The Central Register

Volume 40, Issue 38, September 16, 2020

Published by: The Secretary of the Commonwealth, William Francis Galvin

CENTRAL REGISTER Published weekly by William Francis Galvin, Secretary of the Commonwealth

Volume 40, Issue 38, September 16, 2020

DESIGNER SERVICES Request for Proposals 1

GENERAL CONTRACTS Invitation to Bid 5

CONTRACTORS OBTAINING PLANS/SPECIFICATIONS 40

CONTRACT AWARDS 47

LEASE, RENTAL, SALE, PURCHASE, ACQUISITION OR DISPOSITION OF REAL PROPERTY Notice of Proposed Disposition of Real Property 52 Office of Lease Management 58

MISCELLANEOUS -

LIST OF DEBARRED CONTRACTORS DCAMM 60 Attorney General 61

DEPARTMENT OF INDUSTRIAL ACCIDENTS DEBARMENT LIST 62

LIST OF DECERTIFIED CONTRACTORS DCAMM 63

SUPPLIER DIVERSITY OFFICE Companies Certified 64 Companies Decertified -

DEPARTMENT OF TRANSPORTATION CERTIFICATION OFFICE Companies Certified 70 Companies Decertified 71

DESIGNER SELECTION BOARD -

The Central Register is a state publication of public contracting opportunities, contract awards and related information received by the Secretary of the Commonwealth under the provisions of M.G.L. c. 9, § 20A. William Francis Galvin Secretary of the Commonwealth STATE BOOKSTORE State House, Room 116 Boston, MA 02133 (617) 727-2834

CENTRAL REGISTER SUBSCRIPTION INFORMATION

The Central Register is available in electronic form only. The total subscription price is $101.50 per year.

You may subscribe to this publication on the following website: http://www.sec.state.ma.us/PublicationSubscriptionPublic/Login.aspx

Please feel free to contact the State Bookstore with any questions that you may have regarding your subscription.

Phone: (617) 727-2834 Email: [email protected]

** State Agencies Only** CHECKS WILL NOT BE ACCEPTED FROM STATE AGENCIES. State agencies are required to use the IE/ITI system. State agencies must complete the following information in order for their subscription to be processed.

DEPT. CODE (3 letters): ______ORG. # (4 numbers): ______

AMOUNT TO BE ENCUMBERED: $______

AGENCY NAME: ______

CONTACT NAME: ______

ADDRESS: ______

PHONE:______CONTACT EMAIL:______CENTRAL REGISTER - DESIGNER SERVICES CR-1 Public projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 1206-01 Boston, City of Designer's Fee: Negotiated NTE $25,000.00 Housing Authority 52 Chauncy Street, 6th Floor Estimated Construction Cost: Boston, MA 02111 Time Period for Completed Project:

CONTACT INFORMATION: PHONE: FAX: Procurement Department EMAIL: [email protected] CONTRACT INFORMATION:

PROJECT: Licensed Site Professional (LSP) Services for Lenox Development. SCOPE:

SPECIFIC DESIGNER SERVICES DEADLINE FOR APPLICATION FORM: Architect Landscape Architect Planner Programmer 10/2/20 @ 2:00 P.M. Engineer Land Surveyor Space Planner Project Manager Other Specify Licensed Site Professional (LSP) Services

PROJECT PROGRAM AVAILABILITY: BRIEFING SESSION: ADDITIONAL INFORMATION Pre-proposal meeting: 9/24/20 @ 2:00 P.M., front of the Lenox Apartments Management Office, 136 Lenox St., Boston, MA. RFP packages available via request to [email protected] free of charge. Questions or requests for modifications regarding this RFP will be accepted in writing only to [email protected] on or before 9/28/20 at 2:00 P.M.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 1206-07 Boston, City of Designer's Fee: Negotiated NTE $25,000.00 Housing Authority 52 Chauncy Street, 6th Floor Estimated Construction Cost: Boston, MA 02111 Time Period for Completed Project:

CONTACT INFORMATION: PHONE: FAX: Procurement Department EMAIL: [email protected] CONTRACT INFORMATION:

PROJECT: Licensed Site Professional (LSP) Services for Lenox Development. SCOPE:

PROJECT PROGRAM AVAILABILITY: BRIEFING SESSION: ADDITIONAL INFORMATION Pre-proposal meeting: 9/24/20 @ 2:00 P.M., front of the Lenox Apartments Management Office, 136 Lenox St., Boston, MA. RFP packages available via request to [email protected] free of charge. Questions or requests for modifications regarding will be accepted in writing only to [email protected] and must be submitted on or before 9/28/20 at 2:00 P.M.

1 CENTRAL REGISTER - DESIGNER SERVICES CR-1 Public projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: RFQ 2020-2 Lowell, City of Designer's Fee: Negotiated Housing Authority 350 Moody Street Estimated Construction Cost: $995,000.00 Lowell, MA 01854 Time Period for Completed Project:

CONTACT INFORMATION: PHONE: 978-364-5341 FAX: 888-364-8835 Rita V. Brousseau EMAIL: [email protected] CONTRACT INFORMATION:

PROJECT: A&E Design services for the Electrical Redistribution - Phase II. SCOPE: Responsibilities will include schematic design, bidding and construction documents (with minimal bidding assistance), submittal approval, construction administration, weekly site and construction meetings and meeting notes, and related tasks.

SPECIFIC DESIGNER SERVICES DEADLINE FOR APPLICATION FORM: Architect Landscape Architect Planner Programmer 10/7/20 @ 11:00 A.M. Engineer Land Surveyor Space Planner Project Manager Other Specify

PROJECT PROGRAM AVAILABILITY: BRIEFING SESSION: 9/24/20 @ 10:00 A.M.: https://global.gotomeeting.com/join/471643181 ADDITIONAL INFORMATION The RFQ can be downloaded at www.lhma.org/bids.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: #21-13 Newton, City of Designer's Fee: Set Fee $89,000 1000 Commonwealth Avenue Newton, MA 02459 Estimated Construction Cost: $861,000. Time Period for Completed Project: One year. CONTACT INFORMATION: PHONE: 617.796.1220 FAX: 617.796.1227 Nicholas Read EMAIL: [email protected] CONTRACT INFORMATION:

PROJECT: RFQ Louise Levingston Cove Improvements. SCOPE: Request for Qualifications for design development, construction documentation and permitting as outlined in the project documents.

SPECIFIC DESIGNER SERVICES DEADLINE FOR APPLICATION FORM: Architect Landscape Architect Planner Programmer 10/1/20 @ 11:00 A.M. Engineer Land Surveyor Space Planner Project Manager Other Specify Designer

PROJECT PROGRAM AVAILABILITY: 9/17/20 BRIEFING SESSION: Pre-Bid Meeting: 9/24/20 @ 11:00 A.M., Levingston Cove, Berwick Rd Entrance, Newton (Not Mandatory) ADDITIONAL INFORMATION Project documents are available at www.newtonma.gov/bids or pick-up at Town Hall, Room 108, 1above agency address, after 9/17/20 @ 10:00 A.M.

2 CENTRAL REGISTER - DESIGNER SERVICES CR-1 Public projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: RFP: UFHASS2020A Uxbridge, Town of Designer's Fee: Negotiated 21 S. Main Street Uxbridge, MA 01569 Estimated Construction Cost: Time Period for Completed Project:

CONTACT INFORMATION: PHONE: 508-278-8600 x4 FAX: Department of Economic Development and Community Planning EMAIL: CONTRACT INFORMATION:

PROJECT: The Town of Uxbridge seeks the services of a Preservation Professional Architect to review the existing conditions, including an evaluation of the physical structure, of the Cornet John Farnum House located at 44 Mendon Street, Uxbridge, MA and to make recommendations regarding restoration of this Historical building. SCOPE:

SPECIFIC DESIGNER SERVICES DEADLINE FOR APPLICATION FORM: Architect Landscape Architect Planner Programmer 9/30/20 @ 3:00 P.M. Engineer Land Surveyor Space Planner Project Manager Other Specify

PROJECT PROGRAM AVAILABILITY: Requests for Proposals are available at https://www.uxbridge-ma.gov/ or by request from the following: Town of Uxbridge Department of Economic Development and Community Planning, 21 South Main Street, Uxbridge, MA 01569 508-278-8600x4; mgallerani@uxbr BRIEFING SESSION: ADDITIONAL INFORMATION Proposals are due by deadline at which time will be publicly opened. The Request for Proposal (“RFP”) is made pursuant to M.G.L. c. 30B, pertaining to Consultant Contract Services. The subject property, Farnum House, is listed on the State Register of Historic Places and must comply with the Secretary of the Interior’s Standards for the Treatment of Historic Properties and the project is being partially funded with a grant from the Massachusetts Preservation Projects Fund, Massachusetts Historical Commission. State Law prohibits discrimination and it is the policy of the Town of Uxbridge to provide equal employment opportunities without regard to race, color, religion, sex, national origin, age, disability, marital status, veteran status, sexual orientation, genetic information or any other protected characteristic under applicable law.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 7429 Water Resources Authority, Massachusetts Designer's Fee: Charlestown Navy Yard 100 First Avenue, Building 39 Estimated Construction Cost: Boston, MA 02129 Time Period for Completed Project:

CONTACT INFORMATION: PHONE: 617-242-6000 FAX: 617-788-4882 Rita Mercado EMAIL: [email protected] CONTRACT INFORMATION:

PROJECT: RFQ/P Design and Engineering Services During Construction for Ward Street and Columbus Park Headworks Upgrade SCOPE:

SPECIFIC DESIGNER SERVICES DEADLINE FOR APPLICATION FORM: Architect Landscape Architect Planner Programmer 10/30/20 @ 11:00 A.M. Engineer Land Surveyor Space Planner Project Manager Other Specify

PROJECT PROGRAM AVAILABILITY: on or after 9/16/20 BRIEFING SESSION: ADDITIONAL INFORMATION To access and bid on this Event, please go to the MWRA Supplier Portal at www.mwra.com.

3 CENTRAL REGISTER - DESIGNER SERVICES CR-1 Public projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: RFQ #21-0001 Springfield Parking Authority Designer's Fee: Negotiated $60,000 150 Bridge Street Springfield, MA 01103 Estimated Construction Cost: $500,000 to $700,000 Time Period for Completed Project: 18 weeks CONTACT INFORMATION: PHONE: 413-273-8419 FAX: Bokul Bhuiya EMAIL: [email protected] CONTRACT INFORMATION:

PROJECT: The Springfield Parking Authority is seeking Designer and Engineering services for capital improvements and system upgrades to be performed at the City Stage unit located at One Columbus Center. The Project Cost for this potential work is estimated to range from $500,000 to $700,000 (inclusive) and that is ultimately approved by a vote of the Springfield Parking Authority Governing Board. The Fee for these Services shall not exceed $60,000 and will be negotiated. SCOPE: Please request details from the Authority via email.

SPECIFIC DESIGNER SERVICES DEADLINE FOR APPLICATION FORM: Architect Landscape Architect Planner Programmer 10/14/20 @ 12:00 P.M. Engineer Land Surveyor Space Planner Project Manager Other Specify

PROJECT PROGRAM AVAILABILITY: 9/14/20 BRIEFING SESSION: N/A ADDITIONAL INFORMATION Last day for questions from Respondents is 9/30/20. Questions to be answered and forwarded to Respondents by 10/5/20. Responses due by 10/14/20 @ 12:00 P.M. and opened publicly. RFQ Evaluation, Potential Interviews, Award of Contract, Execution of Contract 10/14/20 - 10/21/20.

4 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Acton, Town of Department of Public Works ESTIMATED COST: 14 Forest Rd CONTRACTOR QUALIFICATION: Acton, MA 01720 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Impacted Soil Excavation CONTACT INFORMATION PHONE: FAX: Corey York EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at Acton DPW/Highway Division, [email protected], 9/20/20 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/28/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 21DPW-04 Ayer, Town of 1 Main Street ESTIMATED COST: $1.3 million Ayer, MA 01432 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The work under this contract includes, but is not necessarily limited to, furnishing and installing within the Town of Ayer approximately 1,450 linear feet of 3-inch HDPE pressure sewer and services and manholes, 1,360 linear feet of 2-inch HDPE pressure sewer and services and manholes, and 2,600 linear feet of 8-inch DI water main and services; trench pavement; and disposal of all excess material; and all appurtenances and incidental work necessary to complete the construction. CONTACT INFORMATION PHONE: 978-772-8240 FAX: Mark Wetzel EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE An electronic copy: https://www.ayer.ma.us/bids (place, date and time) Hard copies: Ayer DPW, 25 Brook Street, Ayer, MA 01432, Telephone 978-772-8240 on/after 9/16/20 from 7:30 A.M. - 3:30 P.M. Mon. - Fri. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 1:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

5 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: n/a Barnstable, Town of 230 South Street ESTIMATED COST: $500,000 Hyannis, MA 02601 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: 2020 Oyster Harbors Bridge Rehabilitation Project. CONTACT INFORMATION PHONE: 508-737-3280 FAX: Amber Patterson, Acting Chief Procurement Officer EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.townofbarnstable.us (Bid & RFP System). (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION See bid documents for all other information, including virtual bid opening information and pre-bid meeting date/time/location.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Belmont, Town of Belmont Municipal Light Department ESTIMATED COST: 40 Prince street CONTRACTOR QUALIFICATION: Belmont, MA 02478 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: RFP 4003 Belmont Light Managed Services Provider for IT Infrastructure CONTACT INFORMATION PHONE: 617-993-2800 FAX: 617-993-2846 Robin Tillberg EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Electronic copies will be available free of charge by written request to [email protected], (place, date and time) 9/17/20. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/12/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION For any questions regarding this RFP email to [email protected]

6 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Bolton, Town of 663 Main Street ESTIMATED COST: $57,000 Bolton, MA 01740 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The purchase and installation of of a diesel exhaust particulate filter (DPF) on the Public Safety Building generator. CONTACT INFORMATION PHONE: 978-779-6402 FAX: 978-779-0301 Donald Lowe EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE For bid package and specifications contact the Town of Bolton DPW at [email protected] starting (place, date and time) 9/16/20. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Bolton, Town of 663 Main Street ESTIMATED COST: $22,000 Bolton, MA 01740 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Winter Use Sand: approximately 3000 cubic yards of screened sand delivered to the Town of Bolton Transfer Station CONTACT INFORMATION PHONE: 978-779-6402 FAX: 978-779-0301 Donald Lowe EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

7 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 7208 Boston, City of Public Facilities Department ESTIMATED COST: $1,586,526 26 Court Street, 10th Floor CONTRACTOR QUALIFICATION: DCAMM Certificate Boston, MA 02108 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Roslindale Community Center Emergency Upgrades. CONTACT INFORMATION PHONE: 617-635-4809 FAX: 617-635-4852 Bid Counter EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at the Public Facilities Department - Bid Counter or through [email protected] on 9/14/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: 9/30/20 @ 12:00 P.M. GENERAL BID DEADLINE: 10/14/20 @ 12:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: Resilient Flooring, Painting, Acoustical Tile, Fire Protection, HVAC and Electrical. ADDITIONAL INFORMATION Site viewing: 9/23/20 from 10:00 A.M. - 11:00 A.M., Roslindale Community Center, 6 Cummins Highway, Roslindale, MA 02131. All Vendors are advised to visit our website regularly at https://www.boston.gov/departments/public- facilities, as PFD bidding information is fluid and can change at any time. Please review the information on the website regarding procedures required for where to submit/drop off bid documents. All questions or concerns should be emailed to [email protected]. DCAMM Certification Category: General Building Construction.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 1689-02 Boston, City of Housing Authority ESTIMATED COST: $702,097.00 52 Chauncy Street, 6th Floor CONTRACTOR QUALIFICATION: DCAMM Certificate Boston, MA 02111 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: 200-11, 200-12, and 200-5 Security Camera Installation, Boston, Massachusetts. The Project consists of: The addition of security cameras including NVRs and all associated equipment and appurtenances at three Boston Housing Authority Sites. CONTACT INFORMATION PHONE: 781-848-4464 FAX: Lucas Pomerleau EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE to download via request to [email protected] (free of charge). (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: 9/30/20 @ 11:00 A.M. GENERAL BID DEADLINE: 10/14/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: Electrical ADDITIONAL INFORMATION Pre-Bid Walkthrough: 9/17/20 @ 10:00 A.M., meet at the Franklin Field Development, 100 Ames St., Boston, MA. We will travel to the other two locations as required.

