SOLAR RFS BID DOCUMENT

REQUEST FOR SELECTION FOR

GRID CONNECTED SOLAR POWER PROJECTS

Bid No.01/2013/CE-IPC-APPCC/Vidyut Soudha/Khairatabad/Hyderabad

Important Dates

Last date of submission of bids 07 Feb 2013

ISSUED BY

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED (APTRANSCO)

VIDYUT SOUDHA HYDERABAD 500082

Tele fax: 040 - 23393304,

Email - [email protected] Website: www.aptransco.gov.in

January 2013 `

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 1

SOLAR RFS BID DOCUMENT

Section 1

INTRODUCTION & BACKGROUND

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 2

SOLAR RFS BID DOCUMENT

Section 1

1.0 Introduction and Background

1.0.1 A solar capacity of 1000 MW is envisaged by floating this RfS under competitive bidding route to setup Solar Power Projects in the state at various Locations to have distributed energy generation as per the policy announced by GoAP vide G.O.Ms No.46, dated 27.11.2012.

1.0.2. The main objective of this RfS is to evacuate the solar power at any of the EHT substations (“Location(s)”) or at any 33/11 kV substations connected under each identified EHT substation/Location notified in the Annexure –A with a capacity limitation for easy and immediate evacuation of the solar power. As such, the Bidder has the flexibility to choose the project site at an EHT substation and/or any of the 33/11 kV substations under the corresponding EHT substation.

1.1. The Andhra Pradesh State Electricity Regulatory Commission (“APERC”) issued Regulation No.1 of 2012, mandating Renewable Power Purchase Obligation and its Compliance in accordance with Sections 61, 66 and 86(1)(e) & 181 of the Electricity Act, 2003, by the DISCOMs, Open Access Consumers, Captive Consumers in the State, to consume a quantum of power not less than 5% of their consumption from RE sources. The said regulation also mandated to purchase a minimum of 0.25% solar power out of the 5% RPPO specified from RE sources.

1.1.1 The distribution licensees (“DISCOM”) were incorporated in the state of Andhra Pradesh, under the provisions of the Companies Act, 1956, with the main objective of performing power distribution functions in the state, in accordance with A.P.Electricity Reform Act 1998, by procuring power from

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 3

SOLAR RFS BID DOCUMENT

different sources and supplying electrical energy to the needy consumers in the state.

1.2. The APTRANSCO has been designated by GoAP in the Solar Power Policy issued Vide G.O.Ms.No.46,dated:27.11.2012 for inviting RfS requests from interested Companies, and/or Bidding Consortium and or any Consortium Member thereof (Bidders) for selection of successful bidder(s) for setting up of Solar Power Projects through a competitive bidding process as per Section-63 of the Electricity Act,2003. The responsibility of the successful Bidder(s) is to supply power to the DISCOM(s) as per terms & conditions of Power Purchase Agreement (“PPA”), issued under this RfS, which would be executed and signed between DISCOM(s) and successful bidder(s), for a period of 20 years.

1.3 However, under this RfS, Developer shall not be eligible to obtain Renewable Energy Certificates (“REC”) for the energy generated from the solar power plant set up by him.

1.4 Total capacity of the project

This RfS is floated for inviting competitive bids for setting up of Solar Photo Voltaic/Solar Thermal Projects subject to the maximum permissible capacity at specified Locations as mentioned in Annexure-A.

1.5 Project site:

The Developer is at his liberty to identify and acquire the suitable land required for the Project near the EHT substation or associated 33/11 kV substations. The Developer shall be responsible for getting all statutory clearances from the concerned departments.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 4

SOLAR RFS BID DOCUMENT

1.5.1 Technology: The Bidder is at his liberty to choose any available technology, subject to fulfillment of technical criteria as defined in Section 3C, suitable for setting up of Solar Power Projects in the specified Locations as mentioned in Annexure-A. 1.6. Scope of the project:

The main scope of the Project shall mean and include, a) Designing, constructing, erecting, testing and commissioning of the solar power plant(s) including all necessary electrical equipment for metering, transmission and evacuation of electricity to the nearest 33/11kV or 132/33kV substation and supply of contracted capacity to DISCOMs. b) Operation and Maintenance of the aforesaid solar projects including associated evacuation lines till Interconnection Point for the period of the PPA. c) Performance and fulfillment of all other obligations of the Developer as per this RfS and entering into a Power Purchase Agreement (“PPA”) and matters incidental thereto or necessary for the performance of any or all of the obligations of the Developer. d) Installation of all necessary protection devices to protect the power plant and connected lines from lightning, sudden surges in voltage and current and to ensure safety of the grid to which the Project is connected. The Developer shall also ensure protection of human lives and equipment likely to be endangered due to the installed solar power plant.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 5

SOLAR RFS BID DOCUMENT

1.7 Issue of RFS: The eligibility criteria for the qualification of Bidders for Bid submission are indicated in this RfS. 1.8 The RfS can be downloaded from http//tender.eprocurement.gov.in. The same will be available in website of APTRANSCO (www.aptransco.gov.in) for information. 1.9 Receipt of Bid: Bids shall be submitted via e-procurement platform and Bidders shall obtain all necessary keys from Andhra Pradesh Technology Services (APTS) and can obtain assistance from Vayam Technologies, Panjagutta, Opp. NIMS, Hyderabad. Phone Number: 040 - 44426250/251 (Timings 9:00 AM to 9:00 PM). Bidder shall have to pay the transaction fee of Rs.25,000 + Service tax as applicable, to APTS. 1.10 Steps for E-Procurement: i) Bidder shall obtain digital signature from APTS (Phone Number: 040 23224283/ 0305). ii) Using the digital signature, bidder shall register himself on the AP procurement website (URL: https://tender.eprocurement.gov.in). iii) After successful registration, Bidder shall send a mail confirming the registration details to Vayam Technologies at: [email protected]. iv) The user ID created by the Bidder in the previous step will be validated by Vayam Technologies after which the Bidder can upload the bid documents using the user ID created on the e-procurement website. In addition to the bid on e-procurement the following should be sent in hard copy to the following address:- Chief Engineer/IPC/APPCC,401/A, Vidyut Soudha, Khairtabad, Hyderabad. Email: [email protected], Telefax: 040-23393304.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 6

SOLAR RFS BID DOCUMENT

Details of processing fee and bid security:

I. Processing fee as per 3.2 (b) in the form of DD or online payment through RTGS. Insufficient processing fee paid by the bidder through RTGS or DD is liable for rejection of bids and the scanned copies of DD should be uploaded. DD in original containing the Bidders name (on the cover and backside of the DD, if applicable) - are to be submitted in a sealed cover before the due date as mentioned to the above address. II. EMD (Bid security) as per 3.2(c) in the form of BG (as per Format 6.14) shall be uploaded in the bid. Insufficient bid security and insufficient validity (120 days) is liable for rejection of the bids.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 7

SOLAR RFS BID DOCUMENT

List of Abbreviations

APERC AP Electricity Regulatory Commission APPCC Andhra Pradesh Power Coordination Committee APTRANSCO Transmission Corporation of Andhra Pradesh BG Bank Guarantee BIS Bureau of Indian standards CDM Clean Development Mechanism CEA Central Electricity Authority CERC Central Electricity Regulatory Commission DD Demand Draft DISCOM Power Distribution Company Limited of AP EMD Earnest Money Deposit GoI Government of GoAP Government of AP HV High Voltage IEC International Electro-technical Commission INR Indian Rupees kV Kilo Volt L.C. Letter of Credit LLC Limited Liability Company LLP Limited Liability Partnership LoI Letter of Intent MNRE Ministry of New and Renewable Energy MU Million Units MVAR Mega Volt-Ampere Reactive MW Mega Watt NREDCAP New and Renewable Energy Development Corporation of AP PPA Power Purchase Agreement PV Photo Voltaic RE Renewable Energy REC Renewable Energy certificate RFID Radio Frequency identification RfS Request for Selection ROC Registrar of Companies RPPO Renewable Power Purchase Obligation

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 8

SOLAR RFS BID DOCUMENT

SBI State Bank of India SCADA Supervisory Control and Data Acquisition SGC State Grid Code SLDC State Load Dispatch Centre SPD Selected Solar Power Developer STU State Transmission Utility USD United States Dollars VAR Volt-Ampere Reactive

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 9

SOLAR RFS BID DOCUMENT

Section 2

Definitions

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 10

SOLAR RFS BID DOCUMENT

Section-2

2. Definitions

“Affiliate” shall mean a Company that, directly or indirectly, i) controls, or ii) is controlled by, or iii) is under common control with, a Company developing a Project or a Member in a Consortium developing the Project and control means ownership by one Company of at least 26% (twenty six per cent) of the voting rights of the other Company;

“Performance Bank Guarantee (BG)” shall mean a bank guarantee (BG) issued by banks, listed in the Annexure 2, to guarantee timely and satisfactory completion of a project by a Developer.

“Benchmark Price” shall be decided by a Committee after opening of the financial bids. It will be the same for all Locations.

“Bid” shall mean the Non-Financial Bid and the Financial Bid submitted by the Bidder, in response to this RfS, in accordance with the terms and conditions hereof.

“Bidder” shall mean Bidding Company or a Bidding Consortium submitting the Bid. Any reference to the Bidder includes Bidding Company/ Bidding Consortium / Consortium, Member of a Bidding Consortium including its successors, executors and permitted assignees and Lead Member of the Bidding Consortium

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 11

SOLAR RFS BID DOCUMENT

jointly and severally, as the context may require. After the selection of successful bidder, the successful bidder will be referred as “Developer”.

“Bidding Company” shall refer to such single company that has submitted the response in accordance with the provisions of the RfS.

“Bidding Consortium” or ”Consortium” shall refer to a group of companies that has collectively submitted the response in accordance with the provisions of this RfS. “Contracted Capacity" shall mean the capacity allocated at each Location to the Solar Power Developer as described in Clause 3.7.

“Contract Performance Bank Guarantee” shall refer to the bank guarantee to be produced by Developer/Successful Bidder to the concerned DISCOMs on the difference of L1 Tariff and Committee decided Benchmark Price to the tune of amount of rupees equivalent to the energy that would be generated for 3 [three] years at CUF (capacity utilization factor) of 25% from the plant. If the difference between the Benchmark Price and the Tariff quoted by the successful bidder is less than or equal to 5% of the Benchmark Price, then the CPBG is not required to be submitted.

“Chartered Accountant” shall mean a person (with a minimum experience of 5 years) practicing in India or a firm (in operation for at least 5 years) whereof all the partners are practicing in India as a Chartered Accountant(s) within the meaning of the Chartered Accountants Act, 1949.

“Commercial Date of Operation” (COD) shall mean with respect to each generating unit, the date on which such generating unit is declared by the Developer to be operational, provided that the Developer shall not declare a generating unit to be operational until such generating unit has completed its

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 12

SOLAR RFS BID DOCUMENT

standard procedures.

“Company” shall mean a body corporate incorporated in India under the Companies Act, 1956.

”Controlling shareholding” shall mean more than 50 % of the voting rights in the Company/ Consortium.

“Capacity Utilization factor” (“CUF”) shall have the same meaning as provided by APERC from time to time. Till such time, it shall have the same meaning as provided in CERC (Terms and Conditions for the Tariff determination from Renewable Energy Sources) Regulations, 2012 and as amended from time to time. “Developer” shall have the same meaning as “Successful Bidder” as defined below in this RfS.

“Financial Closure” or “Project Financing Arrangements” shall mean arrangements of necessary funds by the Developer either by way of commitments of funds by the company from its internal resources and / or tie up of funds through a bank / financial institution by way of sanction of a loan.

“Group Company” of a Company shall mean (i) a Company which, directly or indirectly, holds 10% (ten per cent) or more of the share capital of the Company or (ii) a Company in which the Company, directly or directly, holds 10% (ten per cent) or more of the share capital of such Company or (iii) a Company in which the Company, directly or indirectly, has the power to direct or cause to be directed the management and policies of such Company whether through the ownership of securities or agreement or any other arrangement or otherwise or (iv) a Company which, directly or indirectly, has the power to direct or cause to be directed the management and policies of the Company whether through the ownership of securities or agreement or any other

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 13

SOLAR RFS BID DOCUMENT

arrangement or otherwise or (v) a Company which is under common control with the Company, and control means ownership by one Company of at least 10% (ten per cent) of the share capital of the other Company or power to direct or cause to be directed the management and policies of such Company whether through the ownership of securities or agreement or any other arrangement or otherwise.

Provided that a financial institution, scheduled bank, foreign institutional investor, non-banking financial Company, and any mutual fund shall not be deemed to be Group Company, and its shareholding and the power to direct or cause to be directed the management and policies of a Company shall not be considered for the purposes of this definition unless it is Project Company or a Member of the Consortium developing the Project.

“Interconnection Point/Injection Point/ Metering point” shall mean the point or points where the Project and the DISCOM’s grid system are interconnected at APTRANSCO/DISCOM substation. The Developer shall install main and check meters of static type of 0.2 class accuracy at interconnection point. Besides the above, the Developer shall install a separate standby meter of same accuracy as that of main and check meters in C&R panel as per CEA metering regulations, to account the energy in case of failure of main and check meters. Metering arrangements shall be done in accordance with APTRANSCO/DISCOMs procedures in vogue at the specified interconnection point by providing specified meters approved by DISCOMs where the power would be injected into the GRID.

“L1 bidder” shall mean the shortlisted Bidder who quotes the lowest Tariff per unit (kWh) of electricity per Location.

“L2 bidder” shall mean the shortlisted Bidder who quotes the second lowest Tariff per unit (kWh) of electricity per Location.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 14

SOLAR RFS BID DOCUMENT

“L3, L4, L5.....Ln bidder” shall mean the shortlisted Bidder quoting the 3rd, 4th, 5th ...... nth lowest Tariff per unit (kWh) of electricity per Location.

“L1 Tariff” shall mean the lowest quoted Tariff in Indian Rupees per unit (kWh) of electricity per Location.

“Location” shall mean the EHT substations as per the list specified in Annexure – A. Any Bidder willing to bid at a specific 33/11 kV substation under the respective EHT substation should refer to the corresponding EHT substation as a Location.

“Lead Member of the Bidding Consortium” or “Lead Member” shall mean the member of the Consortium nominated by the other members of the Consortium to be the Lead Member of the Consortium.

“Letter of Intent” or “LoI” shall mean the letter issued by APTRANSCO to the Selected Bidder for the awarding of the Project.

“Limited Liability Partnership” of “LLP” shall mean a Company governed by

Limited Liability Partnership Act-2008.

“LLC” shall mean Limited Liability Company;

“Maximum Cumulative Capacity” shall mean the maximum capacity the Bidder will be allowed to bid for across the Locations. This capacity is limited to 200 MW for a Bidder, Affiliates, Parent Company, Group Companies and the Ultimate Parent Company.

“Member in a Bidding Consortium” or “Member” shall mean each Company in a Bidding Consortium.

“Month” shall mean only 30 days for all transactions under this RfS.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 15

SOLAR RFS BID DOCUMENT

“Parent” shall mean a Company, which holds at least 26% equity either directly or indirectly in the Bidding Company or in a Member of a Consortium developing the Project. “Performance bank guarantee” shall refer to bank guarantee to be produced by the successful bidder to the concerned DISCOMS to the total tune of Rs 10 (ten) Lakhs per MW in three different bank guarantees i.e. Rs 2(two) lakhs per MW, Rs 3 (three) lakhs per MW and Rs 5 (five) lakhs per MW for a validity period of 22 months from the date of signing of PPA. However the same will be returned after commissioning of the solar project.

“Power Purchase Agreement (PPA)” shall mean the power purchase agreement between Developer and DISCOM for selling the solar power.

“Procurer(s)/DISCOM” shall mean the DISCOMs in the state concerned based on geographic area of location.

“Project(s)” shall mean the solar power plant set up by the Developer.

“Project Company” shall mean the company incorporated by the bidder as per the Indian Companies Act, 1956 in accordance with clause 3.5.

“Scheduled COD” shall mean 12 months from the date of signing of this Agreement (PPA).

“Selected Bidder or Successful Bidder” shall mean the Bidder selected by APTRANSCO pursuant to this RfS to set up the Project and supply electrical output as per the terms of PPA. This Bidder is also referred to as the “Developer”.

“Solar Power Project(s)” shall mean either a Solar PV Power Project or a Solar

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 16

SOLAR RFS BID DOCUMENT

Thermal Power Project.

“Solar PV Project” shall mean the Solar Photo Voltaic Power Project that uses sunlight for direct conversion into electricity through photo voltaic technology.

“Solar Thermal Power Project” shall mean the solar thermal power project that uses sunlight through Concentrated Solar Power Technology (based on either line focus or point focus principle) for conversion into heat/steam which can be used for producing electricity.

“Statutory Auditors” shall mean a reputable firm of Chartered Accountants acting as the Statutory Auditors of the Company under the provisions of the Companies Act, 1956.

”Tariff” shall mean the quoted price per kWh of energy delivered from the proposed solar power plant to the grid by the Bidder in response to the RfS per Location.

“Technology Partner” shall mean any entity from which the Bidder proposes to take technology support. “Ultimate Parent” shall mean a Company, which owns at least twenty six per cent (26%) paid up equity capital in the Bidding Company or Member of a Bidding Consortium either directly or indirectly in the Parent and Affiliates.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 17

SOLAR RFS BID DOCUMENT

Section 3

INFORMATION AND INSTRUCTIONS TO BIDDERS

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 18

SOLAR RFS BID DOCUMENT

Section 3

3. Information and Instruction to Bidders

3.1 Total capacity offered:

Initially, it is proposed to invite prospective Bidders to setup about 1000 MW capacity Solar Power Projects based on the available solar technology as per the AP Solar State Policy vide G.O. Ms.No. 46, dated 27.11.2012 under competitive bidding route. Sl.No. Interfacing/grid substation Voltage level Maximum capacity (interconnection point) 1 33/11 kV 33 kV 1-5 MW* 2 132/33 kV 33 kV 1-10 MW* 3 132/33 kV 132 kV 10-20 MW*

*The above maximum capacity shall be limited to the capacities specified in specific Locations as per the Annexure-A. The maximum permissible capacity at each Location is as mentioned in Annexure A. The Bidder can choose any 33/11 kV or 132/33 kV substation under each Location, subject to the maximum permissible capacity mentioned under that Location, for the purpose of Bid. Any quoted capacity by the Bidder shall not be less than 1 MW.

For eg:-

Maximum permissible capacity at Chilakapalem (named as Location as per this RfS document) – 5 MW according to Annexure A.

Thus solar capacity at Chilakapalem EHT substation and all associated 33/11 kV substations cannot exceed 5 MW.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 19

SOLAR RFS BID DOCUMENT

Each Bidder will be allowed to participate in the competitive bid for a maximum capacity at the identified Locations in Annexure to this RfS as indicated below:

1. At 33/11 kV Substation: 1 to 5MW capacity of solar projects at evacuation voltage of 33kV. A maximum of 5 MW are permitted at 33/11kV substation. However the bidder can quote based on the availability as per the identified respective substations only.

2. At 132/33 kV Substation: 1 to 10 MW of solar projects at 33kV connection voltage level and 10 to 20 MW of solar projects at 132 kV evacuation voltage level. However the bidder can quote based on the availability as per the identified respective substations only.

Note: The capacity of the Project in MW is the installed capacity of the Project/ rated power output (AC) from the solar power plant, which can be scheduled at any point of injection to the grid during the day time. Further, the Bidder has to visit the proposed Location(s) as mentioned in Annexure A and assess the suitability of distribution /EHT substations for evacuation of solar power, and ascertain the feasibility for evacuation before quoting the bid. 3.2 Obtaining RfS Document and Processing Fees

a) RfS is also available in the website Error! Hyperlink reference not valid. information.

b) Bidders are required to submit their bid for each Location, along with a

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 20

SOLAR RFS BID DOCUMENT

non-refundable processing fee of Rs 2.00 lakhs for each Location in the form of Demand Draft payable to APPCC A/c. No. 52117479223 at Hyderabad or the same by online payment through RTGS (RTGS details as per Annexure – C for RTGS). Bid submitted without or insufficient processing fee shall be liable for rejection without any intimation.

c) Bid security: EMD in the form of BG as follows: Rs. 2 lakhs/MW BG in favor of Chief Engineer/IPC/APPCC/APTRANSCO according to the format specified in 6.14. with a validity period of 90 days from the date of bid submission and claim period of one more month over and above validity period. EMD will be returned to all unsuccessful bidders within 15 days of issue of LOI. Insufficient/Part Bid security submitted by the bidders will be rejected without any intimation.

3.3 Proposal for Short-listing of Projects

Bidders shall submit response to Request for Selection (RfS) for establishment of Solar Power Projects as per the terms & conditions detailed herein.

3.4 Number of response to RfS by a Company

The Company, including its Parent, Affiliate or Ultimate Parent or any Group Company, or a Bidding consortium will be allowed to submit only one RfS upto capacity mentioned in Clause 3.1 per each Location as mentioned in Annexure-A. Alternate bids are prohibited in each Location. The total capacity of Projects to be Bid for by a Company including its Parent, Affiliate or Ultimate Parent-or any Group Company shall be limited to 200 MW (Maximum Cumulative Capacity) across Locations.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 21

SOLAR RFS BID DOCUMENT

The capacity Bid for across Locations must be indicated in the Format 6.11. 3.5 Qualification Requirements:

Shortlisting of the Bidders will be based on meeting the qualification requirements specified for net worth, technical criteria and connectivity with grid as given below: A. Companies eligible for participation:

i) Companies incorporated in India under the Companies Act 1956.

ii) A foreign company can also participate individually or as a Member of Consortium at RfS stage. But before signing of PPA, keeping the original shareholding unchanged, it has to be incorporated as an Indian Company registered under the Companies Act 1956. iii) Limited Liability Partnership (LLPs)/ Limited Liability Companies (LLCs) are not eligible for participation. B. Financial Criteria i) Net worth: The net worth of the Bidder should be equal to or greater than the value calculated at the rate of Rs 1 Crore per MW (across all Locations bid for) Illustration:- A Bidder bids for following Locations :- Capacity Bids Offered(MW)

Location 1 10 Location 2 5 Location 3 8 Location 4 2 Location 5 1

Total Net worth requirement: (10 + 5 + 8 + 2 + 1 ) * 1 Cr = 26 Cr.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 22

SOLAR RFS BID DOCUMENT

Computation of net worth shall be based on unconsolidated audited annual accounts of the Company. The Company would thus be required to submit annual audited accounts comprising of aud ited balance sheet, profit and loss account, notes and cash flow statement for the FY 2011-12 and three years preceding it, along with certificate duly stamped and signed from a Statutory Auditor/Chartered Accountant to demonstrate eligibility criteria. In case of a foreign company, the company needs to submit annual account certificate from a Chartered Accountant or Statutory Auditor for the immediate previous accounting year. ii) For companies which are newly incorporated, the net worth criteria should be met on any date within seven days prior to the date of submission of RfS document by the Bidder. To demonstrate fulfillment of the criteria, the Bidder shall submit a certificate from a Chartered Accountant certifying the net worth on the date within seven days prior to submission of RfS. Further, the Bidder shall submit the unaudited financial statements of the Company for the date on which the certificate of Chartered Accountant has been obtained.

Note: For the qualification requirements, if data is provided by the Bidder in foreign currency, equivalent rupees of net worth will be calculated using bills selling exchange rates(card rates) INR of State Bank of India prevailing on the date of closing the accounts for the respective financial year or the date as applicable to newly incorporated companies as certified by the Bidder’s banker, and on the date for indicating the net worth as applicable as per the provisions of the RfS.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 23

SOLAR RFS BID DOCUMENT

Net Worth

=Paid-up Share Capital

Add: Free Reserves

Subtract: Revaluation Reserves

Subtract: Intangible Assets

Subtract: Miscellaneous Expenditures to the extent not written off and carry forward losses

Share premium will form an integral part of Net Worth provided it is realized in cash or cash equivalents.

Paid-up Share Capital will include:

a) Paid-up equity share capital and b) Fully, compulsorily and mandatorily convertible Preference shares and c) Fully, compulsorily and mandatorily convertible Debentures.

iii) For the purpose of meeting financial requirements, only unconsolidated audited accounts shall be used. However, audited consolidated annual accounts of the Bidder may be used for the purpose of financial requirements provided, the Bidder has at least twenty six per cent (26%) equity in each Company whose accounts are merged in the audited consolidated account and provided further that the financial capability of such Companies (of which accounts are being merged in the consolidated account) shall not be considered again for the purpose of evaluation of any bid.

iv) Existing companies

The computation of net worth shall be based on unconsolidated audited annual accounts of the company. The Bidder would be required

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 24

SOLAR RFS BID DOCUMENT

to submit annual audited accounts for the last four financial years viz 2008-09, 2009-10 and 2010-11, 2011-12. If the period of existence of the Company is less than four years, then annual audited accounts should be submitted starting from the year of incorporation. In case of a foreign company, the same for calendar years - 2009, 2010, 2011, 2012 or the accounting year as adopted by the company and acceptable as per laws of the respective Country should be submitted. Net worth of individuals/ Directors, Association of Persons, Partnerships Firms, section 25 companies of the Companies Act, 1956 etc., shall not be considered for computation of net worth of Bidders.

In case of existing Companies/ Consortiums, the net worth criteria shall be met as on day within seven days prior to the last date of submission of response to RfS by the Bidding Companies/ Consortium. To demonstrate fulfillment of the criteria, the Bidder shall submit a certificate from a Chartered Accountant certifying the availability of net worth on the date within seven days prior to submission of response to RfS along with a certified copy of audited Balance Sheet, Profit and Loss account, Schedules and Cash Flow Statement supported with Bank statements. All pages of the above financial documents should be signed and stamped by the concerned Chartered Accountant as token of their endorsement of the document as well as certification.

Net worth, bank statement and shareholding pattern indicating controlling shareholding should be submitted as on any date within 7 days prior to submission of the bid.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 25

SOLAR RFS BID DOCUMENT

Newly Incorporated Companies

For a newly incorporated Company relying solely on its credentials, where the annual accounts have not been prepared, the net worth criteria should be met on any day within seven days prior to the last date of submission of response to RfS by the Bidding Company/Consortium. To demonstrate fulfillment of the criteria, the Bidder shall submit a certificate from a Chartered Accountant certifying the availability of net worth on any day within 7 days prior to submission of response to RfS along with a certified copy of balance sheet, profit and loss account, schedules and cash flow statement supported with bank statements. All pages of the above financial documents should be signed and stamped by the concerned Chartered Accountant as token of their endorsement of the document as well as certification.

v) If the response to RfS is submitted by a Consortium the financial requirement shall be met collectively by all members in the Bidding Consortium. The financial requirement to be met by each member of the Consortium shall be computed to the equity commitment made by each of them in the Project Company. For computation of net worth of members methodology as provided under Para (i) above shall be followed. Any Consortium, if selected, shall, for the purpose of supply of power to DISCOMs of that area, incorporate a Project Company with equity participation by Members in line with Consortium agreement ( to be submitted along with RfS) before signing the PPA with DISCOM i.e. the Project Company incorporated shall have the same share holding pattern as given at the time of RfS. This shall not change till the signing of PPA.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 26

SOLAR RFS BID DOCUMENT

For newly incorporated Company the bidder may seek qualification on the basis of financial capability of Its Parent, Ultimate Parent and / or its Affiliate (s) for the purpose of meeting the qualification requirements.

Note:

i) Whether or not financial resources of Parents and/ or Affiliates(s) are relied upon to achieve the required net worth, the required net worth has to be infused in the Project Company before signing of PPA. The bank statement will also be required to be submitted before 7 days of signing of PPA.

For exhibiting shareholding pattern indicating the controlling shareholding a certificate from the Chartered Accountant should be submitted as on any date within 7 days prior to the date of submission of the bid document. ii) It is not necessary to have the Technology Partner at RfS stage. Further it is also not necessary for the Technology Partner to have an equity stake in the Bidding Company/ Consortium. iii) Net worth, bank statement and shareholding pattern indicating controlling shareholding should be submitted as on any date within 7 days prior to submission of the bid.

C) Technical Criteria

The Bidder shall deploy commercially established solar technologies. The Bidder is required to undertake to furnish evidence of meeting the above eligibility criteria. The undertaking shall be as per enclosed Format – 6.7. Detailed technical parameters for the project are given in Annexure 1. TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 27

SOLAR RFS BID DOCUMENT

D) Connectivity with Grid Substation

(I) The plant should be designed for interconnection with the distribution/ transmission network of DISCOM or APTRANSCO at voltage level of 33 kV or 132 kV. In this regard the Bidder shall submit Confirmation of Connectivity in Format 6.8 along with the RfS. Letter from concerned DISCOMs/ state transmission utility, confirming that the utility will provide connectivity to the proposed Solar Power Plant should be submitted within seven days prior to signing of the PPA.

(II) The responsibility of getting connectivity with the distribution/ transmission system will lie with the Developer. Transmission of power to the point of interconnection at substation of DISCOM/APTRANSCO where the metering is done shall be the responsibility of the Developer at its own cost. The installation of equipments for metering will be the responsibility of the Developer as per Central Electricity Authority (CEA) norms.

(III) The Interconnection Line from Project switchyard to the designated substation has to be constructed and maintained by the Developer at his cost. The entire cost of transmission including cost of construction of lines, metering equipment, losses, supervision charges etc., from the Project up to the Interconnection Point shall be borne by the Developer and shall not be reimbursed by DISCOM(s). Right of way (RoW) acquisition for laying of the interconnection lines shall lie with the Developer.

(IV) The accounting of energy delivered by the solar project at the Interconnection Point will be maintained by the STU/SLDC/ DISCOM.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 28

SOLAR RFS BID DOCUMENT

3.6 Short-listing of Bidders

Only those responses to RfS which are received by due date and time will be considered for evaluation. The responses will be evaluated based on the qualification requirements and all those responses meeting the qualification requirements shall be short listed.

3.7 Selection process of the Bidders: a) Selection of Bidders will be based on lowest quoted Tariff per unit of electricity. Bidders must bid for each of the Locations separately.

b) The Bidders will be required to submit Financial Bid in 6.12 quoting their Tariff up to four (4) decimal points for the entire tenure of the agreement.

c) After opening of the commercial bids, the Bidders will be listed in the order of their quoted Tariff as L1, L2, L3……………….Ln, and L1 Tariff will be finalized for each Location. Only L1 Bidder in each Location will be offered the project in that particular Location.

d) The Developer shall submit a Contract Performance Bank Guarantee (CPBG), if applicable, to the concerned DISCOM after intimation and before the issuance of LOI. e) In case any Developer does not communicate acceptance of the LoI within 10 days from the date of issue of the LoI (excluding the date of issue), then his EMD (Bid security) and CPBG will be forfeited. f) In the eventuality of a tie in the bidding process in a particular Location, all the Bidders quoting the lowest Tariff will be awarded the Project subject to maximum capacity per Location.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 29

SOLAR RFS BID DOCUMENT

In case the maximum capacity at the Location is exceeded, then the prorated capacity shall be awarded in the ratio of offered capacity by the Bidders subject to technical feasibility at the Interconnection Point of the substation. The decision of APTRANSCO/DISCOM shall be considered as final in this matter.

g) The capacity thus allocated to the Developer will be referred to as Contracted Capacity (“Contracted Capacity”).

