drum 300904 4,46,644 000964 Issued GOPALAKRISHNA Taluk - Kangayam , District - Stick, N Tiruppur Tamirend, Palm, Tamato, chilly

18 22/1 A . DHANDAPANI Foundation Village - Sirukinar, Taluk - 909 4 130880 Chilli , 241909 3,72,789 000968 Issued Dharapuram, District - Tamirend, Tiruppur Palm , Tomato

19 39/0 P. MOGHAN Foundation Village - Vattamali, Taluk - 872/11 4 145740 1,45,740 000969 Issued Dharapuram, District - Tiruppur

20 38/1 P. MOGHAN Foundation Village - Vattamali, Taluk - 940/3 4 119050 1,19,050 000970 Issued Dharapuram, District - Tiruppur

21 36A/0 S KANDASAMY Foundation Village - Uthiyur, Taluk - 66 4 131010 Drum 175000 3,06,010 000972 Issued Kangayam, District - Tiruppur Stick, Tamirend,

106

Palm, chilly

22 24/3 D. RUBIKA Foundation Village - Muthalipalayam, 564/2 4 110850 Drum 220520 3,31,370 000976 Issued Taluk - Kangayam, District - Stick, Tiruppur Tomato , Tamirend, Palm, chilly

23 36/0 P. Foundation Village - Uthiyur, Taluk - 67 /A2 1 23188 23,188 000983 Issued DEIVASIGAMANI Kangayam, District - Tiruppur

24 36/0 PONNATHAL Foundation Village - Uthiyur, Taluk - 67/A1 3 171832 1,71,832 000982 Issued Kangayam, District - Tiruppur

25 37/0 R SUBBALAKSMI Foundation Village - Uthiyur, Taluk - 64/2 4 130370 1,30,370 000913 Issued Kangayam, District - Tiruppur

26 35/0 SIVASAPABATHI Foundation Village - Uthiyur, Taluk - 167 4 264890 Ground 305085 5,69,975 000986 Issued K Kangayam, District - Tiruppur Nut, Tamirend, Drum Stick, Palm, Cholam , chilly

27 26/0 S Foundation Village - Muthalipalayam, 451/1 4 130370 1,30,370 000989 Issued GOPALAKRISHNA Taluk - Kangayam, District - N Tiruppur

28 25/1 VELUSAMY P S Foundation Village - Muthalipalayam, 459 4 110850 Drum 176240 2,87,090 001070 Issued Taluk - Kangayam, District - Stick, Tiruppur Cholam, Tomato, Tarind

29 9/2 K RAMASAMY Foundation Village - Alampalayam, Taluk - 1331/5 4 130880 1,30,880 001082 Issued Kangayam, District - Tiruppur

107

30 9/5 K RAMASAMY Foundation Village - Alampalayam, Taluk - 1283/1 4 110850 1,10,850 001090 Issued DharapuramKangayam, District - Tiruppur

31 27/0 SENTHILKUMAR S Foundation Village -Muthalipalayam, Taluk 350/2 4 252440 2,52,440 001100 Issued - Kangayam, District - Tiruppur

32 22A/0 THAMILARASAN Foundation Village -Pungandhural, Taluk - 559/A 2 166252 Palm, 86208 2,52,460 001103 Issued D Dharapuram, District - Cholam , Tiruppur chilly

33 9/1 ATHIYA Foundation Village -Nallampal, Taluk - 19 4 110850 1,10,850 001104 Issued SULTHANA Dharapuram, District - Tiruppur

Erection

S. Tower Name of affected Stage of Village, Taluk & District Survey No. of Agreed Type of Compensa Total Cheque/D Status N No./Loc landowner assessment no./Patta legs in value for crop tion value compensat D No. of o. . No. no. affecte Land for affected ion payme d land compens crop nt ation (Rs)

1 22/1 S. SAKTHIVEL Erection Village -Salanpalayam, Taluk 907 NA NA Chilly 15223 15223 '001065 issued - Dharapuram , District - Tiruppur

2 24/3 SIVA Erection Village - Muthalipalayam, 564/1 NA NA chilly, 40048 40048 001077 issued SUBRAMANIUM S Taluk - Kangayam, District - Palm Tiruppur

3 38/1 S THANGARAJ Erection Village - Vattamali, Taluk - 940/1 NA NA Chilly 8541 8541 001094 issued Kangayam, District - Tiruppur

4 19/0 SUBRAMANIAN Erection Village - 944/4 NA NA Palm 71285 71285 001093 issued Sankarandampalayam, Taluk Chilly - Dharapuram, District - Tiruppur

Source-TANTRANSCO; NA-Not Applicable

108