8 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Braintree, Town of Department of Public Works ESTIMATED COST: 85 Quincy Ave CONTRACTOR QUALIFICATION: Braintree, MA 02184 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Pursuant to M.G.L. c. 149, §§ 44A-44J and all other applicable laws, the Town of Braintree Department of Public Works cordially invites written bids for the following: Removal and replacement of 7 section heating unit with a new multi fuel (Oil/Gas) steam burner unit and all new boiler controls equal to the existing system, 71 Cleveland Avenue, Braintree, MA CONTACT INFORMATION PHONE: FAX: Kate Sandstrom EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE http://www.braintreema.gov/Bids.aspx beginning 9/17/20 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 1:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Site visit: 9/24/20 @ 10:00 A.M. at 71 Cleveland Avenue, Braintree, MA at which time the job site shall be made available for inspection. Massachusetts Prevailing Wage Laws apply to all services. E-Mail submissions will not be accepted. Late proposals will not be accepted. It is the sole responsibility of a Respondent to ensure that the proposal arrives on time at the designated place. It is strongly encouraged recommended that proposals are mailed or delivered in advance of the due date and time. The vendor shall include the costs of bonds and permits within their bid. The Town of Braintree retains the right to waive any informality or reject all proposals or any portions thereof which such action is deemed to be in the best interest of the Town of Braintree in doing so. The Town of Braintree is an affirmative action/equal employment purchaser.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 0409232020 Braintree, Town of Housing Authority ESTIMATED COST: $40,000 25 Roosevelt Street CONTRACTOR QUALIFICATION: Braintree, MA 02184 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: One Year Contract for Fire Alarm Testing. CONTACT INFORMATION PHONE: 781-848-1484 FAX: Lauren Murphy EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

9 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Brewster, Town of 2198 Main Street ESTIMATED COST: $1,700,0000 Brewster MA 02631 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Site work associated with the Brewster Woods Housing Development of a vacant parcel off Brewster Road, including site clearing, grubbing, grading, driveway construction, sidewalk construction, excavation and installation of drainage and sewage disposal systems, water main installation, conduit installation for future utilities, wall construction, restoration of disturbed area and all work incidental thereto CONTACT INFORMATION PHONE: 508-896-3701 FAX: 508-896-8089 Donna J. Kalinick EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at the Brewster Town Offices, 2198 Main Street, Tues. and Thurs., 8:30 A.M. - 4:00 P.M. or by email (place, date and time) request to [email protected] CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/9/20 @ 10:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION All bids subject to the provisions of MGL. Ch.3039M, 5% bid bond, selected contractor must provide 100% performance and labor & material bonds; Pre-Bid Conference: 9/28/20 @ 10:00 A.M. on site

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 042087 Bridgewater, Town of Bridgewater Housing Authority ESTIMATED COST: $16,500 10 Heritage Circle CONTRACTOR QUALIFICATION: Bridgewater, MA 02324 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Removal of existing front entry door system, and replacement with new steel entry door system with automatic door operator. CONTACT INFORMATION PHONE: 857-206-9457 FAX: 508-812-7050 Moll EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.Projectdog.com, 9/16/20. Project Code 837859. Login with an existing account or click "Sign Up" to (place, date and time) register for free. Select "Acquire Documents" to download. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION THIS PROJECT IS BEING ELECTRONICALLY BID (E-BID). Hard copies of the bidding documents may be viewed at Projectdog's physical address. The jobsite will be available for inspection 9/23/20 by appointment only between 9:00 A.M. - 11:00 A.M. Contact [email protected] to schedule an appointment on or before 9/22/20. Direct questions is writing to [email protected].

10 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 042088 Bridgewater, Town of Bridgewater Housing Authority ESTIMATED COST: $24,500 10 Heritage Circle CONTRACTOR QUALIFICATION: Bridgewater, MA 02324 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Removal of existing carpet, LVT and linoleum flooring and accessories; and replacement with luxury vinyl tile (LVT) flooring and accessories. CONTACT INFORMATION PHONE: 857-206-9457 FAX: 508-812-7050 Molly Parris EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.Projectdog.com, 9/16/20. Project Code 840294. Login with an existing account, or click "Sign Up" (place, date and time) to register for free. Select "Acquire Documents" to download. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION THIS PROJECT IS BEING ELECTRONICALLY BID (E-BID). Hard copies of the bidding documents may be viewed at Projectdog's physical address. The jobsite will be available for inspection on 9/23/20 by appointment only between 10:00 A.M. - 12:00 P.M. Contact [email protected] to schedule an appointment. Direct questions in writing to [email protected].

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 1311 Cambridge, City of Housing Authority **REBID** ESTIMATED COST: $21.7 million 362 Green Street, 3rd Floor CONTRACTOR QUALIFICATION: DCAMM Certificate Cambridge, MA 02139 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Cambridge Housing Authority seeks Tile and Resilient Floors firms to work on the Modernization of Truman Apartments, a 59-unit building for elderly and disabled residents. CONTACT INFORMATION PHONE: 617-520-6394 FAX: Maura Barry-Garland EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE via request to [email protected] on 9/16/20 @ 9:00 A.M.. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: 9/30/20 @ 12:00 P.M. GENERAL BID DEADLINE: 9/30/20 @ 12:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: Tile ($199,000); Resilient Floors ($359,000) ADDITIONAL INFORMATION This project was previously advertised. Due to insufficient responses, the Awarding Authority is prequalifying Resilient Floors and Tile only for this project.

11 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Cambridge, City of Housing Authority ESTIMATED COST: $12,000 362 Green St. 3rd Floor CONTRACTOR QUALIFICATION: Cambridge, MA 02139 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Security Gate Installation at Manning Apartments. Project consists of furnishing and installing a security gate at drive way garage. Awarding contractor will be responsible for evaluating adequate space and accessibility for security gate installation.The construction period will be 30 calendar days from Notice to Proceed. CONTACT INFORMATION PHONE: 617-520-6243 FAX: Gisell De la Cruz EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at http://cambridge-housing.org/about/additional_information/bids.asp;and https://www.biddocsonline.com. (place, date and time) after 9/17/20 @ 12:00 P.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/8/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Site visit: 9/23/20 @ 10:00 A.M., meet at the front entrance of 237 Franklin St., Cambridge, MA 02139. Please practice social distancing and wear masks. Please refer to Technical specifications § 01 10 02 for required procedures during COVID-19. Each bidder is encouraged to visit the site of the proposed work and become fully acquainted with the conditions as they exist to fully understand conditions, restrictions,and difficulties attending the execution of the work under this contract. By submitting a bid,the bidder warrants that he has examined the site and bid documents and,that the bid documents are adequate,and the required result can be produced as written. No increase in the contract sum nor claim for damages due to delay will be permitted because of the contractor’s failure to accomplish any or all of these requirements.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 9360 Cambridge, City of Purchasing Department ESTIMATED COST: $875,000 795 Massachusetts Ave., Room 303 CONTRACTOR QUALIFICATION: Cambridge, MA 02139 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: DPW Mooney Street Alteration. DCAMM General Category: General Building Construction. Filed Sub Bid Categories: Painting & Fire Protection. CONTACT INFORMATION PHONE: 617-349-4310 FAX: 617-349-4008 Elizabeth Unger EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at [email protected] on 9/17/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: 10/8/20 @ 2:00 P.M. GENERAL BID DEADLINE: 10/15/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: Painting & Fire Protection. ADDITIONAL INFORMATION

12 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 9369 Cambridge, City of Purchasing Department ESTIMATED COST: $65,000 795 Massachusetts Ave., Room 303 CONTRACTOR QUALIFICATION: Cambridge, MA 02139 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Parks and Playgrounds Maintenance and Repair Services. CONTACT INFORMATION PHONE: 617-349-4310 FAX: 617-349-4008 Vilsabel David EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE by contacting [email protected] on 9/17/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 9370 Cambridge, City of Purchasing Department ESTIMATED COST: $140,000.00 795 Massachusetts Ave., Room 303 CONTRACTOR QUALIFICATION: Cambridge, MA 02139 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Hartcourt Surfaces - Maintenance and Repair Services. CONTACT INFORMATION PHONE: 617-349-4310 FAX: 617-349-4008 Vilsabel David EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE by contacting [email protected] on 9/17/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

13 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 2020-3 Clinton, Town of c/o Board of Selectmen ESTIMATED COST: $250,000 242 Church Street CONTRACTOR QUALIFICATION: Clinton, MA 01510 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The work for this project consists of the pressure washing and recoating of the exterior surfaces (walls and dome) of the Burditt Hill 1.6-million-gallon water storage tank (prestressed concrete reservoir) and furnishing / installation of an aeration system for THM removal. CONTACT INFORMATION PHONE: 508-281-5136 FAX: Nick Shaw EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at Comprehensive Environmental, Inc., 41 Main Street, Bolton, MA 01740 after 9/16/20, 8:30 A.M. - 4:30 (place, date and time) P.M., Mon. - Fri. Contract Documents may be obtained upon the deposit of $30/set (refundable) by check or money order made payable to Comprehensive Environmental Inc. Bidders requesting Contract Documents by mail shall include an additional check or money order made payable to Comprehensive Environmental Inc., in the amount of $35/set (non-refundable) to cover the costs of handling and mailing. Upon request, an electric copy of the Contract Documents will be emailed to prospective bidders (no charge). CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 2021-01 Cohasset, Town of 41 Highland Ave ESTIMATED COST: Cohasset, MA 02025 CONTRACTOR QUALIFICATION: DCAMM Certificate

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The Town of Cohasset, acting through its Board of Selectmen, in conjunction with the Alternative Energy Committee and School Committee, seeks competitive proposals for the lease of certain Town owned real property to construct a commercial or utility class solar energy array and associated equipment for the purpose of supplying electrical energy via net metering to Town facilities. The lease shall be for a term of twenty years. CONTACT INFORMATION PHONE: 781-383-4100 x5114 FAX: Michelle leary EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Email: [email protected] (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/9/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

14 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 2198 Concord, Town of 22 Monument Square ESTIMATED COST: $20,000 Concord, MA 01742 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Heywood Meadow Stone Wall Extension CONTACT INFORMATION PHONE: 978-318-3285 FAX: Delia Kaye EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at 141 Keyes Road (via email: [email protected]), 9/16/20 @ 12:00 P.M. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/2/20 @ 10:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: FY2021-02 Erving, Town of 12 East Main Street ESTIMATED COST: $10,000 Erving, MA 01344 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: In accordance with M.G.L. c. 149, the Town of Erving, Massachusetts, acting through the Board of Selectmen, is soliciting quotes for the installation of 29 new LED streetlights and associated equipment that has already been procured by the Town. The Town of Erving (“Town”) reserves the right to reject any and all quotes in part or in whole. It also reserves the right to make an award in any manner consistent with Massachusetts General Law and deemed to be in the best interest of the Town. The contract for this service must be approved by the Erving Board of Selectmen. CONTACT INFORMATION PHONE: 413-422-2800 FAX: Bryan A Smith EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE For a copy of the procurement document visit www.erving-ma.gov/bids. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/2/20 @ 3:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

15 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Falmouth, Town of Public Schools ESTIMATED COST: $165,000 Office of Finance and Operations CONTRACTOR QUALIFICATION: DCAMM Cert. and 340 Teaticket Highway Highway Division Falmouth, MA 02536 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Generator Replacement at Teaticket Elementary School. CONTACT INFORMATION PHONE: 978-486-4301 x15 FAX: 978-428-0067 John Pierga, P.E. EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE via request to BLW Engineers, Inc. at [email protected] on 9/16/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: 9/30/20 @ 1:00 P.M. GENERAL BID DEADLINE: 10/07/20 @ 1:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: HVAC ADDITIONAL INFORMATION Pre-Bid Conference: 9/23/20 @ 3:00 P.M., Teaticket Elementary School, 45 Maravista Ave., Extension, East Falmouth, MA (enter via side entrance), at which time the job site shall be available for inspection. DCAMM Certification: Electrical.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 097122 Fitchburg, City of Housing Authority ESTIMATED COST: $77,464 50 Day Street CONTRACTOR QUALIFICATION: Fitchburg, MA 01420 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Remove existing wood or vinyl windows. Replace with new vinyl windows. Replace existing door and frame with new fiberglass door, frame and sidelights. CONTACT INFORMATION PHONE: 978-761-3627 FAX: Gwen Erskine EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at BidDocsonline.com or Nashoba Blue Inc., 433 Main Street, Hudson, MA 01749. 978-568-1167. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 1:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Pre-bid Conference: 9/21/20, 11:00 A.M. - 1:00 P.M. is by pre-registration only. Call 978-761-3627 or email [email protected] to request a 20 minute time slot.