3.8 Execution of Power Purchase Agreement

The PPA shall be executed between the Selected Bidder(s) and DISCOM(s) after acceptance of LOI by the Bidder. Power Purchase Agreement will be valid for tenure of 20 years from the date of scheduled COD or from actual COD in case of delay, subject to clause 3.20.

3.9 Purchase of Power

DISCOM, at any time during a contract year, will purchase electricity at the L1 Tariff from the Developer up to the ceiling CUF of 25%, beyond which electricity will be purchased at a flat rate of Rs 3 / (kWh) unit for the entire agreement period.

3.10 Submission of Response to RfS by the Bidder The response to RfS shall contain the following:

1. Bid submission shall be through e-procurement platform. Steps for E-Procurement: i) Bidder shall obtain digital signature from APTS (Phone Number: 040 23224283/ 0305). ii) Using the digital signature, bidder shall register himself on the AP procurement website (URL: https://tender.eprocurement.gov.in).

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 30

SOLAR RFS BID DOCUMENT

iii) After successful registration, Bidder shall send a mail confirming the registration details to Vayam Technologies at: [email protected]. iv) The user ID created by the Bidder in the previous step will be validated by Vayam Technologies after which the Bidder can upload the bid documents using the user ID created on the e-procurement website. 2. Covering letter as per Format 6.1. 3. In case of a Bidding Consortium, Power of Attorney in favor of the Lead Member issued by other Members of the Consortium shall be provided in original as per format 6.2. In the event of any Member of the Bidding Consortium (other than Lead Member) is a foreign entity; it may submit Board Resolutions in place of Power of Attorney for the purpose of fulfilling the requirements under this Clause. Provided that such Board Resolution shall be supported under this unqualified opinion issued by the legal counsel of such foreign entity stating that the Board Resolutions are in compliance with the applicable laws of respective jurisdiction of the issuing Company and the authorizations granted therein are true and valid. 4. Bidders are required to submit their RfS document along with a non- refundable processing fee

I. Processing fee as per 3.2 (b) in the form of DD or online payment through RTGS. Insufficient processing fee paid by the bidder through RTGS or DD is liable for rejection of bids and the scanned copies of DD should be uploaded. DD in original containing the Bidders name (on the cover and backside of the DD, if applicable) - are to be submitted in a sealed cover before the due date as mentioned to the above address.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 31

SOLAR RFS BID DOCUMENT

EMD (Bid security) as per 3.2(c) in the form of BG (as per Format 6.14) shall be uploaded in the bid. Insufficient bid security and insufficient validity (120 days) is liable for rejection of the bids. 5. CPBG as per the format 6.13. 6. Performance Bank Guarantee to be submitted at the time of signing of PPA in form of Bank Guarantee as per Format 6.3. 7. Board Resolutions, as per prescribed formats enclosed as Format 6.4 duly certified by the Company Secretary or the Director of the relevant Bidder, as applicable to the Bidder and mentioned hereunder:

a. Board resolution from the Bidding Company or the Lead Member of the Consortium, as the case may be in favor of the person signing the response to RfS: b. Board Resolution from the Bidding Company committing one hundred per cent (100%) of the equity requirement for the Project / Board Resolutions from each of the Consortium Members together in aggregate committing to one hundred per cent (100%) of equity requirement for the Project (in case of Bidding Consortium); and c. Board Resolutions from Parent and / or Affiliate (whose credentials were used it the response to RfS), of the Bidding Company / any Member of the Bidding Consortium, undertaking to invest the entire amount as committed by Bidding Company / Member of the Bidding Consortium, in event of failure of the same to make such investment. 8. In case of a Consortium, the Consortium agreement between the Members in the Consortium as per Format 6.5 along with Board resolution from each Member of the Consortium for participating in consortium; 9. Format for financial requirement as per Format 6.6 as applicable;

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 32

SOLAR RFS BID DOCUMENT

10. Format for Technical Criteria wherein Bidder shall certify that the technology to be adopted shall be commercially established technology. Final details of the same shall be submitted within 210 days of signing of PPA as per Format 6.7.

11. A letter from the Bidder confirming connectivity of the Project as per Format 6.8.

12. A disclosure statement as per Format 6.9 regarding participation of any related companies in this bidding process.

13. Declaration by the Bidding Company / Lead Member of Bidding Consortium for the Proposed Technology Tie Up as per Format 6.10.

14. Checklist for Bank Guarantee as per Appendix- A;

15. Submission of Summary Data Sheet as per Format-6.11.

16. Technical bid provision made for 161 locations and its associated injections points. Bidder has to choose locations at his choice and has to mention the capacity against the injection points.

17. Price bid provision made for 161 locations and its associated injections points. Bidder has to quote INR/kwh against the same chosen injection point in technical bid.

18. Memorandum and Articles of Association (highlighting relevant provision of Power / Energy/Renewable Energy/ Solar Power Plant development), Certificate of Incorporation (if applicable) of Bidding Company / all Member companies of Bidding Consortium along with shareholders rights and obligations as certified by Chartered Accountant.

19. In addition to the price bid, the Bidder has to submit Format 6.12.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 33

SOLAR RFS BID DOCUMENT

3.11 The Bidder should note that:

a. The Bidder may be short listed based on the declarations made by it in relevant schedules of the RfS. b. If the Bidder/ Member in a Bidding Consortium conceals or does not submit any information, any document, bank guarantee, or any material information or makes a wrong statement or misrepresents facts or makes a misleading statement in its response to RfS, in any manner whatsoever, APTRANSCO reserves the right to reject such response to RfS and/or cancel the Letter of Intent, if issued and in such event the Bank Guarantee provided up to the stage shall be encashed. c. If the event specified at (a) is discovered after the effective date i.e. date of signing the PPA, consequences specified at (b) above shall apply. d. Response submitted by the Bidder shall become the property of APTRANSCO who shall have no obligation to return the same to the Bidder. e. All pages of the response to RfS submitted must be signed and stamped by authorized by the board as per Format 6.4, on behalf of the Bidder as a token of unconditional acceptance of all terms and conditions mentioned in the bid document. f. The response to RfS shall be submitted as mentioned in clause 3.13. No change or supplemental information to a response to RfS will be accepted after the scheduled date and time of submission of response to RfS. APTRANSCO reserves the right to seek additional information from Bidders, if found necessary, during the course of evaluation of the response to RfS.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 34

SOLAR RFS BID DOCUMENT

g. All the information should be submitted in English language only. h. All fees and charges should be deposited as specified for each under this RfS document only. No other mode of payment will be accepted. i. Bidder shall mention the name of the contact person and complete address of the Bidder in the covering letter. j. Response to RfS that are incomplete, which do not substantially meet the requirements prescribed in this RfS, will be liable for rejection by APTRANSCO. k. Response to RfS not submitted in the specified formats will be liable for rejection by APTRANSCO. l. Bidders not submitting any additional information or clarifications as sought by APTRANSCO/DISCOM on or before the dates stipulated by the respective organizations will be liable for rejection by APTRANSCO. m. It is the responsibility of the Bidder /Developer to comply with all the criteria and terms and conditions of the RfS, and for which APTRANSCO will not be responsible in any case. Non submission and /or submission of incomplete data / information required under the provisions of RfS shall not be construed as waiver on the part of APTRANSCO of the obligation of the Bidder to furnish the said date/information unless such waiver is given in writing. n. If necessary, after issue of LoI or at any point of time APTRANSCO reserves the right to seek additional information or documents as per the requirement of RfS. No n submission of any relevant information or relevant document or Bank Guarantee will lead to rejection of the LoI even after issue of the same. Under any circumstance, non fulfillment of any criteria and any terms and conditions under the RfS, APTRANSCO reserves the right to cancel the LoI and such decision

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 35

SOLAR RFS BID DOCUMENT

of APTRANSCO will be final and binding. o. All the Bidders are advised to visit the website of APTRANSCO before submitting the Bid. p. Only High Court of Andhra Pradesh shall have exclusive jurisdiction in all matters pertaining to this RfS document.

3.12 Due Date The bid submission and delivery of bids is as indicated at Time Schedules at 3.23.

3.13 Method of Submission

The bidder shall submit the RfS in the e-procurement platform.

3.14 Validity of the Response to RfS

The Bidder shall submit the response to RfS which shall remain valid for 120 days from the date of Bid submission.

3.15 Preparation Cost

The Bidder shall be responsible for all costs associated with the preparation of the response to RfS and participation in discussions and attending pre-bid meeting(s), etc. APTRANSCO shall not be responsible in any way for such costs, regardless of the conduct or outcome of the bid process. 3.16 Right of APTRANSCO/DISCOM to reject

APTRANSCO/DISCOM reserves the right to reject all or any of the responses to RfS, including L1 bid at any Location, or cancel the RfS without assigning any reasons whatsoever and without any liability incurred.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 36

SOLAR RFS BID DOCUMENT

3.17 Bank Guarantees

The Developer shall provide the following Bank Guarantees and Demand Drafts from any of the Banks listed in Annexure 2, to APTRANSCO as detailed hereunder:

1) Performance Bank Guarantee to be provided to APTRANSCO at the time of signing of PPA as per Format – 6.3 valid for a period of 22 months from the date of submission.

Bank Guarantees issued by foreign banks outside India from bank list given in Annexure – 2 is to be endorsed by the Indian Branch of the same bank or State Bank of India.

Performance Bank Guarantee would be required to be submitted in the form of Bank Guarantee (BG) at the time of signing of PPA and the Performance Bank Guarantee shall be submitted in three numbers of Bank Guarantee in the amounts of Rs. 2 Lakhs/MW,Rs 3 Lakhs/MW and Rs 5 Lakhs/MW to DISCOMs, at the time of signing of PPA with DISCOMs. In case, the Selected Bidder is unable to execute the project within the stipulated time period as specified in the RfS, the Performance Bank Guarantees shall be encashed by DISCOMs as specified in Clause 3.20.

The Performance Bank Guarantees have to be executed on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution. The Performance Bank Guarantees have to be in the name of the Bidding Company or in the

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 37

SOLAR RFS BID DOCUMENT

name of Lead Member in case of a Bidding Consortium. In order to facilitate the Developers to submit the Bank Guarantee as per the prescribed Format 6.3 and in line with the requirements, checklist at Appendix A has been attached. Developers are advised to take note of the above checklist while submitting the Bank Guarantees. 2) Contract Performance Bank Guarantee (CPBG) to APTRANSCO, if applicable, before issuance of LoI as per Format – 6.13 valid for a period of 3 years from the date of submission. DISCOM reserves the right to encash the CPBG in case of non-fulfillment.

3.18 a) Monitoring and Supervision Fee: The Developers are not required to pay such fee in setting up of solar power plants under this RfS to APTRANSCO/DISCOMs. However, the Developer has to pay all relevant charges according to procedures of APTRANSCO/DISCOM for evacuation. b) Operation and Maintenance of the solar plant and its connected lines during PPA period (20 years) is the responsibility of the Developer.

3.19 Financial closure or Project Financing Arrangements:

The Developer shall report tie-up of Financing Arrangements for the project within 180 days from the date of signing of PPA. In case the Developer does not achieve the financial closure within the stipulated time period, DISCOM reserves the right to encash the BG and to terminate the PPA without any intimation. 3.20 Penalties:

3.20.1 Under normal circumstances the Project has to be commissioned within 12 months from the date of signing of this Agreement. In case the

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 38

SOLAR RFS BID DOCUMENT

Developer fails to achieve this milestone, DISCOM shall encash the Performance Bank Guarantee in the following manner.

a) Delay up to one month from scheduled COD: 2 lakhs/MW of capacity not commissioned. b) Delay of more than one month up to two months from scheduled COD: 3 lakhs/MW of capacity not commissioned. c) Delay of more than two months up to four months from scheduled COD: 5 lakhs/MW of capacity not commissioned. d) Delay of more than 4 months: · In case of part commissioning, the Agreement shall be amended to reflect the capacity that has been commissioned · Else, the Agreement stands terminated for unfulfilled obligation. CPBG will be returned on COD. If commissioning doesn’t happen within 15 months of signing this Agreement, the CPBG will be encashed.

3.21 Submissions to be made by Developer

During the installation and commissioning process, the Developer will be required to submit the following documents (Hard and Softcopy on the letter head of the Developer and stamped by the Developer) to APTRANSCO/DISCOM in a timely manner, at least one month before the commissioning.

(a) Sl. No. of all modules. (b) I -V Curve including wattage of each module. (c) PV/STP model Testing Reports of Solar equipments Generator, (as per Annexure-I) (d) Warranty as per Annexure -I (e) Identification and Traceability (as per Annexure-I) (f) Certificate of quality of module (as per Annexure-I)

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 39

SOLAR RFS BID DOCUMENT

(g) All technical details of Inverter, SCADA System, Wires, Cables, including all peripherals (h) Protection devices (lightning arrester, earthing, etc.) and their specifications.technical (i) Protection devices for the safety of Grid at the time of connectivity, and their Technical Specifications. (j) Copy of the bills of module, balance of system, and all other equipment like generators etc. (k) Commissioning Report from DISCOMs, APTRANSCO.

(l) Any other information as per RfS.

3.22 Incentive in case of expedited commissioning:

The Solar Power Developer will be paid an incentive by DISCOM for early commissioning. The incentive will be paid as follows:

i. Commissioning between 30 and 59 days before Scheduled COD: Rs 1 lakh/MW of capacity commissioned. ii. Commissioning between 60 and 89 days before Scheduled COD: Rs 2 lakh/MW of capacity commissioned. iii. Commissioning before 90 days of the Scheduled COD: Rs 3 lakh/MW of capacity commissioned.

3.23 Time Schedules

Event Date

1 Submission of response to RfS Till 07/02/2013 at 3 pm with relevant documents.

2 Opening of technical bid 08/02/2013 at 3 pm

3 Opening of financial bid After evaluation of technical bid.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 40

SOLAR RFS BID DOCUMENT

4 Evaluation and Short-listing 15 days after opening of financial bids of Bidders,

5 Issue of letter of intent Within 7 days from shortlisting of Bidders

6 Communication of acceptance Within 10 days from the date of issue of of LoI by successful bidder LoI excluding the date of issue.

7 Signing of PPA Within 30 days from the date of issue of letter of intent.

Financial closure / Financing Submission of financial closure 8 Arrangement for the project documents 210 days from the date of signing of PPA.

Commissioning of the Project The plant has to be commissioned within 9 12 months from the date of signing of the PPA.

NOTE (1) All the above are to be adhered to strictly as per the requirements under the RfS. (2) For the purpose of determination of dates, the date of issue of the letter will be excluded. However, the decision of APTRANSCO/DISCOMs will be final in this regard and the Bidder has to duly comply with it.

3.24. In the event of any conflict of interpretation in terms and conditions between RfS document and the clarifications issued under this RfS or in case of any ambiguity, the provisions of these RfS guidelines would prevail.

3.25. Check list for submission of documents after issue of LOI.

i. Bank statement, shareholding pattern, Profit & Loss Account, and net worth (Certified by CA).

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 41

SOLAR RFS BID DOCUMENT

ii. Net worth infusion for newly incorporated company (Certified by CA). iii. Controlling shareholding details for the company (Certified by CA). iv. Any other document as per RfS. 3.26 Check list for submission of documents before signing of PPA.

(i) Bank Statement, shareholding pattern, profit & loss Account, and net worth certified by CA). (ii) Net worth infusion for newly incorporated company (certified by CA). (iii) Controlling shareholding details for the company (certified by CA). (iv) Certificate from Transmission Utility (v) Bank Guarantee as per Format 6.3. (vi) Any other document as per RfS. 3.27 Check list for submission of document after signing of PPA.

i. Financial closure or financing arrangements ii. Technology undertaking as per format 6.7. iii. Submission of details about the following (Hard and Softcopy on the letter head of the Developer and stamped by the Developer): (a) Sl. No. of all modules/Turbines/Generators/Heat collecting devices etc. (b) I-V Curve including wattage of each module. (c) Testing Report of plant equipment (as per Annexure-I) (d) Warranty as per Annexure -I. (e) Identification and Traceability (as per Annexure-I)

(f) Certificate of quality of all equipment (as per Annexure - I)

(g) All technical details of Inverter, SCADA System, Wires, Cables, including all peripherals of generators, turbines etc.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 42

SOLAR RFS BID DOCUMENT

(h) Protection devices (lightening arrester, earthling, etc.) and their technical specifications. (i) Protection devices for the safety of Grid at the time of connectivity, and their Technical Specifications. (j) Copy of the bills of solar equipment, balance of system, and all other items. (k) Commissioning Report from DISCOMs/ APTRANSCO. (l) Any other information as per RfS.

Note: All the above are to be submitted as per the provisions in this RfS.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 43

SOLAR RFS BID DOCUMENT

Section 4

Evaluation Criteria

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 44

SOLAR RFS BID DOCUMENT

Section 4

4.0 Evaluation Criteria

4.1 The evaluation process comprises of the following two steps: Step I- Responsiveness check Step II – Technical bid evaluation Step III-Price bid evaluation.

4.2 Step I- Responsiveness check

The response to RfS submitted by the Bidder shall be scrutinized to establish “Responsiveness”. Each Bidder’s response to RfS shall be checked for compliance with the submission of requirements set forth in this RfS. Any of the following conditions shall cause the bid to be “Non- responsive”: a. Response to RfS submitted by a Bidding Consortium not including the Consortium Agreement b. Response to RfS having conflict of interest. c. Non submission of processing fee or EMD in acceptable format along with RfS document. d. Non submission of documents as per the Annexure 3. e. Non-submission of all relevant documents related to Net Worth, Shareholding, Lead Member etc. as required in this RfS document. f. Non submission of Memorandum and Articles of Association (highlighting relevant provision of Power / Energy / Renewable Energy/ Solar Power Plant development), Certificate of Incorporation (if applicable) of Bidding Company / all Member companies of Bidding Consortium along with shareholders rights and obligations as certified by Chartered Accountant. g. Submission of Tariff bid in Format 6.12 h. Non-submission of RfS document duly signed and stamped on every page. i. Submission of financial documents without the signature of the Chartered Accountant on all pages of the same. j. If the bid and other documents are submitted in language other

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 45

SOLAR RFS BID DOCUMENT

than English. Note: Non responsive bids will not be considered for step II bid evaluation. 4.3 Step II-Technical Bid (6.11A) evaluation The bid evaluation will be carried out as per section 6.1 to 6.11- formats and technical bid and Format for RTGS. Bidder can upload either DD or ‘Format for RTGS’ for processing fee.

4.4. Step III -Financial bid The financial bid will be evaluated as per Price Bid 6.12, only for those who qualify in the technical bid.

Evaluation of price bid is based on lowest quoted price for any of the injection point with respect to its location as indicated in the Price Bid i.e. the Bidder’s quoted price at 33kV SS or 132kV SS, both will be referred to the respective location as indicated in the Price Bid.

APTRANSCO/DISCOM reserves the right to reject all or any of the responses to RfS, including L1 bid at any Location, or cancel the RfS without assigning any reasons whatsoever and without any liability incurred to DISCOMs/APTRANSCO.

Bidder can quote their price up to four (4) decimal points only for the entire tenure of the agreement.

Note: The bidder has to choose same injection points both in Technical bid and Price bid. Failing which, the bid is liable for rejection.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 46

SOLAR RFS BID DOCUMENT

Section 5

OTHER PROVISIONS

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 47

SOLAR RFS BID DOCUMENT

Section 5

5.0 Other Provisions

5.1 Role of the State Level Agencies

APTRANSCO/DISCOM has no obligation to recommend any department to grant permissions /sanctions by the Solar Power Projects.

5.2 Role of Carbon Financing Project Developers are encouraged to identify the potential role of carbon finance in their investment analysis including: i. The expected revenues for emission reductions; and ii. The cost of power with and without carbon revenues and iii. Sharing the carbon credits as per PPA.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 48

SOLAR RFS BID DOCUMENT

Section 6

FORMATS FOR BID SUBMISSION

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 49

SOLAR RFS BID DOCUMENT

Format 6.1 -Format of Covering Letter

(The covering letter should be on the Letter Head of the Bidding Company/ Lead Member of the Bidding Consortium)

Date: From: (insert name and address of Bidding Company/ Lead Member of the Bidding Consortium) Tel. #: Fax#: E-mail address#

To

The Chief Engineer/IPC, APPCC, Vidyut Soudha, Hyderabad

Sub: Response to RfS dated for development of _____MW Solar Project

Dear Sir,

We, the undersigned ……. [insert name of the ‘Bidder’] having read, examined and understood in detail the RfS including Qualification Requirements in particular and PPA for supply of power for 20 years to DISCOMs, hereby submit our response to RfS for setting up __ MW solar power plant in Andhra Pradesh.

We confirm that neither we nor any of our Parent Company/ Affiliate/ Group Company has submitted response to RfS other than this response to RfS, directly or indirectly, in response to the aforesaid RfS.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 50

SOLAR RFS BID DOCUMENT

1. We give our unconditional acceptance to the RfS, dated …………….and PPA attached thereto, issued by the APTRANSCO. In token of our unconditional acceptance to the RfS & PPA, the same have been initialed and stamped by us on all pages and enclosed with the response to RfS. We shall ensure that the PPA is executed as per the provisions of the RfS and provisions of PPA shall be binding on us. Further, we confirm that the Project shall be commissioned within 12 months of the date of signing of PPA.

2. Earnest Money Deposit (Bid security) : -

We have enclosed bank guarantee …………. [Insert bank guarantee reference] towards EMD of Rs.______(Insert Amount), dated ………. [Insert date of BG] from ………… [Insert name of bank providing bank guarantee]

3. We have submitted our response to RfS strictly as per Section – 6 (Formats) of this RfS, without any deviations, conditions and without mentioning any assumptions or notes in the said Formats.

4. Acceptance

We hereby unconditionally and irrevocably agree and accept that the decision made by the APTRANSCO in respect of any matter regarding or arising out of the RfS shall be binding on us. We hereby expressly waive any and all claims in respect of this process.

5. Familiarity with Relevant Indian Laws & Regulations

We confirm that we have studied the provisions of the relevant Indian laws and regulations as required to enable us to submit this response to RfS and execute the PPA, in the event of our selection as Successful Bidder.

6. We are enclosing herewith our response to the RfS with formats duly signed as desired by you in the RfS for your consideration.

7. It is confirmed that our response to the RfS is consistent with all the requirements of submission as stated in the RfS and subsequent communications from the APTRANSCO. TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 51

SOLAR RFS BID DOCUMENT

8. The information submitted in our response to the RfS is correct to the best of our knowledge and understanding. We would be solely responsible for any errors or omissions in our response to the RfS.

9. Contact Person

Details of the contact person are furnished as under: Name: …………………………………….

Designation: ……………………………………….. Company : ……………….

Address : …………………………………….

Phone Nos. : ………………………………………. Fax Nos. :………………………….

E-mail address: …………………………………………..

Dated the day of , 20…

Thanking you,

Yours faithfully,

(Name, Designation and Signature of Person Authorized by the board as per Clause 3.10 (5) (a))

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 52

SOLAR RFS BID DOCUMENT

Format 6.2 –Format for Power of Attorney to be provided by each of the other Members of the Consortium in favor of the Lead Member POWER OF ATTORNEY

(To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution.)

KNOW ALL MEN BY THESE PRESENTS THAT …………….……………. [Name of the Consortium Member company] having its registered office at…………..….…..,………..…and …….…………………….…. [Name of the Consortium Member company] having its registere d office at ………………………………….. , (Insert names and registered offices of all Members of the Consortium) the Members of Consortium have formed a Bidding Consortium named …………. (Insert name of the Consortium if finalized) (Hereinafter called the ‘Consortium’) vide Consortium Agreement dated………..……………….. (copy enclosed) and having agreed to appoint ……………………………..…[Name & Address of the Lead Member Company] as the Lead Member of the said Consortium do hereby constitute, nominate and appoint M/s…………….…………..a company incorporated under the laws of ……….………and having its Registered /Head Office at ……………………..……….as our duly constituted lawful Attorney (hereinafter called as Lead Member) to exercise all or any of the powers for and on behalf of the Consortium in regard to submission of the response to RfS and if required. We also authorize the said Lead Member to undertake the following acts:

i) To submit on behalf of Consortium Members response to RfS and if required, to Sign PPA.

ii) To do any other acts or submit any information and documents related to the above response to RfS.

It is expressly understood that in the event of the Consortium being selected as Successful Bidder, this Power of Attorney shall remain valid, binding and irrevocable until the Bidding Consortium achieves execution of PPA.

We as the Member of the Consortium agree and undertake to ratify and confirm all whatsoever the said Attorney/Lead Member has done on behalf of the Consortium Members pursuant to this Power of Attorney and the same shall bind us and deemed to have been done by us.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 53

SOLAR RFS BID DOCUMENT

IN WITNESS WHEREOF …………………………………………..…….[Name of Member consortium Company], as the Member of the Consortium have executed these presents on this……….. day of ...... under the Common Seal of our company.

For and on behalf of Consortium Member

M/s………………………….

------

(Signature of person authorized by the board)

(Name Designation Place: Date:)

Accepted

------

(Signature, Name, Designation and Address

of the person authorized by the board of the Lead Member)

Attested

------

(Signature of the executant)

------

(Signature & stamp of Notary of the place of execution)

Place:------

Date:------

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 54

SOLAR RFS BID DOCUMENT

Format 6.3 – Format for Performance Bank Guarantee

(Note: - Total Performance Bank Guarantee is to be submitted in three separate Bank Guarantees, viz, Rs. 2 lakhs/MW, Rs.3 lakhs/MW, Rs. 5 lakhs/MW).

(To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution.)

In consideration of the ------[Insert name of the Bidder] (hereinafter referred to as selected Solar Power Developer') submitting the response to RfS, inter-alia, for selection of the project of the capacity of ______MW, at …………[Insert name of the place], for supply of power there from on long term basis, in response to the RfS dated ………….issued by APTRANSCO/DISCOM and considering such response to the RfS of ………[insert the name of the selected Solar Power Developer] (which expression shall unless repugnant to the context or meaning thereof include its executers, administrators, successors and assignees) and selecting the Solar Power Project of the Developer and issuing Letter of Intent No ------to (Insert Name of selected Solar Power Developer) as per terms of RfS and the same having been accepted by the selected SPD resulting in a Power Purchase Agreement (PPA) to be entered into, for purchase of Power [from selected Solar Power Developer or a Project Company, M/s ------{a Special Purpose Vehicle (SPV) formed for this purpose}, if applicable ]. As per the terms of the RfS, the [insert name & address of bank] hereby agrees unequivocally, irrevocably and unconditionally to pay to APTRANSCO/ DISCOM at [Insert Name of the Place from the address of the APTRANSCO/DISCOM ] forthwith on demand in writing from APTRANSCO/ DISCOM or any Officer authorized by it in this behalf, any amount up to and not exceeding Rupees------[Total Value] only, on behalf of M/s [Insert name of the selected Solar Power Developer / Project Company]

This guarantee shall be valid and binding on this Bank up to and including ______and shall not be terminable by notice or any change in the constitution of the Bank or the term of contract or by any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any extension of time or variations or alternations made, given, or agreed with or without our knowledge or consent, by or between parties to the respective agreement.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 55

SOLAR RFS BID DOCUMENT

Our liability under this Guarantee is restricted to Rs. (Rs. only). Our Guarantee shall remain in force until _[Insert date] APTRANSCO/ DISCOM shall be entitled to invoke this Guarantee till [Insert date].

The Guarantor Bank hereby agrees and acknowledges that the APTRANSCO/ DISCOM shall have a right to invoke this PERFORMANCE BANK GUARANTEE in part or in full, as it may deem fit.

The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the written demand by APTRANSCO/ DISCOM, made in any format, raised at the above mentioned address of the Guarantor Bank, in order to make the said payment to APTRANSCO/ DISCOM

The Guarantor Bank shall make payment hereunder on first demand without restriction or conditions and notwithstanding any objection by ------[Insert name of the selected Solar Power Developer / Project Company as applicable] and/or any other person. The Guarantor Bank shall not require APTRANSCO/ DISCOM to justify the invocation of this PERFORMANCE BANK GUARANTEE, nor shall the Guarantor Bank have any recourse against APTRANSCO/ DISCOM in respect of any payment made hereunder

This PERFORMANCE BANK GUARANTEE shall be interpreted in accordance with the laws of India and the courts at Andhra Pradesh shall have exclusive jurisdiction.

The Guarantor Bank represents that this PERFORMANCE BANK GUARANTEE has been established in such form and with such content that it is fully enforceable in accordance with its terms as against the Guarantor Bank in the manner provided herein.

This PERFORMANCE BANK GUARANTEE shall not be affected in any manner by reason of merger, amalgamation, restructuring or any other change in the constitution of the Guarantor Bank.

This PERFORMANCE BANK GUARANTEE shall be a primary obligation of the Guarantor Bank and accordingly APTRANSCO/ DISCOM shall not be obliged before enforcing this PERFORMANCE BANK GUARANTEE to take any action in any court or arbitral proceedings against the selected Solar Power Developer / Project Company, to make any claim against or any demand on the selected Solar Power Developer / Project Company or to give any notice to the selected Solar Power Developer / Project Company or to enforce any

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 56

SOLAR RFS BID DOCUMENT

security held by APTRANSCO/ DISCOM or to exercise, levy or enforce any distress, diligence or other process against the selected Solar Power Developer / Project Company .

The Guarantor Bank acknowledges that this PERFORMANCE BANK GUARANTEE is not personal to APTRANSCO/ DISCOM and may be assigned, in whole or in part, (whether absolutely or by way of security) by APTRANSCO/ DISCOM to any entity to whom APTRANSCO/ DISCOM is entitled to assign its rights and obligations under the PPA.

Notwithstanding anything contained hereinabove, our liability under this Guarantee is restricted to Rs. ______(Rupees ______only) and it shall remain in force until with an additional claim period of thirty (30) days thereafter. We are liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only if APTRANSCO/ DISCOM serves upon us a written claim or demand.

Signature

Name

Power of Attorney No. For [Insert Na me of the Bank]

Banker's Stamp and Full Address.

Dated this day of , 20 Witness: 1. ……………………………………. Signature Name and Address 2. …………………………………..

Signature Name and Address

Notes: The Stamp Paper should be in the name of the Executing Bank. The Performance Bank Guarantee shall be executed by any of the Bank from the List of Banks enclosed in Annexure 2.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 57

SOLAR RFS BID DOCUMENT

Format 6.4 - Format for Board Resolutions

(Format for the Board resolution to be passed)

The Board, after discussion, at the duly convened Meeting on ………… (Insert date), with the consent of all the Directors present and in compliance of the provisions of the Companies Act, 1956, passed the following Resolution: 1. RESOLVED THAT Mr/Ms………………., be and is hereby authorized to do on our behalf, all such acts, deeds and things necessary in connection with or incidental to our response to RfS for setting up ______MW solar power plant in AP , including signing and submission of all documents and providing information / response to RfS to APTRANSCO, representing us in all matters before APTRANSCO, and generally dealing with APTRANSCO in all matters in connection with our bid for the said Project. (To be provided by the Bidding Company or the Lead Member of the Consortium) 2. FURTHER RESOLVED THAT pursuant to the provisions of the Companies Act, 1956 and compliance thereof and as permitted under the Memorandum and Articles of Association of the company, approval of the Board be and is hereby accorded to invest total equity in the Project. (To be provided by the Bidding Company)

[Note: In the event the Bidder is a Bidding Consortium, in place of the above resolution at Sl. No. 2, the following resolutions are to be provided]

FURTHER RESOLVED THAT pursuant to the provisions of the Companies Act, 1956 and compliance thereof and as permitted under the Memorandum and Articles of Association of the company, approval of the Board be and is hereby accorded to invest (- ----%) equity [Insert the % equity commitment as specified in Consortium Agreement] in the Project. (To be provided by the each Member of the Bidding Consortium including Lead Member such that total equity commitment is 100%)

FURTHER RESOLVED THAT approval of the Board be and is hereby accorded to participate in consortium with ------[Insert the name of other Members in the Consortium] and Mr/Ms………………., be and is hereby authorized to execute the Consortium Agreement. (To be provided by the

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 58

SOLAR RFS BID DOCUMENT

each Member of the Bidding Consortium including Lead Member) And

FURTHER RESOLVED THAT approval of the Board be and is hereby accorded to contribute such additional amount over and above the percentage limit (specified for the Lead Member and other Member in the Consortium Agreement) to the extent becoming necessary towards the total equity share in the Project Company, obligatory on the part of the Consortium pursuant to the terms and conditions contained in the Consortium Agreement dated …………… executed by the Consortium as per the provisions of the RfS. [To be passed by the Lead Member and other Members of the Bidding Consortium]

3. FURTHER RESOLVED THAT approval of the Board be and is hereby accorded to M/s. ………. (Insert name of Bidding Company/ Consortium Member(s)) to use our financial capability for meeting the Qualification Requirements for setting up a __ MW solar power plant in AP and confirm that all the equity investment obligations of M/s……. (Insert Name of Bidding Company/ Consortium Member(s)), shall be deemed to be our equity investment obligations and in the event of any default the same shall be met by us. [To be passed by the entity(s) whose financial credentials have been used i.e. Parent and / or its affiliate.]

Certified true copy

------(Signature, Name and stamp of Company Secretary / Director)

Notes:

1) This certified true copy should be submitted on the letterhead of the Company, signed by the Company Secretary / Director. 2) The contents of the format may be suitably re-worded indicating the identity of the entity passing the resolution. 3) This format may be modified only to the limited extent required to comply with the local regulations and laws applicable to a foreign entity submitting this resolution. For example, reference to Companies Act 1956 may be suitably modified to refer to the laws applicable to the entity submitting the resolution. However, in such case, the foreign entity shall submit an unqualified opinion issued by the legal counsel of such foreign entity, stating that the Board resolutions are in compliance with the applicable laws of the respective jurisdictions of the issuing company and the authorizations granted therein are tr ue and valid.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 59

SOLAR RFS BID DOCUMENT

Format 6.5 – Consortium Agreement (To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution)

THIS Consortium Agreement (“Agreement”) executed on this day of Two thousand between M/s [insert name of Lead Member]a Company incorporated under the laws of and having its Registered Office at (hereinafter called the “Member-1”, which expression shall include its successors, executors and permitted assigns) and M/s Company incorporated under the laws of and having its Registered Office at (hereina fter called the “Member-2”, which expression shall include its successors, executors and permitted assigns), M/s a Company incorporated under the laws of and having its Registered Office at (hereinafter called the “Member-n”, which expression shall include its successors, executors and permitted assigns), [The Bidding Consortium should list the details of all the Consortium Members] for the purpose of submitting response to RfS, and execution of Power Purchase Agreement (in case of award), against RfS dated ……………

WHEREAS, each Member individually shall be referred to as the “Member” and all of the Members shall be collectively referred to as the “Members” in this Agreement.

WHEREAS the DISCOMs desires to purchase power under Renewable Power Purchase obligation, Regulation 2012;

WHEREAS, the APTRANSCO had invited response to RfS vide its Request for Selection (RfS) dated

WHEREAS the RfS stipulates that in case response to RfS is being submitted by a Bidding Consortium, the Members of the Consortium will have to submit a legally enforceable Consortium Agreement in a format specified by APTRANSCO wherein the Consortium Members have to commit equity investment of a specific percentage for the Project.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 60

SOLAR RFS BID DOCUMENT

NOW THEREFORE, THIS AGREEMENT WITNESS AS UNDER:

In consideration of the above premises and agreements all the Members in this Bidding Consortium do hereby mutually agree as follows:

1. We, the Members of the Consortium and Members to the Agreement do hereby unequivocally agree that Member-1 (M/s ), shall act as the Lead Member as defined in the RfS for self and agent for and on behalf of Member-2, -----, Member-n.

2. The Lead Member is hereby authorized by the Members of the Consortium and Members to the Agreement to bind the Consortium and receive instructions for and on their behalf.

3. Notwithstanding anything contrary contained in this Agreement, the Lead Member shall always be liable for the equity (as well as total financing if committed to be met from internal financing) investment obligations of all the Consortium Members i.e. for both its own liability as well as the liability of other Members.

4. The Lead Member shall be liable and responsible for ensuring the individual and collective commitment of each of the Members of the Consortium in discharging all of their respective equity as well as other financing if committed to be met internally obligations. Each Member further undertakes to be individually liable for the performance of its part of the obligations without in any way limiting the scope of collective liability envisaged in this Agreement.

5. Subject to the terms of this Agreement, the share of each Member of the Consortium in the issued equity share capital of the project Company is/shall be in the following proportion:

Name Percentage Member 1 --- Member 2 --- Member n --- Total 100%

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 61

SOLAR RFS BID DOCUMENT

6. The Lead Member, on behalf of the Consortium, shall inter alia undertake full responsibility for liaising with Lenders or through internal accruals and mobilizing debt resources for the Project, and ensuring that the Seller achieves Financial Closure in terms of the PPA.

7. In case of any breach of any equity investment as well as other financing requirements commitment by any of the Consortium Members, the Lead Member shall be liable for the consequences thereof.

8. Except as specified in the Agreement, it is agreed that sharing of responsibilities as aforesaid and equity investment obligations thereto shall not in any way be a limitation of responsibility of the Lead Member under these presents.

9. It is further specifically agreed that the financial liability for equity contribution of the Lead Member shall not be limited in any way so as to restrict or limit its liabilities. The Lead Member shall be liable irrespective of its scope of work or financial commitments.

10. This Agreement shall be construed and interpreted in accordance with the Laws of India and courts in India alone shall have the exclusive jurisdiction in all matters relating thereto and arising thereunder.

11. It is hereby further agreed that in case of being selected as the Successful Bidder, the Members do hereby agree that they shall furnish the Performance Guarantee in favor of APTRANSCO in terms of the RfS.

12. It is further expressly agreed that the Agreement shall be irrevocable and shall form an integral part of the Power Purchase Agreement (PPA) and shall remain valid until the expiry or early termination of the PPA in terms thereof, unless expressly agreed to the contrary by APTRANSCO/DISCOMs.

13. The Lead Member is authorized and shall be fully responsible for the accuracy and veracity of the representations and information

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 62

SOLAR RFS BID DOCUMENT

submitted by the Members respectively from time to time in the response to RfS.

14. It is hereby expressly understood between the Members that no Member at any given point of time, may assign or delegate its rights, duties or obligations under the PPA except with prior written consent of APTRANSCO.

15. This Agreement

(a) has been duly executed and delivered on behalf of each Member hereto and constitutes the legal, valid, binding and enforceable obligation of each such Member;

(b) sets forth the entire understanding of the Members hereto with respect to the subject matter hereof; and

(c) may not be amended or modified except in writing signed by each of the Members and with prior written consent of APTRANSCO.

16. All the terms used in capitals in this Agreement but not defined herein shall have the meaning as per the RfS & PPA.

IN WITNESS WHEREOF, the Members have, through their authorized representatives, executed these present on the Day, Month and Year first mentioned above.

For M/s------[Member 1] ------

(Signature, Name & Designation of the person authorized vide Board Resolution Dated [?])

Witnesses: 1) Signature ------2) Signature ------Name: ------Name: Address: Address:

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 63

SOLAR RFS BID DOCUMENT

For M/s------[Member 2]

------

(signature, Name & Designation of the person authorized vide Board Resolution Dated [?])

Witnesses: 1) Signature ------Name: Address: 2) Signature ------Name: Address:

For M/s------[Member n]

------

(signature, Name & Designation of the person authorized vide Board Resolution Dated [?])

Witnesses:

1) Signature ------(2) Signature ------

Name:

Address: Name:

Address:

Signature and stamp of Notary of the place of execution

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 64

SOLAR RFS BID DOCUMENT

[on the letter head of Bidder]

Format 6.6- FORMAT FOR FINANCIAL REQUIREMENT – NET WORTH (to be filled separately for individual projects)

To,

` The Chief Engineer/IPC APPCC, VIdyut Soudha, Hyderabad

Dear Sir,

Sub: Response to RfS for setting up______MW Solar Power plants in AP.

We certify that the Bidding Company / Member in a Bidding Consortium [Name of Bidding Company or Bidding Consortium] has a minimum Net Worth of Rs. crore (Rupees ) on

(i) For Existing Companies

Description Select any one (whichever is applicable)

Audited annual accounts of any of the last four (4) Applicable / Not financial years 2008-09, 2009-10, 2010-11 and 2011- Applicable 12 [Strike out the financial years not applicable] Or

Net Worth as on day dd/mm/yyyy (within seven days Applicable / Not prior to the last date of submission of response Applicable to RfS by the bidding companies)

(ii) For new Companies

Net Worth as on day dd/mm/yyyy (not more than seven days prior to the last date of submission of response to RfS by the bidding companies)

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 65

SOLAR RFS BID DOCUMENT

Exhibit (i): Applicable in case of Bidding Company

For the above calculations, we have considered the Net Worth by Bidding Company and/ or its Parent / Affiliates as per following details:

Name of Name of Company Relationship Either Financial Year Net Worth (in Rs. Company / / with Bidding to Crore) of the Parent/ Parent/ Affiliate Company* be considered for Member whose Net Net Worth or Net Affiliate/ Company Worth is to be Worth of the Group respective Company considered Company not later than 7 days prior to submission of RfS Company 1 ------Total

The column for “Relationship with Bidding Company” is to be filled only in case the financial capability of Parent/Affiliate has been used for meeting Qualification Requirements. Further, documentary evidence to establish the relationship, duly certified by the company secretary/chartered accountant is required to be attached with the format.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 66

SOLAR RFS BID DOCUMENT

Exhibit (ii): Applicable in case of Bidding Consortium

(To be filled by each Member in a Bidding Consortium separately)

Name of Member: [Insert name of the Member]

Net worth Requirement to be met by Member in Proportion to the Equity Commitment: Rs. ------Crore (Equity Commitment (%) * Rs. [ ] Crore)

For the above calculations, we have considered Net Worth by Member in Bidding Consortium and/ or Parent/ Affiliate as per following details:

Name of Name of Relationship Either Net Worth Equity Committed Consortiu Company / with Bidding Financial (in Rs. Commit Net Worth m Member Parent/ Affiliate/ Company* Year to be Crore) of ment (in (in Rs. Company Consortium (if any) considered the %age) in Crore) Member whose for Net Consortiu Bidding Net Worth is to Worth or m Consorti be considered Net Worth Member um of the Company respective Company not later than 7 days prior to Company submission 1 ------Total

* The column for “Relationship with Bidding Company” is to be filled only in case the financial capability of Parent/Affiliate has been used for meeting Qualification Requirements. Further, documentary evidence to establish the relationship, duly certified by the company secretary/chartered accountant is required to be attached with the format.

(Signature & Name of the person Authorised (Signature and Stamp of By

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 67

SOLAR RFS BID DOCUMENT

the board) Statutory Auditor or Chartered Accountant)

Date:

Note: i. Along with the above format, in a separate sheet, provide details of computation of Net Worth duly certified by Statutory Auditor. ii. Certified copies of Balance sheet, Profit & Loss Account, Schedules and Cash Flow Statements and Bank statement by bank are to be enclosed in support thereof for confirmation of balance in cash & bank.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 68

SOLAR RFS BID DOCUMENT

[On the letter head of Bidder]

Format 6.7 - FORMAT FOR TECHNICAL CRITERIA

To, The Chief Engineer/IPC APPCC, VIdyut Soudha, Hyderabad

Dear Sir,

Sub: Response to RfS setting up ______MW Solar Power Plant in AP.

We hereby undertake to certify in line with clause 3.21 that the following details shall be furnished within 210 days of signing of PPA: -

1.0 That the technology proposed to be used is commercially established solar technology

2.0 Details of the project with Location and the successful operational period of the project utilizing this technology.

Authorised Signatory

Stamp

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 69

SOLAR RFS BID DOCUMENT

(On the letterhead of the Bidding Company / Consortium)

Format 6.8 Format for Confirmation of Connectivity (To be filled separately for individual Locations)

To,

The Executive Director/Planning, RAC& Reforms, APTRANSCO/Vidyut Soudha, Hyderabad.

Dear Sir,

Sub: Response to RfS for setting up one unit of solar Power Plant of______MW in______Distribution Company Limited of AP.

1. We hereby agree to lay the evacuation with necessary infrastructure from our proposed solar power plant to nearest 33 kV or 132 kV transmission sub- station as may be available at our own cost for all the items as mentioned in the RfS document like transmission lines, grid interface equipment, metering, bay etc.

2. We hereby undertake to obtain the letter from transmission utility /distribution utility confirming connectivity before and after the same is carried out. 3. We hereby undertake to sign necessary Power Purchase Agreement with APTRANSCO/DISCOMs as specified in the RfS. 4. We hereby undertake to pay the connectivity charges as decided by APTRANSCO/DISCOMs.

Authorized Signatory

Stamp

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 70

SOLAR RFS BID DOCUMENT

Format 6.9 - Format for Disclosure

[On the letter head of Bidding Company/Each Member in a Bidding Consortium]

Disclosure

We hereby declare that our Parent, Affiliate or Ultimate Parent-or any Group Company with which we have direct or indirect relationship are not separately participating in this Bid.

We further declare that the above statement is true & correct. We are aware that if at any stage it is found to be incorrect, our response to RfS bid will be rejected and if LoI has been issued or PPA has been signed, the same will be cancelled and the bank guarantees will be encashed.

(Signature & Name of the person Authorised By the board)

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 71

SOLAR RFS BID DOCUMENT

Format 6.10 Declaration by the Solar power Developer for the proposed technology

Name of Bidding Company / Lead Member of Bidding Consortium 1 2 Project proposed Solar 3 Capacity proposed (in MW) Technology proposed to be adopted for the project (solar PV or Solar thermal) 4 to supply contracted annual output (units per MW Conventional / Advance in the first year) 5 Give brief description about the proposed Solar Technology

Signature of the Bidder

Stamp

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 72

SOLAR RFS BID DOCUMENT

Format 6.11 Summary Data Sheet

Summary Data Sheet (Format 6.11)

Asterisk Marked(*) Fields are Mandatory

Re Sectio Details to be Furnished by the Bidder B fer i n dd

e Rf r s

D S e t a

il Do Name ofs Bidder* Bidders

status*

Address (Line-1) Address (Line-2)

City Sta Country Zip/Pin te Bidder's website if any

Bid List of parent/Ultimate

Parent/ Group Companies, if any. Company Details of bids across Project 1 Name Capacity in Loca tio other Locations ,if any, MW n being developed by Parent /Ultimate Parent/ Company Affiliates/ Group Project 2 Name Capacity in Loca tio Companies (ADD ROWS IF MW n NECESSARY)

Name of the Controlling Share holding

Whether listed with any stock Name of Exchange (s) where exchange.* listed

EMD Details of the EMD

De (I) Amount(in (II) Banker t

ails Rs.Lakhs)*

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 73

SOLAR RFS BID DOCUMENT

(III)DD/Pay (IV)DD/Pay Order

Order No Date Details of the Processing Fee

Processing

de (I) Amount(in Rs.Lakhs)* (II) Banker t ails

(III)DD/Pay Order No (IV)DD/Pay Order fee Date

Name & Contact Details of the person authorized by the Company/ Consortium to sign the RfS Au

De t Name of the Person horiza t ails

tion Mobile No Office Tel No(with STD) Fax(with STD Code )

Same as bidders Add Line 1 Add line 2 address

Correspondence City State Country Zip/Pin address

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 74

SOLAR RFS BID DOCUMENT

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 75

SOLAR RFS BID DOCUMENT

Format 6.11A Technical Bid

TECHNICAL BID List of Identified Substations for Solar Power RfS

Bidders No. of Maximum offered Total Tr. Transform Solar capacity in Location Capacity ers X Capacity MW at (MVA) capacity (MW) Injection points

SRIKAKULAM 1X31.5 + Location -1 132 KV SS Chilakapalem 81.50 5 -- 1X50 Injection 132KV a) Chilakapalem Points SS b) 33 KV SS Tadivalasa c) 33 KV SS Indoor d) 33 KV SS A.S.N.COLONY e) 33 KV SS AMADALAVALASA f) 33 KV SS THOGARAM g) 33 KV SS KINTALI h) 33 KV SS PONDURU i) 33 KV SS BUDUMURU j) 33 KV SS LAVERU k) 33 KV SS KS PALEM l) 33 KV SS DHARMAVARAM m) 33 KV SS ETCHERLA n) 33 KV SS GUJARATHIPETA o) 33 KV SS CHALLAPETA p) 33 KV SS TULUGU q) 33 KV SS ARASAVALLI r) 33 KV SS SRIKAKULAM

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 76

SOLAR RFS BID DOCUMENT

s) 33 KV SS BHYRI t) 33 KV SS RAGOLU u) 33 KV SS Alikam

1X31.5 + Location -2 132 KV SS Palakonda 47.50 5 -- 1X16 Injection 132KV a) Palakonda Points SS b) 33 KV SS BHAMINI c) 33 KV SS GURANDI d) 33 KV SS HIRAMANDALAM e) 33 KV SS L.N.PETA S.S f) 33 KV SS KOTTURU g) 33 KV SS NIVAGAM h) 33 KV SS SARUBUJJILI i) 33 KV SS UNGARADAMETTA j) 33 KV SS SANTHAKAVITY k) 33 KV SS KOLLIVALASA l) 33 KV SS NAVAGAM m) 33 KV SS PALAKONDA n) 33 KV SS SEETHAMPETA o) 33 KV SS DONUBAI p) 33 KV SS VANGARA q) 33 KV SS VEERAGATTAM r) 33 KV SS Parvateesampeta

Location -3 132 KV SS Pydibheevaram 2X31.5 63.00 5 -- Injection 132KV a) Pydibheevaram Points SS b) 33 KV SS P.B.Varan c) 33 KV SS Patharlapalli d) 33 KV SS Ranasthalam e) 33 KV SS Yerravaram

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 77

SOLAR RFS BID DOCUMENT

VIZIANAGARAM 1X31.5 + Location -4 132 KV SS Vizianagaram 81.50 5 -- 1X50 Injection 132KV a) Vizianagaram Points SS b) 33 KV SS Dharmapuri c) 33 KV SS Denkada d) 33 KV SS Nathavalasa e) 33 KV SS Vontithadi f) 33 KV SS B. koneru g) 33 KV SS Indoor h) 33 KV SS Phoolbagh i) 33 KV SS Dasannapeta j) 33 KV SS Ayyannapeta k) 33 KV SS Collectrate l) 33 KV SS Gajularega m) 33 KV SS Gotlam n) 33 KV SS Bondapalli o) 33 KV SS Gajapathinagaram p) 33 KV SS Mentada q) 33 KV SS Rajapulova r) 33 KV SS Akkivaram s) 33 KV SS Savaravalli t) 33 KV SS Bhogapuram u) 33 KV SS Mukkam

1X16 + Location -5 132 KV SS Kothavalasa 47.50 5 -- 1X31.5 Injection 132KV a) Kothavalasa Points SS b) 33 KV SS L. Kota c) 33 KV SS Malliveedu d) 33 KV SS Kothavalasa e) 33 KV SS Kantakapalli

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 78

SOLAR RFS BID DOCUMENT

f) 33 KV SS Vepada g) 33 KV SS Ramalingapuram

VISAKHAPATNAM 1X16 + Location -6 132 KV SS Koruprolu 47.50 5 -- 1X31.5 Injection 132KV a) Koruprolu Points SS b) 33 KV SS Bhalighattam c) 33 KV SS Darlapudi d) 33 KV SS Kotavarutla e) 33 KV SS Pamulawaka f) 33 KV SS Narsipatnam g) 33 KV SS Rolugunta h) 33 KV SS Golugonda i) 33 KV SS Chintapalli GK Veedhi j) 33 KV SS (Unmanned) Duppiliwada k) 33 KV SS (Unmanned) l) 33 KV SS Etigyrampeta m) 33 KV SS S.Rayavaram P Dharmavaram n) 33 KV SS (Penugollu) o) 33 KV SS Yelamanchili p) 33 KV SS Koruprolu q) 33 KV SS Upmaka r) 33 KV SS Vempadu s) 33 KV SS Lamsanghai t) 33 KV SS K.D.peta

Location -7 132 KV SS Kasimkota 2X31.5 63.00 5 Injection 132KV a) Kasimkota Points SS

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 79

SOLAR RFS BID DOCUMENT

b) 33 KV SS Venkannapalem c) 33 KV SS Chodavaram d) 33 KV SS Cheedikada e) 33 KV SS Koppaka SS f) 33 KV SS Anakapalle g) 33 KV SS Rajam h) 33 KV SS Gadirai (Vommali) i) 33 KV SS Madugula j) 33 KV SS Waddadi k) 33 KV SS Ravikamatham l) 33 KV SS Kothakota SS m) 33 KV SS Makavarapalem n) 33 KV SS Anarak Aluminium o) 33 KV SS Velagapudi Steels p) 33 KV SS Bayyavaram q) 33 KV SS Narasingabilli r) 33 KV SS Toshali Cements s) 33 KV SS Munagapaka (RECS)

1X16 + Location -8 132 KV SS Payakaraopeta 47.50 5 1X31.5 Injection 132KV a) Payakaraopeta Points SS b) 33 KV SS Srirampuram c) 33 KV SS Nathavaram d) 33 KV SS Satyavaram EAST GODAVARI 2x31.5+1x1 Location -9 132 KV SS Peddapuram 78.00 5 5 Injection 132KV a) Peddaparum Points SS b) 33 KV SS PITHAPURAM, , c) 33 KV SS KUMARAPURAM d) 33 KV SS CHEBROLU

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 80

SOLAR RFS BID DOCUMENT

e) 33 KV SS B.PRATHIPADU f) 33 KV SS DIVILI g) 33 KV SS PEDDAPURAM IDA h) 33 KV SS R.B.PATNAM i) 33 KV SS SAMALKOT j) 33 KV SS PEDDAPURAM k) 33 KV SS MADHAVAPATNAM l) 33 KV SS VETLAPALEM m) 33 KV SS BORRAMPALEM n) 33 KV SS JAGGAMPETA o) 33 KV SS GANDEPALLI p) 33 KV SS RANGAMPETA

Location - 132 KV SS Ramachandrapuram 2x31.5 63.00 5 10 Injection 132KV a) Ramachandrapuram Points SS b) 33 KV SS KUTUKULURU c) 33 KV SS BICCAVOLU d) 33 KV SS BB PURAM e) 33 KV SS RANGAPURAM f) 33 KV SS RAYAVARAM g) 33 KV SS CHELLURU h) 33 KV SS K.GANGAVARAM SEELAMVARI i) 33 KV SS SAVARAM j) 33 KV SS ALAMURU k) 33 KV SS ANGARA l) 33 KV SS SIVALA m) 33 KV SS DRAKSHARAM n) 33 KV SS INJARAM o) 33 KV SS TALLAREVU p) 33 KV SS R.C.PURAM q) 33 KV SS ARYAVATAM

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 81

SOLAR RFS BID DOCUMENT

r) 33 KV SS KARAPA

Location - 1X16 + 132 KV SS Rajanagaram 47.50 5 -- 11 1X31.5 Injection 132KV a) Rajanagaram Points SS b) 33 KV SS G.DONTHAMURU c) 33 KV SS PRC PURAM d) 33 KV SS DIWANCHERUVU e) 33 KV SS KALAVACHARLA f) 33 KV SS RAJANAG ARAM WEST GODAVARI Location - 1x31.5+1x2 132 KV SS Kamavorapukota 51.50 5 -- 12 0 Injection 132KV a) Kamavorapukota Points SS b) 33 KV SS UPPALAPADU c) 33 KV SS ANKALAMPADU d) 33 KV SS EDAVALLI e) 33 KV SS PERAMPETA f) 33 KV SS RAJAVARAM g) 33 KV SS KALLACHERUVU h) 33 KV SS RANGAPURAM i) 33 KV SS R.POTHEPALLI j) 33 KV SS Adamilli k) 33 KV SS G.G.KUNTA l) 33 KV SS TADIKALAPUDI

Location - 132 KV SS Jangareddygudem 2x31.5 63.00 5 13 Injection 132KV a) Jangareddygudem Points SS b) 33 KV SS BUTTAIGUDEM c) 33 KV SS RAMARAOPETA d) 33 KV SS DHRABAGUDEM

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 82

SOLAR RFS BID DOCUMENT

e) 33 KV SS JILUGUMILLI f) 33 KV SS MYSANNAGUDEM g) 33 KV SS TADUVAI h) 33 KV SS J.R.GUDEM i) 33 KV SS LAKKAVARAM j) 33 KV SS BAYYANAGUDEM k) 33 KV SS KOYYALAGUDEM l) 33 KV SS PAREDDYGUDEM

Location - 2x31.5+1x5 132 KV SS Jangareddygudem 113.00 5 -- 14 0 Injection 132KV a) Pedatadepalli Points SS b) 33 KV SS JAGANNAPETA c) 33 KV SS KUNCHANAPALLI d) 33 KV SS MODUGUNTA e) 33 KV SS A.GOKAVARAM f) 33 KV SS BADAMPUDI g) 33 KV SS BHUVANAPALLI h) 33 KV SS CHEBROL i) 33 KV SS VARADARAJAPURAM j) 33 KV SS NEELADRIPURAM k) 33 KV SS VEERAMPALEM l) 33 KV SS P.T.PALLI m) 33 KV SS GOLLAGUDEM n) 33 KV SS YERRAMALLA o) 33 KV SS ARUGOLANU p) 33 KV SS H.B.COLONY q) 33 KV SS PENTAPADU r) 33 KV SS TPG KRISHNA Location - 132 KV SS Nuzivedu 3x50 150.00 10 -- 15 Injection a) 132KV Nuzivedu

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 83

SOLAR RFS BID DOCUMENT

Points SS b) 33 KV SS Advainakkalam c) 33 KV SS Agripalli d) 33 KV SS katrenipadu e) 33 KV SS Meerjapuram f) 33 KV SS Morasapudi g) 33 KV SS Gopavaram h) 33 KV SS Gudipadu i) 33 KV SS Musunuru j) 33 KV SS Venkatapuram k) 33 KV SS Ganapavaram l) 33 KV SS Nuzivedu m) 33 KV SS Chetlapalle n) 33 KV SS Kotapadu o) 33 KV SS Polavaram p) 33 KV SS Thummalagudem q) 33 KV SS Ramanakkapeta r) 33 KV SS Janardhanapuram s) 33 KV SS Vattigudipadu t) 33 KV SS Chatrai u) 33 KV SS Narasapuram v) 33 KV SS Vissanapeta w) 33 KV SS Kondaparava x) 33 KV SS Annavaram GUNTUR Location - 1X31.5 + 132 KV SS Macherla 81.50 5 -- 16 1X50 Injection 132KV a) Macherla Points SS b) 33 KV SS Veldurhy.1 c) 33 KV SS Kadlakunta d) 33 KV SS Gangalakunta e) 33 KV SS Sirigiripadu

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 84

SOLAR RFS BID DOCUMENT

f) 33 KV SS Macherla.II g) 33 KV SS Koppunuru h) 33 KV SS NSDsam i) 33 KV SS Tallapalle j) 33 KV SS Gurajala k) 33 KV SS Retachintala l) 33 KV SS Palvai m) 33 KV SS Mutukuru n) 33 KV SS Durgi o) 33 KV SS Mandadi p) 33 KV SS Bodiveddu q) 33 KV SS Rayavaran

Location - 132 KV SS Piduguralla 2X31.5 63.00 10 -- 17 Injection 132KV a) Piduguralla Points SS b) 33 KV SS Nakarikallu c) 33 KV SS rompicherla Vipparlareddypale d) 33 KV SS m e) 33 KV SS Cherjerala f) 33 KV SS PGPadu g) 33 KV SS Brhamanapalle h) 33 KV SS Macahvaram i) 33 KV SS Srinagar j) 33 KV SS Nadikudi k) 33 KV SS Madinapadu l) 33 KV SS Gadevaripalle m) 33 KV SS Janapadu n) 33 KV SS Piduguralla o) 33 KV SS Kondamodu p) 33 KV SS Bellamkonda q) 33 KV SS Rajupalem

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 85

SOLAR RFS BID DOCUMENT

r) 33 KV SS Papalpalem s) 33 KV SS Sattenpalli t) 33 KV SS Dulipalla

Location - 1X50 + 132 KV SS Chilakaluripeta 81.50 5 -- 18 1X31.5 Injection 132KV a) Chilakaluripeta Points SS b) 33 KV SS Pollireddypalem c) 33 KV SS Maddirala d) 33 KV SS Santhamaguluru e) 33 KV SS Purushothapatnam f) 33 KV SS Kotappakonda g) 33 KV SS Nandivardhana h) 33 KV SS Nadendla i) 33 KV SS Chilaluripeta j) 33 KV SS R.Pasumarru k) 33 KV SS Boppudi l) 33 KV SS Ganapavaram

Location - 1X31.5 + 132 KV SS Marripalem 47.50 5 -- 19 1X16 Injection 132KV a) Marripalem Points SS b) 33 KV SS Edlapadu c) 33 KV SS Boyapaolem d) 33 KV SS Sakku e) 33 KV SS Viswateja f) 33 KV SS Vasundara g) 33 KV SS Supriya h) 33 KV SS Ananathalakshmi i) 33 KV SS Ranganayaka PRAKASHAM Location - 1X31.5 + 132 KV SS Cumbum 63.50 5 -- 20 2X16

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 86

SOLAR RFS BID DOCUMENT

Injection 132KV a) Cumbum Points SS b) 33 KV SS Racherla c) 33 KV SS Yerrabalem d) 33 KV SS Akaveedu e) 33 KV SS Mohiddinpuram f) 33 KV SS Yachavaram g) 33 KV SS Aradhaveedu h) 33 KV SS Akkapalle i) 33 KV SS Pitakayagulla j) 33 KV SS Kandulapuram k) 33 KV SS BVPeta l) 33 KV SS Tarlupadu m) 33 KV SS Ravipadu n) 33 KV SS Ummareddypalle o) 33 KV SS TRPalle p) 33 KV SS Komatikunta q) 33 KV SS Puchakayalapalle r) 33 KV SS Thippayapalem

Location - 132 KV SS Kanigiri 2X31.5 63.00 5 -- 21 Injection 132KV a) Kanigiri Points SS b) 33 KV SS KKMitta c) 33 KV SS Nandanamarella d) 33 KV SS Chinnarikatla e) 33 KV SS Gotlagattu f) 33 KV SS TRPalle g) 33 KV SS SRPuram h) 33 KV SS Veligandla i) 33 KV SS Rallapadu j) 33 KV SS Tallur k) 33 KV SS P.Alavalapadu

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 87

SOLAR RFS BID DOCUMENT

l) 33 KV SS P.Eralapadu m) 33 KV SS PCPalle n) 33 KV SS Guravajipeta o) 33 KV SS BPAddaroad

Location - 1X31.5 + 132 KV SS Kandukuru 46.50 5 -- 22 1X15 Injection 132KV a) Kandukuru Points SS b) 33 KV SS Kandukuru Town c) 33 KV SS East Kandukuru d) 33 KV SS Pamur Road e) 33 KV SS Kandukuru Rural f) 33 KV SS Ponnalur g) 33 KV SS Agraharam h) 33 KV SS Lingasamudram i) 33 KV SS VV Palem j) 33 KV SS Chinnapavani k) 33 KV SS Pokuru l) 33 KV SS Naladalapur m) 33 KV SS Gudlur n) 33 KV SS Machavaram o) 33 KV SS S.Konda p) 33 KV SS Karedu q) 33 KV SS Ulavapadu r) 33 KV SS Tettu s) 33 KV SS Pakala t) 33 KV SS Narasingolu u) 33 KV SS Kondepi v) 33 KV SS Uppalapadu w) 33 KV SS M.Nidamanur x) 33 KV SS Jarugumalli

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 88

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Peddadornala 2X16 32.00 5 -- 23 Injection 132KV a) Peddadornala Points SS b) 33 KV SS Dornala c) 33 KV SS Sanikavaram d) 33 KV SS B.Cherlopalli e) 33 KV SS P.Bommanapuram f) 33 KV SS Y.Cherlopalli

Location - 132 KV SS Martur 2X31.5 63.00 5 -- 24 Injection 132KV a) Martur Points SS b) 33 KV SS Ballikurava c) 33 KV SS Kommalapadu d) 33 KV SS V.Kopperapadu e) 33 KV SS Konanaki f) 33 KV SS Dhramavaram NELLORE Location - 132 KV SS Kavali 2X31.5 63.00 5 -- 25 Injection 132KV a) Kavali Points SS b) 33 KV SS Jaladanki c) 33 KV SS Brahmanakraka d) 33 KV SS Ananathapuram e) 33 KV SS Ayyapreddypalem f) 33 KV SS Basireddypalem g) 33 KV SS Kaligiri h) 33 KV SS Bogolu i) 33 KV SS VRNagar j) 33 KV SS Maddurupadu k) 33 KV SS Pullaredynagar l) 33 KV SS Annagaripalem

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 89

SOLAR RFS BID DOCUMENT

m) 33 KV SS Chowdawaram n) 33 KV SS Kommi o) 33 KV SS Kondapuram

Location - 132 KV SS Chendodu 2X31.5 63.00 5 -- 26 Injection 132KV a) Chendodu Points SS b) 33 KV SS N.P.Kothapalem c) 33 KV SS Kota d) 33 KV SS Siddawaram e) 33 KV SS Gunapadu f) 33 KV SS Eswarawaka g) 33 KV SS Mallam h) 33 KV SS Kothagunta i) 33 KV SS Vakadu j) 33 KV SS BRPalem k) 33 KV SS Konduru l) 33 KV SS Ankulapaturu m) 33 KV SS Chinthavaram

Location - 132 KV SS Naidupet 2X31.5 63.00 5 -- 27 Injection 132KV a) Naidupet Points SS b) 33 KV SS Chillakuru c) 33 KV SS Sirasmabedu d) 33 KV SS KGKandriga e) 33 KV SS Menskur f) 33 KV SS Naidupeta g) 33 KV SS Thummuru h) 33 KV SS Annamedu i) 33 KV SS Yakasini j) 33 KV SS Puduru

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 90

SOLAR RFS BID DOCUMENT

CHITTOOR Location - 1X31.5 + 132 KV SS Palamaneur 81.50 5 -- 28 1X50 Injection 132KV a) Palamaneur Points SS b) 33 KV SS Bairedipalle c) 33 KV SS Kolamasanpalle d) 33 KV SS Kasturinagar e) 33 KV SS Tekumanda f) 33 KV SS Ragimanupenta g) 33 KV SS Mogili h) 33 KV SS Kadirimadugu i) 33 KV SS Pathikonda j) 33 KV SS Peddapurm k) 33 KV SS Melmai

Location - 1X50 + 132 KV SS Madanapally 81.50 10 -- 29 1X31.5 Injection 132KV a) Madanapally Points SS b) 33 KV SS Nimmanapalle c) 33 KV SS Reddivaripalle d) 33 KV SS Vengamavariapalle e) 33 KV SS CTM f) 33 KV SS Kantevaripalle g) 33 KV SS Kotavuru h) 33 KV SS Ammcheruvu mitta i) 33 KV SS Nayanabavi j) 33 KV SS Pothapolu k) 33 KV SS Valasapalle l) 33 KV SS Vemaplle m) 33 KV SS Bommanacheruvu n) 33 KV SS Kurabalakota

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 91

SOLAR RFS BID DOCUMENT

Location - 1X31.5 + 132 KV SS Pakala 47.50 5 -- 30 1X16 Injection 132KV a) Pakala Points SS b) 33 KV SS Achamaagaraharam c) 33 KV SS M.N.Palle d) 33 KV SS Damaracheruvu e) 33 KV SS Kalluru f) 33 KV SS Pulicherla g) 33 KV SS Ashoknagar h) 33 KV SS Mangalamapeta i) 33 KV SS Vallivedu j) 33 KV SS Puthalapattu k) 33 KV SS Petamitta l) 33 KV SS M.Bandapalle

Location - 1X50 + 132 KV SS Shanthipuram 81.50 5 -- 31 1X31.5 Injection 132KV a) Shanthipuram Points SS b) 33 KV SS Rallbuduguru c) 33 KV SS Chinnabaldar d) 33 KV SS Ramakuppam e) 33 KV SS Aanikeri f) 33 KV SS Suddalakuppam g) 33 KV SS Sivaramanapuram h) 33 KV SS Arimanupenta i) 33 KV SS V.Kota j) 33 KV SS Cheldiganipalle

Location - 1X31.5 + 132 KV SS Nagiri 47.50 10 -- 32 1X16 Injection 132KV a) Nagiri Points SS b) 33 KV SS Nethamkandriga

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 92

SOLAR RFS BID DOCUMENT

c) 33 KV SS M.Kothuru d) 33 KV SS Pannuru e) 33 KV SS Vijayapuram f) 33 KV SS Kalikapuram g) 33 KV SS Kosalanagaram h) 33 KV SS Netteri i) 33 KV SS Mittakandriga j) 33 KV SS Irruguvoi

Location - 1X50 + 132 KV SS Kothapallimitta 81.50 10 -- 33 1X31.5 Injection 132KV a) Kothapallimitta Points SS b) 33 KV SS Katiripalle c) 33 KV SS Chinnatayyuru d) 33 KV SS Katikapalle e) 33 KV SS SRPuram f) 33 KV SS Nelavoi g) 33 KV SS Kondakindpalle h) 33 KV SS Vedurkuppam i) 33 KV SS Mambedu j) 33 KV SS NVPalle k) 33 KV SS Allamadugu l) 33 KV SS Penumuru m) 33 KV SS Mattampalle n) 33 KV SS Polavaram o) 33 KV SS Bandarlapalle p) 33 KV SS GDNellore q) 33 KV SS Avulakonda r) 33 KV SS SSKonda s) 33 KV SS VRKuppam t) 33 KV SS SBRpuram u) 33 KV SS Vepamjeri

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 93

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Burakayalakota 2X31.5 63.00 10 -- 34 Injection 132KV a) Burakayalakota Points SS b) 33 KV SS Rangasamudrum c) 33 KV SS Nanbavi d) 33 KV SS kandukuru e) 33 KV SS Gopidinne f) 33 KV SS Chowdasamudurm g) 33 KV SS Burakayalakota h) 33 KV SS Mulakalacherubu i) 33 KV SS B.Kohakota j) 33 KV SS PTM k) 33 KV SS Varikasuvupalle l) 33 KV SS Mallela

Location - 132 KV SS Kuppam 2X31.5 63.00 10 -- 35 Injection 132KV a) Kuppam Points SS b) 33 KV SS Mallanuru c) 33 KV SS Laskhmipuram d) 33 KV SS Adivibuduguru e) 33 KV SS Gudipalle f) 33 KV SS Vasanadu KADAPA Location - 132 KV SS Badwel 2X16 32 5 -- 36 Injection 132KV a) Badvel Points SS b) 33 KV SS Peddapolukunta

c) 33 KV SS Gangapenta

d) 33 KV SS Payalakunta

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 94

SOLAR RFS BID DOCUMENT

e) 33 KV SS B.Kodur f) 33 KV SS Konduru g) 33 KV SS Sidaout h) 33 KV SS Venkatasettipalle i) 33 KV SS D.Agraharam j) 33 KV SS Badvel-II

Location - 132 KV SS Rayachoti 2X31.5 63 5 -- 37 Injection 132KV a) Rayachoti Points SS b) 33 KV SS T.Sundupalli c) 33 KV SS Rayavaram d) 33 KV SS Gundlapalli e) 33 KV SS Pujarivandlapalli f) 33 KV SS Rayachoty g) 33 KV SS Masapeta h) 33 KV SS L.R.Pallif i) 33 KV SS Ramapuram j) 33 KV SS Veeraballi k) 33 KV SS Matil l) 33 KV SS Vangimalla m) 33 KV SS Gadikota n) 33 KV SS Galiveedu o) 33 KV SS Madhavaram p) 33 KV SS Nooliveedu

Location - 132 KV SS Vontimitta 2x16 32 5 -- 38 Injection 132KV a) Vontimitta Points SS b) 33 KV SS Peddapalle c) 33 KV SS Mantapamapalle

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 95

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Jammalamadugu 2X16 32 5 -- 39 Injection 132KV a) Jammalamadugu Points SS b) 33 KV SS Gundlakunta c) 33 KV SS Diguvakalavatala d) 33 KV SS Namalladinne e) 33 KV SS Torivemula Thalamanchipatna f) 33 KV SS m g) 33 KV SS Mylavaram h) 33 KV SS Dodlum i) 33 KV SS Ambavaram j) 33 KV SS Danavulapadu

Location - 132 KV SS Sambepalli 2X16 32 5 -- 40 Injection 132KV a) Sambepalle Points SS b) 33 KV SS C.Mandam c) 33 KV SS Pedamatikona d) 33 KV SS Devapatla e) 33 KV SS Mallur ANANTHAPUR Location - 1X50 + 132 KV SS Kadri 81.5 5 -- 41 1X31.5 Injection 132KV a) Kadri Points SS b) 33 KV SS Kondakamarla c) 33 KV SS Amadugur d) 33 KV SS Mohamadbad e) 33 KV SS Nallacheruv u f) 33 KV SS Tanakallu g) 33 KV SS Chikatimanipalli h) 33 KV SS Kokanti Cross i) 33 KV SS Peddapalli

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 96

SOLAR RFS BID DOCUMENT

j) 33 KV SS N.P.Kunta k) 33 KV SS Gajulavaripalli l) 33 KV SS Gandlapenta m) 33 KV SS Kadiri n) 33 KV SS Kuttagulla o) 33 KV SS N.S.G.Palli p) 33 KV SS Malakavemula q) 33 KV SS Mallepalli r) 33 KV SS Mudigubba s) 33 KV SS Kodavandlapalli t) 33 KV SS O.D.Cheruvu u) 33 KV SS Pulagampalli v) 33 KV SS Talapula w) 33 KV SS Batrepalli x) 33 KV SS Ganjivaripalli

Location - 132 KV SS Tadipatri 2 X50 100 5 -- 42 Injection 132KV a) Tadipatri Points SS Tadipatri Nandyala b) 33 KV SS Road c) 33 KV SS Rayalacheruvu d) 33 KV SS Konauppalapadu e) 33 KV SS Sajjaladinne f) 33 KV SS Chukkalur g) 33 KV SS P.Yekkaluru h) 33 KV SS P.Pappuru i) 33 KV SS Dharmapuram j) 33 KV SS Kammavaripalli k) 33 KV SS Nitturu l) 33 KV SS Bugga m) 33 KV SS AVT.Palli n) 33 KV SS A.Kondapuram

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 97

SOLAR RFS BID DOCUMENT

o) 33 KV SS Maddipalli p) 33 KV SS Yellutla KURNOOL Location - 132 KV SS Allagadda 2X31.5 63 5 -- 43 Injection 132KV a) Allagadda Points SS b) 33 KV SS Uyyalawada, c) 33 KV SS Perusomula, d) 33 KV SS Nossam e) 33 KV SS Chagalamarri, f) 33 KV SS K. Kandukuru, g) 33 KV SS P.Bodanam h) 33 KV SS Chinthalacheruvu i) 33 KV SS Alamuru (Allagada) j) 33 KV SS Ahobilam, k) 33 KV SS C T R Palli l) 33 KV SS Muthylapadu, m) 33 KV SS R.K.Puram, n) 33 KV SS Rudravaram o) 33 KV SS Yerraguntla p) 33 KV SS Dornipadu, Kalugotla q) 33 KV SS (Koilakuntla)

Location - 132 KV SS Adoni 2X31.5 63 5 -- 44 Injection 132KV a) Adoni Points SS b) 33 KV SS S.K.D.Colony, c) 33 KV SS Arts College d) 33 KV SS Baichigiri e) 33 KV SS Kamavaram, f) 33 KV SS Kowthalam g) 33 KV SS Halvi,

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 98

SOLAR RFS BID DOCUMENT

h) 33 KV SS Nadichagi i) 33 KV SS Gulyam j) 33 KV SS yellarthy k) 33 KV SS Holagunda Chippagiri l) 33 KV SS (Alternate) m) 33 KV SS Molagavalli n) 33 KV SS Basaladoddi, o) 33 KV SS Vandagal, p) 33 KV SS Kosigi q) 33 KV SS Kolamanpeta r) 33 KV SS Market yard s) 33 KV SS santhakodur, t) 33 KV SS Kallubavi u) 33 KV SS Alur, v) 33 KV SS Kammarachedu w) 33 KV SS Nagaradona, x) 33 KV SS Halaharvi y) 33 KV SS Ganekal z) 33 KV SS Pedda thumbalam

Location - 132 KV SS Pathikonda 2X31.5 63 10 -- 45 Injection 132KV a) Pathikonda Points SS b) 33 KV SS Devanakonda c) 33 KV SS E.D.Banda, d) 33 KV SS Yerrabadu, e) 33 KV SS Kothiralla f) 33 KV SS Gundlakonda g) 33 KV SS Aspari, h) 33 KV SS Dibbanakal, i) 33 KV SS Devanabanda j) 33 KV SS Maddikera,

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 99

SOLAR RFS BID DOCUMENT

k) 33 KV SS Tuggali, l) 33 KV SS Jonnagiri m) 33 KV SS Pathikonda, n) 33 KV SS R.S.Pendekal

Location - 132 KV SS Gudur 2X16 32 5 -- 46 Injection 132KV a) Gudur Points SS b) 33 KV SS Kothakota c) 33 KV SS Gudur d) 33 KV SS C.Belagal e) 33 KV SS Polakal f) 33 KV SS Gundrevula g) 33 KV SS Kodumur, h) 33 KV SS Pulakurthy

Location - 132 KV SS Banaganapalli 2X16 32 5 -- 47 Injection 132KV a) Banaganapalli, Points SS b) 33 KV SS Yanakandla, c) 33 KV SS Palukuru. d) 33 KV SS Owk, e) 33 KV SS Akumalla, f) 33 KV SS I.K.Peta, g) 33 KV SS Uppalapadu, Ramapuram. h) 33 KV SS (Alternate) i) 33 KV SS Gundla Singavaram j) 33 KV SS Kolilakuntla, k) 33 KV SS Gulladurthy, l) 33 KV SS Sanjamala m) 33 KV SS Pathapadu

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 100

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Gandikota 1X50 50 5 -- 48 Injection 132KV a) Gandikota (LIS) Points SS

MAHABUBNAGAR Location - 1X31.5+1X 132 KV SS Nagarkurnool 81.5 10 -- 49 50 Injection 132KV a) Nagarkurnool Points SS b) 33 KV SS Ithole c) 33 KV SS Tadoor d) 33 KV SS Yangampally e) 33 KV SS Kummera f) 33 KV SS Bijnapally g) 33 KV SS Peddamudunoor h) 33 KV SS Manganoor i) 33 KV SS Mumaipally j) 33 KV SS Waddeman k) 33 KV SS Manthati l) 33 KV SS Kollapur X Roads m) 33 KV SS Telkapally n) 33 KV SS Rakonda o) 33 KV SS Peddur p) 33 KV SS Tallapally q) 33 KV SS Peddapur r) 33 KV SS Kondareddypally

Location - 132 KV SS Wanaparthy 2X50 100 5 -- 50 Injection 132KV a) Wanaparthy Points SS b) 33 KV SS Kothakota c) 33 KV SS Kurumurthy d) 33 KV SS Madanapur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 101

SOLAR RFS BID DOCUMENT

e) 33 KV SS Kothapally f) 33 KV SS Ramanpad g) 33 KV SS Peddamandadi h) 33 KV SS Addakal i) 33 KV SS Ponnakal j) 33 KV SS Veltoor k) 33 KV SS Solipur l) 33 KV SS Buddaram m) 33 KV SS Balijapally n) 33 KV SS Kandur o) 33 KV SS Mamidimada p) 33 KV SS Gopalpet q) 33 KV SS Revally r) 33 KV SS P.K.Pally s) 33 KV SS Thudkurthy t) 33 KV SS Chennaram u) 33 KV SS Peddakarpamula v) 33 KV SS Ayyavaripally w) 33 KV SS Remaddula x) 33 KV SS Rajapur y) 33 KV SS Kodair z) 33 KV SS Tirumalapur a1) 33 KV SS Kethepally a2) 33 KV SS Pangal a3) 33 KV SS Pebbair a4) 33 KV SS Williamkonda a5) 33 KV SS Srinivasapuram a6) 33 KV SS Nasanally a7) 33 KV SS Sri Rangapur

Location - 1X50+2X31 132 KV SS Thimmapur 113 10 -- 51 .5 Injection a) 132KV Thimmapur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 102

SOLAR RFS BID DOCUMENT

Points SS b) 33 KV SS Kothur c) 33 KV SS Sangem d) 33 KV SS Inmulnarva e) 33 KV SS Kothapet

Location - 132 KV SS Gadwal 2X50 100 10 -- 52 Injection 132KV a) Gadwal Points SS b) 33 KV SS Veerapur c) 33 KV SS Beechupally d) 33 KV SS Kodandapur e) 33 KV SS Gadwal f) 33 KV SS Gadwal Town g) 33 KV SS Alwalpad h) 33 KV SS Dharoor i) 33 KV SS Nandinne j) 33 KV SS Dyagadoddi k) 33 KV SS Maldakal l) 33 KV SS Ieeza m) 33 KV SS Mallamdoddi n) 33 KV SS P.T.Pad o) 33 KV SS Budidapad p) 33 KV SS Bijjaram q) 33 KV SS Amarchinta r) 33 KV SS Atmakur s) 33 KV SS Peddakadmoor

Location - 1X50+1X31 132 KV SS Makthal 81.5 5 -- 53 .5 Injection 132KV a) Makthal Points SS b) 33 KV SS Jaklair

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 103

SOLAR RFS BID DOCUMENT

c) 33 KV SS Bijwar d) 33 KV SS Narva e) 33 KV SS Narayanpet f) 33 KV SS Utkoor g) 33 KV SS Pasupula h) 33 KV SS Mushtipally i) 33 KV SS Gudeballore j) 33 KV SS Kolpur k) 33 KV SS Maganoor l) 33 KV SS Krishna

Location - 132 KV SS Kodangal 2X31.5 63 5 -- 54 Injection 132KV a) Kodangal Points SS b) 33 KV SS Dudyal c) 33 KV SS Kosigi d) 33 KV SS Kodangal e) 33 KV SS Ravulapally f) 33 KV SS Doultabad g) 33 KV SS Suraipally h) 33 KV SS Sarjakhanpet i) 33 KV SS Hamsanpally

Location - 1X50+2X31 132 KV SS Balanagar 113 10 -- 55 .5 Injection 132KV a) Balanagar Points SS b) 33 KV SS Chinchode c) 33 KV SS Peddarevally d) 33 KV SS Thommidirekula e) 33 KV SS Balanagar f) 33 KV SS Rajapur g) 33 KV SS Polepally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 104

SOLAR RFS BID DOCUMENT

h) 33 KV SS Kollur i) 33 KV SS Udityal j) 33 KV SS Yedira k) 33 KV SS Raikal l) 33 KV SS Gantlavelly m) 33 KV SS Dooskal n) 33 KV SS Gundlapotlapally

Location - 132 KV SS Achampet 2X31.5 63 5 -- 56 Injection 132KV a) Achampet Points SS b) 33 KV SS Lingal c) 33 KV SS Kondanagula d) 33 KV SS Inole e) 33 KV SS Amrabad f) 33 KV SS Vankeshwaram g) 33 KV SS Hajipur h) 33 KV SS Uppununthala i) 33 KV SS Veltoor j) 33 KV SS Mannewaripally

Location - 132 KV SS Amangal 2X31.5 63 10 -- 57 Injection 132KV a) Amangal Points SS b) 33 KV SS Madgul c) 33 KV SS Nagilla d) 33 KV SS Arkepally e) 33 KV SS Polepally f) 33 KV SS Irvin g) 33 KV SS Akutotapally h) 33 KV SS Amangal i) 33 KV SS Kadthal

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 105

SOLAR RFS BID DOCUMENT

j) 33 KV SS Mudwin k) 33 KV SS Karkalpad l) 33 KV SS Talakondapally m) 33 KV SS Chukapur n) 33 KV SS Raviched

Location - 2X31.5+1X 132 KV SS Kalwakurthy 113 10 -- 58 50 Injection 132KV a) Kalwakurthy Points SS b) 33 KV SS Sirsangandla c) 33 KV SS Tandra d) 33 KV SS Jajala e) 33 KV SS Polkampally f) 33 KV SS Gundoor g) 33 KV SS Ellikal h) 33 KV SS Totapally i) 33 KV SS Dindichintapally j) 33 KV SS Veldanda k) 33 KV SS Peddapur l) 33 KV SS Bollampally m) 33 KV SS Rachur n) 33 KV SS Madaram o) 33 KV SS Marchala p) 33 KV SS Jaknalpally q) 33 KV SS Urkonda r) 33 KV SS Gattuippalapally s) 33 KV SS Juppally t) 33 KV SS Vangoor u) 33 KV SS Sarvareddypally v) 33 KV SS Kalwakurthy

Location - 132 KV SS Midjil 2X16 32 5 -- 59

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 106

SOLAR RFS BID DOCUMENT

Injection 132KV a) Midjil Points SS b) 33 KV SS Velgomula c) 33 KV SS Kothapally d) 33 KV SS Kodgal e) 33 KV SS Konded f) 33 KV SS Avancha g) 33 KV SS Donur h) 33 KV SS Vemula i) 33 KV SS Veljal j) 33 KV SS Keshampet k) 33 KV SS Midjil

Location - 132 KV SS Marikal 2X31.5 63 5 -- 60 Injection 132KV a) Marikal Points SS b) 33 KV SS Kondapur c) 33 KV SS Deverkadra d) 33 KV SS Sanginonipally e) 33 KV SS Nagaram Gate f) 33 KV SS Eklaspur g) 33 KV SS Waddeman h) 33 KV SS Marikal i) 33 KV SS Dhanwada j) 33 KV SS Chinnajatram k) 33 KV SS Kotakonda l) 33 KV SS Koukuntla m) 33 KV SS Krishna MEDAK Location - 1X50+1X31 132 KV SS Sadasivapet 81.5 15 -- 61 .5 Injection 132KV a) Sadasivapet Points SS b) 33 KV SS Nizampur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 107

SOLAR RFS BID DOCUMENT

c) 33 KV SS Athmakur d) 33 KV SS Jackwell e) 33 KV SS Munipally f) 33 KV SS Tatipally g) 33 KV SS Aroor h) 33 KV SS Kamkole i) 33 KV SS Sadasivpet j) 33 KV SS Kohir k) 33 KV SS Bilalpur

Location - 132 KV SS Gajwal 2X50 100 10 -- 62 Injection 132KV a) Gajwel Points SS b) 33 KV SS Gowraram c) 33 KV SS Wargal d) 33 KV SS Markook e) 33 KV SS Adavimajeedpally f) 33 KV SS Karkapatla g) 33 KV SS Mulugu h) 33 KV SS Wantimamidi i) 33 KV SS B.V. Poor j) 33 KV SS Bejgam k) 33 KV SS Ahmedipur l) 33 KV SS Nimtoor m) 33 KV SS Begumpet n) 33 KV SS Wardharajpur o) 33 KV SS Jagadevpur p) 33 KV SS Munigadapa q) 33 KV SS Chatlapally r) 33 KV SS Gajwel s) 33 KV SS Pregnapur t) 33 KV SS Ganeshpally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 108

SOLAR RFS BID DOCUMENT

u) 33 KV SS Kodakandla

Location - 132 KV SS Kandi 2X50 100 5 -- 63 Injection 132KV a) Kandi Points SS b) 33 KV SS Sangareddy - I c) 33 KV SS Sangareddy - II d) 33 KV SS Collector Complex e) 33 KV SS Cheryal f) 33 KV SS Ismailkhan Pet g) 33 KV SS Kondapur h) 33 KV SS Malkapur i) 33 KV SS Gollapally j) 33 KV SS Nandi gama k) 33 KV SS T K Pur l) 33 KV SS Gundla Machnoor m) 33 KV SS Rudraram

Location - 1X31.5+1X 132 KV SS Kowdipally 47.5 5 -- 64 16 Injection 132KV a) Kowdipally Points SS b) 33 KV SS Kulcharam c) 33 KV SS Amsanpally d) 33 KV SS Kowdipally e) 33 KV SS Kanchanpally f) 33 KV SS Rangampet g) 33 KV SS Venkatraopet h) 33 KV SS Siripura i) 33 KV SS Bujarampet j) 33 KV SS Rajipet k) 33 KV SS Salabathpur l) 33 KV SS Waddepally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 109

SOLAR RFS BID DOCUMENT

m) 33 KV SS Yenigandla

Location - 1X50+1X31 132 KV SS Manoharabad 81.5 15 -- 65 .5 Injection 132KV a) Manoharabad Points SS b) 33 KV SS Imampur c) 33 KV SS Toopran d) 33 KV SS Danthanpally e) 33 KV SS Nagulapally f) 33 KV SS Sikindlapur g) 33 KV SS Shivampet Chinna Gotti h) 33 KV SS Mukkala i) 33 KV SS Panbanda j) 33 KV SS Manoharabad k) 33 KV SS Kallakal l) 33 KV SS Nacharam m) 33 KV SS Islampur n) 33 KV SS Chetla Gowraram o) 33 KV SS Muppireddypally

Location - 132 KV SS Zaheerabad 2X31.5 63 10 -- 66 Injection 132KV a) Zaheerabad Points SS b) 33 KV SS Zaheerabad Town c) 33 KV SS Hadnoor d) 33 KV SS Raikode e) 33 KV SS Chalki f) 33 KV SS Metal Kunta g) 33 KV SS Nyalkal h) 33 KV SS Mamidgi i) 33 KV SS Singitham j) 33 KV SS Mohabathpur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 110

SOLAR RFS BID DOCUMENT

k) 33 KV SS Digwal l) 33 KV SS Aligole m) 33 KV SS Jharasangam n) 33 KV SS Machnoor o) 33 KV SS Mannapur p) 33 KV SS Malchelma q) 33 KV SS Chota Hyderabad r) 33 KV SS Sathwar

Location - 1X50+1X31 132 KV SS Gummadiddala 81.5 5 -- 67 .5 Injection 132KV a) Gummadidala Points SS b) 33 KV SS Kanukunta c) 33 KV SS Vishal Projects d) 33 KV SS Nallavally e) 33 KV SS Bonthapally f) 33 KV SS Solakpally g) 33 KV SS Jinnaram h) 33 KV SS Dundigal

Location - 132 KV SS Narayanakhed 2X31.5 63 10 -- 68 Injection 132KV a) Narayanakhed Points SS b) 33 KV SS Bodagattu c) 33 KV SS Shankarampet d) 33 KV SS Nizampet e) 33 KV SS Burugupally f) 33 KV SS Hanmanthraopet g) 33 KV SS Narayankhed h) 33 KV SS Manoor i) 33 KV SS Poosalpad j) 33 KV SS Borancha

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 111

SOLAR RFS BID DOCUMENT

k) 33 KV SS Regode l) 33 KV SS Karasgutti m) 33 KV SS Wasar n) 33 KV SS Thadkal o) 33 KV SS Kangti p) 33 KV SS Ryakal q) 33 KV SS Kalher r) 33 KV SS Bachepally s) 33 KV SS Fathepur t) 33 KV SS Sirgapoor u) 33 KV SS Sanjeevraopet

Location - 132 KV SS Medak 2X31.5 63 10 -- 69 Injection 132KV a) Medak Points SS b) 33 KV SS Pillikotyal c) 33 KV SS NSF d) 33 KV SS Ch.Ghanapur e) 33 KV SS B Bhoopathipur f) 33 KV SS Wadi g) 33 KV SS Thogita h) 33 KV SS Sardana i) 33 KV SS Pathur j) 33 KV SS Nagapur k) 33 KV SS M.Bhupathipur l) 33 KV SS Rajpally m) 33 KV SS Ch.Shankarampet n) 33 KV SS Gavvalapally o) 33 KV SS Suraram p) 33 KV SS Shalipet

Location - 1X31.5+1X 132 KV SS Tukkapur 81.5 10 -- 70 50

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 112

SOLAR RFS BID DOCUMENT

Injection 132KV a) Tukkapur Points SS b) 33 KV SS Mirdoddy c) 33 KV SS Jangapally d) 33 KV SS Khajipur e) 33 KV SS Pedda Chepyal f) 33 KV SS Thukkapur g) 33 KV SS Mettu h) 33 KV SS Gudikandula i) 33 KV SS Lingapur j) 33 KV SS Pallepahad k) 33 KV SS Thoguta l) 33 KV SS Gurralasofa m) 33 KV SS Raipole n) 33 KV SS Ramsagar o) 33 KV SS Dommat p) 33 KV SS Mubaraspur q) 33 KV SS Doulthabad r) 33 KV SS Mohd.Shapur s) 33 KV SS Govindapur

Location - 132 KV SS Chegunta 2X50 100 10 -- 71 Injection 132KV a) Chegunta Points SS b) 33 KV SS Bonala c) 33 KV SS Narlapur d) 33 KV SS Karnalpally e) 33 KV SS Kalwakunta f) 33 KV SS Narsingi g) 33 KV SS D.Dharmaram h) 33 KV SS Chandaipet i) 33 KV SS Masaipet j) 33 KV SS Yeldurthy

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 113

SOLAR RFS BID DOCUMENT

k) 33 KV SS Ramaipally l) 33 KV SS Chegunta

Location - 132 KV SS Narsapur 2X31.5 63 10 -- 72 Injection 132KV a) Narsapur Points SS b) 33 KV SS Lingapur c) 33 KV SS Reddypally d) 33 KV SS Chippalthurthy e) 33 KV SS Kothapet f) 33 KV SS Kagazmaddur g) 33 KV SS Mangalparthy h) 33 KV SS Avancha i) 33 KV SS Nasthipur j) 33 KV SS Hathnoora

Location - 132 KV SS Habsipur 2X31.5 63 10 -- 73 Injection 132KV a) Habsipur Points SS b) 33 KV SS Dubbak c) 33 KV SS Pedda Cheekode d) 33 KV SS Chellapur e) 33 KV SS Gambheerpur f) 33 KV SS Dharmajipet g) 33 KV SS Raghothampally h) 33 KV SS Chittapur i) 33 KV SS Pothareddypet j) 33 KV SS Rudraram k) 33 KV SS Habsipur

Location - 132 KV SS Ramayapet 2X16 32 10 -- 74 Injection a) 132KV Ramayampet

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 114

SOLAR RFS BID DOCUMENT

Points SS b) 33 KV SS Zapthi Shivanur c) 33 KV SS Nizampet d) 33 KV SS Konapur e) 33 KV SS Naskal f) 33 KV SS Katriyal g) 33 KV SS Laxmapur

Location - 132 KV SS Pedda Shankarampeta 1X16 16 10 -- 75 Injection 132KV Pedda a) Points SS Shankarampeta

Location - 132 KV SS Minpur 2X16 32 10 -- 76 Injection 132KV a) Minpur Points SS b) 33 KV SS Podchan pally c) 33 KV SS Kothaipally d) 33 KV SS Minpur e) 33 KV SS Kodapak f) 33 KV SS Narsingi g) 33 KV SS Tekmal h) 33 KV SS Achnapally i) 33 KV SS P.Lingaipaly j) 33 KV SS Palvancha (Dhanoora) k) 33 KV SS Kaduloor RANGA REDDY Location - 1X31.5+2X 132 KV SS Medchal 131.5 5 -- 77 50 Injection 132KV a) Medchal Points SS b) 33 KV SS Kistapur c) 33 KV SS Ravalkole d) 33 KV SS Keshavaram

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 115

SOLAR RFS BID DOCUMENT

e) 33 KV SS Kolthur f) 33 KV SS Laxmapur g) 33 KV SS Uddamarry h) 33 KV SS ICICI i) 33 KV SS Turkapally j) 33 KV SS Medicity k) 33 KV SS Athiwelly l) 33 KV SS Yellempet m) 33 KV SS Bandamadaram n) 33 KV SS Gowdawelly o) 33 KV SS GP Pally p) 33 KV SS Deveryamjal

Location - 132 KV SS 2X31.5 63 10 -- 78 Dharmasagar(Chervella) Injection 132KV Dharmasagar a) Points SS (Chevella)

b) 33 KV SS Kandawada c) 33 KV SS Shabad d) 33 KV SS Chandanvally e) 33 KV SS Tallapally f) 33 KV SS Bobbiligaon g) 33 KV SS Aloor h) 33 KV SS Kowkuntla i) 33 KV SS Devunieravally

Location - 1x31.5+1x1 132 KV SS Puttapahad 47.5 10 -- 79 6 Injection 132KV a) Puttapahad Points SS b) 33 KV SS Chowdapur c) 33 KV SS Marikal d) 33 KV SS Puttapahad e) 33 KV SS Mohmmadabad

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 116

SOLAR RFS BID DOCUMENT

f) 33 KV SS Salkarpet g) 33 KV SS Mumbapur h) 33 KV SS Nancherla i) 33 KV SS Veenuchedu j) 33 KV SS Dirsampally k) 33 KV SS Gundal l) 33 KV SS Doma m) 33 KV SS Mujahidpur n) 33 KV SS Mothukuru o) 33 KV SS Kulkacherla

Location - 132 KV SS Turkayamjal 2x31.5 63 10 -- 80 (Hayatnagar) Injection 132KV Turkayamjal a) Points SS (Hayatnagar) b) 33 KV SS Vanasthalipuram c) 33 KV SS Turkayamzal

Location - 132 KV SS Pargi 2x31.5 63 10 -- 81 Injection 132KV a) Pargi Points SS b) 33 KV SS Manneguda c) 33 KV SS Peddumenthol d) 33 KV SS Siddalur e) 33 KV SS Pargi f) 33 KV SS Rapole g) 33 KV SS Rangampally HYDERABAD Location - Swt. 132 KV SS Vikarabad Swt. Sn 15 -- 82 Sn Injection 132KV a) Vikarabad Points SS

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 117

SOLAR RFS BID DOCUMENT

NALGONDA Location - 1x50+2x31. 132 KV SS Nalgonda 113 15 -- 83 5 Injection 132KV a) Nalgonda Points SS b) 33 KV SS Pole Centre c) 33 KV SS Panagal d) 33 KV SS SLBC e) 33 KV SS Velugupally f) 33 KV SS Mushampally g) 33 KV SS P.D.Pally h) 33 KV SS Narsingbatla i) 33 KV SS Appajipeta j) 33 KV SS Anneparthy k) 33 KV SS Indoor l) 33 KV SS Gollaguda m) 33 KV SS Rayanaguda n) 33 KV SS Pazzur o) 33 KV SS Rajupet p) 33 KV SS Ch.Mamidi q) 33 KV SS Gudapur r) 33 KV SS Kattangur s) 33 KV SS Aitipamula t) 33 KV SS Pamanagundla

Location - 132 KV SS Alair (Kolanupak) 2x50 100 15 -- 84 Injection 132KV a) Alair(Kolanupak) Points SS b) 33 KV SS Motakonduru c) 33 KV SS Shaharajpeta d) 33 KV SS Bhachannapeta

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 118

SOLAR RFS BID DOCUMENT

e) 33 KV SS Raghunathpuram f) 33 KV SS Yadagirigutta g) 33 KV SS Suddala h) 33 KV SS Alair i) 33 KV SS Rajapeta

Location - 1x16+1x31. 132 KV SS Wadapally 47.5 10 -- 85 5 Injection 132KV a) Wadapally Points SS b) 33 KV SS Dameracherla c) 33 KV SS A.D.Pally(U.P) d) 33 KV SS K.N.Konda e) 33 KV SS Janpahad

Location - 2x50+1x31. 132 KV SS K.Mallepally 131.5 5 -- 86 5 Injection 132KV a) K.Mallepally Points SS b) 33 KV SS Pulicharla c) 33 KV SS Deverakonda d) 33 KV SS K.M.Pally e) 33 KV SS Padmatipally f) 33 KV SS Mudigonda g) 33 KV SS Singarajpally h) 33 KV SS Palvai i) 33 KV SS Junuthala j) 33 KV SS Chandampet k) 33 KV SS Teldeverapally l) 33 KV SS Cherkupally m) 33 KV SS Yerraram n) 33 KV SS Chinthapally o) 33 KV SS Madnapur p) 33 KV SS Teededu

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 119

SOLAR RFS BID DOCUMENT

q) 33 KV SS Nampally r) 33 KV SS Mellavai s) 33 KV SS Angadipet t) 33 KV SS Ghanpur u) 33 KV SS Dugyala v) 33 KV SS Puttamgandi w) 33 KV SS Azmapur x) 33 KV SS Kothapally

Location - 132 KV SS Suryapet 2x80 160 20 -- 87 Injection 132KV a) Suryapet Points SS b) 33 KV SS Repala c) 33 KV SS Mamillagudem d) 33 KV SS Sirikonda e) 33 KV SS Suryapet(Jammigadd a) f) 33 KV SS IndlEstate g) 33 KV SS Penpahad h) 33 KV SS S.V.College i) 33 KV SS Kasarabad j) 33 KV SS Cheedella k) 33 KV SS GTGiri l) 33 KV SS Nuthankal m) 33 KV SS Athmakur n) 33 KV SS Yerkaram o) 33 KV SS Koduru p) 33 KV SS Kandhagatla q) 33 KV SS Chandupatla r) 33 KV SS Aipoor s) 33 KV SS Tekumatla t) 33 KV SS Kethepally u) 33 KV SS Koppole(K)

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 120

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Ramannapet 2x50 100 10 -- 88 Injection 132KV a) Ramannapet Points SS b) 33 KV SS Narketpally c) 33 KV SS Chityala d) 33 KV SS Veliminedu e) 33 KV SS Aregudem f) 33 KV SS Urumadla g) 33 KV SS Ramannapet h) 33 KV SS Yellanki i) 33 KV SS Laxmapur j) 33 KV SS Yennram k) 33 KV SS Iskilla l) 33 KV SS Aroor m) 33 KV SS Puligilla n) 33 KV SS Valigonda o) 33 KV SS Gollenepally

Location - 132 KV SS 2x31.5 63 15 -- 89 Huzurnagar(Matampally) Injection 132KV Huzurnagar a) Points SS (Mattampalli) b) 33 KV SS Mattapally c) 33 KV SS Mattamaplly d) 33 KV SS Raghunadhapalerm e) 33 KV SS Pedaveedu f) 33 KV SS BheelayanaikThanda

Location - 1x50+1x31. 132 KV SS Shaligouraram 81.5 15 -- 90 5 Injection 132KV a) Shaligouraram Points SS b) 33 KV SS Akkenapally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 121

SOLAR RFS BID DOCUMENT

c) 33 KV SS Arvapally d) 33 KV SS Nagaram e) 33 KV SS Wangamarthy f) 33 KV SS Nakrekal g) 33 KV SS Palem h) 33 KV SS ChervuAnnaram i) 33 KV SS Bairavonibanda j) 33 KV SS Akaram k) 33 KV SS Eeduluru l) 33 KV SS S.Gowraram m) 33 KV SS Arlagaddagudem n) 33 KV SS Marror o) 33 KV SS Addaguduru p) 33 KV SS Azeempet

Location - 132 KV SS Choutuppal 2x31.5 63 10 -- 91 Injection 132KV a) Choutuppal Points SS b) 33 KV SS Narayanpur c) 33 KV SS Jangam d) 33 KV SS Survail e) 33 KV SS Choutuapapl f) 33 KV SS D.Nagaram g) 33 KV SS Varkatpally

Location - 1x16+1x31. 132 KV SS Halia 47.5 5 -- 92 5 Injection 132KV a) Halia Points SS b) 33 KV SS Nidmanoor c) 33 KV SS Haliya d) 33 KV SS Rajavaram e) 33 KV SS Pulimamidi

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 122

SOLAR RFS BID DOCUMENT

f) 33 KV SS Yacharam g) 33 KV SS Peddavoora h) 33 KV SS Pottichelma i) 33 KV SS Nellikal j) 33 KV SS Velmagudem

Location - 1x31.5+1x1 132 KV SS Kodad 47.5 10 93 6 Injection 132KV a) Kodad Points SS b) 33 KV SS KodadIndoor c) 33 KV SS Bethovolu d) 33 KV SS Ananthagiri e) 33 KV SS N.B.Gudem f) 33 KV SS Gondriyala g) 33 KV SS Munagala h) 33 KV SS Akupamula i) 33 KV SS Nadigudem j) 33 KV SS siripuram

Location - 132 KV SS Tungathurthy 2x31.5 63 5 -- 94 Injection 132KV a) Tungathurthy Points SS b) 33 KV SS Ravulapally c) 33 KV SS Reddygudem d) 33 KV SS Dirshanapally e) 33 KV SS Thungaturthy f) 33 KV SS Annaram g) 33 KV SS Gundepuri h) 33 KV SS Phanigiri i) 33 KV SS Thirumalagiri j) 33 KV SS Jalalpuram

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 123

SOLAR RFS BID DOCUMENT

Location - 1x31.5+1x1 132 KV SS Madugulapalli 47.5 5 -- 95 6 Injection 132KV a) Madugulapalli Points SS b) 33 KV SS Jalalpuram c) 33 KV SS Thipparthy d) 33 KV SS Chervupally e) 33 KV SS Madugulapally f) 33 KV SS Mamidala g) 33 KV SS V.K.Palem h) 33 KV SS Settipalem i) 33 KV SS Buggabaigudem j) 33 KV SS Agamothkur k) 33 KV SS Thadakamalla l) 33 KV SS Laxmideviguda m) 33 KV SS Seetyathanda n) 33 KV SS Cherukupally

Location - 1x31.5+1x1 132 KV SS Mothukur 47.5 5 -- 96 6 Injection 132KV a) Mothukur Points SS b) 33 KV SS Gundala c) 33 KV SS Peddapatashala d) 33 KV SS Ambala e) 33 KV SS Paladugu f) 33 KV SS Pallerla g) 33 KV SS Chamapur h) 33 KV SS Athmakur

Location - 1x31.5+1x1 132 KV SS Marriguda 47.5 5 -- 97 6 Injection 132KV a) Marriguda Points SS b) 33 KV SS Chandur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 124

SOLAR RFS BID DOCUMENT

c) 33 KV SS Pullemla d) 33 KV SS Gattuppal e) 33 KV SS Marriguda f) 33 KV SS Shivannaguda g) 33 KV SS D.B.Pally

Location - 1x31.5+1x1 132 KV SS Kanagal 47.5 5 -- 98 6 Injection 132KV a) Kanagal Points SS b) 33 KV SS G.Yedavelly c) 33 KV SS Pagidimarry d) 33 KV SS Thimmanaguda e) 33 KV SS Thoragal f) 33 KV SS Gurrampode g) 33 KV SS Pochampally h) 33 KV SS Koppole

Location - 132 KV SS Guntipally 1x16 16 5 99 Injection 132KV a) Guntipally Points SS

Location - 132 KV SS Dirsincherla 2x16 32 5 -- 100 Injection 132KV a) Dirsincherlla Points SS b) 33 KV SS Palakeedu c) 33 KV SS Alingapuram d) 33 KV SS Garidepally e) 33 KV SS Keethavarigudem

KHAMMAM Location - 1x31.5+1x1 132 KV SS Aswaraopet 47.5 10 -- 101 6

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 125

SOLAR RFS BID DOCUMENT

Injection 132KV a) Aswaraopeta Points SS b) 33 KV SS Naramvarigudem c) 33 KV SS Dammapeta d) 33 KV SS Malkaram e) 33 KV SS Naidupeta f) 33 KV SS Vinayakapuram g) 33 KV SS Gangaram(B)

Location - 1x31.5+1x1 132 KV SS Kusumanchi 47.5 10 102 6 Injection 132KV a) Kusumanchi Points SS b) 33 KV SS N.S.Gudem c) 33 KV SS Bachodu d) 33 KV SS Kakaravai e) 33 KV SS Perikasingaram f) 33 KV SS Kusumanc hi g) 33 KV SS Banapuram h) 33 KV SS Vallabhi i) 33 KV SS Pammi j) 33 KV SS Madhapuram k) 33 KV SS N.K.Pally l) 33 KV SS Buddaram m) 33 KV SS R.J.Puram n) 33 KV SS Jellacheruvu o) 33 KV SS Palair p) 33 KV SS Patharlapadu q) 33 KV SS Tippareddygudem r) 33 KV SS Sublaid

Location - 132 KV SS Penubaily 2x31.5 63 10 -- 103 Injection 132KV a) penubaily Points SS

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 126

SOLAR RFS BID DOCUMENT

b) 33 KV SS Gowravaram c) 33 KV SS Maddukuru d) 33 KV SS Chandrugonda e) 33 KV SS Brahmanakunta f) 33 KV SS Pedakorikondi g) 33 KV SS Kurnavalli h) 33 KV SS Kalluru i) 33 KV SS Enkoor j) 33 KV SS SS Palam k) 33 KV SS Raidupalam l) 33 KV SS Kandukuru m) 33 KV SS Vemsoor n) 33 KV SS Marlakunta o) 33 KV SS Guduru p) 33 KV SS Penubally q) 33 KV SS Sathupally r) 33 KV SS Gowrigudem

Location - 1x16+1x31. 132 KV SS Bhadrachalam 47.5 10 -- 104 5 Injection 132KV a) Bhadrachalam Points SS b) 33 KV SS Burgampadu c) 33 KV SS Sarapaka d) 33 KV SS Charla e) 33 KV SS S.N.Puram f) 33 KV SS Wazeedu g) 33 KV SS Dharamavaram h) 33 KV SS Venkatapuram i) 33 KV SS Suraveedu j) 33 KV SS Chintoor k) 33 KV SS Sarivella l) 33 KV SS Nellipaka

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 127

SOLAR RFS BID DOCUMENT

m) 33 KV SS Dummugudem n) 33 KV SS Kunavaram

Location - 132 KV SS Madhira 2x16 32 5 105 Injection 132KV a) Madhira Points SS b) 33 KV SS Bonakal c) 33 KV SS K.I.Padu d) 33 KV SS Siripuram e) 33 KV SS Yerrupalam f) 33 KV SS Mamunoor g) 33 KV SS Mulugumadu

Location - 1x16+1x31. 132 KV SS Gangaram 47.5 5 106 5 Injection 132KV a) Gangaram Points SS b) 33 KV SS Pakalagudem c) 33 KV SS Ankampalam d) 33 KV SS Nagupally e) 33 KV SS Gandugulapally f) 33 KV SS Mulakalapally

Location - 132 KV SS Yellandu 2x16 32 10 -- 107 Injection 132KV a) Yellandu Points SS b) 33 KV SS Garla c) 33 KV SS Kothapeta d) 33 KV SS Bayyaram e) 33 KV SS ChallaSamudram f) 33 KV SS Mamakannu g) 33 KV SS Tekulapally h) 33 KV SS Karepally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 128

SOLAR RFS BID DOCUMENT

i) 33 KV SS Cheemalapadu j) 33 KV SS Komararam Location - 1x31.5+1x5 132 KV SS 81.5 5 -- 108 0 Injection 132KV a) Nekkonda Points SS b) 33 KV SS Nagaram c) 33 KV SS Teegalaveni d) 33 KV SS Upparapalli e) 33 KV SS f) 33 KV SS Gudur g) 33 KV SS Kesamudram h) 33 KV SS Lingagiri i) 33 KV SS Nekkonda j) 33 KV SS Rangapur k) 33 KV SS Alankanipeta l) 33 KV SS m) 33 KV SS Enugallu n) 33 KV SS Parwathagiri o) 33 KV SS Redlawada p) 33 KV SS Sangem q) 33 KV SS Theegarajpally

Location - 1x31.5+1x5 132 KV SS Mustyal 81.5 10 -- 109 0 Injection 132KV a) Mustyal Points SS b) 33 KV SS Bachannapet c) 33 KV SS Laxmapur Padamati d) 33 KV SS Keshavapur e) 33 KV SS Ramchandrapuram f) 33 KV SS Akunoor g) 33 KV SS Bekkal h) 33 KV SS Chityal

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 129

SOLAR RFS BID DOCUMENT

i) 33 KV SS Dhoolmitta j) 33 KV SS Mustyal k) 33 KV SS Guruvannapet l) 33 KV SS Komuravelly m) 33 KV SS Nagapuri n) 33 KV SS Ankushapur o) 33 KV SS Rebarthy p) 33 KV SS Tharigoppula q) 33 KV SS Veldanda

Location - 1x16+1x31. 132 KV SS Chelpur 47.5 5 -- 110 5 Injection 132KV a) Chelpur Points SS b) 33 KV SS Gudadpally c) 33 KV SS Jadalpeta d) 33 KV SS Bhoopalpally e) 33 KV SS Nandigama f) 33 KV SS Bagirthipeta g) 33 KV SS (T) h) 33 KV SS Regonda i) 33 KV SS Repaka

Location - 1x31.5+1x5 132 KV SS Waradannapet 81.5 10 -- 111 0 Injection 132KV a) Waradannapet Points SS b) 33 KV SS Kondur c) 33 KV SS d) 33 KV SS Dammanapet e) 33 KV SS Kunoor f) 33 KV SS Venkatapur g) 33 KV SS Zafferghad h) 33 KV SS Annram Shariff

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 130

SOLAR RFS BID DOCUMENT

i) 33 KV SS Liabarthy j) 33 KV SS Mylaram k) 33 KV SS Ellanda l) 33 KV SS Nandanam m) 33 KV SS Panthini n) 33 KV SS Wadlakonda

Location - 1x31.5+1x5 132 KV SS Ayyagaripally 81.5 10 -- 112 0 Injection 132KV a) Ayyagaripally Points SS b) 33 KV SS Amangal c) 33 KV SS Chenigapuram d) 33 KV SS Chinnaguduru e) 33 KV SS Inugurthy f) 33 KV SS Kalwala g) 33 KV SS Dornakal h) 33 KV SS Jamandlapally i) 33 KV SS Bodhugonda j) 33 KV SS Mogilicherla k) 33 KV SS Nerada l) 33 KV SS Edjerla m) 33 KV SS Giripuram n) 33 KV SS Maripeda o) 33 KV SS Gollacherla p) 33 KV SS Mannegudem q) 33 KV SS P'Sankeesa r) 33 KV SS Upparagudem

Location - 132 KV SS Madikonda 2x31.5 63 10 -- 113 (Waddepalli) Injection 132KV a) Madikonda Points SS b) 33 KV SS Dharmasagar

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 131

SOLAR RFS BID DOCUMENT

c) 33 KV SS Jayagiri d) 33 KV SS Mallikudurla e) 33 KV SS Narayanagiri f) 33 KV SS Velair

g) 33 KV SS Gopalpur

h) 33 KV SS KUC

i) 33 KV SS Madikonda j) 33 KV SS West City k) 33 KV SS REC l) 33 KV SS Shayampet

Location - 1x16+1x31. 132 KV SS Ghanpur 47.5 5 -- 114 5 Injection 132KV a) Ghanpur Points SS b) 33 KV SS Malkapur c) 33 KV SS Peddapendyal d) 33 KV SS Peechara e) 33 KV SS Rajavaram f) 33 KV SS Gudur (P) g) 33 KV SS Ippagudem h) 33 KV SS Namiligonda i) 33 KV SS Suraram j) 33 KV SS k) 33 KV SS Thatikonda

Location - 132 KV SS Mulugu 3x16 48 10 -- 115 Injection 132KV a) Mulugu Points SS b) 33 KV SS Mallampally c) 33 KV SS Ramchandrapur d) 33 KV SS Abbapur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 132

SOLAR RFS BID DOCUMENT

e) 33 KV SS Gorikothapally f) 33 KV SS Koppula g) 33 KV SS Mulugu h) 33 KV SS Govindraopet i) 33 KV SS Kasimdevipeta j) 33 KV SS Medaram k) 33 KV SS Pasra l) 33 KV SS Laxmidevipeta m) 33 KV SS Peddapur n) 33 KV SS Velthurlapally

Location - 132 KV SS Dharmasagar 2x50+1x16 116 10 116 Injection 132KV a) Dharmasagar Points SS

Location - 1x31.5+1x1 132 KV SS 47.5 5 -- 117 6 Injection 132KV a) Narsampet Points SS b) 33 KV SS Gangaram c) 33 KV SS Kothaguda d) 33 KV SS Mangalavaripet e) 33 KV SS Sadireddypally f) 33 KV SS Dasaripally g) 33 KV SS Medapally h) 33 KV SS i) 33 KV SS Narsampet j) 33 KV SS k) 33 KV SS Elkurthy l) 33 KV SS Mondrai m) 33 KV SS Rekhampally

Location - 132 KV SS Jangaon 2x16 32 10 -- 118

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 133

SOLAR RFS BID DOCUMENT

Injection 132KV a) Obulakeshapur Points SS b) 33 KV SS Adavukeshapur c) 33 KV SS Jangaon-I d) 33 KV SS Jangaon-I e) 33 KV SS Jangaon-II f) 33 KV SS Marigadi g) 33 KV SS Jeedikal h) 33 KV SS Lingala Ghanpur i) 33 KV SS Pemberthy

Location - 132 KV SS Chityala 2x16 32 5 -- 119 Injection 132KV a) Chityal Points SS b) 33 KV SS Rangapur c) 33 KV SS Ramakistapur d) 33 KV SS Tekumatla

Location - 132 KV SS Peddanagaram 2x16 32 5 -- 120 Injection 132KV a) Kousalyadevipally Points SS b) 33 KV SS Kommulavancha c) 33 KV SS Munigalaveedu d) 33 KV SS Pedda Nagaram e) 33 KV SS Danthalapally f) 33 KV SS Peddamupparam g) 33 KV SS Reponi h) 33 KV SS Yellampet KARIMNAGAR Location - 1x50+1x31. 132 KV SS Korutla 81.5 10 -- 121 5 Injection 132KV a) Korutla Points SS b) 33 KV SS Ambaripeta

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 134

SOLAR RFS BID DOCUMENT

c) 33 KV SS Thandrial d) 33 KV SS Manala e) 33 KV SS Bhushanraopet f) 33 KV SS Korutla Town g) 33 KV SS Paidimadugu h) 33 KV SS Dharmaram i) 33 KV SS Ailapur j) 33 KV SS Vempet k) 33 KV SS Metpally l) 33 KV SS Korutla Town-II m) 33 KV SS Vellulla n) 33 KV SS Athmakur o) 33 KV SS Jaggasagar p) 33 KV SS Bommena q) 33 KV SS Mannegudem r) 33 KV SS Govindaram s) 33 KV SS Yakeenpur

Location - 132 KV SS Sircilla 2x50 100 15 -- 122 Injection 132KV a) Sircilla Points SS b) 33 KV SS Pedur c) 33 KV SS Rallapeta d) 33 KV SS Namapur e) 33 KV SS Pegadapally f) 33 KV SS Boanala g) 33 KV SS Marthanapet h) 33 KV SS Nizamabad i) 33 KV SS Textile Park j) 33 KV SS Thangallapally k) 33 KV SS Shivanagar l) 33 KV SS Nerella

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 135

SOLAR RFS BID DOCUMENT

m) 33 KV SS Avunoor n) 33 KV SS Nampally o) 33 KV SS Ramvaram p) 33 KV SS Vankupally

Location - 1x50+1x31. 132 KV SS Jagityal 81.5 10 -- 123 5 Injection 132KV a) Jagityal Points SS b) 33 KV SS Allipur c) 33 KV SS Kothakonda d) 33 KV SS Itikyal e) 33 KV SS Voddelingapur f) 33 KV SS Chelgal g) 33 KV SS Venakatraopet h) 33 KV SS Medipally i) 33 KV SS Venkatapur j) 33 KV SS Jagitial k) 33 KV SS Polasa l) 33 KV SS Laxmipur m) 33 KV SS Pegadapally n) 33 KV SS T.R.Nagar

Location - 132 KV SS Husnabad 2x31.5 63 5 -- 124 Injection 132KV a) Husnabad Points SS b) 33 KV SS Gandipally c) 33 KV SS Gouravelly d) 33 KV SS Vangara e) 33 KV SS Potharam f) 33 KV SS Kothakonda g) 33 KV SS Samudrala h) 33 KV SS Indurthy

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 136

SOLAR RFS BID DOCUMENT

i) 33 KV SS Rekonda

Location - 132 KV SS Sultanabad 2x31.5 63 5 -- 125 (Suglampally) Injection 132KV Sultanabad(Suglampa a) Points SS lly ) b) 33 KV SS Eligedu c) 33 KV SS Julapally d) 33 KV SS Kachapur e) 33 KV SS Rangampally f) 33 KV SS Raghavapur g) 33 KV SS Peddapally (T) h) 33 KV SS Maredugonda i) 33 KV SS Bojannapet j) 33 KV SS Jafferkhanpet k) 33 KV SS Pegadapally l) 33 KV SS Kolanur m) 33 KV SS Pothkapally n) 33 KV SS Chinnabonkur o) 33 KV SS Kanagarthy p) 33 KV SS Odela q) 33 KV SS Sultanabad

Location - 1x16+1x31. 132 KV SS Huzurabad 47.5 5 -- 126 5 Injection 132KV a) Huzurabad Points SS b) 33 KV SS Godishala c) 33 KV SS Kothagattu d) 33 KV SS Thadikal e) 33 KV SS Uppal f) 33 KV SS Peddapapaiahpally g) 33 KV SS Elkathurthy

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 137

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Mallaram 2x16 32 5 -- 127 Injection 132KV a) Mallaram Points SS b) 33 KV SS Baosaipet c) 33 KV SS Mallaram d) 33 KV SS Marrigadda e) 33 KV SS Vemulawada f) 33 KV SS Nimmapalli g) 33 KV SS Sanugula h) 33 KV SS Bejjanki

Location - 1x31.5+1x1 132 KV SS Ellantakunta 47.5 10 128 6 Injection 132KV a) Ellantakunta Points SS b) 33 KV SS Peddalingapur c) 33 KV SS Kasimpet d) 33 KV SS Somarampet

Location - 132 KV SS Dharmapuri 2x16 32 5 -- 129 Injection 132KV a) Dharmapuri Points SS b) 33 KV SS Sirikonda c) 33 KV SS Jaina d) 33 KV SS Nerella

Location - 132 KV SS Pudur 2x16 32 5 130 Injection 132KV a) Pudur Points SS b) 33 KV SS Thatipally c) 33 KV SS Bathikepally d) 33 KV SS Kodimyal e) 33 KV SS Maddutla

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 138

SOLAR RFS BID DOCUMENT

f) 33 KV SS Burugupally

Location - 132 KV SS Yellareddypeta 1x25+1x16 41 5 131 Injection 132KV a) Yellareddypeta Points SS b) 33 KV SS Lingannapet c) 33 KV SS Kothapally d) 33 KV SS Gajasingaram e) 33 KV SS Garjanapally f) 33 KV SS Rajannapet g) 33 KV SS Yellareddypet

Location - 132 KV SS Manakondur 2x16 32 5 132 Injection 132KV a) Manakondur Points SS b) 33 KV SS Elbaka c) 33 KV SS Pochampally d) 33 KV SS Chenjerla

Location - 132 KV SS Dharmaram 2x16 32 5 133 Injection 132KV a) Dharmaram Points SS b) 33 KV SS Mallapur c) 33 KV SS Yellapur d) 33 KV SS Kothur e) 33 KV SS Velgatoor f) 33 KV SS Basanthnagar g) 33 KV SS Khilavanaparthy f) 33 KV SS Chilvakodur

Location - 132 KV SS Shanigarm 2x16 32 5 134 Injection a) 132KV Shanigaram

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 139

SOLAR RFS BID DOCUMENT

Points SS b) 33 KV SS Thotapally c) 33 KV SS Begumpet d) 33 KV SS Koheda e) 33 KV SS Ramchandrapur

Location - 132 KV SS Godur 2x16 32 5 -- 135 Injection 132KV a) Godur Points SS b) 33 KV SS Varshakonda c) 33 KV SS Medipally d) 33 KV SS Ragavapuram e) 33 KV SS Mallapur

Location - 132 KV SS Kataram 2x16 32 5 -- 136 Injection 132KV a) Kataram Points SS b) 33 KV SS Maha Mutharam c) 33 KV SS Mahadevpur d) 33 KV SS Peddampet e) 33 KV SS Kaleshwaram f) 33 KV SS Koyyur g) 33 KV SS Gangaram f) 33 KV SS V.V. Raopet

Location - 1x31.5+1x1 132 KV SS RTS 'B' Yellampalli 47.5 5 -- 137 6 Injection 132KV a) RTS 'B' Yellampalli Points SS

Location - 132 KV SS Gangadhra (LIS) 1x50+1x25 75 5 -- 138 Injection 132KV a) Gangadhra(LIS) Points SS

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 140

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Yellampally 2x16 32 5 139 Injection 132KV a) Yellampally Points SS

NIZAMABAD Location - 1x50+1x31. 132 KV SS 81.5 10 140 5 Injection 132KV a) Kamareddy - I Points SS b) 33 KV SS Siricilla Road-KMR c) 33 KV SS Arepally d) 33 KV SS Bhavanipet-M e) 33 KV SS Issaipet f) 33 KV SS Velupugonda g) 33 KV SS Brahmanpally h) 33 KV SS Gandhari i) 33 KV SS Sarvapoor j) 33 KV SS Adloor k) 33 KV SS S.S.Nagar l) 33 KV SS Padmajiwadi m) 33 KV SS n) 33 KV SS Housing Board- KMR o) 33 KV SS Lingapoor p) 33 KV SS Rajampet q) 33 KV SS Chinnamallareddy r) 33 KV SS Tadwai s) 33 KV SS Aragonda t) 33 KV SS Yerrapahad u) 33 KV SS Kondapur v) 33 KV SS Posanipet

Location - 132 KV SS Renjal 1x31.5+1x1 47.5 10 --

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 141

SOLAR RFS BID DOCUMENT

141 6 Injection 132KV a) Renjal Points SS b) 33 KV SS Navipet c) 33 KV SS Dandigutta d) 33 KV SS Rampoor e) 33 KV SS Kosli f) 33 KV SS Yemcha g) 33 KV SS Neela h) 33 KV SS Tadbiloli i) 33 KV SS Pegadapally j) 33 KV SS Ch.Mavandi k) 33 KV SS Saloora l) 33 KV SS A.R.P.Camp m) 33 KV SS Mangalpahad n) 33 KV SS Yedapally o) 33 KV SS Renjal

Location - 1x50+1x31. 132 KV SS Jakhora 81.5 15 -- 142 5 Injection 132KV a) Jakhora Points SS b) 33 KV SS Srinagar c) 33 KV SS Chandoor d) 33 KV SS Chinthakunta e) 33 KV SS Mosra f) 33 KV SS Jalalpur g) 33 KV SS Kotagiri h) 33 KV SS Pothangal i) 33 KV SS Jakhora (Varni) j) 33 KV SS Nasrullabad k) 33 KV SS Sangam l) 33 KV SS Kalloor m) 33 KV SS Kothapally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 142

SOLAR RFS BID DOCUMENT

n) 33 KV SS Ambam o) 33 KV SS Rudrur p) 33 KV SS Raikur

Location - 1x50+1x31. 132 KV SS Nandipet 81.5 5 -- 143 5 Injection 132KV a) Nandipet Points SS b) 33 KV SS Degoam c) 33 KV SS Manthani d) 33 KV SS Aloor

Location - 132 KV SS Domakonda 2x31.5 63 5 144 Injection 132KV a) Domakonda Points SS b) 33 KV SS Kyasampally c) 33 KV SS Muthyampet d) 33 KV SS Domakonda e) 33 KV SS Laxmidevanpally f) 33 KV SS Jangampally g) 33 KV SS Thippaur h) 33 KV SS Talamadla i) 33 KV SS Narsannapally j) 33 KV SS Janagoan k) 33 KV SS Mohommadapur l) 33 KV SS Bibipet m) 33 KV SS Issanagar n) 33 KV SS Thujalpur o) 33 KV SS Fareedpet p) 33 KV SS Chukkapur q) 33 KV SS Lachapet r) 33 KV SS Annaram s) 33 KV SS Yellampet

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 143

SOLAR RFS BID DOCUMENT

t) 33 KV SS Somavarpet

Location - 1x31.5+1x1 132 KV SS Armoor 47.5 5 145 6 Injection 132KV a) Armoor Points SS b) 33 KV SS Munipally c) 33 KV SS Issapally d) 33 KV SS Ankapoor e) 33 KV SS Pipri f) 33 KV SS Maggidi g) 33 KV SS Komanpally h) 33 KV SS Perkit i) 33 KV SS Govindpet j) 33 KV SS Lakkora k) 33 KV SS Fathepur

Location - 132 KV SS Bichkonda 2x16 32 5 146 Injection 132KV a) Bichkunda Points SS b) 33 KV SS Madnoor c) 33 KV SS Menoor d) 33 KV SS Dongli e) 33 KV SS Peddakodapgal f) 33 KV SS Kemrajkallali g) 33 KV SS Somur h) 33 KV SS Jukkal i) 33 KV SS Pulkal j) 33 KV SS Kathgoan

Location - 132 KV SS Lingapet 2x16 32 5 147 Injection 132KV a) Lingampet Points SS

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 144

SOLAR RFS BID DOCUMENT

b) 33 KV SS Bhavanipet c) 33 KV SS Gandimasanipet d) 33 KV SS Mothe e) 33 KV SS Parmalla f) 33 KV SS Khannapur g) 33 KV SS S.S.Reddy h) 33 KV SS Malthummeda i) 33 KV SS Ramalaxmanpally

Location - 1x31.5+1x1 132 KV SS Morthad 47.5 5 148 6 Injection 132KV a) Morthad Points SS b) 33 KV SS Kammarpally c) 33 KV SS Basheerabad d) 33 KV SS Anksapur e) 33 KV SS Kuknoor f) 33 KV SS Donkal g) 33 KV SS Morthad h) 33 KV SS Palem i) 33 KV SS Uploor j) 33 KV SS Timmapur

Location - 132 KV SS 2x16 32 5 -- 149 Injection 132KV a) Banswada Points SS b) 33 KV SS Damarancha c) 33 KV SS Maddelcheru d) 33 KV SS Shanthapoor e) 33 KV SS Chillargi f) 33 KV SS Birkur g) 33 KV SS Mirzapur h) 33 KV SS Konapur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 145

SOLAR RFS BID DOCUMENT

i) 33 KV SS Ibrahimpet

Location - 132 KV SS Dharmora 2x16 32 5 -- 150 (Gutta LI scheme) Injection 132KV Dharmora(Gutta LI a) Points SS Scheme)

Location - 132 KV SS C.H.Kondur 2x16 32 5 151 (Gutta LI scheme)

Injection 132KV C.H.Kondur(Gutta a) Points SS LI Scheme)

Location - 132 KV SS Bikanoor 2x16 32 5 -- 152 Injection 132KV a) Biknoor Points SS b) 33 KV SS Baswapoor c) 33 KV SS Peddamallareddy d) 33 KV SS Kachapoor e) 33 KV SS Isannapaly f) 33 KV SS Thippapur g) 33 KV SS Talamadla

Location - 132 KV SS Reddypet 2x16 32 5 153 Injection 132KV a) Reddypet Points SS b) 33 KV SS Shasodopur c) 33 KV SS Ramreddy d) 33 KV SS Adloor Location - 132 KV SS Adilabad 2x31.5 63 5 154 Injection 132KV a) Adilabad Points SS

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 146

SOLAR RFS BID DOCUMENT

b) 33 KV SS Bukthapur c) 33 KV SS Rampur d) 33 KV SS G.S.Nagar e) 33 KV SS Kailasnagar f) 33 KV SS Thamsi g) 33 KV SS Talamadugu h) 33 KV SS Arli i) 33 KV SS Ponnari j) 33 KV SS Jainath k) 33 KV SS Bhoraj l) 33 KV SS Sathnala m) 33 KV SS Bela n) 33 KV SS

Location - 132 KV SS Bellampally 1x15+1x16 31 5 -- 155 Injection 132KV a) Bellampally Points SS b) 33 KV SS Andugulpet c) 33 KV SS Kondapoor d) 33 KV SS Nennel e) 33 KV SS Bellampally (T) f) 33 KV SS Rebbana g) 33 KV SS Thandoor h) 33 KV SS Kannepally i) 33 KV SS Ginnedari j) 33 KV SS Thiryani k) 33 KV SS Asifabad l) 33 KV SS Ippal Navegoam m) 33 KV SS Wankidi n) 33 KV SS Kerameri o) 33 KV SS Jankapur p) 33 KV SS Rechini

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 147

SOLAR RFS BID DOCUMENT

q) 33 KV SS Vankulam Shivalayam/Bellamp r) 33 KV SS aly Town

Location - 1x31.5+1x1 132 KV SS Mancherial 47.5 5 -- 156 6 Injection 132KV a) Mancherial Points SS b) 33 KV SS ACC c) 33 KV SS Ramnagar d) 33 KV SS Jaipoor e) 33 KV SS Kundaram f) 33 KV SS Naspoor g) 33 KV SS Hazipoor h) 33 KV SS Ryali Gadpoor i) 33 KV SS RKP j) 33 KV SS Gudipet k) 33 KV SS Awadam l) 33 KV SS RK 6 Huts

Location - 132 KV SS Sirpurkagaznagar 2x16 32 5 157 132KV a) Sirpurkagaznagar SS b) 33 KV SS Kagaz nagar (t) c) 33 KV SS Nazrool nagar d) 33 KV SS jambuga e) 33 KV SS Sirpur(t) f) 33 KV SS Kowtala g) 33 KV SS Ravindranagar h) 33 KV SS Rebbena(B) i) 33 KV SS Beejjur j) 33 KV SS Elkapally

k) 33 KV SS Dahegam

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 148

SOLAR RFS BID DOCUMENT

Location - 132 KV SS 2x31.5 63 5 -- 158 132KV a) BHAINSA SS b) 33 KV SS DEGAON c) 33 KV SS WANALPAD d) 33 KV SS LOHESRA e) 33 KV SS PIPREE f) 33 KV SS ABDULLAPUR g) 33 KV SS MANMAD h) 33 KV SS KALLUR i) 33 KV SS KUNTALA j) 33 KV SS Gollamada k) 33 KV SS KUBEER l) 33 KV SS Sonari m) 33 KV SS Mudhole n) 33 KV SS EDBID o) 33 KV SS BRAHMAN GOAN p) 33 KV SS THANOOR q) 33 KV SS Beltharoda

Location - 132 KV SS Luxettipeta 2x16 32 5 159 -- 132KV a) Luxettipeta SS b) 33 KV SS Suraram c) 33 KV SS Jannaram d) 33 KV SS Dandepally e) 33 KV SS Velganoor f) 33 KV SS Venkatraopet g) 33 KV SS Kawal h) 33 KV SS Thapalpur

Location - 132 KV SS Ichoda 2x16 32 5 -- 160

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 149

SOLAR RFS BID DOCUMENT

132KV a) Ichoda SS b) 33 KV SS Barampur c) 33 KV SS Echoda d) 33 KV SS Bazarhathnoor e) 33 KV SS Pochera (Boath) f) 33 KV SS Sonala g) 33 KV SS Neradigonda h) 33 KV SS Utnoor i) 33 KV SS Pulimadugu j) 33 KV SS Narnoor k) 33 KV SS Lokari l) 33 KV SS Jainoor m) 33 KV SS Sirpur U n) 33 KV SS Indervelly o) 33 KV SS Dasnapur (Ivelly) p) 33 KV SS Gudihathnoor q) 33 KV SS Seethagondi

Location - 132 KV SS Chennur 2x16 32 5 -- 161 132KV a) Chennur SS b) 33 KV SS Kotapally c) 33 KV SS Neelwai d) 33 KV SS Bheemaram e) 33 KV SS Devula Wada f) 33 KV SS Chennor g) 33 KV SS Kommera

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 150

SOLAR RFS BID DOCUMENT

FORMAT -6.12 –Format for Price Bid

PRICE BID List of Identified Substations for Solar Power RfS

Bidders Maximum offered Price No. of Total Tr. Solar capacity in offered by Location Transformers X Capacity Capacity MW at the Bidders capacity (MVA) (MW) Injection in Rs./kwh points

SRIKAKULAM Location - 132 KV SS Chilakapalem 1X31.5 + 1X50 81.50 5 -- 1 Injection Points a) 132KV SS Chilakapalem

b) 33 KV SS Tadivalasa c) 33 KV SS Indoor d) 33 KV SS A.S.N.COLONY e) 33 KV SS AMADALAVALASA f) 33 KV SS THOGARAM g) 33 KV SS KINTALI h) 33 KV SS PONDURU i) 33 KV SS BUDUMURU j) 33 KV SS LAVERU k) 33 KV SS KS PALEM l) 33 KV SS DHARMAVARAM m) 33 KV SS ETCHERLA n) 33 KV SS GUJARATHIPETA o) 33 KV SS CHALLAPETA p) 33 KV SS TULUGU q) 33 KV SS ARASAVALLI r) 33 KV SS SRIKAKULAM s) 33 KV SS BHYRI t) 33 KV SS RAGOLU u) 33 KV SS Alikam

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 151

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Palakonda 1X31.5 + 1X16 47.50 5 -- 2 Injection a) 132KV SS Palakonda Points b) 33 KV SS BHAMINI c) 33 KV SS GURANDI HIRAMANDAL d) 33 KV SS AM e) 33 KV SS L.N.PETA S.S f) 33 KV SS KOTTURU g) 33 KV SS NIVAGAM h) 33 KV SS SARUBUJJILI UNGARADAM i) 33 KV SS ETTA SANTHAKAVI j) 33 KV SS TY k) 33 KV SS KOLLIVALASA l) 33 KV SS NAVAGAM m) 33 KV SS PALAKONDA SEETHAMPET n) 33 KV SS A o) 33 KV SS DONUBAI p) 33 KV SS VANGARA VEERAGATTA q) 33 KV SS M Parvateesam r) 33 KV SS peta

Location - 132 KV SS Pydibheevaram 2X31.5 63.00 5 -- 3 Injection Pydibheevar a) 132KV SS Points am b) 33 KV SS P.B.Varan c) 33 KV SS Patharlapalli d) 33 KV SS Ranasthalam e) 33 KV SS Yerravaram

VIZIANAGARAM

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 152

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Vizianagaram 1X31.5 + 1X50 81.50 5 -- 4 Injection a) 132KV SS Vizianagaram Points b) 33 KV SS Dharmapuri c) 33 KV SS Denkada d) 33 KV SS Nathavalasa e) 33 KV SS Vontithadi f) 33 KV SS B. koneru g) 33 KV SS Indoor

h) 33 KV SS Phoolbagh i) 33 KV SS Dasannapeta j) 33 KV SS Ayyannapeta k) 33 KV SS Collectrate l) 33 KV SS Gajularega m) 33 KV SS Gotlam n) 33 KV SS Bondapalli Gajapathinag o) 33 KV SS aram p) 33 KV SS Mentada q) 33 KV SS Rajapulova r) 33 KV SS Akkivaram s) 33 KV SS Savaravalli t) 33 KV SS Bhogapuram u) 33 KV SS Mukkam

Location - 5 132 KV SS Kothavalasa 1X16 + 1X31.5 47.50 5 -- Injection a) 132KV SS Kothavalasa Points b) 33 KV SS L. Kota c) 33 KV SS Malliveedu d) 33 KV SS Kothavalasa e) 33 KV SS Kantakapalli f) 33 KV SS Vepada g) 33 KV SS Ramalingapur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 153

SOLAR RFS BID DOCUMENT

am

VISAKHAPATNAM Location - 132 KV SS Koruprolu 1X16 + 1X31.5 47.50 5 -- 6 Injection a) 132KV SS Koruprolu Points b) 33 KV SS Bhalighattam c) 33 KV SS Darlapudi d) 33 KV SS Kotavarutla e) 33 KV SS Pamulawaka f) 33 KV SS Narsipatnam g) 33 KV SS Rolugunta h) 33 KV SS Golugonda i) 33 KV SS Chintapalli

GK Veedhi j) 33 KV SS (Unmanned)

Duppiliwada k) 33 KV SS (Unmanned)

l) 33 KV SS Etigyrampeta m) 33 KV SS S.Rayavaram P n) 33 KV SS Dharmavaram (Penugollu) o) 33 KV SS Yelamanchili p) 33 KV SS Koruprolu q) 33 KV SS Upmaka r) 33 KV SS Vempadu s) 33 KV SS Lamsanghai t) 33 KV SS K.D.peta

Location - 132 KV SS Kasimkota 2X31.5 63.00 5 7 Injection a) 132KV SS Kasimkota Points Venkannapale b) 33 KV SS m

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 154

SOLAR RFS BID DOCUMENT

c) 33 KV SS Chodavaram d) 33 KV SS Cheedikada e) 33 KV SS Koppaka SS f) 33 KV SS Anakapalle g) 33 KV SS Rajam Gadirai h) 33 KV SS (Vommali) i) 33 KV SS Madugula j) 33 KV SS Waddadi Ravikamatha k) 33 KV SS m l) 33 KV SS Kothakota SS Makavarapale m) 33 KV SS m Anarak n) 33 KV SS Aluminium Velagapudi o) 33 KV SS Steels p) 33 KV SS Bayyavaram q) 33 KV SS Narasingabilli Toshali r) 33 KV SS Cements Munagapaka s) 33 KV SS (RECS)

Location - 132 KV SS Payakaraopeta 1X16 + 1X31.5 47.50 5 8 Injection Payakaraopet a) 132KV SS Points a b) 33 KV SS Srirampuram c) 33 KV SS Nathavaram d) 33 KV SS Satyavaram EAST GODAVARI Location - 132 KV SS Peddapuram 2x31.5+1x15 78.00 5 9 Injection a) 132KV SS Peddaparum Points PITHAPURAM, b) 33 KV SS , KUMARAPURA c) 33 KV SS M d) 33 KV SS CHEBROLU

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 155

SOLAR RFS BID DOCUMENT

B.PRATHIPAD e) 33 KV SS U f) 33 KV SS DIVILI PEDDAPURAM g) 33 KV SS IDA h) 33 KV SS R.B.PATNAM i) 33 KV SS SAMALKOT j) 33 KV SS PEDDAPURAM MADHAVAPAT k) 33 KV SS NAM l) 33 KV SS VETLAPALEM BORRAMPALE m) 33 KV SS M n) 33 KV SS JAGGAMPETA o) 33 KV SS GANDEPALLI p) 33 KV SS RANGAMPETA

Location - 132 KV SS Ramachandrapuram 2x31.5 63.00 5 10 Injection Ramachandra a) 132KV SS Points puram b) 33 KV SS KUTUKULURU c) 33 KV SS BICCAVOLU d) 33 KV SS BB PURAM e) 33 KV SS RANGAPURAM f) 33 KV SS RAYAVARAM g) 33 KV SS CHELLURU K.GANGAVAR h) 33 KV SS AM SEELAMVARI i) 33 KV SS SAVARAM j) 33 KV SS ALAMURU k) 33 KV SS ANGARA l) 33 KV SS SIVALA m) 33 KV SS DRAKSHARAM n) 33 KV SS INJARAM o) 33 KV SS TALLAREVU p) 33 KV SS R.C.PURAM

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 156

SOLAR RFS BID DOCUMENT

q) 33 KV SS ARYAVATAM r) 33 KV SS KARAPA

Location - 132 KV SS Rajanagaram 1X16 + 1X31.5 47.50 5 -- 11 Injection a) 132KV SS Rajanagaram Points G.DONTHAMU b) 33 KV SS RU c) 33 KV SS PRC PURAM DIWANCHERU d) 33 KV SS VU KALAVACHARL e) 33 KV SS A RAJANAGARA f) 33 KV SS M WEST GODAVARI Location - 132 KV SS Kamavorapukota 1x31.5+1x20 51.50 5 -- 12 Injection Kamavorapuk a) 132KV SS Points ota b) 33 KV SS UPPALAPADU ANKALAMPAD c) 33 KV SS U d) 33 KV SS EDAVALLI e) 33 KV SS PERAMPETA f) 33 KV SS RAJAVARAM

g) 33 KV SS KALLACHERUV U

h) 33 KV SS RANGAPURAM

i) 33 KV SS R.POTHEPALLI j) 33 KV SS Adamilli k) 33 KV SS G.G.KUNTA

l) 33 KV SS TADIKALAPUDI

Location - 132 KV SS Jangareddygudem 2x31.5 63.00 5 -- 13 Injection Points a) 132KV SS Jangareddygudem

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 157

SOLAR RFS BID DOCUMENT

b) 33 KV SS BUTTAIGUDEM c) 33 KV SS RAMARAOPETA d) 33 KV SS DHRABAGUDEM e) 33 KV SS JILUGUMILLI f) 33 KV SS MYSANNAGUDEM g) 33 KV SS TADUVAI h) 33 KV SS J.R.GUDEM i) 33 KV SS LAKKAVARAM j) 33 KV SS BAYYANAGUDEM k) 33 KV SS KOYYALAGUDEM l) 33 KV SS PAREDDYGUDEM

Location - 132 KV SS Jangareddygudem 2x31.5+1x50 113.00 5 -- 14 Injection a) 132KV SS Pedatadepalli Points b) 33 KV SS JAGANNAPETA c) 33 KV SS KUNCHANAPALLI d) 33 KV SS MODUGUNTA e) 33 KV SS A.GOKAVARAM f) 33 KV SS BADAMPUDI g) 33 KV SS BHUVANAPALLI h) 33 KV SS CHEBROL VARADARAJAPURA i) 33 KV SS M j) 33 KV SS NEELADRIPURAM k) 33 KV SS VEERAMPALEM l) 33 KV SS P.T.PALLI m) 33 KV SS GOLLAGUDEM n) 33 KV SS YERRAMALLA o) 33 KV SS ARUGOLANU p) 33 KV SS H.B.COLONY q) 33 KV SS PENTAPADU r) 33 KV SS TPG

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 158

SOLAR RFS BID DOCUMENT

KRISHNA Location - 132 KV SS Nuzivedu 3x50 150.00 10 -- 15 Injection a) 132KV SS Nuzivedu Points b) 33 KV SS Advainakkalam c) 33 KV SS Agripalli d) 33 KV SS katrenipadu e) 33 KV SS Meerjapuram f) 33 KV SS Morasapudi g) 33 KV SS Gopavaram h) 33 KV SS Gudipadu i) 33 KV SS Musunuru j) 33 KV SS Venkatapuram k) 33 KV SS Ganapavaram l) 33 KV SS Nuzivedu m) 33 KV SS Chetlapalle n) 33 KV SS Kotapadu o) 33 KV SS Polavaram p) 33 KV SS Thummalagudem q) 33 KV SS Ramanakkapeta r) 33 KV SS Janardhanapuram s) 33 KV SS Vattigudipadu t) 33 KV SS Chatrai u) 33 KV SS Narasapuram v) 33 KV SS Vissanapeta w) 33 KV SS Kondaparava x) 33 KV SS Annavaram GUNTUR Location - 132 KV SS Macherla 1X31.5 + 1X50 81.50 5 -- 16 Injection a) 132KV SS Macherla Points b) 33 KV SS Veldurhy.1 c) 33 KV SS Kadlakunta

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 159

SOLAR RFS BID DOCUMENT

d) 33 KV SS Gangalakunta e) 33 KV SS Sirigiripadu f) 33 KV SS Macherla.II g) 33 KV SS Koppunuru h) 33 KV SS NSDsam i) 33 KV SS Tallapalle j) 33 KV SS Gurajala k) 33 KV SS Retachintala l) 33 KV SS Palvai m) 33 KV SS Mutukuru n) 33 KV SS Durgi o) 33 KV SS Mandadi p) 33 KV SS Bodiveddu q) 33 KV SS Rayavaran

Location - 17 132 KV SS Piduguralla 2X31.5 63.00 10 -- Injection a) 132KV SS Piduguralla Points b) 33 KV SS Nakarikallu c) 33 KV SS rompicherla Vipparlareddypale d) 33 KV SS m e) 33 KV SS Cherjerala f) 33 KV SS PGPadu g) 33 KV SS Brhamanapalle h) 33 KV SS Macahvaram i) 33 KV SS Srinagar j) 33 KV SS Nadikudi k) 33 KV SS Madinapadu l) 33 KV SS Gadevaripalle m) 33 KV SS Janapadu n) 33 KV SS Piduguralla o) 33 KV SS Kondamodu

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 160

SOLAR RFS BID DOCUMENT

p) 33 KV SS Bellamkonda q) 33 KV SS Rajupalem r) 33 KV SS Papalpalem s) 33 KV SS Sattenpalli t) 33 KV SS Dulipalla

Location - 18 132 KV SS Chilakaluripeta 1X50 + 1X31.5 81.50 5 -- Injection a) 132KV SS Chilakaluripeta Points b) 33 KV SS Pollireddypalem c) 33 KV SS Maddirala d) 33 KV SS Santhamaguluru Purushothapatna e) 33 KV SS m f) 33 KV SS Kotappakonda g) 33 KV SS Nandivardhana h) 33 KV SS Nadendla i) 33 KV SS Chilaluripeta j) 33 KV SS R.Pasumarru k) 33 KV SS Boppudi l) 33 KV SS Ganapavaram

Location - 132 KV SS Marripalem 1X31.5 + 1X16 47.50 5 -- 19 Injection a) 132KV SS Marripalem Points b) 33 KV SS Edlapadu c) 33 KV SS Boyapaolem d) 33 KV SS Sakku e) 33 KV SS Viswateja f) 33 KV SS Vasundara g) 33 KV SS Supriya h) 33 KV SS Ananathalakshmi i) 33 KV SS Ranganayaka PRAKASHAM

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 161

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Cumbum 1X31.5 + 2X16 63.50 5 -- 20 Injection a) 132KV SS Cumbum Points b) 33 KV SS Racherla c) 33 KV SS Yerrabalem d) 33 KV SS Akaveedu e) 33 KV SS Mohiddinpuram f) 33 KV SS Yachavaram g) 33 KV SS Aradhaveedu h) 33 KV SS Akkapalle i) 33 KV SS Pitakayagulla j) 33 KV SS Kandulapuram k) 33 KV SS BVPeta l) 33 KV SS Tarlupadu m) 33 KV SS Ravipadu n) 33 KV SS Ummareddypalle o) 33 KV SS TRPalle p) 33 KV SS Komatikunta q) 33 KV SS Puchakayalapalle r) 33 KV SS Thippayapalem

Location - 132 KV SS Kanigiri 2X31.5 63.00 5 -- 21 Injection a) 132KV SS Kanigiri Points b) 33 KV SS KKMitta c) 33 KV SS Nandanamarella d) 33 KV SS Chinnarikatla e) 33 KV SS Gotlagattu f) 33 KV SS TRPalle g) 33 KV SS SRPuram h) 33 KV SS Veligandla i) 33 KV SS Rallapadu j) 33 KV SS Tallur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 162

SOLAR RFS BID DOCUMENT

k) 33 KV SS P.Alavalapadu l) 33 KV SS P.Eralapadu m) 33 KV SS PCPalle n) 33 KV SS Guravajipeta o) 33 KV SS BPAddaroad

Location - 22 132 KV SS Kandukuru 1X31.5 + 1X15 46.50 5 -- Injection a) 132KV SS Kandukuru Points b) 33 KV SS Kandukuru Town c) 33 KV SS East Kandukuru d) 33 KV SS Pamur Road e) 33 KV SS Kandukuru Rural f) 33 KV SS Ponnalur g) 33 KV SS Agraharam h) 33 KV SS Lingasamudram i) 33 KV SS VV Palem j) 33 KV SS Chinnapavani k) 33 KV SS Pokuru l) 33 KV SS Naladalapur m) 33 KV SS Gudlur n) 33 KV SS Machavaram o) 33 KV SS S.Konda p) 33 KV SS Karedu q) 33 KV SS Ulavapadu r) 33 KV SS Tettu s) 33 KV SS Pakala t) 33 KV SS Narasingolu u) 33 KV SS Kondepi v) 33 KV SS Uppalapadu w) 33 KV SS M.Nidamanur x) 33 KV SS Jarugumalli

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 163

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Peddadornala 2X16 32.00 5 -- 23 Injection a) 132KV SS Peddadornala Points b) 33 KV SS Dornala c) 33 KV SS Sanikavaram d) 33 KV SS B.Cherlopalli e) 33 KV SS P.Bommanapuram f) 33 KV SS Y.Cherlopalli

Location - 24 132 KV SS Martur 2X31.5 63.00 5 -- Injection a) 132KV SS Martur Points b) 33 KV SS Ballikurava c) 33 KV SS Kommalapadu d) 33 KV SS V.Kopperapadu e) 33 KV SS Konanaki f) 33 KV SS Dhramavaram NELLORE Location - 132 KV SS Kavali 2X31.5 63.00 5 -- 25 Injection a) 132KV SS Kavali Points b) 33 KV SS Jaladanki c) 33 KV SS Brahmanakraka d) 33 KV SS Ananathapuram e) 33 KV SS Ayyapreddypalem f) 33 KV SS Basireddypalem g) 33 KV SS Kaligiri h) 33 KV SS Bogolu i) 33 KV SS VRNagar j) 33 KV SS Maddurupadu k) 33 KV SS Pullaredynagar l) 33 KV SS Annagaripalem m) 33 KV SS Chowdawaram n) 33 KV SS Kommi

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 164

SOLAR RFS BID DOCUMENT

o) 33 KV SS Kondapuram

Location - 26 132 KV SS Chendodu 2X31.5 63.00 5 -- Injection Points a) 132KV SS Chendodu b) 33 KV SS N.P.Kothapalem c) 33 KV SS Kota d) 33 KV SS Siddawaram e) 33 KV SS Gunapadu f) 33 KV SS Eswarawaka g) 33 KV SS Mallam h) 33 KV SS Kothagunta i) 33 KV SS Vakadu j) 33 KV SS BRPalem k) 33 KV SS Konduru l) 33 KV SS Ankulapaturu m) 33 KV SS Chinthavaram

Location - 27 132 KV SS Naidupet 2X31.5 63.00 5 -- Injection a) 132KV SS Naidupet Points b) 33 KV SS Chillakuru c) 33 KV SS Sirasmabedu d) 33 KV SS KGKandriga e) 33 KV SS Menskur f) 33 KV SS Naidupeta g) 33 KV SS Thummuru h) 33 KV SS Annamedu i) 33 KV SS Yakasini j) 33 KV SS Puduru CHITTOOR Location - 132 KV SS Palamaneur 1X31.5 + 1X50 81.50 5 -- 28 Injection a) 132KV SS Palamaneur Points

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 165

SOLAR RFS BID DOCUMENT

b) 33 KV SS Bairedipalle c) 33 KV SS Kolamasanpalle d) 33 KV SS Kasturinagar e) 33 KV SS Tekumanda f) 33 KV SS Ragimanupenta g) 33 KV SS Mogili h) 33 KV SS Kadirimadugu i) 33 KV SS Pathikonda j) 33 KV SS Peddapurm k) 33 KV SS Melmai

Location - 29 132 KV SS Madanapally 1X50 + 1X31.5 81.50 10 -- Injection Points a) 132KV SS Madanapally b) 33 KV SS Nimmanapalle c) 33 KV SS Reddivaripalle Vengamavariapall d) 33 KV SS e e) 33 KV SS CTM f) 33 KV SS Kantevaripalle g) 33 KV SS Kotavuru Ammcheruvu h) 33 KV SS mitta i) 33 KV SS Nayanabavi j) 33 KV SS Pothapolu k) 33 KV SS Valasapalle l) 33 KV SS Vemaplle m) 33 KV SS Bommanacheruvu n) 33 KV SS Kurabalakota

Location - 132 KV SS Pakala 1X31.5 + 1X16 47.50 5 -- 30 Injection a) 132KV SS Pakala Points Achamaagarahara b) 33 KV SS m

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 166

SOLAR RFS BID DOCUMENT

c) 33 KV SS M.N.Palle d) 33 KV SS Damaracheruvu e) 33 KV SS Kalluru f) 33 KV SS Pulicherla g) 33 KV SS Ashoknagar h) 33 KV SS Mangalamapeta i) 33 KV SS Vallivedu j) 33 KV SS Puthalapattu k) 33 KV SS Petamitta l) 33 KV SS M.Bandapalle

Location - 31 132 KV SS Shanthipuram 1X50 + 1X31.5 81.50 5 -- Injection Points a) 132KV SS Shanthipuram b) 33 KV SS Rallbuduguru c) 33 KV SS Chinnabaldar d) 33 KV SS Ramakuppam e) 33 KV SS Aanikeri f) 33 KV SS Suddalakuppam g) 33 KV SS Sivaramanapuram h) 33 KV SS Arimanupenta i) 33 KV SS V.Kota j) 33 KV SS Cheldiganipalle

Location - 132 KV SS Nagiri 1X31.5 + 1X16 47.50 10 -- 32 Injection a) 132KV SS Nagiri Points b) 33 KV SS Nethamkandriga c) 33 KV SS M.Kothuru d) 33 KV SS Pannuru e) 33 KV SS Vijayapuram f) 33 KV SS Kalikapuram g) 33 KV SS Kosalanagaram

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 167

SOLAR RFS BID DOCUMENT

h) 33 KV SS Netteri i) 33 KV SS Mittakandriga j) 33 KV SS Irruguvoi

Location - 132 KV SS Kothapallimitta 1X50 + 1X31.5 81.50 10 -- 33 Injection a) 132KV SS Kothapallimitta Points b) 33 KV SS Katiripalle c) 33 KV SS Chinnatayyuru d) 33 KV SS Katikapalle e) 33 KV SS SRPuram f) 33 KV SS Nelavoi g) 33 KV SS Kondakindpalle h) 33 KV SS Vedurkuppam i) 33 KV SS Mambedu j) 33 KV SS NVPalle k) 33 KV SS Allamadugu l) 33 KV SS Penumuru m) 33 KV SS Mattampalle n) 33 KV SS Polavaram o) 33 KV SS Bandarlapalle p) 33 KV SS GDNellore q) 33 KV SS Avulakonda r) 33 KV SS SSKonda s) 33 KV SS VRKuppam t) 33 KV SS SBRpuram u) 33 KV SS Vepamjeri

Location - 132 KV SS Burakayalakota 2X31.5 63.00 10 -- 34 Injection a) 132KV SS Burakayalakota Points b) 33 KV SS Rangasamudrum c) 33 KV SS Nanbavi

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 168

SOLAR RFS BID DOCUMENT

d) 33 KV SS kandukuru e) 33 KV SS Gopidinne f) 33 KV SS Chowdasamudurm g) 33 KV SS Burakayalakota h) 33 KV SS Mulakalacherubu i) 33 KV SS B.Kohakota j) 33 KV SS PTM k) 33 KV SS Varikasuvupalle l) 33 KV SS Mallela

Location - 132 KV SS Kuppam 2X31.5 63.00 10 -- 35 Injection a) 132KV SS Kuppam Points b) 33 KV SS Mallanuru c) 33 KV SS Laskhmipuram d) 33 KV SS Adivibuduguru e) 33 KV SS Gudipalle f) 33 KV SS Vasanadu KADAPA Location - 132 KV SS Badwel 2X16 32 5 -- 36 Injection a) 132KV SS Badvel Points b) 33 KV SS Peddapolukunta

c) 33 KV SS Gangapenta

d) 33 KV SS Payalakunta e) 33 KV SS B.Ko dur f) 33 KV SS Konduru g) 33 KV SS Sidaout h) 33 KV SS Venkatasettipalle i) 33 KV SS D.Agraharam j) 33 KV SS Badvel-II

Location - 132 KV SS Rayachoti 2X31.5 63 5 --

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 169

SOLAR RFS BID DOCUMENT

37 Injection a) 132KV SS Rayachoti Points b) 33 KV SS T.Sundupalli c) 33 KV SS Rayavaram d) 33 KV SS Gundlapalli e) 33 KV SS Pujarivandlapalli f) 33 KV SS Rayachoty g) 33 KV SS Masapeta h) 33 KV SS L.R.Pallif i) 33 KV SS Ramapuram j) 33 KV SS Veeraballi k) 33 KV SS Matil l) 33 KV SS Vangimalla m) 33 KV SS Gadikota n) 33 KV SS Galiveedu o) 33 KV SS Madhavaram p) 33 KV SS Nooliveedu

Location - 132 KV SS Vontimitta 2x16 32 5 -- 38 Injection a) 132KV SS Vontimitta Points b) 33 KV SS Peddapalle c) 33 KV SS Mantapamapalle

Location - 132 KV SS Jammalamadugu 2X16 32 5 -- 39 Injection a) 132KV SS Jammalamadugu Points b) 33 KV SS Gundlakunta c) 33 KV SS Diguvakalavatala d) 33 KV SS Namalladinne e) 33 KV SS Torivemula Thalamanchipatna f) 33 KV SS m g) 33 KV SS Mylavaram

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 170

SOLAR RFS BID DOCUMENT

h) 33 KV SS Dodlum i) 33 KV SS Ambavaram j) 33 KV SS Danavulapadu

Location - 132 KV SS Sambepalli 2X16 32 5 -- 40 Injection a) 132KV SS Sambepalle Points b) 33 KV SS C.Mandam c) 33 KV SS Pedamatikona d) 33 KV SS Devapatla e) 33 KV SS Mallur ANANTHAPUR Location - 132 KV SS Kadri 1X50 + 1X31.5 81.5 5 -- 41 Injection a) 132KV SS Kadri Points b) 33 KV SS Kondakamarla c) 33 KV SS Amadugur d) 33 KV SS Mohamadbad e) 33 KV SS Nallacheruvu f) 33 KV SS Tanakallu g) 33 KV SS Chikatimanipalli h) 33 KV SS Kokanti Cross i) 33 KV SS Peddapalli j) 33 KV SS N.P.Kunta k) 33 KV SS Gajulavaripalli l) 33 KV SS Gandlapenta m) 33 KV SS Kadiri n) 33 KV SS Kuttagulla o) 33 KV SS N.S.G.Palli p) 33 KV SS Malakavemula q) 33 KV SS Mallepalli r) 33 KV SS Mudigubba s) 33 KV SS Kodavandla palli

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 171

SOLAR RFS BID DOCUMENT

t) 33 KV SS O.D.Cheruvu u) 33 KV SS Pulagampalli v) 33 KV SS Talapula w) 33 KV SS Batrepalli x) 33 KV SS Ganjivaripalli

Location - 42 132 KV SS Tadipatri 2 X50 100 5 -- Injection a) 132KV SS Tadipatri Points Tadipatri b) 33 KV SS Nandyala Road c) 33 KV SS Rayalacheruvu d) 33 KV SS Konauppalapadu e) 33 KV SS Sajjaladinne f) 33 KV SS Chukkalur g) 33 KV SS P.Yekkaluru h) 33 KV SS P.Pappuru i) 33 KV SS Dharmapuram j) 33 KV SS Kammavaripalli k) 33 KV SS Nitturu l) 33 KV SS Bugga m) 33 KV SS AVT.Palli n) 33 KV SS A.Kondapuram o) 33 KV SS Maddipalli p) 33 KV SS Yellutla KURNOOL Location - 132 KV SS Allagadda 2X31.5 63 5 -- 43 Injection a) 132KV SS Allagadda Points b) 33 KV SS Uyyalawada, c) 33 KV SS Perusomula, d) 33 KV SS Nossam e) 33 KV SS Chagalamarri, f) 33 KV SS K. Kandukuru,

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 172

SOLAR RFS BID DOCUMENT

g) 33 KV SS P.Bodanam h) 33 KV SS Chinthalacheruvu Alamuru i) 33 KV SS (Allagada) j) 33 KV SS Ahobilam, k) 33 KV SS C T R Palli l) 33 KV SS Muthylapadu, m) 33 KV SS R.K.Puram, n) 33 KV SS Rudravaram o) 33 KV SS Yerraguntla p) 33 KV SS Dornipadu, Kalugotla q) 33 KV SS (Koilakuntla)

Location - 132 KV SS Adoni 2X31.5 63 5 -- 44 Injection a) 132KV SS Adoni Points b) 33 KV SS S.K.D.Colony, c) 33 KV SS Arts College d) 33 KV SS Baichigiri e) 33 KV SS Kamavaram, f) 33 KV SS Kowthalam g) 33 KV SS Halv i, h) 33 KV SS Nadichagi i) 33 KV SS Gulyam j) 33 KV SS yellarthy k) 33 KV SS Holagunda Chippagiri l) 33 KV SS (Alternate) m) 33 KV SS Molagavalli n) 33 KV SS Basaladoddi, o) 33 KV SS Vandagal, p) 33 KV SS Kosigi q) 33 KV SS Kolamanpeta r) 33 KV SS Market yard

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 173

SOLAR RFS BID DOCUMENT

s) 33 KV SS santhakodur, t) 33 KV SS Kallubavi u) 33 KV SS Alur, v) 33 KV SS Kammarachedu w) 33 KV SS Nagaradona, x) 33 KV SS Halaharvi y) 33 KV SS Ganekal z) 33 KV SS Pedda thumbalam

Location - 132 KV SS Pathikonda 2X31.5 63 10 -- 45 Injection a) 132KV SS Pathikonda Points b) 33 KV SS Devanakonda c) 33 KV SS E.D.Banda, d) 33 KV SS Yerrabadu, e) 33 KV SS Kothiralla f) 33 KV SS Gundlakonda g) 33 KV SS Aspari, h) 33 KV SS Dibbanakal, i) 33 KV SS Devanabanda j) 33 KV SS Maddikera, k) 33 KV SS Tuggali, l) 33 KV SS Jonnagiri m) 33 KV SS Pathikonda, n) 33 KV SS R.S.Pendekal

Location - 132 KV SS Gudur 2X16 32 5 -- 46 Injection a) 132KV SS Gudur Points b) 33 KV SS Kothakota c) 33 KV SS Gudur d) 33 KV SS C.Belagal e) 33 KV SS Polakal

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 174

SOLAR RFS BID DOCUMENT

f) 33 KV SS Gundrevula g) 33 KV SS Kodumur, h) 33 KV SS Pulakurthy

Location - 132 KV SS Banaganapalli 2X16 32 5 -- 47 Injection a) 132KV SS Banaganapalli, Points b) 33 KV SS Yanakandla, c) 33 KV SS Palukuru. d) 33 KV SS Owk, e) 33 KV SS Akumalla, f) 33 KV SS I.K.Peta, g) 33 KV SS Uppalapadu, Ramapuram. h) 33 KV SS (Alternate) Gundla i) 33 KV SS Singavaram j) 33 KV SS Kolilakuntla, k) 33 KV SS Gulladurthy, l) 33 KV SS Sanjamala m) 33 KV SS Pathapadu

Location - 132 KV SS Gandikota 1X50 50 5 -- 48 Injection Points a) 132KV SS Gandikota (LIS)

MAHABUBNAGAR Location - 132 KV SS Nagarkurnool 1X31.5+1X50 81.5 10 -- 49 Injection a) 132KV SS Nagarkurnool Points b) 33 KV SS Ithole c) 33 KV SS Tadoor d) 33 KV SS Yangampally e) 33 KV SS Kummera f) 33 KV SS Bijnapally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 175

SOLAR RFS BID DOCUMENT

g) 33 KV SS Peddamudunoor h) 33 KV SS Manganoor i) 33 KV SS Mumaipally j) 33 KV SS Waddeman k) 33 KV SS Manthati l) 33 KV SS Kollapur X Roads m) 33 KV SS Telkapally n) 33 KV SS Rakonda o) 33 KV SS Peddur p) 33 KV SS Tallapally q) 33 KV SS Peddapur r) 33 KV SS Kondareddypally

Location - 132 KV SS Wanaparthy 2X50 100 5 -- 50 Injection a) 132KV SS Wanaparthy Points b) 33 KV SS Kothakota c) 33 KV SS Kurumurthy d) 33 KV SS Madanapur e) 33 KV SS Kothapally f) 33 KV SS Ramanpad g) 33 KV SS Peddamandadi h) 33 KV SS Addakal i) 33 KV SS Ponnakal j) 33 KV SS Veltoor k) 33 KV SS Solipur l) 33 KV SS Buddaram m) 33 KV SS Balijapally n) 33 KV SS Kandur o) 33 KV SS Mamidimada p) 33 KV SS Gopalpet q) 33 KV SS Revally r) 33 KV SS P.K.Pally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 176

SOLAR RFS BID DOCUMENT

s) 33 KV SS Thudkurthy t) 33 KV SS Chennaram u) 33 KV SS Peddakarpamula v) 33 KV SS Ayyavaripally w) 33 KV SS Remaddula x) 33 KV SS Rajapur y) 33 KV SS Kodair z) 33 KV SS Tirumalapur a1) 33 KV SS Kethepally a2) 33 KV SS Pangal a3) 33 KV SS Pebbair a4) 33 KV SS Williamkonda a5) 33 KV SS Srinivasapuram a6) 33 KV SS Nasanally a7) 33 KV SS Sri Rangapur

Location - 132 KV SS Thimmapur 1X50+2X31.5 113 10 -- 51 Injection a) 132KV SS Thimmapur Points b) 33 KV SS Kothur c) 33 KV SS Sangem d) 33 KV SS Inmulnarva e) 33 KV SS Kothapet

Location - 132 KV SS Gadwal 2X50 100 10 -- 52 Injection a) 132KV SS Gadwal Points b) 33 KV SS Veerapur c) 33 KV SS Beechupally d) 33 KV SS Kodandapur e) 33 KV SS Gadwal f) 33 KV SS Gadwal Town g) 33 KV SS Alwalpad

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 177

SOLAR RFS BID DOCUMENT

h) 33 KV SS Dharoor i) 33 KV SS Nandinne j) 33 KV SS Dyagadoddi k) 33 KV SS Maldakal l) 33 KV SS Ieeza m) 33 KV SS Mallamdoddi n) 33 KV SS P.T.Pad o) 33 KV SS Budidapad p) 33 KV SS Bijjaram q) 33 KV SS Amarchinta r) 33 KV SS Atmakur s) 33 KV SS Peddakadmoor

Location - 132 KV SS Makthal 1X50+1X31.5 81.5 5 -- 53 Injection a) 132KV SS Makthal Points b) 33 KV SS Jaklair c) 33 KV SS Bijwar d) 33 KV SS Narva e) 33 KV SS Narayanpet f) 33 KV SS Utkoor g) 33 KV SS Pasupula h) 33 KV SS Mushtipally i) 33 KV SS Gudeballore j) 33 KV SS Kolpur k) 33 KV SS Maganoor l) 33 KV SS Krishna

Location - 132 KV SS Kodangal 2X31.5 63 5 -- 54 Injection a) 132KV SS Kodangal Points b) 33 KV SS Dudyal c) 33 KV SS Kosigi

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 178

SOLAR RFS BID DOCUMENT

d) 33 KV SS Kodangal e) 33 KV SS Ravulapally f) 33 KV SS Doultabad g) 33 KV SS Suraipally h) 33 KV SS Sarjakhanpet i) 33 KV SS Hamsanpally

Location - 132 KV SS Balanagar 1X50+2X31.5 113 10 -- 55 Injection a) 132KV SS Balanagar Points b) 33 KV SS Chinchode c) 33 KV SS Peddarevally d) 33 KV SS Thommidirekula e) 33 KV SS Balanagar f) 33 KV SS Rajapur g) 33 KV SS Polepally h) 33 KV SS Kollur i) 33 KV SS Udityal j) 33 KV SS Yedira k) 33 KV SS Raikal l) 33 KV SS Gantlavelly m) 33 KV SS Dooskal n) 33 KV SS Gundlapotlapally

Location - 132 KV SS Achampet 2X31.5 63 5 -- 56 Injection a) 132KV SS Achampet Points b) 33 KV SS Lingal c) 33 KV SS Kondanagula d) 33 KV SS Inole e) 33 KV SS Amrabad f) 33 KV SS Vankeshwaram g) 33 KV SS Hajipur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 179

SOLAR RFS BID DOCUMENT

h) 33 KV SS Uppununthala i) 33 KV SS Veltoor j) 33 KV SS Mannewaripally

Location - 132 KV SS Amangal 2X31.5 63 10 -- 57 Injection a) 132KV SS Amangal Points b) 33 KV SS Madgul c) 33 KV SS Nagilla d) 33 KV SS Arkepally e) 33 KV SS Polepally f) 33 KV SS Irvin g) 33 KV SS Akutotapally h) 33 KV SS Amangal i) 33 KV SS Kadthal j) 33 KV SS Mudwin k) 33 KV SS Karkalpad l) 33 KV SS Talakondapally m) 33 KV SS Chukapur n) 33 KV SS Raviched

Location - 132 KV SS Kalwakurthy 2X31.5+1X50 113 10 -- 58 Injection a) 132KV SS Kalwakurthy Points b) 33 KV SS Sirsangandla c) 33 KV SS Tandra d) 33 KV SS Jajala e) 33 KV SS Polkampally f) 33 KV SS Gundoor g) 33 KV SS Ellikal h) 33 KV SS Totapally i) 33 KV SS Dindichintapally j) 33 KV SS Veldanda

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 180

SOLAR RFS BID DOCUMENT

k) 33 KV SS Peddapur l) 33 KV SS Bollampally m) 33 KV SS Rachur n) 33 KV SS Madaram o) 33 KV SS Marchala p) 33 KV SS Jaknalpally q) 33 KV SS Urkonda r) 33 KV SS Gattuippalapally s) 33 KV SS Juppally t) 33 KV SS Vangoor u) 33 KV SS Sarvareddypally v) 33 KV SS Kalwakurthy

Location - 132 KV SS Midjil 2X16 32 5 -- 59 Injection a) 132KV SS Midjil Points b) 33 KV SS Velgomula c) 33 KV SS Kothapally d) 33 KV SS Kodgal e) 33 KV SS Konded f) 33 KV SS Avancha g) 33 KV SS Donur h) 33 KV SS Vemula i) 33 KV SS Veljal j) 33 KV SS Keshampet k) 33 KV SS Midjil

Location - 60 132 KV SS Marikal 2X31.5 63 5 -- Injection a) 132KV SS Marikal Points b) 33 KV SS Kondapur c) 33 KV SS Deverkadra d) 33 KV SS Sanginonipally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 181

SOLAR RFS BID DOCUMENT

e) 33 KV SS Nagaram Gate f) 33 KV SS Eklaspur g) 33 KV SS Waddeman h) 33 KV SS Marikal i) 33 KV SS Dhanwada j) 33 KV SS Chinnajatram k) 33 KV SS Kotakonda l) 33 KV SS Koukuntla m) 33 KV SS Krishna MEDAK Location - 132 KV SS Sadasivapet 1X50+1X31.5 81.5 15 -- 61 Injection a) 132KV SS Sadasivapet Points b) 33 KV SS Nizampur c) 33 KV SS Athmakur d) 33 KV SS Jackwell e) 33 KV SS Munipally f) 33 KV SS Tatipally g) 33 KV SS Aroor h) 33 KV SS Kamkole i) 33 KV SS Sadasivpet j) 33 KV SS Kohir k) 33 KV SS Bilalpur

Locati on - 132 KV SS Gajwal 2X50 100 10 -- 62 Injection a) 132KV SS Gajwel Points b) 33 KV SS Gowraram c) 33 KV SS Wargal d) 33 KV SS Markook e) 33 KV SS Adavimajeedpally f) 33 KV SS Karkapatla g) 33 KV SS Mulugu

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 182

SOLAR RFS BID DOCUMENT

h) 33 KV SS Wantimamidi i) 33 KV SS B.V. Poor j) 33 KV SS Bejgam k) 33 KV SS Ahmedipur l) 33 KV SS Nimtoor m) 33 KV SS Begumpet n) 33 KV SS Wardharajpur o) 33 KV SS Jagadevpur p) 33 KV SS Munigadapa q) 33 KV SS Chatlapally r) 33 KV SS Gajwel s) 33 KV SS Pregnapur t) 33 KV SS Ganeshpally u) 33 KV SS Kodakandla

Location - 63 132 KV SS Kandi 2X50 100 5 -- Injection a) 132KV SS Kandi Points b) 33 KV SS Sangareddy - I c) 33 KV SS Sangareddy - II d) 33 KV SS Collector Complex e) 33 KV SS Cheryal f) 33 KV SS Ismailkhan Pet g) 33 KV SS Kondapur h) 33 KV SS Malkapur i) 33 KV SS Gollapally j) 33 KV SS Nandi gama k) 33 KV SS T K Pur l) 33 KV SS Gundla Machnoor m) 33 KV SS Rudraram

Location - 132 KV SS Kowdipally 1X31.5+1X16 47.5 5 -- 64

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 183

SOLAR RFS BID DOCUMENT

Injection a) 132KV SS Kowdipally Points b) 33 KV SS Kulcharam c) 33 KV SS Amsanpally d) 33 KV SS Kowdipally e) 33 KV SS Kanchanpally f) 33 KV SS Rangampet g) 33 KV SS Venkatraopet h) 33 KV SS Siripura i) 33 KV SS Bujarampet j) 33 KV SS Rajipet k) 33 KV SS Salabathpur l) 33 KV SS Waddepally m) 33 KV SS Yenigandla

Location - 132 KV SS Manoharabad 1X50+1X31.5 81.5 15 -- 65 Injection a) 132KV SS Manoharabad Points b) 33 KV SS Imampur c) 33 KV SS Toopran d) 33 KV SS Danthanpally e) 33 KV SS Nagulapally f) 33 KV SS Sikindlapur g) 33 KV SS Shivampet Chinna Gotti h) 33 KV SS Mukkala i) 33 KV SS Panbanda j) 33 KV SS Manoharabad k) 33 KV SS Kallakal l) 33 KV SS Nacharam m) 33 KV SS Islampur n) 33 KV SS Chetla Gowraram o) 33 KV SS Muppireddypally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 184

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Zaheerabad 2X31.5 63 10 -- 66 Injection a) 132KV SS Zaheerabad Points b) 33 KV SS Zaheerabad Town c) 33 KV SS Hadnoor d) 33 KV SS Raikode e) 33 KV SS Chalki f) 33 KV SS Metal Kunta g) 33 KV SS Nyalkal h) 33 KV SS Mamidgi i) 33 KV SS Singitham j) 33 KV SS Mohabathpur k) 33 KV SS Digwal l) 33 KV SS Aligole m) 33 KV SS Jharasangam n) 33 KV SS Machnoor o) 33 KV SS Mannapur p) 33 KV SS Malchelma q) 33 KV SS Chota Hyderabad r) 33 KV SS Sathwar

Location - 132 KV SS Gummadiddala 1X50+1X31.5 81.5 5 -- 67 Injection a) 132KV SS Gummadidala Points b) 33 KV SS Kanukunta c) 33 KV SS Vishal Projects d) 33 KV SS Nallavally e) 33 KV SS Bonthapally f) 33 KV SS Solakpally g) 33 KV SS Jinnaram h) 33 KV SS Dundigal

Location - 132 KV SS Narayanakhed 2X31.5 63 10 -- 68

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 185

SOLAR RFS BID DOCUMENT

Injection a) 132KV SS Naraya nakhed Points b) 33 KV SS Bodagattu c) 33 KV SS Shankarampet d) 33 KV SS Nizampet e) 33 KV SS Burugupally f) 33 KV SS Hanmanthraopet g) 33 KV SS Narayankhed h) 33 KV SS Manoor i) 33 KV SS Poosalpad j) 33 KV SS Borancha k) 33 KV SS Regode l) 33 KV SS Karasgutti m) 33 KV SS Wasar n) 33 KV SS Thadkal o) 33 KV SS Kangti p) 33 KV SS Ryakal q) 33 KV SS Kalher r) 33 KV SS Bachepally s) 33 KV SS Fathepur t) 33 KV SS Sirgapoor u) 33 KV SS Sanjeevraopet

Location - 132 KV SS Medak 2X31.5 63 10 -- 69 Injection a) 132KV SS Medak Points b) 33 KV SS Pillikotyal c) 33 KV SS NSF d) 33 KV SS Ch.Ghanapur e) 33 KV SS B Bhoopathipur f) 33 KV SS Wadi g) 33 KV SS Thogita h) 33 KV SS Sardana

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 186

SOLAR RFS BID DOCUMENT

i) 33 KV SS Pathur j) 33 KV SS Nagapur k) 33 KV SS M.Bhupathipur l) 33 KV SS Rajpally m) 33 KV SS Ch.Shankarampet n) 33 KV SS Gavvalapally o) 33 KV SS Suraram p) 33 KV SS Shalipet

Location - 132 KV SS Tukkapur 1X31.5+1X50 81.5 10 -- 70 Injection a) 132KV SS Tukkapur Points b) 33 KV SS Mirdoddy c) 33 KV SS Jangapally d) 33 KV SS Khajipur e) 33 KV SS Pedda Chepyal f) 33 KV SS Thukkapur g) 33 KV SS Mettu h) 33 KV SS Gudikandula i) 33 KV SS Lingapur j) 33 KV SS Pallepahad k) 33 KV SS Thoguta l) 33 KV SS Gurralasofa m) 33 KV SS Raipole n) 33 KV SS Ramsagar o) 33 KV SS Dommat p) 33 KV SS Mubaraspur q) 33 KV SS Doulthabad r) 33 KV SS Mohd.Shapur s) 33 KV SS Govindapur

Location - 132 KV SS Chegunta 2X50 100 10 -- 71

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 187

SOLAR RFS BID DOCUMENT

Injection a) 132KV SS Chegunta Points b) 33 KV SS Bonala c) 33 KV SS Narlapur d) 33 KV SS Karnalpally e) 33 KV SS Kalwakunta f) 33 KV SS Narsingi g) 33 KV SS D.Dharmaram h) 33 KV SS Chandaipet i) 33 KV SS Masaipet j) 33 KV SS Yeldurthy k) 33 KV SS Ramaipally l) 33 KV SS Chegunta

Location - 132 KV SS Narsapur 2X31.5 63 10 -- 72 Injection a) 132KV SS Narsapur Points b) 33 KV SS Lingapur c) 33 KV SS Reddypally d) 33 KV SS Chippalthurthy e) 33 KV SS Kothapet f) 33 KV SS Kagazmaddur g) 33 KV SS Mangalparthy h) 33 KV SS Avancha i) 33 KV SS Nasthipur j) 33 KV SS Hathnoora

Location - 132 KV SS Habsipur 2X31.5 63 10 -- 73 Injection a) 132KV SS Habsipur Points b) 33 KV SS Dubbak c) 33 KV SS Pedda Cheekode d) 33 KV SS Chellapur e) 33 KV SS Gambheerpur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 188

SOLAR RFS BID DOCUMENT

f) 33 KV SS Dharmajipet g) 33 KV SS Raghothampally h) 33 KV SS Chittapur i) 33 KV SS Pothareddypet j) 33 KV SS Rudraram k) 33 KV SS Habsipur

Location - 132 KV SS Ramayapet 2X16 32 10 -- 74 Injection a) 132KV SS Ramayampet Points b) 33 KV SS Zapthi Shivanur c) 33 KV SS Nizampet d) 33 KV SS Konapur e) 33 KV SS Nas kal f) 33 KV SS Katriyal g) 33 KV SS Laxmapur

Location - 132 KV SS Pedda Shankarampeta 1X16 16 10 -- 75 Injection Pedda a) 132KV SS Points Shankarampeta

Location - 132 KV SS Minpur 2X16 32 10 -- 76 Injection Points a) 132KV SS Minpur b) 33 KV SS Podchan pally c) 33 KV SS Kothaipally d) 33 KV SS Minpur e) 33 KV SS Kodapak f) 33 KV SS Narsingi g) 33 KV SS Tekmal h) 33 KV SS Achnapally i) 33 KV SS P.Lingaipaly

j) 33 KV SS Palvancha (Dhanoora)

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 189

SOLAR RFS BID DOCUMENT

k) 33 KV SS Kaduloor RANGA REDDY Location - 77 132 KV SS Medchal 1X31.5+2X50 131.5 5 -- Injection Points a) 132KV SS Medchal b) 33 KV SS Kistapur c) 33 KV SS Ravalkole d) 33 KV SS Keshavaram e) 33 KV SS Kolthur f) 33 KV SS Laxmapur g) 33 KV SS Uddamarry h) 33 KV SS ICICI i) 33 KV SS Turkapally j) 33 KV SS Medicity k) 33 KV SS Athiwelly l) 33 KV SS Yellempet m) 33 KV SS Bandamadaram n) 33 KV SS Gowdawelly o) 33 KV SS GP Pally p) 33 KV SS Deveryamjal

Location - 132 KV SS Dharmasagar(Chervella) 2X31.5 63 10 78 -- Injection Dharmasagar a) 132KV SS Points (Chevella)

b) 33 KV SS Kandawada c) 33 KV SS Shabad d) 33 KV SS Chandanvally e) 33 KV SS Tallapally f) 33 KV SS Bobbiligaon g) 33 KV SS Aloor h) 33 KV SS Kowkuntla i) 33 KV SS Devunieravally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 190

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Puttapahad 1x31.5+1x16 47.5 10 -- 79 Injection a) 132KV SS Puttapahad Points b) 33 KV SS Chowdapur c) 33 KV SS Marikal d) 33 KV SS Puttapahad e) 33 KV SS Mohmmadabad f) 33 KV SS Salkarpet g) 33 KV SS Mumbapur h) 33 KV SS Nancherla i) 33 KV SS Veenuchedu j) 33 KV SS Dirsampally k) 33 KV SS Gundal l) 33 KV SS Doma m) 33 KV SS Mujahidpur n) 33 KV SS Mothukuru o) 33 KV SS Kulkacherla

Location - 132 KV SS Turkayamjal (Hayatnagar) 2x31.5 63 10 -- 80 Injection Turkayamjal a) 132KV SS Points (Hayatnagar)

b) 33 KV SS Vanasthalipuram c) 33 KV SS Turkayamzal

Location - 132 KV SS Pargi 2x31.5 63 10 -- 81 Injection a) 132KV SS Pargi Points

b) 33 KV SS Manneguda c) 33 KV SS Peddumenthol d) 33 KV SS Siddalur e) 33 KV SS Pargi

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 191

SOLAR RFS BID DOCUMENT

f) 33 KV SS Rapole g) 33 KV SS Rangampally HYDERABAD Location - 132 KV SS Vikarabad Swt. Sn Swt. Sn 15 -- 82 Injection a) 132KV SS Vikarabad Points

NALGONDA Location - 132 KV SS Nalgonda 1x50+2x31.5 113 15 -- 83 Injection a) 132KV SS Nalgonda Points b) 33 KV SS Pole Centre c) 33 KV SS Panagal d) 33 KV SS SLBC e) 33 KV SS Velugupally f) 33 KV SS Mushampally g) 33 KV SS P.D.Pally h) 33 KV SS Narsingbatla i) 33 KV SS Appajipeta j) 33 KV SS Anneparthy k) 33 KV SS Indoor l) 33 KV SS Gollaguda m) 33 KV SS Rayanaguda n) 33 KV SS Pazzur o) 33 KV SS Rajupet p) 33 KV SS Ch.Mamidi q) 33 KV SS Gudapur r) 33 KV SS Kattangur s) 33 KV SS Aitipamula t) 33 KV SS Pamanagundla

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 192

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Alair (Kolanupak) 2x50 100 15 84 -- Injection a) 132KV SS Alair(Kolanupak) Points b) 33 KV SS Motakonduru c) 33 KV SS Shaharajpeta d) 33 KV SS Bhachannapeta e) 33 KV SS Raghunathpuram f) 33 KV SS Yadagirigutta g) 33 KV SS Suddala h) 33 KV SS Alair i) 33 KV SS Rajapeta

Location - 132 KV SS Wadapally 1x16+1x31.5 47.5 10 -- 85 Injection a) 132KV SS Wadapally Points b) 33 KV SS Dameracherla c) 33 KV SS A.D.Pally(U.P) d) 33 KV SS K.N.Konda e) 33 KV SS Janpahad

Location - 132 KV SS K.Mallepally 2x50+1x31.5 131.5 5 -- 86 Injection a) 132KV SS K.Mallepally Points b) 33 KV SS Pulicharla c) 33 KV SS Deverakonda d) 33 KV SS K.M.Pally e) 33 KV SS Padmatipally f) 33 KV SS Mudigonda g) 33 KV SS Singarajpally h) 33 KV SS Palvai i) 33 KV SS Junuthala j) 33 KV SS Chandampet k) 33 KV SS Teldeverapally l) 33 KV SS Cherkupally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 193

SOLAR RFS BID DOCUMENT

m) 33 KV SS Yerraram n) 33 KV SS Chinthapally o) 33 KV SS Madnapur p) 33 KV SS Teededu q) 33 KV SS Nampally r) 33 KV SS Mellavai s) 33 KV SS Angadipet t) 33 KV SS Ghanpur u) 33 KV SS Dugyala v) 33 KV SS Puttamgandi w) 33 KV SS Azmapur x) 33 KV SS Kothapally

Location - 132 KV SS Suryapet 2x80 160 20 -- 87 Injection a) 132KV SS Suryapet Points b) 33 KV SS Repala c) 33 KV SS Mamillagudem d) 33 KV SS Sirikonda e) 33 KV SS Suryapet(Jammigad da) f) 33 KV SS IndlEstate g) 33 KV SS Penpahad h) 33 KV SS S.V.College i) 33 KV SS Kasarabad j) 33 KV SS Cheedella k) 33 KV SS GTGiri l) 33 KV SS Nuthankal m) 33 KV SS Athmakur n) 33 KV SS Yerkaram o) 33 KV SS Koduru p) 33 KV SS Kandhagatla q) 33 KV SS Chandupatla

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 194

SOLAR RFS BID DOCUMENT

r) 33 KV SS Aipoor s) 33 KV SS Tekumatla t) 33 KV SS Kethepally u) 33 KV SS Koppole(K)

Location - 132 KV SS Ramannapet 2x50 100 10 -- 88 Injection a) 132KV SS Ramannapet Points b) 33 KV SS NarketpallyIE c) 33 KV SS Chityala d) 33 KV SS Veliminedu e) 33 KV SS Aregudem f) 33 KV SS Urumadla g) 33 KV SS Ramannapet h) 33 KV SS Yellanki i) 33 KV SS Laxmapur j) 33 KV SS Yennram k) 33 KV SS Iskilla l) 33 KV SS Aroor m) 33 KV SS Puligilla n) 33 KV SS Valigonda o) 33 KV SS Gollenepally

Location - 132 KV SS Huzurnagar(Matampally) 2x31.5 63 15 -- 89 Injection Huzurnagar(Matta Points a) 132KV SS mpalli)

b) 33 KV SS Mattapally c) 33 KV SS Mattamaplly d) 33 KV SS Raghunadhapalerm e) 33 KV SS Pedaveedu f) 33 KV SS BheelayanaikThand a

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 195

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Shaligouraram 1x50+1x31.5 81.5 15 -- 90 Injection a) 132KV SS Shaligouraram Points b) 33 KV SS Akkenapally c) 33 KV SS Arvapally d) 33 KV SS Nagaram e) 33 KV SS Wangamarthy f) 33 KV SS Nakrekal g) 33 KV SS Palem h) 33 KV SS ChervuAnnaram i) 33 KV SS Bairavonibanda j) 33 KV SS Akaram k) 33 KV SS Eeduluru l) 33 KV SS S.Gowraram m) 33 KV SS Arlagaddagudem n) 33 KV SS Marror o) 33 KV SS Addaguduru p) 33 KV SS Azee mpet

Location - 132 KV SS Choutuppal 2x31.5 63 10 91 -- Injection a) 132KV SS Choutuppal Points b) 33 KV SS Narayanpur c) 33 KV SS Jangam d) 33 KV SS Survail e) 33 KV SS Choutuapapl f) 33 KV SS D.Nagaram g) 33 KV SS Varkatpally

Location - 132 KV SS Halia 1x16+1x31.5 47.5 5 -- 92 Injection a) 132KV SS Halia Points b) 33 KV SS Nidmanoor c) 33 KV SS Haliya

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 196

SOLAR RFS BID DOCUMENT

d) 33 KV SS Rajavaram e) 33 KV SS Pulimamidi f) 33 KV SS Yacharam g) 33 KV SS Peddavoora h) 33 KV SS Pottichelma i) 33 KV SS Nellikal j) 33 KV SS Velmagudem

Location - 132 KV SS Kodad 1x31.5+1x16 47.5 10 93 Injection a) 132KV SS Points Kodad b) 33 KV SS KodadIndoor c) 33 KV SS Bethovolu d) 33 KV SS Ananthagiri e) 33 KV SS N.B.Gudem f) 33 KV SS Gondriyala g) 33 KV SS Munagala h) 33 KV SS Akupamula i) 33 KV SS Nadigudem j) 33 KV SS siripuram

Location - 132 KV SS Tungathurthy 2x31.5 63 5 -- 94 Injection a) 132KV SS Tungathurthy Points b) 33 KV SS Ravulapally c) 33 KV SS Reddygudem d) 33 KV SS Dirshanapally e) 33 KV SS Thungaturthy f) 33 KV SS Annaram g) 33 KV SS Gundepuri h) 33 KV SS Phanigiri i) 33 KV SS Thirumalagiri j) 33 KV SS Jalalpuram

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 197

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Madugulapalli 1x31.5+1x16 47.5 5 95 -- Injection a) 132KV SS Madugulapalli Points b) 33 KV SS Jalalpuram c) 33 KV SS Thipparthy d) 33 KV SS Chervupally e) 33 KV SS Madugulapally f) 33 KV SS Mamidala g) 33 KV SS V.K.Palem h) 33 KV SS Settipalem i) 33 KV SS Buggabaigudem j) 33 KV SS Agamothkur k) 33 KV SS Thadakamalla l) 33 KV SS Laxmideviguda m) 33 KV SS Seetyathanda n) 33 KV SS Cherukupally

Location - 96 132 KV SS Mothukur 1x31.5+1x16 47.5 5 -- Injection a) 132KV SS Mothukur Points b) 33 KV SS Gundala c) 33 KV SS Peddapatashala d) 33 KV SS Ambala e) 33 KV SS Paladugu f) 33 KV SS Pallerla g) 33 KV SS Chamapur h) 33 KV SS Athmakur

Location - 132 KV SS Marriguda 1x31.5+1x16 47.5 5 -- 97 Injection a) 132KV SS Marriguda Points b) 33 KV SS Chandur c) 33 KV SS Pullemla

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 198

SOLAR RFS BID DOCUMENT

d) 33 KV SS Gattuppal e) 33 KV SS Marriguda f) 33 KV SS Shivannaguda g) 33 KV SS D.B.Pally

Location - 132 KV SS Kanagal 1x31.5+1x16 47.5 5 -- 98 Injection a) 132KV SS Points Kanagal b) 33 KV SS G.Yedavelly c) 33 KV SS Pagidimarry d) 33 KV SS Thimmanaguda e) 33 KV SS Thoragal f) 33 KV SS Gurrampode g) 33 KV SS Pochampally h) 33 KV SS Koppole

Location - 132 KV SS Guntipally 1x16 16 5 99 Injection a) 132KV SS Guntipally Points

Location - 132 KV SS Dirsincherla 2x16 32 5 -- 100 Injection Points a) 132KV SS Dirsincherlla b) 33 KV SS Palakeedu c) 33 KV SS Alingapuram d) 33 KV SS Garidepally e) 33 KV SS Keethavarigudem

KHAMMAM Location - 132 KV SS Aswaraopet 1x31.5+1x16 47.5 10 -- 101 Injection a) 132KV SS Points Aswaraopeta b) 33 KV SS Naramvarigudem

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 199

SOLAR RFS BID DOCUMENT

c) 33 KV SS Dammapeta d) 33 KV SS Malkaram e) 33 KV SS Naidupeta f) 33 KV SS Vinayakapuram g) 33 KV SS Gangaram(B)

Location - 102 132 KV SS Kusumanchi 1x31.5+1x16 47.5 10 Injection a) 132KV SS Kusumanchi Points b) 33 KV SS N.S.Gudem c) 33 KV SS Bachodu d) 33 KV SS Kakaravai e) 33 KV SS Perikasingaram f) 33 KV SS Kusumanchi g) 33 KV SS Banapuram h) 33 KV SS Vallabhi i) 33 KV SS Pammi j) 33 KV SS Madhapuram k) 33 KV SS N.K.Pally l) 33 KV SS Buddaram m) 33 KV SS R.J.Puram n) 33 KV SS Jellacheruvu o) 33 KV SS Palair p) 33 KV SS Patharlapadu q) 33 KV SS Tippareddygudem r) 33 KV SS Sublaid

Location - 103 132 KV SS Penubaily 2x31.5 63 10 -- Injection a) 132KV SS penubaily Points b) 33 KV SS Gowravaram c) 33 KV SS Maddukuru d) 33 KV SS Chandrugonda

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 200

SOLAR RFS BID DOCUMENT

e) 33 KV SS Brahmanakunta f) 33 KV SS Pedakorikondi g) 33 KV SS Kurnavalli h) 33 KV SS Kalluru i) 33 KV SS Enkoor j) 33 KV SS SS Palam k) 33 KV SS Raidupalam l) 33 KV SS Kandukuru m) 33 KV SS Vemsoor n) 33 KV SS Marlakunta o) 33 KV SS Guduru p) 33 KV SS Penubally q) 33 KV SS Sathupally r) 33 KV SS Gowrigudem

Location - 104 132 KV SS Bhadrachalam 1x16+1x31.5 47.5 10 -- Injection a) 132KV SS Points Bhadrachalam b) 33 KV SS Burgampadu c) 33 KV SS Sarapaka d) 33 KV SS Charla e) 33 KV SS S.N.Puram f) 33 KV SS Wazeedu g) 33 KV SS Dharamavaram h) 33 KV SS Venkatapuram i) 33 KV SS Suraveedu j) 33 KV SS Chintoor k) 33 KV SS Sarivella l) 33 KV SS Nellipaka m) 33 KV SS Dummugudem n) 33 KV SS Kunavaram

Location - 132 KV SS Madhira 2x16 32 5

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 201

SOLAR RFS BID DOCUMENT

105 Injection a) 132KV SS Points Madhira b) 33 KV SS Bonakal c) 33 KV SS K.I.Padu d) 33 KV SS Siripuram e) 33 KV SS Yerrupalam f) 33 KV SS Mamunoor g) 33 KV SS Mulugumadu

Location - 132 KV SS Gangaram 1x16+1x31.5 47.5 5 106 Injection a) 132KV SS Points Gangaram b) 33 KV SS Pakalagudem c) 33 KV SS Ankampalam d) 33 KV SS Nagupally e) 33 KV SS Gandugulapally f) 33 KV SS Mulakalapally

Location - 132 KV SS Yellandu 2x16 32 10 -- 107 Injection a) 132KV SS Yellandu Points b) 33 KV SS Garla c) 33 KV SS Kothapeta d) 33 KV SS Bayyaram e) 33 KV SS ChallaSamudram f) 33 KV SS Mamakannu g) 33 KV SS Tekulapally h) 33 KV SS Karepally i) 33 KV SS Cheemalapadu j) 33 KV SS Komararam

Location - 132 KV SS Nekkonda 1x31.5+1x50 81.5 5 -- 108 Injection a) 132KV SS Nekkonda

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 202

SOLAR RFS BID DOCUMENT

Points

b) 33 KV SS Nagaram c) 33 KV SS Teegalaveni d) 33 KV SS Upparapalli e) 33 KV SS Chennaraopet f) 33 KV SS Gudur g) 33 KV SS Kesamudram h) 33 KV SS Lingagiri i) 33 KV SS Nekkonda j) 33 KV SS Rangapur k) 33 KV SS Alankanipeta l) 33 KV SS Choutapally m) 33 KV SS Enugallu n) 33 KV SS Parwathagiri o) 33 KV SS Redlawada p) 33 KV SS Sangem q) 33 KV SS Theegarajpally

Location - 132 KV SS Mustyal 1x31.5+1x50 81.5 10 -- 109 Injection a) 132KV SS Mustyal Points b) 33 KV SS Bachannapet c) 33 KV SS Laxmapur Padamati d) 33 KV SS Keshavapur Ramchandrapura e) 33 KV SS m f) 33 KV SS Akunoor g) 33 KV SS Bekkal h) 33 KV SS Chityal i) 33 KV SS Dhoolmitta j) 33 KV SS Mustyal k) 33 KV SS Guruvannapet l) 33 KV SS Komuravelly

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 203

SOLAR RFS BID DOCUMENT

m) 33 KV SS Nagapuri n) 33 KV SS Ankushapur o) 33 KV SS Rebarthy p) 33 KV SS Tharigoppula q) 33 KV SS Veldanda

Location - 110 132 KV SS Chelpur 1x16+1x31.5 47.5 5 -- Injection a) 132KV SS Chelpur Points b) 33 KV SS Gudadpally c) 33 KV SS Jadalpeta d) 33 KV SS Bhoopalpally e) 33 KV SS Nandigama f) 33 KV SS Bagirthipeta g) 33 KV SS Parkal(T) h) 33 KV SS Regonda i) 33 KV SS Repaka

Location - 111 132 KV SS Waradannapet 1x31.5+1x50 81.5 10 -- Injection a) 132KV SS Waradannapet Points b) 33 KV SS Kondur c) 33 KV SS Rayaparthy d) 33 KV SS Dammanapet e) 33 KV SS Kunoor f) 33 KV SS Venkatapur g) 33 KV SS Zafferghad h) 33 KV SS Annram Shariff i) 33 KV SS Liabarthy j) 33 KV SS Mylaram k) 33 KV SS Ellanda l) 33 KV SS Nandanam m) 33 KV SS Panthini

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 204

SOLAR RFS BID DOCUMENT

n) 33 KV SS Wadlakonda

Location - 112 132 KV SS Ayyagaripally 1x31.5+1x50 81.5 10 -- Injection Points a) 132KV SS Ayyagaripally b) 33 KV SS Amangal c) 33 KV SS Chenigapuram d) 33 KV SS Chinnaguduru e) 33 KV SS Inugurthy f) 33 KV SS Kalwala g) 33 KV SS Dornakal h) 33 KV SS Jamandlapally i) 33 KV SS Bodhugonda j) 33 KV SS Mogilicherla k) 33 KV SS Nerada l) 33 KV SS Edjerla m) 33 KV SS Giripuram n) 33 KV SS Maripeda o) 33 KV SS Gollacherla p) 33 KV SS Mannegudem q) 33 KV SS P'Sankeesa r) 33 KV SS Upparagudem

Location - 132 KV SS Madikonda (Waddepalli) 2x31.5 63 10 -- 113 Injection a) 132KV SS Madikonda Points b) 33 KV SS Dharmasagar c) 33 KV SS Jayagiri d) 33 KV SS Mallikudurla e) 33 KV SS Narayanagiri f) 33 KV SS Velair

g) 33 KV SS

h) 33 KV SS KUC

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 205

SOLAR RFS BID DOCUMENT

i) 33 KV SS Madikonda j) 33 KV SS West City k) 33 KV SS REC l) 33 KV SS Shayampet

Location - 132 KV SS Ghanpur 1x16+1x31.5 47.5 5 114 -- Injection a) 132KV SS Points Ghanpur b) 33 KV SS Malkapur c) 33 KV SS Peddapendyal d) 33 KV SS Peechara e) 33 KV SS Rajavaram f) 33 KV SS Gudur (P) g) 33 KV SS Ippagudem h) 33 KV SS Namiligonda i) 33 KV SS Suraram j) 33 KV SS Thimmampet k) 33 KV SS Thatikonda

Location - 132 KV SS Mulugu 3x16 48 10 -- 115 Injection a) 132KV SS Mulugu Points b) 33 KV SS Mallampally c) 33 KV SS Ramchandrapur d) 33 KV SS Abbapur e) 33 KV SS Gorikothapally f) 33 KV SS Koppula g) 33 KV SS Mulugu h) 33 KV SS Govindraopet i) 33 KV SS Kasimdevipeta j) 33 KV SS Medaram k) 33 KV SS Pasra l) 33 KV SS Laxmidevipeta

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 206

SOLAR RFS BID DOCUMENT

m) 33 KV SS Peddapur n) 33 KV SS Velthurlapally

Location - 132 KV SS Dharmasagar 2x50+1x16 116 10 116 Injection a) 132KV SS Dharmasagar Points

Location - 132 KV SS Narsampet 1x31.5+1x16 47.5 5 -- 117 Injection a) 132KV SS Narsampet Points b) 33 KV SS Gangaram c) 33 KV SS Kothaguda d) 33 KV SS Mangalavaripet e) 33 KV SS Sadireddypally f) 33 KV SS Dasaripally g) 33 KV SS Medapally h) 33 KV SS Nallabelly i) 33 KV SS Narsampet j) 33 KV SS Duggondi k) 33 KV SS Elkurthy l) 33 KV SS Mondrai m) 33 KV SS Rekhampally Location - 132 KV SS Jangaon 2x16 32 10 -- 118 Injection a) 132KV SS Obulakeshapur Points b) 33 KV SS Adavukeshapur c) 33 KV SS Jangaon-I d) 33 KV SS Jangaon-I e) 33 KV SS Jangaon-II f) 33 KV SS Marigadi g) 33 KV SS Jeedikal h) 33 KV SS Lingala Ghanpur i) 33 KV SS Pemberthy

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 207

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Chityala 2x16 32 5 -- 119 Injection a) 132KV SS Chityal Points b) 33 KV SS Rangapur c) 33 KV SS Ramakistapur d) 33 KV SS Tekumatla

Location - 132 KV SS Peddanagaram 2x16 32 5 -- 120 Injection a) 132KV SS Kousalyadevipally Points b) 33 KV SS Kommulavancha c) 33 KV SS Munigalaveedu d) 33 KV SS Pedda Nagaram e) 33 KV SS Danthalapally f) 33 KV SS Peddamupparam g) 33 KV SS Reponi h) 33 KV SS Yellampet KARIMNAGAR Location - 132 KV SS Korutla 1x50+1x31.5 81.5 10 -- 121 Injection a) 132KV SS Korutla Points b) 33 KV SS Ambaripeta c) 33 KV SS Thandrial d) 33 KV SS Manala e) 33 KV SS Bhushanraopet f) 33 KV SS Korutla Town g) 33 KV SS Paidimadugu h) 33 KV SS Dharmaram i) 33 KV SS Ailapur j) 33 KV SS Vempet k) 33 KV SS Metpally l) 33 KV SS Korutla Town-II m) 33 KV SS Vellulla n) 33 KV SS Athmakur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 208

SOLAR RFS BID DOCUMENT

o) 33 KV SS Jaggasagar p) 33 KV SS Bommena q) 33 KV SS Mannegudem r) 33 KV SS Govindaram s) 33 KV SS Yakeenpur

Location - 122 132 KV SS Sircilla 2x50 100 15 -- Injection a) 132KV SS Sircilla Points b) 33 KV SS Pedur c) 33 KV SS Rallapeta d) 33 KV SS Namapur e) 33 KV SS Pegadapally f) 33 KV SS Boanala g) 33 KV SS Marthanapet h) 33 KV SS Nizamabad i) 33 KV SS Textile Park j) 33 KV SS Thangallapally k) 33 KV SS Shivanagar l) 33 KV SS Nerella m) 33 KV SS Avunoor n) 33 KV SS Nampally o) 33 KV SS Ramvaram p) 33 KV SS Vankupally

Location - 132 KV SS Jagityal 1x50+1x31.5 81.5 10 -- 123 Injection a) 132KV SS Jagityal Points b) 33 KV SS Allipur c) 33 KV SS Kothakonda d) 33 KV SS Itikyal e) 33 KV SS Voddelingapur f) 33 KV SS Chelgal

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 209

SOLAR RFS BID DOCUMENT

g) 33 KV SS Venakatraopet h) 33 KV SS Medipally i) 33 KV SS Venkatapur j) 33 KV SS Jagitial k) 33 KV SS Polasa l) 33 KV SS Laxmipur m) 33 KV SS Pegadapally n) 33 KV SS T.R.Nagar

Location - 132 KV SS Husnabad 2x31.5 63 5 -- 124 Injection a) 132KV SS Husnabad Points b) 33 KV SS Gandipally c) 33 KV SS Gouravelly d) 33 KV SS Vangara e) 33 KV SS Potharam f) 33 KV SS Kothakonda g) 33 KV SS Samudrala h) 33 KV SS Indurthy i) 33 KV SS Rekonda

Location - 132 KV SS Sultanabad (Suglampally) 2x31.5 63 5 -- 125 Injection Sultanabad(Sugla a) 132KV SS Points mpally) b) 33 KV SS Eligedu c) 33 KV SS Julapally d) 33 KV SS Kachapur e) 33 KV SS Rangampally f) 33 KV SS Raghavapur g) 33 KV SS Peddapally (T) h) 33 KV SS Maredugonda i) 33 KV SS Bojannapet j) 33 KV SS Jafferkhanpet

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 210

SOLAR RFS BID DOCUMENT

k) 33 KV SS Pegadapally l) 33 KV SS Kolanur m) 33 KV SS Pothkapally n) 33 KV SS Chinnabonkur o) 33 KV SS Kanagarthy p) 33 KV SS Odela q) 33 KV SS Sultanabad

Location - 132 KV SS Huzurabad 1x16+1x31.5 47.5 5 -- 126 Injection a) 132KV SS Huzurabad Points b) 33 KV SS Godishala c) 33 KV SS Kothagattu d) 33 KV SS Thadikal e) 33 KV SS Uppal

f) 33 KV SS Peddapapaiahpall y g) 33 KV SS Elkathurthy

Location - 132 KV SS Mallaram 2x16 32 5 -- 127 Injection a) 132KV SS Mallaram Points b) 33 KV SS Baosaipet c) 33 KV SS Mallaram d) 33 KV SS Marrigadda e) 33 KV SS Vemulawada f) 33 KV SS Nimmapalli g) 33 KV SS Sanugula h) 33 KV SS Bejjanki

Location - 132 KV SS Ellantakunta 1x31.5+1x16 47.5 10 128 Injection a) 132KV SS Ellan takunta Points b) 33 KV SS Peddalingapur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 211

SOLAR RFS BID DOCUMENT

c) 33 KV SS Kasimpet d) 33 KV SS Somarampet

Location - 132 KV SS Dharmapuri 2x16 32 5 -- 129 Injection a) 132KV SS Dharmapuri Points b) 33 KV SS Sirikonda c) 33 KV SS Jaina d) 33 KV SS Nerella

Location - 132 KV SS Pudur 2x16 32 5 130 Injection a) 132KV SS Pudur Points b) 33 KV SS Thatipally c) 33 KV SS Bathikepally d) 33 KV SS Kodimyal e) 33 KV SS Maddutla f) 33 KV SS Burugupally

Location - 132 KV SS Yellareddypeta 1x25+1x16 41 5 131 Injection a) 132KV SS Yellareddypeta Points b) 33 KV SS Lingannapet c) 33 KV SS Kothapally d) 33 KV SS Gajasingaram e) 33 KV SS Garjanapally f) 33 KV SS Rajannapet g) 33 KV SS Yellareddypet

Location - 132 KV SS Manakondur 2x16 32 5 132 Injection a) 132KV SS Manakondur Points b) 33 KV SS Elbaka c) 33 KV SS Pochampally

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 212

SOLAR RFS BID DOCUMENT

d) 33 KV SS Chenjerla

Location - 133 132 KV SS Dharmaram 2x16 32 5 Injection Points a) 132KV SS Dharmaram b) 33 KV SS Mallapur c) 33 KV SS Yellapur d) 33 KV SS Kothur e) 33 KV SS Velgatoor f) 33 KV SS Basanthnagar g) 33 KV SS Khilavanaparthy f) 33 KV SS Chilvakodur

Location - 132 KV SS Shanigarm 2x16 32 5 134 Injection a) 132KV SS Shanigaram Points b) 33 KV SS Thotapally c) 33 KV SS Begumpet d) 33 KV SS Koheda e) 33 KV SS Ramchandrapur

Location - 132 KV SS Godur 2x16 32 5 -- 135 Injection Points a) 132KV SS Godur b) 33 KV SS Varshakonda c) 33 KV SS Medipally d) 33 KV SS Ragavapuram e) 33 KV SS Mallapur

Location - 132 KV SS Kataram 2x16 32 5 136 -- Injection a) 132KV SS Kataram Points b) 33 KV SS Maha Mutharam c) 33 KV SS Mahadevpur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 213

SOLAR RFS BID DOCUMENT

d) 33 KV SS Peddampet e) 33 KV SS Kaleshwaram f) 33 KV SS Koyyur g) 33 KV SS Gangaram f) 33 KV SS V.V. Raopet

Location - 137 132 KV SS RTS 'B' Yellampalli 1x31.5+1x16 47.5 5 -- Injection a) 132KV SS RTS 'B' Yellampalli Points

Location - 132 KV SS Gangadhra (LIS) 1x50+1x25 75 5 -- 138 Injection a) 132KV SS Gangadhra(LIS) Points

Location - 132 KV SS Yellampally 2x16 32 5 139 Injection a) 132KV SS Yellampally Points

NIZAMABAD Location - 140 132 KV SS Kamareddy 1x50+1x31.5 81.5 10 Injection Points a) 132KV SS Kamareddy - I Siricilla Road- b) 33 KV SS KMR c) 33 KV SS Arepally d) 33 KV SS Bhavanipet-M e) 33 KV SS Issaipet f) 33 KV SS Velupugonda g) 33 KV SS Brahmanpally h) 33 KV SS Gandhari i) 33 KV SS Sarvapoor j) 33 KV SS Adloor Yellareddy k) 33 KV SS S.S.Nagar l) 33 KV SS Padmajiwadi m) 33 KV SS Utnoor

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 214

SOLAR RFS BID DOCUMENT

n) 33 KV SS Housing Board- KMR o) 33 KV SS Lingapoor p) 33 KV SS Rajampet q) 33 KV SS Chinnamallareddy r) 33 KV SS Tadwai s) 33 KV SS Aragonda t) 33 KV SS Yerrapahad u) 33 KV SS Kondapur v) 33 KV SS Posanipet

Location - 132 KV SS Renjal 1x31.5+1x16 47.5 10 -- 141 Injection a) 132KV SS Renjal Points b) 33 KV SS Navipet c) 33 KV SS Dandigutta d) 33 KV SS Rampoor e) 33 KV SS Kosli f) 33 KV SS Yemcha g) 33 KV SS Neela h) 33 KV SS Tadbiloli i) 33 KV SS Pegadapally j) 33 KV SS Ch.Mavandi k) 33 KV SS Saloora l) 33 KV SS A.R.P.Camp m) 33 KV SS Mangalpahad n) 33 KV SS Yedapally o) 33 KV SS Renjal

Location - 132 KV SS Jakhora 1x50+1x31.5 81.5 15 142 -- Injection a) 132KV SS Jakhora Points b) 33 KV SS Srinagar c) 33 KV SS Chandoor

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 215

SOLAR RFS BID DOCUMENT

d) 33 KV SS Chinthakunta e) 33 KV SS Mosra f) 33 KV SS Jalalpur g) 33 KV SS Kotagiri h) 33 KV SS Pothangal i) 33 KV SS Jakhora (Varni) j) 33 KV SS Nasrullabad k) 33 KV SS Sangam l) 33 KV SS Kalloor m) 33 KV SS Kothapally n) 33 KV SS Ambam o) 33 KV SS Rudrur p) 33 KV SS Raikur

Location - 132 KV SS Nandipet 1x50+1x31.5 81.5 5 -- 143 Injection a) 132KV SS Nandipet Points b) 33 KV SS Degoam c) 33 KV SS Manthani d) 33 KV SS Aloor

Location - 132 KV SS Domakonda 2x31.5 63 5 144 Injection a) 132KV SS Domakonda Points b) 33 KV SS Kyasampally c) 33 KV SS Muthyampet d) 33 KV SS Domakonda e) 33 KV SS Laxmidevanpally f) 33 KV SS Jangampally g) 33 KV SS Thippaur h) 33 KV SS Talamadla i) 33 KV SS Narsannapally j) 33 KV SS Janagoan

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 216

SOLAR RFS BID DOCUMENT

k) 33 KV SS Mohommadapur l) 33 KV SS Bibipet m) 33 KV SS Issanagar n) 33 KV SS Thujalpur o) 33 KV SS Fareedpet p) 33 KV SS Chukkapur q) 33 KV SS Lachapet r) 33 KV SS Annaram s) 33 KV SS Yellampet t) 33 KV SS Somavarpet

Location - 145 132 KV SS Armoor 1x31.5+1x16 47.5 5 Injection Points a) 132KV SS Armoor b) 33 KV SS Munipally c) 33 KV SS Issapally d) 33 KV SS Ankapoor e) 33 KV SS Pipri f) 33 KV SS Maggidi g) 33 KV SS Komanpally h) 33 KV SS Perkit i) 33 KV SS Govindpet j) 33 KV SS Lakkora k) 33 KV SS Fathepur

Location - 132 KV SS Bichkonda 2x16 32 5 146 Injection a) 132KV SS Bichkunda Points b) 33 KV SS Madnoor c) 33 KV SS Menoor d) 33 KV SS Dongli e) 33 KV SS Peddakodapgal f) 33 KV SS Kemrajkallali

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 217

SOLAR RFS BID DOCUMENT

g) 33 KV SS Somur h) 33 KV SS Jukkal i) 33 KV SS Pulkal j) 33 KV SS Kathgoan

Location - 132 KV SS Lingapet 2x16 32 5 147 Injection a) 132KV SS Points Lingampet b) 33 KV SS Bhavanipet c) 33 KV SS Gandimasanipet d) 33 KV SS Mothe e) 33 KV SS Parmalla f) 33 KV SS Khannapur g) 33 KV SS S.S.Reddy h) 33 KV SS Malthummeda i) 33 KV SS Ramalaxmanpally

Location - 132 KV SS Morthad 1x31.5+1x16 47.5 5 148 Injection a) 132KV SS Morthad Points b) 33 KV SS Kammarpally c) 33 KV SS Basheerabad d) 33 KV SS Anksapur e) 33 KV SS Kuknoor f) 33 KV SS Donkal g) 33 KV SS Morthad h) 33 KV SS Palem i) 33 KV SS Uploor j) 33 KV SS Timmapur

Location - 132 KV SS Banswada 2x16 32 5 149 -- