Purchase of Training Equipment for Surveying Laboratory

Employment through Skill Sindh Technical Education & Vocational Training Authority (STEVTA) ST-19, Block 6, Gulshan-e-Iqbal, near NIPA, Karachi. Phone No. 99244112-7 Fax No. 99244118 Website: http://www.stevta.gos.pk

Reference No. RFQ/06/2017-18 Request for Quotations Purchase of Training Equipment for Surveying Laboratory

SURVEYING LABORATORY LIST OF TOOL MACHINERY EQUIPMENTS REQUIRED STEVTA has received a credit from the World Bank and intends to apply some of its proceeds for procurement of training equipment to implement Surveying Laboratory program at Government College of Technology, Hyderabad. The list of items and quantity is mentioned below:-

Following are the Requirements of Tool Machinery Equipment for “Surveying Laboratory Course” as per SSDP Competency Package of the Course.

Sr Required Name of Items with Specification No Quantity 1 Total Station: 01 Nos. Telescope: Resolving power 2.5" Magnification 30x. Tilt Angle Compensation: Compensation Liquid 2-axis tilt Sensor Range± 6.DISTANCE MEASUREMENT Prism EDM Range 5000 m Prism EDM Accuracy 2mm + 2ppm. 1000 m. Measuring Time Fine 0.9 Second. Fine RefleadorRapid 0.85 Sec. COMMUNICATION Long Link TM interference free Communication USB 2.0 Slot (Host + Slaven). GENERAL Display Color Touch TFT 320X240 illuminator Battery Operation up to 4 hours IP58. 2 Auto Level. 02 Nos. TELESCOPE Image Erect. Magnification 32x Stadia Constant Zero Stadia Ratio 100 w/o Optical Micrometer 1.0mm Standard Development to 1 Km Double level with Optical Micrometer 0.7mm 0.5mm Shortest Sighting Distance. 3 Aluminum Leveling Staff: 06 Nos. Stared Length 1.245mm Graduation 5mm/10mm, Yellow in Color

RFQ-Surveying Laboratory Page 1 Sr Required Name of Items with Specification No Quantity 4 Multi Media Projector: 01 No. Display Technology: Single 0.45" DMD DLP ® Technology by Texas instruments TMNative Resolution VGA WSXGA+ (1680X1050) HDMI HD 1920x1080 Brightness 700 Lumens Contrast Ratio 10,000 1 (full on/full off) Displayable Colors 16.7 Million Light Source Life and Type 20,000 + Hours LED Projection Method Front, Rear, Ceiling Mount, Table Top Off Set 100% Projection Distance 18' – 10.6' (0.55- 3.23m) Image Size Diagonal 17"-100" (0.43- 2.54m) Projection Lens F=2.0, F=14.95mm) Digital Zoom 1.7x Audio One 1-Watt Speaker Noise Level (Normal Bright) 30db Remote Control iR remote control Memory 1.5 GB Onboard memory, micro SD slot supports up to 32 GB Compatibility Specification Computer Compatibility WSXGA + SXGA +, WXGA+, WXGA, SXGA, XGA, SVGA, VGA resized, VESA, PC and Macintosh compatible Video input compatibility NTSC, PAL, SECAM, SDTV (480), EDTV (480p) HDTV (720p, 1080/p). Vertical Scan Rate 50-120Hz Horizontal Scan Rate 15-100Khz User Controls Complete on-screen menu, adjustment in 16 languages Image file compatibility jpg bmp Office file compatibility Power Point Word, Excel, pdf. Music file compatibility mp3 wma, ogg, adpcm-wav, pcm- wav, aacVideo file Compatibilityavi, mkv, divx, ts, dat, vob, mpg, mpeg, mov, mps4, rm, rmvb, wmv i/o connection ports 24-pins universal port (VGA), HDMI, micro osd.

The procurement process will be conducted in accordance with the shopping method as contained in the World Bank Guidelines 2011. Preparation and submission of Quotations:Quotations must contain:

1. Quotation Submission Sheet; 2. Activity Schedule; 3. Documents evidencing your eligibility.

Formats for above documents can be downloaded from our website: ssdp.stevta.gos.pk

The quotation validity required is 45daysand must be submitted insealed single envelope, addressed to Project Director, SSDP, ST-19 Block 6, near NIPA, Gulshan-e-Iqbal, Karachi latest by 03rd November, at 2:00 pm. The quotations shall be opened on same day at 03:00 pm.

(Project Director, SSDP)

RFQ-Surveying Laboratory Page 2 QuotationSubmissionSheet [Complete this form with all the requested details and submit it as the first page of your quotation, with the documents requested above attached. Ensure that your quotation is authorised in the signature block below. A signature and authorisation on this form will confirm that the terms and conditions of this RFQ prevail over any attachments. If your quotation is not authorised, it may be rejected.]

Quotation Addressed to (Implementing St-19 Block Near Nipa Chowrangi Gulshan-e-Iqbal Karachi Agency):

Date of Quotation: 03rd November, 2017.

Procurement Reference Number: RFQ/06/2017-18

Subject of Procurement: Instrumentation & Control in Govt. College of Technology Hyderabad.

We offer to provide the Goods detailed in the Statement of Requirements, in accordance with the terms and conditions stated in your Request for Quotations referenced above. We confirm that we are eligible to participate in public procurement and meet the eligibility criteria specified in this Request for Quotations. The validity period of our quotation is: 07 days from the time and date of the submission deadline. We confirm that the prices quoted in the Activity Schedule are fixed and firm for the duration of the validity period and will not be subject to revision or variation. The goods will commence within 02 days/weeks/months from date of Contract. The goods will be completed within 30 days/weeks/months from date of Contract.

Both Parties Signature:

Signature: ______Name: ______

Position: ______Date: ______(DD/MM/YY) Authorized for and on behalf of:

Company: ______

Address: ______

______

RFQ-Surveying Laboratory Page 3 STATEMENT OF REQUIREMENTS Scope of Goods Procurement Reference Number: ______Brief Description of Goods Purchase of Training Equipment for Surveying Laboratory.

Location (Site) of Goods Govt. College of Technology,Hyderabad. Commencement and completion periods required Activity Schedule [Complete the unit and total prices for each item listed below. Authorize the prices quoted in the signature block below.] Items of the Goods for which no rate or price has been entered in will not be paid for by the Employer and shall be deemed covered by other rates and prices in the Contract.

Ite m Description of Goods Unit rate Total Price No (Rs.)

Other additional costs Subtotal Applicable Taxes Total Quotation authorised by:

Signature: ______Name: ______

Position: ______Date: ______Authorized for and on behalf of: (DD/MM/YY)

Company: ______

RFQ-Surveying Laboratory Page 4 Specifications and Drawings The Goods are to be performed in accordance with the following attached Technical Specifications and Drawings: 1. 2. 3. 4.

RFQ-Surveying Laboratory Page 5 Contract Data

The Employer: The Employer is: Project Director, SSDP.

The Project Manager: The Project Manager is: Project Coordinator, SSDP.

The Employer representative: The Employer’s representative is: Deputy Project Coordinator (Procurement), SSDP Registered firms having sales tax registration number (F/A) Eligibility Criteria:

Documents Evidencing Eligibility: Valid certificate of registration. (F/B)

Eligible Countries: Pakistan

Currency: Pak Rupees.

Insurance: The minimum insurance covers shall be: N/A

Required Completion Date: The Required Completion Date shall be: 30 days from the date of Contract is executed by both parties.

Site for the Goods and Estimated Govt. College of Technology S.I.T.E. Karachi. Cost:

Duties and Taxes: As per Rules of land on supplies.

Proposed Start Date: Within 01 week of award of contract.

Type of Contract: Lump Sum.

Quotation Prices: Quotations shall cover all costs of Labour, materials, equipment, overheads, profits and all associated costs for performing the goods and shall include all taxes and duties.

Right to Reject: The Implementing Agency reserves the right to accept or reject any quotation or to cancel the bidding process and reject all quotations.

Possession of the Site: _____ August, 2017.

Defects Liability Period: The Defects Liability Period shall be: N/A

Advance Payment N/A

Paymentretention: 100% After verification of Delivery

Adeel Khan RFQ-Surveying Laboratory General Conditions of Contract Any resulting contract shall be placed by means of a Letter of Acceptance or a Contract against the General Conditions of Contract (GCC) for the Procurement of Goods below, except where modified by the provisions of this Request for Quotation. Reference to Contract Data in these General Conditions of Contract shall mean this Request for Quotations.

Language and Law 1.1 The law governing the Contract shall be the laws of the Republic of Pakistan and the language of the Contract shall be English unless otherwise stated in the Contract.

Communications 2.1 All communications between parties shall be in writing.

Sub-contracting 3.1 The Contractor may subcontract with the approval of the Project and other Manager. contractors Personnel 4.1 If the Project Manager asks the Contractor to remove a person who is a member of the Contractor’s staff or work force, stating the reasons, the Contractor shall ensure that the person leaves the Site within 72 hours and has no further connection with the work in the Contract.

Contractor’s Risks 5.1 From the Starting Date until the Defects Correction Certificate has been issued, the risks of personal injury, death, and loss of or damage to property (including, without limitation, the Goods, Plant, Materials, and Equipment) which are not Employer’s risks are Contractor’s risks.

Insurance 6.1 The Contractor shall provide, in the joint names of the Employer and the Contractor, insurance cover from the Start Date to the end of the Defects Liability Period, in the amounts stated in the Contract Data for the following events which are due to the Contractor’s risks:

a). loss of or damage to the Goods, Equipment, Plant and Materials; b). loss of or damage to property (except the Goods, Plant, Materials, and Equipment) in connection with the Contract; and personal injury or death. Third party liability. 6.2 Policies and certificates for insurance shall be delivered by the Contractor to the Project Manager for approval within 15 days of receipt by the Contractor of the Employer’s Letter of Acceptance.

Contractor to 7.1 The Contractor shall construct and install the Goods and rectify all Construct the defects in accordance with the Specifications and Drawings. Goods Completion Date 8.1 The Contractor shall commence execution of the Goods on the Start Date and shall carry out the Goods in accordance with the Program by the Required Completion Date.

Safety 9.1 The Contractor shall be responsible for the safety of all activities on the Site.

Program 10.1 The Contractor shall submit to the Project Manager for approval a Program showing the general methods, arrangements, order, and timing for all the activities in the Goods. The Contractor shall update the Program at intervals agreed with the Project Manager.

Completion Date 11.1 The Project Manager shall authorise any extension of time for the Extension Goods.

Adeel Khan RFQ-Surveying Laboratory Instructions of the 12.1 The Contractor shall comply with the instructions given by the Project Manager Project Manager or delegated assistant on any matter related to the Contract.

Correction of 13.1 The Project Manager shall give notice to the Contractor of any Defects Defects before the end of the Defects Liability Period, which begins at Completion, and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected.

Uncorrected 14.1 If the Contractor has not corrected a Defect within the time specified Defects in the Project Manager’s notice, the Project Manager will assess the cost of having the Defect corrected, and the Contractor will pay this amount, or the Employer shall recuperate these amounts by deduction from the amounts due to the Contractor.

Payment 15.1 The Contractor shall submit to the Project Manager monthly Certificates statements of the estimated value of the work executed less the cumulative amount certified previously.

Payments 16.1 Payments shall be adjusted for deductions for advance payments and retention. The Employer shall pay the Contractor the amounts certified by the Project Manager within 28 days of the date of each certificate

Tax 17.1 The Contractor is liable for all taxes in accordance with the laws of the Republic of Pakistan

Advance Payment 18.1 The Employer shall make advance payment to the Contractor of the amounts stated in the Contract Data after the Contractor has delivered to the site construction equipment and/or materials for initiating the work.

18.2 The advance payment shall be repaid by deducting proportionate amounts from payments otherwise due to the Contractor, to be recovered within one half of the completion period.

Retention Moneys 19.1 An amount, specified in the Contract Data, will be retained from each payment to the Contractor. Retention moneys shall be repaid to the Contractor on completion of the Goods or as agreed between the Employer and Contractor.

Day goods 20.1 If applicable, the Day goods rates in the Contractor’s Bid shall be used for small additional amounts of work only when the Project Manager has given written instructions in advance for additional work to be paid for in that way. Subject to obtaining signed Day work forms.

Cost of Repairs 21.1 Loss or damage to the Goods or Materials to be incorporated in the Goods between the Start Date and the issue of the Completion Certificate shall be remedied by the Contractor at the Contractor’s cost if the loss or damage arises from the Contractor’s acts or omissions.

Completion and 22.1 The Contractor shall request the Project Manager to issue a certificate Taking Over. of completion of the Goods, and the Project Manager will issue such a certificate when he determines that the work is satisfactorily completed. The Employer shall take over the site and the goods within seven days of the Project Manager’s issuing of a certificate of completion.

Adeel Khan RFQ-Surveying Laboratory Final Account 23.1 The Contractor shall supply the Project Manager with a detailed account of the total amount that the Contractor considers payable under the Contract before the end of the Defects Liability Period.

Termination-action 24.1 The Employer or the Contractor may terminate the Contract if the other party causes a fundamental breach of the Contract.

24.2 Notwithstanding the above, the Employer may terminate the Contract for convenience by giving the Contractor a thirty-day notice in writing.

24.3 If the Contract is terminated, the Contractor shall stop work immediately, make the Site safe and secure, and leave the Site within 15 days of the completion of the notice period.

Payment upon 25.1 If the Contract is terminated for whatever reason, the Project Termination Manager shall determine the amounts due or recoverable from the Contractor

Resolution of 26.1 The Employer and the Contractor shall make every effort to resolve Disputes amicably by direct informal negotiation any disagreement or dispute arising between them under or in connection with the Contract. If after thirty (30) days from the commencement of such informal negotiations, the Employer and the Contractor have been unable to resolve amicably a dispute arising out of this Contract; either party can take the matter to arbitration in accordance with the Law governing the Contract.

Adeel Khan RFQ-Surveying Laboratory