16 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 325-1804 Foxborough, Town of 70 Elm Street ESTIMATED COST: $815,000.00 Foxborough, MA 02035 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The work under this contract includes, but is not necessarily limited to, the construction of the Oak Street Replacement Wells 7R, 9R, and 10R implementation. The project includes furnishing all services, equipment, and materials for the required demolition work and abandonment of wells; the installation of submersible pumps, well piping and well pitless adapters, process piping and valves; disinfection/chlorination of well and process piping; connecting to the existing raw water system; site work including erosion controls, fencing, clearing, grubbing, and grading; instrumentation and controls upgrades; and electrical work to provide a fully functioning replacement well system. CONTACT INFORMATION PHONE: 617-657-0200 FAX: 617-657-0201 Dave Patangia, P.E. EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Bid forms and contract documents will be available at www.projectdog.com, 9/16/20. Project Code: 836591 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/13/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Pre-bid meeting: 9/24/20 @ 10:00 A.M. at the Oak Street WTF, 11 Lamson Street, Foxborough, MA. All bidders are strongly encouraged to attend.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 21074 Gloucester, City of Purchasing Department ESTIMATED COST: $100,000 9 Dale Avenue CONTRACTOR QUALIFICATION: Gloucester, MA 01930 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Electrical Repair Services as Needed. Provide maintenance and repair services to all City electrical systems, fire alarms & equipment. Services to include normal and emergency electrical maintenance and repairs for City owned buildings, equipment & outdoor services as required. CONTACT INFORMATION PHONE: 978-281-9710 FAX: 978-281-8763 Donna Compton EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE by contacting [email protected] on 9/16/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/8/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

17 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: E2765 Great Barrington, Town of 334 Main Street ESTIMATED COST: $215,000 Great Barrington, MA 01230 CONTRACTOR QUALIFICATION: Highway Division

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Housatonic Main Street - Sidewalk Construction & Related Work. CONTACT INFORMATION PHONE: 413-499-1560 FAX: Maureen Jacoby EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE request to [email protected] after 9/16/20 @ 2:00 P.M. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/8/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Non-mandatory pre-bid site visit: 9/24/20 @ 2:00 P.M., meet at corner of Main St. and Rt. 41 in the Village of Housatonic, MA.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 113099 Greenfield, City of Greenfield Housing Authority ESTIMATED COST: $20,000 1 Elm Terrace CONTRACTOR QUALIFICATION: Greenfield, MA 01301 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Elm Terrace, 667-2, Re-Paving of parking area CONTACT INFORMATION PHONE: 413-774-2932 x206 FAX: 413-772-0616 Andrea (Andi) Guy EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.BidDocsonline.com or at Nashoba Blue, Inc., 433 Main Street, Hudson, MA 01749, 978-568-1167 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Pre-bid Site Visit: 9/23/20 @ 10:00 A.M. Meet at 1 Elm Terrace, Greenfield

18 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 128096 Haverhill, City of Haverhill Housing Authority ESTIMATED COST: $47,000 25C Washington Square CONTRACTOR QUALIFICATION: Haverhill, MA 01831 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Bathroom Renovations at 16 Highland Avenue 689-1 Special Needs Housing. CONTACT INFORMATION PHONE: 508-843-2924 FAX: Ray Guertin EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Projectdog, 18 Graf Rd., Newburyport, MA 01950, 978-499-9014 or online at www.projectdog.com (place, date and time) (Project Code 840010). CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: None ADDITIONAL INFORMATION Pre-bid conference: 9/23/20 @ 10:00 A.M. at 16 Highland Avenue, Haverhill, MA - site briefing to follow CDC & State COVID-19 Guidelines for social distancing - all attendees must wear a mask. Go to www.projectdog.com and click "Sign Up" for free or login with your existing account. In the toolbox, click "Acquire Documents" to download bid documents. A free project CD-ROM may be requested by contacting Projectdog - shipping & handling charges apply. All plan holders must have an active online account on www.projectdog.com to acquire documents, receive project notifications, and to submit bids electronically. Hard copies of the documents may also be view, but not removed, from the office of Projectdog, Inc., 18 Graf Road - Unit 8, Newburyport, MA Monday - Friday 8:30 am to 5 pm. Questions regarding the website or project distribution should be directed to Projectdog at 978-499-9014. This Project is being ELECTRONICALLY BID.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 133057 Holbrook, Town of Holbrook Housing Authority ESTIMATED COST: $35,500 One Holbrook Court CONTRACTOR QUALIFICATION: Holbrook, MA 02343 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Community Room Ceiling Replacement CONTACT INFORMATION PHONE: 781-767-0024 FAX: 781-767-4081 Sherry Guilbault EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE www.Projectdog.com project code 840293, 9/16/20 @ 9:00 A.M. This project is being electronically bid. To (place, date and time) obtain contract documents, go to www.Projectdog.com and click “Sign Up” for free, or login with an existing account. Enter Project Code 840293 in the project locator box. Select “Acquire Documents” to download documents, review a hard copy at Projectdog’s physical location, or request a free project CD. Questions regarding the website or project distribution should be directed to Projectdog at 978-499-9014. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 10:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION The job site will be available for inspection by appointment only on 9/23/20.

19 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Lawrence, City of Lawrence Housing Authority ESTIMATED COST: $35,000 65 Union Street CONTRACTOR QUALIFICATION: Lawrence, MA 01840 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Raise the existing primary duct bank and re-support, and replace the existing medium voltage primary cables from the utility pole to the existing transformer vault at 60 Auburn Street. CONTACT INFORMATION PHONE: 978-382-9445 FAX: Chris McGuire EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Bid Forms and Contract Documents will be available online and for purchase at www.Projectdog.com, (place, date and time) project code 840287 on 9/16/20 CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION The job site and/or existing building will be available for observation on the morning of 9/24/20. To limit the number of bidders present at any one time, multiple observation times may be held. Bidders must contact Nangle Engineering Inc. ([email protected] or 978-777-7650) prior to close of business on the Monday prior to schedule an appointment. Bidders attending will be limited to one person per firm. Attendees must bring and wear a face mask which covers the nose and mouth, and may wear gloves. To maintain social distancing, attendees may be asked to enter the work spaces one at a time. No access to dwelling units is required, or allowed.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 153103 Leominster, City of Leominster Housing Authority ESTIMATED COST: $212,700 100 Main Street CONTRACTOR QUALIFICATION: DCAMM Certificate Leominster, MA 01453 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Comprehensive modernization of Single Family Home interior & exterior, 705-01 at 633 Main Street in Leominster, MA. Includes MEP, site work and asbestos & lead abatement. CONTACT INFORMATION PHONE: 781-354-6722 FAX: Jennifer Steffek EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at Project Dog, 9/16/20 @ 2:00 P.M. Go to www. Projectdog.com on and enter Project Code #840290. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: 9/30/20 @ 3:00 P.M. GENERAL BID DEADLINE: 10/7/20 @ 3:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: 22.00.00 Plumbing; 23.00.00 HVAC; 26.00.00 Electrical ADDITIONAL INFORMATION Pre-bid Conference / Site Visit: 9/22/20 by appointment between 10:00 A.M. - 12:00 P.M. at 633 Main Street, Leominster, MA. All attendees must wear a face mask. For an appointment call: Adam Gautie at 978-728-6997

20 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 21-23 Lexington, Town of 1625 Massachusetts Ave. ESTIMATED COST: Lexington, MA 02420 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Catch Basin Cleaning. CONTACT INFORMATION PHONE: 781-698-4628 FAX: Elizabeth Mancini EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.lexingtonma.gov/bids on 9/17/20 @ 12:00 P.M. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 12:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 03-354 Lynn, City of Purchasing Department Rm 205 ESTIMATED COST: $40,000 3 City Hall Square CONTRACTOR QUALIFICATION: Lynn, MA 01901 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The City of Lynn is soliciting quotes from qualified contractors to rrovide all labor, material and equipment for the repair and resurfacing of five bituminous concrete all-weather tennis courts. Courts are located behind Lynn English High School, 50 Goodridge Street, Lynn, MA 01902. Project includes the repair of structural and random cracks with Armor Crack Repair System and applying a three coat acrylic surface system to bituminous concrete surface as outlined in specifications. Approximately – 225 linear feet 3,460 square yards CONTACT INFORMATION PHONE: 781-586-6893 FAX: Tim Leonard EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE emailed or mailed upon request at [email protected] or call 781-586-6893, 9/16/20 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 10:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Project to be completed 30days from contract signing. Site visit email Lisa Nerich, DPW - [email protected]

21 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Marblehead, Town of Abbot Hall ESTIMATED COST: $120,000 188 Washington Street CONTRACTOR QUALIFICATION: Highway Division Marblehead, MA 01945 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: ADA ramps at various intersections. CONTACT INFORMATION PHONE: 781-631-0000 FAX: Rebecca Cutting EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at Abbot Hall, above agency address, on 9/16/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 10:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Marblehead, Town of Abbot Hall ESTIMATED COST: $35,000 188 Washington Street CONTRACTOR QUALIFICATION: Marblehead, MA 01945 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Interior painting of some office rooms walls and trim, and prep work. CONTACT INFORMATION PHONE: 781-631-0000 FAX: Rebecca Cutting EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at Abbot Hall, above agency address, on 9/16/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/5/20 @ 10:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

22 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: WS 2020-01 Marlborough, City of Department of Public Works Water & Sewer Division ESTIMATED COST: $50,000 135 Neil Street CONTRACTOR QUALIFICATION: Marlborough, MA 01752 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Class 1 Service (Air-End) On Four Siemens Compressors at Easterly Wastewater Treatment Plant in Marlborough, MA. CONTACT INFORMATION PHONE: 508-624-6910 x 33121 FAX: Andrew Pope EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Obtained from Projectdog.com. Enter Project Code 839008. Due to COVID-19 Pandemic, at this time a (place, date and time) hard copy cannot be viewed. Contact ProjectDog for Free CD, 9/17/20 @ 10:00 A.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/8/20 (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Nantucket, Town of Nantucket Memorial Airport Commission ESTIMATED COST: $150,000 14 Airport Road CONTRACTOR QUALIFICATION: DCAMM Certificate Nantucket, MA 02554 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The Town of Nantucket, acting through the Nantucket Airport Commission, invites bids for the “Point of Entry Treatment System Installations – Project Number MJ-PN-01”. This project is for the design, installation, and commissioning of Point of Entry Treatment Systems (POETs) at select locations with private water supply wells in vicinity of the Airport. CONTACT INFORMATION PHONE: 508-325-5303 FAX: Katy Perales EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Bid documents may be obtained online at www.biddocsonline.com, 9/17/20 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION In order for a bidder to be considered responsible, that bidder must document that they have at least 5 consecutive years of POETs installation experience.

23 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Natick, Town of Town Hall ESTIMATED COST: 13 East Central Street CONTRACTOR QUALIFICATION: Natick, MA 01760 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Invitation for Bids - Generator Maintenance (Three Years, Subject to Annual Appropriation, Commencing December 2020) at Various Locations in Natick, MA 01760. CONTACT INFORMATION PHONE: 508-647-6438 FAX: 508-647-6560 Bryan R. Le Blanc EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE via request to [email protected] or hard copy available at DPW, 75 West St., Natick, MA on 9/16/20 (place, date and time) @ 8:00 A.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/2/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: N/A ADDITIONAL INFORMATION Sealed bids due to DPW 75 West St. Natick, MA by deadline. Virtual bid opening: Join Zoom Meeting https://zoom.us/j/93746505995 Meeting ID: 937 4650 5995 One tap mobile +13126266799,,93746505995# US (Chicago) +19292056099,,93746505995# US (New York) Dial by your location +1 312 626 6799 US (Chicago) +1 929 205 6099 US (New York) +1 301 715 8592 US (Germantown) +1 346 248 7799 US (Houston) +1 669 900 6833 US (San Jose) +1 253 215 8782 US (Tacoma) Meeting ID: 937 4650 5995 Find your local number: https://zoom.us/u/adAOqx5HZq. The Town reserves the right to reject any/all bids in the public interest. Award is subject to vote of the Select Board and sufficient appropriation.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: #21-09 Newton, City of 1000 Commonwealth Avenue ESTIMATED COST: $900,000. Newton, MA 02459 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Waban Hill Reservoir Improvements as outlined in the project documents. CONTACT INFORMATION PHONE: 617-796-1220 FAX: 617-796-1227 Nichlas Read EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Project documents are available at www.newtonma.gov/bids or pick-up at Purchasing Dept., Room 108, at (place, date and time) above agency address on 9/18/20 @ 10:00 A.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/8/20 @ 10:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Pre-Bid Meeting: 9/24/20 @ 10:00 A.M., Waban Hill Reservoir, Opposite of 155 Waban Hill Road North. 5% Bid Surety Required.

24 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 20357 North Reading, Town of Department of Public Works ESTIMATED COST: $2,500,000 235 North Street CONTRACTOR QUALIFICATION: North Reading, MA 01864 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The work consists of constructing approximately 2,600 linear feet of 8-inch ductile iron water main and appurtenances in the same trench as the 6- inch existing water mains along Mt. Vernon Street and approximately 4,500 linear feet of 12-inch ductile iron water main along North Street as part of the Base Bid. The project also includes temporary water service for the duration of construction. The time for completion of this Contract is 180 calendar days. CONTACT INFORMATION PHONE: 603-570-7123 FAX: 978-470-3558 Collin Stuart EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Bidding Documents may be viewed and/or obtained online at http://www.wright-pierce.com/projects, (place, date and time) 9/16/20. Interested parties will be furnished one PDF download set at no cost. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/7/20 @ 1:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION There will be no pre-bid conference. 5% Bid Bond, 100% Performance and Payment Bonds.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Northampton, City of Department of Public Works ESTIMATED COST: $155,000 125 Locust Street CONTRACTOR QUALIFICATION: Northampton, MA 01060 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Replacement of 12" diameter RCP storm drain pipe with 12" diameter ductile iron pipe. Project includes installation of manholes and catch basins, a grass lined swale, and restoration. CONTACT INFORMATION PHONE: 413-522-2419 FAX: Zachariah Chornyak EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Bidding Documents may be obtained electronically from the Tighe & Bond website at: (place, date and time) http://www.tighebond.com/Projects_Out_to_Bid.php at 9/16/20 @ 8:00 A.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/2/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

25 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Orange, Town of Wastewater Treatment Facility ESTIMATED COST: $11,700,000 295 West Main Street CONTRACTOR QUALIFICATION: DCAMM Certificate Orange, MA 01364 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Wastewater Treatment Facility Upgrades Project. The work consists of: a new influent flow combination structure, influent screening system upgrades, influent wetwell upgrades, influent pumping station upgrades, grit removal system upgrades, new grit building, new secondary clarifier flow distribution structure, secondary clarification system mechanical upgrades, sludge thickening system upgrades, roofing system upgrades, building HVAC modifications, building architectural modifications, instrumentation and control/SCADA system modifications, new main electrical switchgear, and new emergency power system. CONTACT INFORMATION PHONE: FAX: Justin Skelly EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE by contacting [email protected] on 9/16/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: 10/14/20 @ 10:00 A.M. GENERAL BID DEADLINE: 10/28/20 @ 10:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: Masonry, Roofing & Flashing, Painting, HVAC, and Electrical. ADDITIONAL INFORMATION Non-mandatory pre-bid telephone conference call: 9/23/20 @ 10:00 A.M. Dial-in number is 916-235-1420, and PIN # is 789150#. Non-mandatory in-person pre-bid tours: 10/1/20 @ 9:00 A.M., 10:00 A.M, and 11:00 A.M. at Orange WWTF, 295 West Main St., Orange, MA 01364 It is intended that individual group sizes will be limited to a safe number. To accommodate this, the Owner requests that only prequalified subcontractors and general contractors attend, and that no more than two representatives from any one company be present. Please email [email protected] to request an appointment for one of the available timeslots. To ensure fairness in the bidding process, no verbal questions received during the tours will be answered and all inquiries must be submitted in writing via email.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 244075 Randolph, Town of Randolph Housing Authority ESTIMATED COST: $181,000 One Decelle Drive CONTRACTOR QUALIFICATION: DCAMM Certificate Randolph, MA 02368 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Removal of existing wood framed windows and associated exterior trim in eight apartment buildings and one Community building (Add Alternate No. 01) and replacement with new vinyl windows and new trim Asbestos Abatement of window glazing. CONTACT INFORMATION PHONE: 781-961-1400 FAX: 781-963-0251 Nancy Gordon EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE online at www.biddocsonline.com (may be viewed electronically and hardcopy requested) or at Nashoba (place, date and time) Blue Inc., 443 Main Street Hudson, MA 01749. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 12:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Non-mandatory pre-bid conference on site (Sunshine Avenue) on 9/23/20 @ 11:00 A.M. Meet at the Community Building.

26 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 2020-002 Rockport, Town of Department of Public Works (DPW) ESTIMATED COST: $150,000 34 Broadway CONTRACTOR QUALIFICATION: Highway Division Rockport, MA 01966 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Asphalt patch repairs and minor granite block seawall repairs at 3 public wharf parking areas. CONTACT INFORMATION PHONE: 978-546-3525 FAX: Joe Parisi EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE by email request to [email protected] on or after 9/16/20 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Pre-bid site meeting: 9/22/20 @ 10:00 A.M. starting at T-Wharf, Rockport, MA

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: ProjectDog#840289 DHCD#258148 Salem, City of Salem Housing Authority ESTIMATED COST: $104,000 27 Charter St. CONTRACTOR QUALIFICATION: DCAMM Certificate Salem, MA 01970 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Replace existing asphalt shingles and accessories at Norton Terrace (two buildings) and Bates Terrace (two buildings) for a total of four buildings CONTACT INFORMATION PHONE: 978-744-4431 FAX: Cathy Hoog EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Bid Forms and Contract Documents will be available electronically or for purchase at www.Projectdog.com, (place, date and time) project code 840289 at 9/16/20 @ 9:00 A.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/2/20 @ 9:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION The Norton Terrace site will be available for inspection on 9/24/20 @ 11:00 A.M. after that time we will move to Bates Terrace. No other appointments will be made.

27 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 2020-014 Seekonk, Town of Seekonk Public Schools ESTIMATED COST: $190,000 Administration Office CONTRACTOR QUALIFICATION: DCAMM Certificate 25 Water Lane Seekonk, MA 02771 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Seekonk High School Swimming Pool Systems Replacement, 261 Arcade Ave, Seekonk, MA 02771 CONTACT INFORMATION PHONE: 508-399-5106 FAX: Jill Brilhante, School Business Administrator EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.biddocsonline.com or hard copies from (place, date and time) Nashoba Blue, Inc. at 433 Main Street, Hudson, MA 01749 (978-568-1167), 9/17/20 @ 9:00 A.M. CONTRACT INFORMATION: SUB BID DEADLINE: 9/24/20 @ 10:00 A.M. GENERAL BID DEADLINE: 9/30/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: Electrical ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: IFB #4 Shrewsbury, Town of 100 Maple Ave ESTIMATED COST: $500,000 Shrewsbury, MA 01545 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: The project includes all labor, material, and equipment to complete and install a fully functioning Distribution Fiber Network by installation of fiber optic cables from SELCO’s existing Node Distribution Cabinets CONTACT INFORMATION PHONE: 508-841-8617 FAX: John Laverty EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/2/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Pre-Bid meeting: 9/15/20 @ 1:00 P.M.

28 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 273051 Somerset, Town of Housing Authority ESTIMATED COST: $38,000 75 John Kennedy Terrace CONTRACTOR QUALIFICATION: Somerset, MA 02726 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Removal of existing asphalt shingle roofing system and installation of new architectural asphalt shingle roofing system with venting. CONTACT INFORMATION PHONE: 857-206-9457 FAX: 508-812-7050 Molly Parris EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.Projectdog.com, 9/16/20. Project Code 840295. Login with an existing account or click "Sign Up" to (place, date and time) register for free. Select "Acquire Documents" to download. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION THIS PROJECT IS BEING ELECTRONICALLY BID (E-BID). Hard copies of the bidding documents may be viewed at Projectdog's physical address. The jobsite will be available for inspection by appointment only 9/22/20 between 9:00 A.M. - 11:00 A.M. Contact [email protected] to schedule an appointment on or before 9/21/20. Direct questions in writing to [email protected].

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 2021-004 Swampscott, Town of 22 Monument Ave. ESTIMATED COST: $150,000 Swampscott, MA 01907 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Provide all necessary testing, adjusting, and balancing of outside air equipment, exhaust, and return equipment in order to maximum existing ventilation air to space. Schools consist of two typical designs, decentralized and centralized. CONTACT INFORMATION PHONE: 781-596-8800 FAX: Martha Sybert EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Available online at www.swampscottma.gov/bids (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Bid Submission Deadline is 9/11/20. DCAMM approved the early deadline as this is an emergency procurement.

29 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 294082 Templeton, Town of Templeton Housing Authority ESTIMATED COST: $11,000 99 Bridge St. CONTRACTOR QUALIFICATION: Baldwinville, MA 01436 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Replace 12 Exterior Entry Doors CONTACT INFORMATION PHONE: 978-429-5647 FAX: Steve Larry, RCAT EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.projectdog.com, 9/16/20 @ 10:00 A.M. Enter code # 840206. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Pre-bid viewing by appointment only. Contact Steve Larry, RCAT Central/West, 978-429-5647

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Creamery Road Town of Egremont P.O. Box 368 ESTIMATED COST: $161,676 South Egremont MA 01258 CONTRACTOR QUALIFICATION: Highway Division

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Creamery Road - install 1 1/2" Hot Mix Asphalt surface course with tack coat. CONTACT INFORMATION PHONE: 413-528-1106 FAX: 413-528-5465 James Noe EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE No plans/specs. Contact James Noe, Road Super, [email protected] or 413-528-1106 for (place, date and time) details after 9/11/20. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

30 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 2020-08-001 Tyngsborough, Town of 25 Bryants Lane ESTIMATED COST: $105,000 Tyngsborough, MA 01879 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Camp Kiwanis Improvements - The work under this contract shall consist of: construction of a gravel driveway, gravel parking lot, accessible stone dust trail, grading, stormwater improvements, and all other appurtenant work. The town will also consider the installation of site furnishings and signage, and demolition of existing wood structures. CONTACT INFORMATION PHONE: 978-743-5339 FAX: Colin Loiselle EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE via request to [email protected] or hard copy available at Town Hall, above agency address (place, date and time) ,for $20 fee on 9/16/20. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 12:00 P.M. (date and time) (date and time) SUB BID CATEGORIES:

ADDITIONAL INFORMATION Full IFB can be found at: www.tyngsboroughma.gov.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: DHCD #339085 Wilbraham, Town of Housing Authority ESTIMATED COST: $71,883.00 88 Stony Hill Road CONTRACTOR QUALIFICATION: Wilbraham, MA 01095 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Replacement of existing gas fired boilers, select piping and ancillary equipment CONTACT INFORMATION PHONE: 978-39-49710 FAX: David Siniscalchi EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.biddocsonline or at Nashoba Blue, Inc., 433 Main St., Hudson MA. 01749, tel. 978-568-1167 on (place, date and time) 9/16/20. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/2/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION Pre-bid walkthrough: 9/23/20 @ 10:00 A.M at 88 Stony Hill Rd., Wilbraham MA. All attendees shall meet outside in the main parking lot prior to walk through. You will be escorted to project location.

31 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Winthrop, Town of 1 Metcalf Square ESTIMATED COST: $40,000 Winthrop, MA 02152 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: We are currently accepting quotes for a vendor to furnish and deliver materials to the Town of Winthrop to construct a 50’ x 75’ Steel Building. CONTACT INFORMATION PHONE: 617-846-1750 FAX: 617-539-4442 Monica Ford EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE via request to [email protected] on 9/16/20 @ 8:00 A.M. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 4:30 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION This is a Request for Quotes. Questions and quotes may be emailed to: [email protected].

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: RFB No. 4 (FY21) Bridgewater State University 131 Summer Street ESTIMATED COST: $86,000 Bridgewater, MA 02325 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: This project consists of pavement improvements at the entrance of Great Hill Drive, including installation of traffic controls, preparation, repavement, and restriping. CONTACT INFORMATION PHONE: 508-531-2110 FAX: 508-531-4110 Ryan Johnson EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE THIS PROJECT IS BEING ELECTRONICALLY BID. Bid documents are available on (place, date and time) www.biddocsonline.com CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/2/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION A pre-bid walkthrough will be held on the date and time specified in the bid documents. Please note the COVID guidance contained therein.

32 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: DPH1605 Capital Asset Management and Maintenance, Division of (DCAMM) **2nd Request** **Sub-Bids Only** ESTIMATED COST: $21,000,000 One Ashburton Place, Room 107 CONTRACTOR QUALIFICATION: DCAMM Certificate Boston, MA 02108 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: RFQ for Two Trade Contractor Packages: Masonry (2nd Request); Painting, for the Western Mass. Hospital - Mechanical Upgrades, Westfield, MA. This Project is for HVAC Improvements at the 93,000 square foot, four-story, inpatient facility. Implementation and phasing of this project will require close coordination to minimize the impact and displacement of the sensitive patient population. CONTACT INFORMATION PHONE: 617-727-4003 FAX: DCAMM Bid Room EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Request for Qualifications (RFQ) may be downloaded from http://www.commbuys.com or from DCAMM's (place, date and time) E-Bid Room, 9/16/20 CONTRACT INFORMATION: SUB BID DEADLINE: 10/1/20 @ 12:00 P.M. GENERAL BID DEADLINE: (date and time) (date and time) SUB BID CATEGORIES: Masonry - 2nd Request ($120,000); Painting ($65,000) ADDITIONAL INFORMATION RFQs due 10/1/20. This is a Construction Management at Risk project under M.G.L. c. 149A. Interested Firms MUST submit a Qualification Statement by the deadline and be prequalified if they are interested in later bidding on this project. DCAMM Certification applies for this process. This Request for Qualifications is the first part of a two-step process for Trade Contractors. First, interested firms must submit the Qualification Statement and then, at a later date, only the prequalified firms will be invited to submit bids for the category of works in which they were prequalified. This required Qualifications Statement is different from DCAMM Certification. All firms must be qualified for this project, even if they are already DCAMM Certified. The Construction Manager is The Whiting-Turner Contracting Company.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: CBRSD2020-01 Central Berkshire Regional School District (CBRSD) 254 Hinsdale Road ESTIMATED COST: $45,000 P.O. Box 299 CONTRACTOR QUALIFICATION: Dalton, MA 01227 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Central Berkshire Regional School District, Kittredge Elementary School HVAC Controls Retrofit. In accordance with M.G.L. c. 149, CBRSD is seeking bids to convert the existing 24 classroom univents from standalone electronic controls to Andover BMS network at Kittredge Elementary School, Hinsdale, MA. Demolition of existing HVAC control system and installation of new controllers and components. CONTACT INFORMATION PHONE: 413-684-0320 FAX: 413-684-4088 Gregory Boino EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Contact Gregory Boino at 413-684-0320 x1002 or by email [email protected], 254 Hinsdale Rd, Dalton, (place, date and time) MA, 01226, 9/11/20 @ 9:00 A.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

33 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: P20-3351-C3A Conservation and Recreation, Department of 251 Causeway Street, Suite 600 ESTIMATED COST: $315,000.00 Boston, MA 02114-2104 CONTRACTOR QUALIFICATION: DCAMM Certificate

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Fire Alarm System at John Augustus Hall: Installation of a new fire alarm system including; all labor, electrical work, necessary equipment and materials. Demolition of existing non-functioning system, and testing of new system. CONTACT INFORMATION PHONE: FAX: Rob Healey- Project Manager EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE Individual sets of contract documents will only be available on DCR’s E-bid room (place, date and time) at www.bidexpress.com/businesses/36765/home. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/14/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: n/a ADDITIONAL INFORMATION Pre-bid conference: 9/24/20 @ 10:00 A.M. at the project site 180 Beamon St., West Boylston, MA 01583 and via conference call number 605-475-3235; Pin # 309889.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: Norfolk, County of 614 High St. ESTIMATED COST: Dedham MA 02026 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Maintenance of Existing Drainage Outfall CONTACT INFORMATION PHONE: 781-461-6139 FAX: 781-326-6480 Nancy Rockwell EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at Norfolk County Purchasing 614 High St Dedham, MA (place, date and time) 9/16/20 @ 11:00 A.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 11:00 A.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION

34 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: FY21-724 North Middlesex Regional School District 66 Brookline Street ESTIMATED COST: $51,000 Townsend, MA 01469 CONTRACTOR QUALIFICATION:

(required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: High School Glass Project at the North Middlesex Regional High School 19 Main Street, Townsend, MA 01469 CONTACT INFORMATION PHONE: 978-597-8713 FAX: 978-743-4984 Nancy Haines EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE by contacting [email protected] with full contact information, address, phone email, 9/16/20 @ 10:00 (place, date and time) A.M. CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/1/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES:

ADDITIONAL INFORMATION pre-bid meeting will be held 9/23/20 @ 1:00 P.M. at the NMRSD High School 19 Main Street, Townsend, MA 01469

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 2021-04 Springfield Technical Community College One Armory Square ESTIMATED COST: $14,000 PO Box 9000 CONTRACTOR QUALIFICATION: Springfield, MA 01102-9000 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: B25 Abatement rms 108, 110 & 112: Encapsulation and removal of damaged pipe insulation using glove bag method CONTACT INFORMATION PHONE: 413-755-4794 FAX: 413-755-6040 Margaret Solitario EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE on the STCC website: http://www.stcc.edu/facilities/constructionbids/ (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 9/30/20 @ 3:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: ADDITIONAL INFORMATION MANDATORY site visit: 9/22/20 @ 1:00 P.M. at Building 25 (map in documents). Prevailing wage will apply

35 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 609276 Transportation, Department of (MassDOT) Highway Division ESTIMATED COST: $101,000.00 10 Park Plaza, Suite 6260 CONTRACTOR QUALIFICATION: Highway Division Boston, MA 02116 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: DISTRICT 5 - Scheduled and Emergency Impact Attenuator Repairs and Related Work at Various Locations (Re-Advertised Project). CONTACT INFORMATION PHONE: 857-368-9520 FAX: 857-368-0630 Eric M. Cardone, P.E. EMAIL: PLANS/SPECIFICATIONS AVAILABLE at [email protected] and above agency address on or about 9/30/20 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/14/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: No Filed Sub Bids ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 610843 Transportation, Department of (MassDOT) Highway Division ESTIMATED COST: $8,721,000 10 Park Plaza, Suite 6260 CONTRACTOR QUALIFICATION: Highway Division Boston, MA 02116 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: BOSTON-MILTON - Resurfacing and Related Work (Including 3 Bridge Decks) along Sections of Interstate 93. CONTACT INFORMATION PHONE: 857-368-9520 FAX: 857-368-0630 Eric M. Cardone, P.E. EMAIL: PLANS/SPECIFICATIONS AVAILABLE at [email protected] and above agency address (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/20/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: No Filed Sub Bids ADDITIONAL INFORMATION

36 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 606316 Transportation, Department of (MassDOT) Highway Division ESTIMATED COST: $3,425,000 10 Park Plaza, Suite 6260 CONTRACTOR QUALIFICATION: Highway Division Boston, MA 02116 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: BROOKLINE - Pedestrian Bridge Replacement and Related Work (Including Painting) Br. No. B-27-016 Carlton Street Footbridge over the MBTA D Green Line (Re-Advertised Project). CONTACT INFORMATION PHONE: 857-368-9520 FAX: 857-368-0630 Eric M. Cardone, P.E. EMAIL: PLANS/SPECIFICATIONS AVAILABLE at [email protected] and above agency address, on or about 10/6/20 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/27/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: No Filed Sub Bids ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 609379 Transportation, Department of (MassDOT) Highway Division ESTIMATED COST: $2,346,000.00 10 Park Plaza, Suite 6260 CONTRACTOR QUALIFICATION: Highway Division Boston, MA 02116 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: DISTRICT 5 - Installation of Intelligent Transportation System (ITS) Including 10 Closed Circuit Television Cameras (CCTV) 2 Variable Message Signs (VMS) and 5 Traffic Counting Stations (TCS) along Sections of Interstates 95, 195 and 495 and Routes 3, 24, 25, 44, 79 and 140. CONTACT INFORMATION PHONE: 857-368-9520 FAX: 857-368-0630 Eric M. Cardone, P.E. EMAIL: PLANS/SPECIFICATIONS AVAILABLE at [email protected] and above agency address on or about 10/6/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/27/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: No Filed Sub Bids ADDITIONAL INFORMATION

37 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 608791 Transportation, Department of (MassDOT) Highway Division ESTIMATED COST: $1,670,000 10 Park Plaza, Suite 6260 CONTRACTOR QUALIFICATION: Highway Division Boston, MA 02116 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: WINCHESTER - Roadway Reconstruction and Related Work (Including Signals) on a Section of Ridge Street and Johnson Road (Safe Routes to School) - Vinson-Owen Elementary School. CONTACT INFORMATION PHONE: 857-368-9520 FAX: 857-368-0630 Eric M. Cardone, P.E. EMAIL: PLANS/SPECIFICATIONS AVAILABLE at [email protected] and above agency address on or about 10/6/20. (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/27/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: No Filed Sub Bids ADDITIONAL INFORMATION

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: OP-416 Water Resources Authority, Massachusetts Charlestown Navy Yard ESTIMATED COST: $269,790 100 First Avenue, Building 39 CONTRACTOR QUALIFICATION: Boston, MA 02129 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Hydraulic Equipment Service CONTACT INFORMATION PHONE: 617-242-6000 FAX: 617-788-4882 Tom Gentile EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE at www.mwra.com on or after 9/16/20 (place, date and time) CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/6/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: N/A ADDITIONAL INFORMATION Pre-bid conference will be held remotely on 9/23/20 @ 10:00 A.M. Interested parties must contact [email protected] before 9/22/20 @ 1:00 P.M. for remote meeting access information. There will be no site visit.

38 CENTRAL REGISTER - GENERAL CONTRACTS CR-2 Public Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: 6650C Water Resources Authority, Massachusetts Charlestown Navy Yard ESTIMATED COST: $1,800,000 100 First Avenue, Building 39 CONTRACTOR QUALIFICATION: DCAMM Certificate Boston, MA 02129 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: MWRA Boat Storage Facility and Cosgrove Deck Drainage Improvements. Contractor Category: General Building Construction. CONTACT INFORMATION PHONE: 617-242-6000 FAX: 617-788-4882 Tom Gentile EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE To access and bid on this Event, please go to the MWRA Supplier Portal at www.mwra.com on or after (place, date and time) 9/16/20 CONTRACT INFORMATION: SUB BID DEADLINE: 10/1/20 @ 11:30 A.M. GENERAL BID DEADLINE: 10/23/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: Div 9 - Painting; Div 15 - Plumbing; Div 15 - HVAC; Div 16 - Electrical ADDITIONAL INFORMATION Site Visit: 9/24/20 by APPOINTMENT at the Cosgrove Facilities : 301 Boylston Street, Clinton, MA 01510. Interested parties must contact [email protected] by 9/21/20 @ 1:00 P.M. information for site visit instructions.

AWARDING AUTHORITY AND PROJECT INFORMATION AGENCY: PROJECT NUMBER: W327 Water Resources Authority, Massachusetts Charlestown Navy Yard ESTIMATED COST: $240,000 100 First Avenue, Building 39 CONTRACTOR QUALIFICATION: Boston, MA 02129 (required for building contracts over $150,000 and highway contracts over $50,000) PROJECT: Wachusett Reservoir North Dike and South Dike Instrumentation CONTACT INFORMATION PHONE: 617-242-6000 FAX: 617-788-4882 Rita Mercado EMAIL: [email protected] PLANS/SPECIFICATIONS AVAILABLE To access and bid on this Event, please go to the MWRA Supplier Portal at www.mwra.com on or after (place, date and time) 9/16/20 CONTRACT INFORMATION: SUB BID DEADLINE: GENERAL BID DEADLINE: 10/28/20 @ 2:00 P.M. (date and time) (date and time) SUB BID CATEGORIES: N/A ADDITIONAL INFORMATION REMOTE pre-bid conference: 9/28/20 @ 10:00 A.M. and site visit(s) will be held on 9/30/20 through 10/2/20 by APPOINTMENT ONLY at the South Dike of Wachusett Reservoir (North Dike at Wachusett Reservoir is open to public access). Interested parties must contact [email protected] by 9/25/20 @ 5:00 P.M. for remote meeting access information and site visit instructions at South Dike.

39 CR-5 CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTS

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: Belmont, Town of PROJECT: Belmont Fire Substation Improvements - Package 1 Building 19 Moore Street Envelope Repairs (Phases 1 and 3) Belmont, MA 02478 CONTACT: PHONE FAX: biddocsonline.com EMAIL: [email protected]

Works in Progress Capeway Roofing Systems, Inc. Nashoba Blue Contracting Specialists Inc. 20 Farrell Street 664 Sanford Road 433 Main Street 453 South Main St South Burlington, VT 05403 Westport, MA 02790 Hudson, MA 01749 Attleboro, MA 02703

Stanley Roofing Co., Inc. Silktown Roofing, Inc. Projectdog 37 Magnolia Ave 27 Pleasant Street 18 Graf Road Magnolia, MA 01930 Manchester, CT 06040 Newburyport, MA 01950

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 9355 Cambridge, City of PROJECT: Graham & Parks School Switchgear Replacement - Early Site Work. Purchasing Department 795 Massachusetts Ave., Room 303 Cambridge, MA 02139 CONTACT: PHONE 617-349-4310 FAX: 617-349-4008 Vilsabel David EMAIL: [email protected]

Brite Lite Electrical Company Dagle Electrical Construction Corp Systems Electrical Services CMD Group 11 Front Street 68 Industrial Way 5 Wesley Street 30 Technology Pkwy. South, Ste Weymouth, MA 02188 Wilmington, MA 01887 Chelsea, MA 02150 Norcross, GA 30092

Construct Connect Construction Journal Contractors Register, Inc. Dodge 30 Technology Pkwy. South, Ste. 1 400 SW 7th Street d/b/a The Blue Book 285 Phoenix St. Norcross, GA 30092 Stuart, FL 34994 800 E. Main Street Vernon, CT 06066 Jefferson Valley, NY 10535

North America Procurement ProjectDog Council, Inc. 18 Graf Road P.O. Box 40445 Newburyport, MA 01950 Grand Junction, CO 81504

40 CR-5 CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTS

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 9356 Cambridge, City of PROJECT: Main Library Signage. Purchasing Department 795 Massachusetts Ave., Room 303 Cambridge, MA 02139 CONTACT: PHONE 617-349-4310 FAX: 617-349-4008 Vilsabel David EMAIL: [email protected]

Contractors Register, Inc. Dodge North America Procurement ProjectDog d/b/a The Blue Book 285 Phoenix St. Council, Inc. 18 Graf Road 800 E. Main Street Vernon, CT 06066 P.O. Box 40445 Newburyport, MA 01950 Jefferson Valley, NY 10535 Grand Junction, CO 81504

Prime Vendor, Inc. United Sign Corp. BidPrime, Inc. CMD Group 4622 Cedar Ave., Suite 123 853 S. Peach Tree St. 1301 S. IH 35 30 Technology Pkwy. South, Ste Wilmington, NC 28403 Historic Norcross, GA 30071 Austin, TX 78741 Norcross, GA 30092

ConstructConnect Construction Journal e.republic Kneeland Construction Corporati 30 Technology Pkwy. South, Ste. 1 400 SW 7th Street 100 Blue Ravine Road 407R Mystic Ave., Suite 34B Norcross, GA 30092 Stuart, FL 34994 Folsom, CA 95630 Medford, MA 02155

LLM Design 75 Broad Street Boston, MA 02109

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: RFQ 20200916 Chester, Town of PROJECT: Chester Bromley Road Milling 15 Middlefield Road Chester, MA 01011 CONTACT: PHONE 413-774-3167 x131 FAX: Ellen Batchelder/FRCOG EMAIL: [email protected]

IMS North America Procurement Counc Onvia palmer paving corporation San Diego,CA92109 Inc. Seattle,WA 98101 Palmer,MA 01069 PBC Grand Junction, CO81504

Prime Vendor Projectdog Shay Enterprise The Bluebook Building Construc Wilmington,NC28403 Newburyport,MA01950 Tacoma,WA 98402 And Network Jefferson valley, NY 10535

THWilson Bonds Construction Bid Source Deltek Dodge Data &; Analytics Co. Clovis,CA 93619 Cary,NC 27518 Herndon,VA 20171 Hamilton Township, NJ 08619

Eurovia Atlantic Coast LLC Garrity Asphalt Reclaiming Alcaide, Inc. All States Asphalt, Inc. dba Northeast Paving Bloomfield,CT06002 dba A&;J Construction Sunderland, MA 01375 Westfield,MA 01085 Brookfield CT06804

bidprime ConstructConnect Austin,TX 78741 Cincinnati,OH45209

41 CR-5 CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTS

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: DPW 21-04 Greenfield, City of PROJECT: Fiske Ave. Retaining Wall Replacement Department of Public Works 189 Wells Street Greenfield, MA 01301 CONTACT: PHONE 413-772-1528 FAX: Alan Twarog EMAIL: [email protected]

A. Martins &; Sons Construction, I Kurtz, Inc. Nunes Companies, Inc. Keiter Builders 679 Moore Street 810 Southampton Road 658 Center Street 35 Main Street Ludlow, MA 01056 Westfield, MA 01085 Ludlow, MA 01056 Florence, MA 01062

Caracas Construction Corporation Projectdog Campora Construction Co., Inc. Construct Connect 592 Holyoke Street 18 Graf Road, Unit #8 77 Stivens Drive 3825 Edwards Road, Suite 800 Ludlow, MA 01056 Newburyport, MA 01950 Ludlow, MA 01056 Cincinnati, OH 45209

Cole Contracting, Inc. The Bluebook Building &; 152 Webster Street Construction Network Worcester, MA 01603 800 E. Main Street Jefferson Valley, NY 10535

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 840015 Lynn, City of PROJECT: Reconstruction of Lower Washington Street 3 City Hall Square Lynn, MA 01901 CONTACT: PHONE 781-586-6893 FAX: Tim Leonard EMAIL: [email protected]

Century Paving &; Construction Co D&;R General Contracting North America Procurement Counc MDR Construction 167 Hyacinth Street 732 Newburyport Turnpike Inc. PBC 1693 Shawsheen Street Fall River, MA 02720 Melrose, MA 02176 P.O. Box 40445 Tewksbury, MA 01876 Grand Junction, CO 81504

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 839817 Lynn, City of PROJECT: New Modular Classroom Building at Lynn English High School 3 City Hall Square Lynn, MA 01901 CONTACT: PHONE 781-586-6893 FAX: Tim Leonard EMAIL: [email protected]

Site Improvements, Inc. Sciaba Construction Corp Mackay Companies BidClerk PO Box 1145 1801 Main Street 197 Ballardvale Street 28 N Clark, Ste. 450 Andover, MA 01810 Walpole, MA 02081 Wilmington, MA 01887 Chicago, IL 60602

GVW, Inc Construction Journal Valley Communications Massey Construction Corp 1200 Bennington Street 400 SW 7th Street 20 1st Avenue 144 Stetson Avenue East Boston, MA 02128 Stuart, FL 34994 Chicopee, MA 01020 Swampscott, MA 01907

42 CR-5 CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTS

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: Nantucket, Town of PROJECT: Fuel Farm Upgrades Phase III, Nantucket Memorial Airport 16 Broad Street, 1st Floor Nantucket, MA 02554 CONTACT: PHONE FAX: biddocsonline.com EMAIL: [email protected]

Lawrence-Lynch Corp. Nashoba Blue Nantucket Memorial Airport KEAR Civil Corporation P.O. Box 913 433 Main Street 14 Airport Road 22555 N 20th Ave Falmouth, MA 02541 Hudson, MA 01749 Nantucket, MA 02554 Phoenix, AZ 85027

Projectdog 18 Graf Road Newburyport, MA 01950

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: Natick, Town of PROJECT: Request for Responses - Restoration of the Town Clock Off the Town Hall Common, (East Central Street) Natick, MA 01760. 13 East Central Street Natick, MA 01760 CONTACT: PHONE 508-647-6438 FAX: 508-647-6560 Bryan R. Le Blanc EMAIL: [email protected]

Valley Restoration Kneeland Construction Project Dog Calhess Restoration 47 Wyoming Avenue 407R Mystic Avenue, Suite 34B 18 Graf Road, Unit 8 374 University Avenue Torrington, CT 06970 Medford, MA 02155 Newburyport, MA 01950 Westwood, MA 02090

Capasso Enterprises Ace Restoration 251 Middle Street 29 Linden Street Middletown, CT 06457 Medford, MA 02155

43 CR-5 CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTS

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 21DPW045C Needham, Town of PROJECT: Transfer Station Repairs 500 Dedham Ave. Needham, MA 02492 CONTACT: PHONE 7814557550 FAX: Cecilia Simchak EMAIL: [email protected]

Lantern Light &; Electric, Inc. MacKay Construction Services Mcgraw-hill dodgereports Needham Certified Welding Corp 11 Oakview Circle 197 Ballardvale Road 1333 burr ridge pkwy P.O. Box 647 Medway, MA 02053 Wilmington, MA 01887 Burr Ridge, IL 60527 Needham Heights, MA 02494

Northern Contracting Corp. Ocean State Technical Services Projectdog Construction Bid Source 68 Jackson Street 55 Chapman Street 18 Graf Road Unit 8 413 Brisbane Woods Way Canton, MA 02021 Providence, RI 02905 Newburyport, MA 01950 Cary, NC 27518

D C WELDING Davison Company G &; H Heating &; Cooling LLC Galway Electrical Co Inc 195 Meadowcroft St 90 Clarendon Ave 133 County Road 329 Great Plain Ave lowell, MA 01852 Somerville, MA 02144 East Freetown, MA 02717 Needham, MA 02492

HZ Electric Supply J J Cardosi Inc John Turner Consulting Accent Printing, Inc 274 Taylor St 28 Boston Street 44 Lafayette Road 99 Chelmsford Road SPRINGFIELD, MA 01105 East Providence, RI 02914 North Hampton, NH 03862 No. Billerica, MA 01862

Amp Electrical, Inc AVCO Electric, Inc. Brite-Lite Electrical Co., Inc. Cam hvac &; construction inc. 1420 Union Street 47 Grace Street 11 Front Street 116 lydia ann road West Springfield, MA 01089 Malden, MA 02148 Weymouth, MA 02188 Smithfield, RI 02917

Classic Construction &; Developm ConstructConnect The Blue Book Building and Tower Construction Corp. Corp. 30 Technology Parkway South, Ste Construction Network 10 Southern Industrial Dr. 129 Commonwealth Ave. 100 800 E. Main St. Cranston, RI 02921 Concord, MA 01742 Norcross, GA 30092 Jefferson Valley, NY 10535

TRI Construction UELContractors, Inc Wayne J. Griffin Electric, Inc. Works in Progress 320 Adams Street 65 Parker Street 116 Hopping Brook Road 20 Farrell Street Dorchester, MA 02122 Clinton, MA 01510 Holliston, MA 01746 South Burlington, VT 05403

Sparks Company Inc. 15 ( Rear ) Simmons Road Little Compton, RI 02837

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: NLD-21-02 Norwood, Town of PROJECT: Light Department Building Roofing Project 566 Washington Street, 3rd Floor Norwood, MA 02062 CONTACT: PHONE 781-762-1240 FAX: 781-278-3015 Catherine Carney EMAIL: [email protected]

Gibson Roofs, Inc. B.A. Perazim, Inc. Commercial Roofing Capeway Roofing Systems, Inc. 369 Winter Street 9 Woodville Park 340 Kennedy Drive, P.O. Box 647 664 Sanford Road Hanover, MA 02339 Roxbury, MA 02119 Putnam, CT 06260 Westport, MA 02490

Corolla Contracting, Inc. Rockwell Roofing, Inc. 15 Bates Ave. 44 Pond Street Winthrop, MA 02152 Leominster, MA 01453

44 CR-5 CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTS

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: NSD-21-02 Norwood, Town of PROJECT: Request for Services - Coakley Middle School Feasibility Design. 566 Washington St, 3rd Floor Norwood, MA 02062 CONTACT: PHONE 781-762-1240 FAX: 781-278-3015 Catherine Carney EMAIL: [email protected]

Norian/Siani Engineering, Inc. DiGiorgio Associates Inc. NV5 Arrowstreet 43 Bradford Street, 3rd Floor A LiRo Group Company 200 Brickstone Square 10 Post Office Square, Suite 700N Concord, MA 01742 529 Main Street Andover, MA 01844 Boston, MA 02109 Boston, MA 02129

Hammer & Walsh Design, Inc. Gibson Roofs, Inc. Brennan Consulting, Inc. LGCI 281 Summer Street, 6th Floor 369 Winter Street 24 Ray AVe 100 Chelmsford Road, Suite 2 Boston, MA 02210 Hanover, MA 02339 Burlington, MA 01803 North Billerica, MA 01862

Activitas, Inc. Moody Nolan, Inc. MDS/Miller Dyer Spears Warner Larson Landscape Archit 70 Milton Street 1621 Euclid Ave. 99 Chauncy Street, 8th Floor 130 West Broadway Dedham, MA 02026 Cleveland, OH 44115 Boston, MA 02111 Boston, MA 02127

Langan The S/L/A/M Collaborative (SLAM Rider Levett Bucknall Raymond Design Associates 888 Boylston Street, Suite 510 250 Summer Street, 4th Floor Two Financial Center 60 Ledgewood Place, 2nd Floor Boston, MA 02119 Boston, MA 02210 Boston, MA 02111 Rockland, MA 02370

Marquis Architecture, LLC Compass Project Management Fennick McCredie Architure Ai3 Architects 129 Spring Street 1 Edgewater Drive, Suite 204 70 Franklin Street 526 Boston Post Road Watertown, MA 02472 Norwood, MA 02062-4677 Boston, MA 02110 Wayland, MA 01778

Flansburgh Architects William Rawn Associates Drummey Rosane Anderson, Inc. Shawmut Design & Construction 77 North Washington St. 10 Post Office Square 260 Charles Street, Studio 300 560 Harrison Ave. Boston, MA 02114 Boston, MA 02109 Waltham, MA 02453 Boston, MA 02118

Creative Acoustics, LLC CBT Taylor & Burns PEER Consultants, P.C. 5 Inwood Lane 110 Canal Street 58 Winter Place, #3 67 S. Bedford Street, Suite 400 W Westport, CT 06880 Boston, MA 02111 Boston, MA 02108-4714 Burlington, MA 01803

Studio G Architects Tappe Architects Dore & Whittier Kaestle Boos Associates, Inc. 179 Boylston Street 6 Edgerly Place 260 Merrimac Street 416 Slater Road Jamaica Plain, MA 02130 Boston, MA 02116 Newburyport, MA 01950 New Britain, CT 06053

Mount Vernon Group Architects Tecton Architects, PC B+AC, LLC Prismatic Services, Inc. 200 Harvard Mills Square 34 Sequassen St., Suite 200 214 Arlington Street 20460 Chartwell Center Dr., Ste. Wakefield, MA 02188 Hartford, CT 06106 Chelsea, MA 02150 Mooresville, NC 28031

Thornton Tomasetti Finegold Alexander Architects Silman 27 Wormwood Street 77 North Washington Street 111 Devonshire Street Boston, MA 02210 Boston, MA 02114 Boston, MA 10005

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: Salisbury, Town of PROJECT: Salisbury Beach Comfort Station and Welcome Center 5 Beach Road Salisbury, MA 01952 CONTACT: PHONE FAX: biddocsonline.com EMAIL: [email protected]

Castagna Construction 100 Connifer Hill Drive, #507 Danvers, MA 01923

45 CR-5 CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTS

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: DCP1905 DC1 Capital Asset Management and Maintenance, Division of PROJECT: McCormack State Office Building Immediate Needs, Boston, MA (DCAMM) One Ashburton Place, Room 107 Boston, MA 02108 CONTACT: PHONE 617-727-4003 FAX: DCAMM Bid Room EMAIL: [email protected]

Contracting Specialists, Inc. Lighthouse Masonry, Inc. Marmelo Bros. Construction Costa Brothers Masonry 453 South Main Street 150 John Vertente Blvd. 13 Ventura Drive 2 Lambeth Park Drive Attleboro, MA 02703 New Bedford, MA 02745 North Dartmouth, MA 02747 Fairhaven, MA 02719

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: DCP1843 Capital Asset Management and Maintenance, Division of PROJECT: Staff Lounge and Innovation Lab Renovation, Office of the (DCAMM) Comptroller, McCormack Building, Boston, MA One Ashburton Place, Room 107 Boston, MA 02108 CONTACT: PHONE 617-727-4003 FAX: DCAMM Bid Room EMAIL: [email protected]

Santangelo Flooring SRS Contractors, Inc. United Steel, Inc. Watermark Environmental, Inc. 75 Christopher Street 153 Winthrop Ave 164 School St. 175 Cabot Street Dorchester, MA 02122 Lowell, MA 01851 East Hartford, CT 06108 Lowell, MA 01854

Wayne J. Griffin Electric, Inc. Your Electrical Solution, Inc. King Painting, Inc. NOREL Service Co., Inc. 116 Hopping Brook Road 345 Washington Street 50 High Street 230 2nd Avenue Holliston, MA 01746 Pembroke, MA 02359 North Andover, MA 01845 Waltham, MA 02451

Auburn Construction Co., Inc. Banner Environmental Services, In Brite-Lite Electrical Co., Inc. Casby Brothers, Inc. 1207 Auburn St. 31 Hayward St., Suite 2A-205 11 Front Street 197 Gardner St. Whitman, MA 02382 Franklin, MA 02038 Weymouth, MA 02188 West Roxbury, MA 02132

CDS Contracting Services, LLC Chapman Waterproofing Company Compass Restoration Services, LLC Connectivity Point Design &; 275 Centre Street, Suite 1 620 South Street 1020 East Street Installation, LLC Holbrook, MA 02343 Holbrook, MA 02343 Ludlow, MA 01056 187 Washington St. Auburn, ME 04210

Cornerstone Dandreo Brothers General Contrac Enterprise Equipment Co., Inc. F.L. Caulfield &; Sons, Inc. 9F Presidential Way &; Masonry LLC 276 Libbey Parkway 85 Federal Ave. Woburn, MA 01801 106 Oakville Street Weymouth, MA 02189 Quincy, MA 02169 Lynn, MA 01905

General Air Conditioning &; Heati GVW, Inc. Hub Electric, Inc. J.J. White Inc. 1200 Bennington Street 10 Draper Street, Unit 19 529 Main Street 7 Gaston Street East Boston, MA 02128 Woburn, MA 01801 Charlestown, MA 02129 Dorchester, MA 02121

Maron Construction Co., Inc. NEL Corp. New England Builders &; Contract Northern Contracting Corp. 180 Buttonhole Drive 3 Ajootian Way, Bldg. B 464 Merrimack Street 68 Jackson St. Providence, RI 02909 Middleton, MA 01929 Methuen, MA 01844 Canton, MA 02021

One Source Construction, LLC Page Building Construction Compa Patrick J. Kennedy &; Sons, Inc. R. Mullen Associates, Inc. 5 Wayside Inn Road 135 Old Page Street 39 Gibson Street 18 Autumn Circle Framingham, MA 01701 Stoughton, MA 02072 Boston, MA 02122 Hingham, MA 02043

Robert W. Irvine &; Sons, Inc. 147 Blossom Street Lynn, MA 01902

46 CR-4 CENTRAL REGISTER - CONTRACT AWARD

AWARDING AUTHORITY: AGENCY: Andover, Town of PROJECT NUMBER: RFQ 047/05-20/185 Town Offices 36 Bartlet St. Andover, MA 01810 PROJECT TYPE: Designer Services

CONTACT INFORMATION: PHONE: 978-623-8951 FAX: Theresa Peznola, Purchasing Agent EMAIL: [email protected] DESCRIPTION: Building Commissioning Consultant On-call for Various Construction Projects.

CONTRACT AWARDED TO: CONTRACT AMOUNT: Richard D. Kimball Co., Inc. Not to exceed $200,000 over three-year period. d/b/a NV5 200 Brickstone Square Andover, MA 01810

Sub Contract Award:

AWARDING AUTHORITY: AGENCY: Boston, City of PROJECT NUMBER: 7193 Public Facilities Department 26 Court Street, 10th Floor Boston, MA 02108 PROJECT TYPE: Designer Services

CONTACT INFORMATION: PHONE: 617-635-3613 FAX: James Sessum EMAIL: [email protected] DESCRIPTION: Architectural design and construction administration services associated with the Fire Alarm Building Roof and Antenna project.

CONTRACT AWARDED TO: CONTRACT AMOUNT: CSS Architects, Inc. $110,000.00 107 Audubon Road Building 2, Suite 300 Wakefield, MA 01880

Sub Contract Award:

AWARDING AUTHORITY: AGENCY: Cambridge, City of PROJECT NUMBER: 9255 Purchasing Department 795 Massachusetts Ave., Room 303 Cambridge, MA 02139 PROJECT TYPE: General Contract

CONTACT INFORMATION: PHONE: 617-349-4310 FAX: 617-349-4008 Vilsabel David EMAIL: [email protected] DESCRIPTION: Water Treatment Plant Building Air-Cooled Chiller Replacement.

CONTRACT AWARDED TO: CONTRACT AMOUNT: Enterprise Equipment Co., Inc. $139,440.00 276 Libbey Parkway Weymouth, MA 02189

Sub Contract Award:

47 CR-4 CENTRAL REGISTER - CONTRACT AWARD

AWARDING AUTHORITY: AGENCY: Dracut, Town of PROJECT NUMBER: Veterans Memorial Park We 62 Arlington Street Dracut, MA 01826 PROJECT TYPE: General Contract

CONTACT INFORMATION: PHONE: 978-770-2584 FAX: Barbara O'Connor EMAIL: [email protected] DESCRIPTION: Remove, supply and install pump, pipe, wire and all other materials for irrigation well at Veterans Memorial Park, Rte. 113 Broadway Road, Dracut, MA 01826

CONTRACT AWARDED TO: CONTRACT AMOUNT: Epping Well & Pump Co. Inc $15,342.00 337 Calef Highway (Route 125) Epping, NH 03042

Sub Contract Award: N/A

AWARDING AUTHORITY: AGENCY: Lexington, Town of PROJECT NUMBER: 21-05R 1625 Massachusetts Ave. Lexington, MA 02420 PROJECT TYPE: General Contract

CONTACT INFORMATION: PHONE: 781-698-4628 FAX: Elizabeth Mancini EMAIL: [email protected] DESCRIPTION: On-call HVAC Controls.

CONTRACT AWARDED TO: CONTRACT AMOUNT: Control Technologies, Inc. $150,000 One Corporation Way, Suite 110 Peabody, MA 01960

Sub Contract Award:

AWARDING AUTHORITY: AGENCY: Capital Asset Management & Maintenance, Division of PROJECT NUMBER: DFS2002 One Ashburton Place, 15th Floor Boston, MA 02108 PROJECT TYPE: Designer Services

CONTACT INFORMATION: PHONE: FAX: Elizabeth Minnis, Deputy Commissioner of Planning EMAIL: DESCRIPTION: Southeast Fire Academy Master Plan and Certified Study, Department of Fire Services, Bridgewater DSB List #20-08.

CONTRACT AWARDED TO: CONTRACT AMOUNT: Dore + Whittier $250,000 260 Merrimac St., Bldg. #7, 2nd Fl. Newburyport, MA 01950 on 8/10/20

Sub Contract Award:

48 CR-4 CENTRAL REGISTER - CONTRACT AWARD

AWARDING AUTHORITY: AGENCY: MassDevelopment PROJECT NUMBER: 21-001 33 Andrews Parkway Devens, MA 01434 PROJECT TYPE: General Contract

CONTACT INFORMATION: PHONE: 978-784-2926 FAX: Jon Marc-Aurele EMAIL: [email protected] DESCRIPTION: Massachusetts Development Finance Agency (“MassDevelopment”) is seeking qualified bidders for the installation of an 8” water service across Route 202 (State Street) located in Belchertown MA (Project No. 21-001). Work includes but not limited to excavating a test pit, roadway saw cutting, trench excavation, installation of a 12”x8” Wet Tap and valve, installation of approximately 100 linear feet of 8” Ductile Iron Pipe water main and appurtenances, trench restoration via excavatable flowable fill backfill and 6” of bituminous binder course. Bid to include all permits and testing.

CONTRACT AWARDED TO: CONTRACT AMOUNT: Ludlow Construction Co. $51,579.70 19 Carmelina’s Circle Ludlow, MA 01056 Tel 413-583-2522

Sub Contract Award:

AWARDING AUTHORITY: AGENCY: MassDevelopment PROJECT NUMBER: 19-005 33 Andrews Parkway Devens, MA 01434 PROJECT TYPE: General Contract

CONTACT INFORMATION: PHONE: 978-784-2926 FAX: Jon Marc-Aurele EMAIL: [email protected] DESCRIPTION: Project 19-005: Abatement and Demolition of a single family residential structure located at 36 Cabot Street in Westfield, MA. Work to include: abatement and legal disposal of asbestos and hazardous materials; demolition of building and foundations; abandonment of existing well, septic system and other utilities; demolition of various site features and final site restoration.

CONTRACT AWARDED TO: CONTRACT AMOUNT: Western Mass Demolition $25,899.00 50 Medeiros Way Westfield MA. 01085

Sub Contract Award:

49 CR-4 CENTRAL REGISTER - CONTRACT AWARD

AWARDING AUTHORITY: AGENCY: Worcester County Sheriff's Office PROJECT NUMBER: WCSO 2020 HD 5 Paul X Tivnan Drive West Boylston, MA 01583 PROJECT TYPE: Designer Services

CONTACT INFORMATION: PHONE: FAX: Jason Rives, Esq, Assistant Superintendent EMAIL: DESCRIPTION: Study & Design of General Building Renovations, Repairs and Upgrades Worcester County Sheriff's Office (WCSO) West Boyston DSB List #20-10

CONTRACT AWARDED TO: CONTRACT AMOUNT: 09-03-2020 $500,000 Civitects Architecture 66 Troy Street 4th Floor Fall River, MA 02720

Sub Contract Award:

AWARDING AUTHORITY: AGENCY: Worcester County Sheriff's Office PROJECT NUMBER: WCSO 2020 HD 5 Paul X Tivnan Drive West Boylston, MA 01583 PROJECT TYPE: Designer Services

CONTRACT AWARDED TO: CONTRACT AMOUNT: 09-03-2020 $500,000 HDR Architecture, PC 99 High Street Suite 2300 Boston, MA 02110

Sub Contract Award:

50 CR-4 CENTRAL REGISTER - CONTRACT AWARD

AWARDING AUTHORITY: AGENCY: Worcester County Sheriff's Office PROJECT NUMBER: WCSO 2020 HD 5 Paul X Tivnan Drive West Boylston, MA 01583 PROJECT TYPE: Designer Services

CONTRACT AWARDED TO: CONTRACT AMOUNT: 09-03-2020 $500,000 SMRT Architects and Engineeers 200 Brickstone Square, Suite 303 Andover, MA 01810

Sub Contract Award:

AWARDING AUTHORITY: AGENCY: Worcester County Sheriff's Office PROJECT NUMBER: WCSO 2020 HD 5 Paul X Tivnan Drive West Boylston, MA 01583 PROJECT TYPE: Designer Services

CONTRACT AWARDED TO: CONTRACT AMOUNT: 09-03-2020 $500,000 STV, Inc. One Financial Center, 3rd Floor Boston, MA 02111

Sub Contract Award:

51 CR-3 CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTY The proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 20-40 Arlington, Town of 730 Massachusetts Avenue PROPOSAL DEADLINE DATE AND TIME: Arlington, MA 02476 10/20/20 @ 1:00 P.M.

CONTACT INFORMATION: PHONE 781-316-3003 FAX: 781-316-3019 Domenic R. Lanzillotti Email: [email protected] TRANSACTION TERMS: ACQUISITION: PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: Lease of Space at 23 Maple St. ESTIMATED VALUE, SOURCE OF VALUATION:

ADDITIONAL INFORMATION: Bid documents available for review and download at: www.arlingtonma.gov/purchasing.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: BHA 1867-01 Boston, City of Housing Authority PROPOSAL DEADLINE DATE AND TIME: Procurement Department, 6th Floor 52 Chauncy St 10/16/20 @ 2:00 P.M. Boston, MA 02111

CONTACT INFORMATION: PHONE 617-988-4036 FAX: 617-988-4292 Procurement Department Email: [email protected] TRANSACTION TERMS: ACQUISITION: PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: The Boston Housing Authority seeks to lease space on the roof or other connection areas at one or more BHA public housing developments throughout the City of Boston for the transmission and reception of telecommunication and Internet signals. Interested parties can submit either a bid to lease such space or submit a proposal to provide in-kind Internet services as part of their fee. The estimated fee for each lease area is $3,000 - $4,000 per month. The term is five-years with two optional five-year renewals. The Lease and use of these spaces will be on a nonexclusive basis. Multiple awards may be made available space permitting. ESTIMATED VALUE, SOURCE OF VALUATION: $3,000 - $4,000 per month per lease area, prior leases ADDITIONAL INFORMATION: Invitation for Bids and Proposal copies are available via email only. The Authority will email the package free of charge. Contact the Authority by e-mail at [email protected] and include complete contact information. Inquiries or requests for modifications regarding this procurement will be accepted in writing until 9/7/20 @ 2:00 P.M. The Authority reserves the right to reject any or all bids if it is in the public interest to do so.

52 CR-3 CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTY The proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 6890 Framingham, City of 150 Concord Street PROPOSAL DEADLINE DATE AND TIME: Framingham, MA 01702 10/16/20 @ 10:00 A.M.

CONTACT INFORMATION: PHONE 508-532-5407 FAX: Amy Putney Email: [email protected] TRANSACTION TERMS: ACQUISITION: PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: For the purchase of real property to be conveyed in fee at Kendall Street, Framingham, Massachusetts consisting of 4,750 square feet of area, being Assessors Parcel Identification Number of 128-96-1555-000 and shown on Plan No. 987 of 1957 and described in the order of taking recorded with Middlesex South District Registry of Deeds at Book 8978, Page 90, (the land is hereinafter referred to as the "Premises") as shown on the plan included as Exhibit A attached to this Request for Proposals (“RFP”). ESTIMATED VALUE, SOURCE OF VALUATION: $45,000 ADDITIONAL INFORMATION: RFP documents can be obtained electronically through the City of Framingham’s Vendor Registry portal: https://vrapp.vendorregistry.com/Vendor/Register/Index/city-of-framingham-ma-vendor-registration.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: N/A Haverhill, City of Water/Wastewater Department PROPOSAL DEADLINE DATE AND TIME: 40 South Porter Street Haverhill, MA 01830 @

CONTACT INFORMATION: PHONE 978-374-2382 FAX: Robert Ward Email: [email protected] TRANSACTION TERMS: ACQUISITION: PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: Notice of Unique Property Acquisition - The City of Haverhill will purchase 20.56 acres of undeveloped land at 0 Groveland Bridge Road (Parcel 464- 3-1) for $272,000 for the purpose of drinking water supply protection. The property is located within the Millvale Reservoir Watershed. ESTIMATED VALUE, SOURCE OF VALUATION: $272,000 - Appraisal ADDITIONAL INFORMATION: Property being sold by (party with beneficial interest): D&D Realty Trust, Richard Early Sr. (trustee), 6 Puzzle Lane, Newton, NH.

53 CR-3 CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTY The proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: Holbrook, Town of 50 North Franklin Street PROPOSAL DEADLINE DATE AND TIME: Holbrook, MA 02343 10/20/20 @ 12:00 P.M.

CONTACT INFORMATION: PHONE 781-767-4312 FAX: Tim Gordon / James O'Mara Email: [email protected] TRANSACTION TERMS: ACQUISITION:PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: The subject property located at 719 South Franklin Street, Holbrook is the former South Elementary School which has been out of service and transferred to the Board of Selectmen in 2017. The property is approximately 11 acres with a 38,000 square foot former school building in vacant and distressed condition. ESTIMATED VALUE, SOURCE OF VALUATION: $2,500,000 - 2017 appraised value of the property for mixed use development. ADDITIONAL INFORMATION: The subject property was submitted to an RFP process in August, 2017 which failed to obtain bid offer greater than $1,000,000. The subject property was rebid in January, 2019 and again failed to attain bid great than $1,000,000. In February, 2019 the property was placed out for bid in an RFP process and only two bids were received, each commensurate with the other at $1,000,000. The successful bidder must pay for demolition and environmental remediation and proposes approximately 40 town house style one- and two-bedroom units which are designed in harmony with adjacent residential properties. The proposed development is anticipated to have low impact on traffic, schools and emergency services. The difference between the appraised value and the price received is due to the failure of multiple earlier bid process and aforestated quality of the proposed development.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 21-840205 Mansfield, Town of 6 Park Row PROPOSAL DEADLINE DATE AND TIME: Mansfield, MA 02048 11/20/20 @ 10:00 A.M.

CONTACT INFORMATION: PHONE 508-261-7335 FAX: Mike Ahern Email: [email protected] TRANSACTION TERMS: ACQUISITION:PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: Disposition Sale of former central fire station located at 291 North Main Street in Town of Mansfield through RFP process. ESTIMATED VALUE, SOURCE OF VALUATION: $425,000 estimated value - 2019 appraisal. ADDITIONAL INFORMATION:

54 CR-3 CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTY The proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: Melrose, City of Park Commission PROPOSAL DEADLINE DATE AND TIME: 100 Slayton Road Melrose, MA 02176 10/16/20 @ 2:00 P.M.

CONTACT INFORMATION: PHONE 781-662-0210 FAX: Joan Bell, Superintendent Email: [email protected] TRANSACTION TERMS: ACQUISITION:PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: RFP for the non-exclusive lease of Slayton Tower space for Wireless Telecommunications Facilities on Mount Hood Memorial Park and Gold Course Real Property. ESTIMATED VALUE, SOURCE OF VALUATION:

ADDITIONAL INFORMATION:

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: #1-2020 Nantucket, Town of Housing Authority PROPOSAL DEADLINE DATE AND TIME: 3 Manta Dr. Nantucket, MA 02554 10/20/20 @ 2:00 P.M.

CONTACT INFORMATION: PHONE 508-228-0296 FAX: Renee H. Ceely Email: [email protected] TRANSACTION TERMS: ACQUISITION:PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: Vacant property shown as Lots 17B & 17C on Plan No. 2020-13 located on a portion of property at 9 Benjamin Drive, Nantucket, MA. ESTIMATED VALUE, SOURCE OF VALUATION: $290,000 - Appraisal; subject to an Affordable Housing Restriction, on 7/22/20. ADDITIONAL INFORMATION:

55 CR-3 CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTY The proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: Sandwich, Town of 130 Main Street PROPOSAL DEADLINE DATE AND TIME: Sandwich, MA 02563 10/21/20 @ 1:00 P.M.

CONTACT INFORMATION: PHONE 781-639-0140 FAX: 781-639-4416 David J. Coppola, Esq. Email: [email protected] TRANSACTION TERMS: ACQUISITION: PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: A parcel of land, with the buildings thereon, located at 85 Route 130, Sandwich, MA, shown as Lot 68 on the Town of Sandwich Assessors' Map 11, containing approximately 41,818 square feet. ESTIMATED VALUE, SOURCE OF VALUATION: $337,300.00 - estimated value according to the Town's assessing records. ADDITIONAL INFORMATION: The property at 85 Route 130 will be offered for sale at a Public Auction to be held on 10/21/20 @ 1:00 P.M. at 85 Route 130, Sandwich, MA. The Town of Sandwich will be retaining an easement for parking for the benefit of the property known as the Greenville Schoolhouse located at 87 Route 130, Sandwich, MA. The location of said easement is to be determined. The successful bidders will be required to pay a nonrefundable deposit in the form of a bank check at the auction in the amount of $20,000.00. The successful bidder will also be required to pay the pro forma real estate taxes for the remainder of Fiscal Year 2021, a buyer's premium in the amount of 5% of the sale price, and a deed recording fee in the amount of $155.00 at the time of closing. The balance of the purchase price and all fees must be paid on or before 12/4/20. The property is being sold “As-Is”. Additional terms and conditions will be announced prior to the commencement of the auction.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 21-038 Springfield, City of Office of Procurement PROPOSAL DEADLINE DATE AND TIME: 36 Court Street, Room 307 Springfield, MA 01103 10/16/20 @ 2:00 P.M.

CONTACT INFORMATION: PHONE 413-787-6284 FAX: 413-787-6295 Lauren Stabilo, CPO Email: [email protected] TRANSACTION TERMS: ACQUISITION: PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: The City of Springfield is requesting proposals for the redevelopment of the properties known as E S Armory Street. The properties are located in the McKnight Neighborhood. The properties consist of four distinct parcels totaling 15,835 square feet. ESTIMATED VALUE, SOURCE OF VALUATION: $71,100.00 - Assessors value. ADDITIONAL INFORMATION: The property consists of four parcels zoned as Business A. The parcels, according to the City of Springfield Assessor’s Office, contains a total of approximately .36 of an acre or (15,835 square feet). The four lots are all vacant and adjacent to each other. The City will require a certificate of occupancy within 12 months of the transfer of property to the designated developer or the property will revert back to the City.

56 CR-3 CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTY The proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: 21-039 Springfield, City of Office of Procurement PROPOSAL DEADLINE DATE AND TIME: 36 Court Street, Room 307 Springfield, MA 01103 10/16/20 @ 2:00 P.M.

CONTACT INFORMATION: PHONE 413-787-6284 FAX: 413-787-6295 Lauren Stabilo, CPO Email: [email protected] TRANSACTION TERMS: ACQUISITION: PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: The City of Springfield is requesting proposals for the redevelopment of W S Wilbraham Ave. (ID 12280 – 0017) which is located in the Upper Hill Neighborhood of Springfield. The parcel total square footage is 13,995 and is zoned as Industrial A. The City envisions a development that incorporates any reasonable proposals which could include some or all of the following elements: • Creating positive street level activity; • Firm financing letters or proof of funding to undertake redevelopment costs; • Timeline to have project completed; and • Creating jobs and/or quality housing opportunities for Springfield residents. ESTIMATED VALUE, SOURCE OF VALUATION: $34,900 - assessed value. ADDITIONAL INFORMATION: The City will entertain all competitive bids for the property. Price will not be the only factor in selection, but proposers are encouraged to make the best financial benefit case possible to the City.

AWARDING AUTHORITY: AGENCY: PROJECT NUMBER: CR-7434-1-W1 Worcester, City of Purchasing Division PROPOSAL DEADLINE DATE AND TIME: 455 Main Street Worcester, MA 01608 10/16/20 @ 10:00 A.M.

CONTACT INFORMATION: PHONE 508-799-1220 FAX: Chris Gagliastro Email: [email protected] TRANSACTION TERMS: ACQUISITION: PURCHASE LEASE DISPOSITION: SALE LEASE DESCRIPTION OF PROPERTY: Property Lease - Alternative School/WPS. ESTIMATED VALUE, SOURCE OF VALUATION: $100,000 annually - market evaluation.

ADDITIONAL INFORMATION: Proposal documents available via open bids page at: www.worcesterma.gov.

57 Page 1 of 2

DIVISION OF CAPITAL ASSET MANAGEMENT AND MAINTENANCE OFFICE OF LEASING AND STATE OFFICE PLANNING ONE ASHBURTON PLACE, 14th FLOOR – ROOM 1411 BOSTON, MASSACHUSETTS 02108 617-727-8000 WEEK OF SEPTEMBER 13, 2020 LEASED SPACE SOUGHT FOR STATE AGENCIES

The Division of Capital Asset Management and Maintenance Office of Leasing and State Office Planning is advertising the availability of the Requests for Proposals (RFPs) listed below. RFPs include the Lease Proposal form, instructions for submitting proposals, and the Commonwealth standard lease and associated documents. Please note that proposals must be received at the Office of Leasing and State Office Planning at the address listed above by the submission deadline. Proposals received after the deadline will not be considered.

RFPs can be obtained through the Internet at: www.mass.gov/dcamm/leasing. Under Requests for Proposals (RFP) to Lease Space, click on “COMMBUYS” and then click on “Find It”. You may also request an RFP by email, at [email protected], or by writing to the address listed above, or by coming to the Office at the address listed above. When requesting a copy of an RFP, please indicate the RFP Project # and include the name, address, and telephone and fax number of the person to receive the RFP; if you mail in your request, please enclose a business card with this information. Allow up to nine business days for receipt of an RFP by U.S. Mail.

Submission Project # User Agency Space Type Usable Sq. Ft. (USF) Locations Deadline & Term

09/17/20 202053000.1 Bristol Community Classrooms and Approximately Taunton 2:00 PM 10 Years College Science Labs 23,600 OR Classrooms Approximately Only 19,800

09/24/20 202085000.1 Division of Flex, or Light Approximately 5,200 Ashland, Bolton, Chelmsford, 2:00 PM 10 Years Standards Industrial Devens, Framingham, Hopkinton, Hudson, Littleton, Lowell, Marlborough, Millbury, Natick, Northborough, Shrewsbury, Southborough, Westborough, Westford, or Worcester Page 2 of 2

On August 4th, 2020, the DCAMM Commissioner certified that an emergency exists relating to a Department of Early Education and Care office, hence the following Invitation For Proposals (IFP)

See Below Project # User Agency Space Type Usable Sq. Ft. Location & Term (USF)

◊ 202082000.1 Department of Office Approximately Boston, within an approximately ½ Early Education 15,800 mile radius of an MBTA Rapid Not less than and Care Transit Station on the Green Line, 36 months and Orange Line, or Red Line not more than 60 months

◊ Proposals will be opened upon receipt and review will commence immediately. The Commonwealth of Massachusetts Executive Office for Administration and Finance Division of Capital Asset Management and Maintenance One Ashburton Place Boston, Massachusetts 02108 Tel: (617) 727-4050 Fax: (617) 727-5363 CHARLES D. BAKER MICHAEL J. HEFFERNAN GOVERNOR SECRETARY ADMINISTRATION & FINANCE KARYN E. POLITO CAROL W. GLADSTONE LIEUTENANT GOVERNOR COMMISSIONER

The Division of Capital Asset Management and Maintenance (DCAMM) list of suspended or debarred contractors is now available online at: https://www.mass.gov/service-details/contractors-and-vendors-suspended-or-debarred-by-dcamm THE COMMONWEALTH OF MASSACHUSETTS OFFICE OF THE ATTORNEY GENERAL ONE ASHBURTON PLACE BOSTON, MASSACHUSETTS 02108

MAURA HEALEY (617) 727-2200 ATTORNEY GENERAL TTY (617) 727-4765 www.mass.gov.ago

The Attorney General Office’s list of debarred contractors is now available online.

The Attorney General’s Office has replaced the List of Debarred Contractors that was previously published in the Central Register with an online database.

You can access the database by visiting www.mass.gov/ago/flddebarment and clicking on Debarred Contractors. Department of Industrial Accidents Debarment List

Under the provisions of the Workers' Compensation Law, Massachusetts General Laws, Chapter 152, Section 25C (10), once a business has been issued a Stop Work Order by the Department of Industrial Accidents, it is prevented from bidding on or participating in any state or municipal funded contracts for a period of three (3) years and, where applicable, is subject to penalties provided under M.G.L., Chapter 152, Section 25C (5), which provides for imprisonment for not more than one year or by a fine of not more than one thousand five hundred dollars, or by both such fine and imprisonment.

Companies currently on the debarment list can be found on the following link: http://www.mass.gov/lwd/workers-compensation/investigations/swos-issued.html The Commonwealth of Massachusetts Executive Office for Administration and Finance Division of Capital Asset Management and Maintenance One Ashburton Place Boston, Massachusetts 02108 Tel: (617) 727-4050 Fax: (617) 727-8284 CHARLES D. BAKER MICHAEL J. HEFFERNAN GOVERNOR SECRETARY ADMINISTRATION & FINANCE KARYN E. POLITO CAROL W. GLADSTONE LIEUTENANT GOVERNOR COMMISSIONER

CONTRACTORS DECERTIFIED BY THE DIVISION OF CAPITAL ASSET MANAGEMENT AND MAINTENANCE Updated February 23, 2018

The following contractors were previously certified, and are currently decertified, by the Division of Capital Asset Management and Maintenance (DCAMM) and have had their DCAMM Certificate(s) of Eligibility revoked. During the period of decertification, decertified contractors are not eligible to bid on public projects for which DCAMM Certification is required under M.G.L. Chapter 149, Chapter 149A and/or Chapter 25A.

There Are No Contractors That Are Currently Decertified.

NOTE: To determine if a contractor is currently certified by DCAMM, please check for the contractor’s name on DCAMM’s list of Certified Contractors at: WWW.Mass.Gov/DCAMM/Certification

Page 1 of 1 COMPANIES CERTIFIED BY THE Supplier Diversity Office (SDO)

Company: AC Fresh Interiors, LLC d/b/a: White Cottage Mrs. Cheryl Meyer 45 E Main Street, Suite 3 Westboro, MA 01581 (508)366-4040 Fax: [email protected] www.whitecottageco.com Certified by: Supplier Diversity Office Classification: WBE Effective Date: May 28, 2020

Company: Audrey E. Lochiatto d/b/a: Corporate Image Interiors Ms. Audrey Lochiatto 51 East Shore Drive Exeter, RI 02822 (401)397-9667 Fax: (401)397-9667 [email protected] www.TheFurnitureLady.com Certified by: Supplier Diversity Office Classification: WBE Effective Date: May 28, 2020

Company: Clean Slate Environmental, Inc. Ms. Beth G. Roccapriore 351 West Street Hebron, CT 06248 (860)228-2461 Fax: (860)228-2471 [email protected] http://www.cleanslateenv.com Certified by: Supplier Diversity Office Classification: WBE Effective Date: May 28, 2020

Company: Collins Construction Co., Inc. Ms. Linda Jones P O Box 2569 Bristol, MA 02722 (508)678-5201 Fax: (508)672-2960 [email protected] Certified by: Supplier Diversity Office Classification: WBE Effective Date: June 11, 2020

COMPANIES CERTIFIED BY THE Supplier Diversity Office (SDO)

Company: Commercial Contracting Supplies, LLC Ms. Rita Skinner 24 Mowery Road New Castle, DE 19720 (302)324-8110 Fax: (302)324-1604 [email protected] www.wbesales.com Certified by: Supplier Diversity Office Classification: WBE Effective Date: June 11, 2020

Company: Core Empowerment, LLC Ms. Peri Higgins 401A Centre Street Jamaica Plain, MA 02130 (610)420-5535 [email protected] www.corecannabis.org Certified by: Supplier Diversity Office Classification: WBE Effective Date: June 4, 2020

Company: Cox Associates Dr. Gerard Cox 951 LaGrange Street Boston, MA 02132 (617)739-0799 Fax: (617)739-0799 [email protected] www.gerardcoxassociates.com Certified by: Supplier Diversity Office Classification: MBE Effective Date: May 28, 2020

Company: Design Build Boston Mr. Arick Dyrdal 29 Mystic Avenue Somerville, MA 02145 (603)479-9489 [email protected] www.designbuild-boston.com Certified by: Supplier Diversity Office Classification: MBE and VBE Effective Date: May 28, 2020 COMPANIES CERTIFIED BY THE Supplier Diversity Office (SDO)

Company: Diversified Technology, Inc. Mr. Darryl Henry 65 E. Wacker Place, Suite 1400 Chicago, IL 60601 (312)385-3504 [email protected] www.divtech.com Certified by: Supplier Diversity Office Classification: MBE Effective Date: June 4, 2020

Company: Guardrail Solutions, LLC Mrs. Tanya Carr 108A Front Street West Springfield, MA 01089 (413)310-2428 Fax: (413)310-2542 [email protected] Certified by: Supplier Diversity Office Classification: WBE Effective Date: June 4, 2020

Company: High End Chocolate Company, LLC, The Ms. Helen Gomez Andrews 110 Winter Street Holyoke, MA 01040 (646)251-3662 [email protected] Certified by: Supplier Diversity Office Classification: MBE and WBE Effective Date: June 4, 2020

Company: HSI Construction, Inc. Mrs. Maureen Mainelli Po Box 2244 Pawtucket, RI 02861 (401)724-2600 [email protected] Certified by: Supplier Diversity Office Classification: WBE Effective Date: June 4, 2020 COMPANIES CERTIFIED BY THE Supplier Diversity Office (SDO)

Company: IMMI International Marketing Management, Inc. Ms. Celeste DeCosta 466 Central Avenue, Suite 14 Dover, NH 03820 (603)742-1119 Fax: (603)742-1119 [email protected] www.IMMIEnergy.com Certified by: Supplier Diversity Office Classification: MBE and WBE Effective Date: May 28, 2020

Company: Infore Consulting, LLC Mrs. Vera Bondarenko 75 Arlington Street, Suite 500 Boston, MA 02116 (617)281-6633 [email protected] https://www.infore.consulting Certified by: Supplier Diversity Office Classification: WBE Effective Date: May 28, 2020

Company: Integrity Park, Inc. Mrs. Natalia Doron 20 Green Street Marblehead, MA 01945 (617)519-8581 [email protected] www.integrity-park.com Certified by: Supplier Diversity Office Classification: WBE and PBE Effective Date: May 28, 2020

Company: LV Trucking Mr. Lamarkus Vick 200 Woodview Way, Unit 2312 Franklin, MA 02038 (781)817-0024 [email protected] Certified by: Supplier Diversity Office Classification: MBE Effective Date: June 11, 2020 COMPANIES CERTIFIED BY THE Supplier Diversity Office (SDO)

Company: Royalty Group, LLC Ms. Andrea Pearce 279 Tremont Street Boston, MA 02116 (978)479-9772 [email protected] www.royaltygroupllc.com Certified by: Supplier Diversity Office Classification: WBE Effective Date: June 4, 2020

Company: Sage Energy Consulting, LLC Ms. Geri Nicholson 2820 Carrollton Road Annapolis, MD 21403 (410)268-0511 [email protected] www.sage-energy.com Certified by: Supplier Diversity Office Classification: WBE Effective Date: June 4, 2020

Company: Sinsemilla Seminars Ms. Ellen Brown 48 Sconset Circle Sandwich, MA 02563 (508)419-4420 [email protected] www.sinsemillaseminars.com Certified by: Supplier Diversity Office Classification: WBE and VBE Effective Date: May 28, 2020

Company: TamBo's Kitchen, Inc. Ms. Oluwatoyin Adewumi 490 W Main Street Avon, MA 02322 (857)205-4868 [email protected] www.tamboskitchen.com Certified by: Supplier Diversity Office Classification: MBE and WBE Effective Date: June 4, 2020 COMPANIES CERTIFIED BY THE Supplier Diversity Office (SDO)

Company: Tech Choice, LLC Mr. Paul Storella 500 Victory Road, Suite 400 Quincy, MA 02171 (617)751-6232 [email protected] www.techchoice.com Certified by: Supplier Diversity Office Classification: MBE Effective Date: June 4, 2020

Company: Tigertown, LLC Mr. Richard Rainone 56 Jackson Street Holyoke, MA 01040 (954)350-1300 [email protected] Certified by: Supplier Diversity Office Classification: VBE Effective Date: June 4, 2020

Company: Timothy Haahs & Associates, Inc. Mr. Timothy H. Haahs 550 Township Line Road, Suite 100 Blue Bell, PA 19422 (484)342-0200 Fax: (484)342-0222 [email protected] http://www.timhaahs.com Certified by: Supplier Diversity Office Classification: MBE Effective Date: June 4, 2020

Company: Tri-State Emulsions Corp. Ms. Jodi Loud 188 Littmann Lane Sandgate, VT 05250 (802)375-6791 [email protected] Certified by: Supplier Diversity Office Classification: WBE Effective Date: June 11, 2020 DBE Certification Office | MassUCP

COMPANIES CERTIFIED BY THE MassUCP/DBE Certification Office 05/25/2020 - 06/12/2020

Company: Bloom Companies, LLC Mr. Mathew Tharaniyil 10501 W. Research Drive, Suite 100 Milwaukee, WI 53226 (414)771-3390 Fax: (414)771-4490 [email protected] www.bloomcos.com Certified by: MassUCP/DBE Office Classification: DBE Effective Date: June 4, 2020

Company: Coastal Construction & Management Co. Mr. Lucner Charles P O Box 777 Stoughton, MA 02072 (617)990-6507 [email protected] http://www.ccomanagement.com Certified by: MassUCP/DBE Office Classification: DBE Effective Date: June 11, 2020

Company: KNH Consulting, LLC d/b/a: Ingenious Culinary Concepts Mr. Kern Halls 1746 E. Silver Star Road, Suite #276 Ocoee, FL 34761 (888)994-3476 Fax: (888)994-3476 [email protected] www.ingeniouscc.com Certified by: MassUCP/DBE Office Classification: DBE Effective Date: June 1, 2020

Company: Nationwide Fleet Installations Ms. Salome Y.D. Brittingham 10125 Monaco Drive El Paso, TX 79925 (915)591-9506 Fax: [email protected] https://www.nfinstalls.com/ Certified by: MassUCP/DBE Office Classification: DBE Effective Date: June 4, 2020

Ten Park Plaza, Suite 2600-B, Boston, MA 02116 Tel: 857-368-8656

DBE Certification Office | MassUCP

COMPANIES DECERTIFIED and/or REMOVED by MassUCP/DBE Certification Office 05/25/2020 - 06/12/2020

Company: Allez Consulting, Inc. d/b/a: Z-Tech 181 Bedford Street, Suite 2 Lexington, MA 02420 Withdrew: MassUCP/DBE Office Classification: DBE Effective Date: June 10, 2020

Company: Coastal Construction & Management Co. P O Box 777 Stoughton, MA 02072 Decertified: MassUCP/DBE Office Classification: DBE Effective Date: June 11, 2020

Company: Conover + Gould Strategic Communications, Inc. d/b/a: Conover + Gould Strategy Group 69 Milk Street, #101A Westborough, MA 01581 Withdrew: MassUCP/DBE Office Classification: DBE Effective Date: June 4, 2020

Ten Park Plaza, Suite 2600-B, Boston, MA 02116 Tel: 857-368-8656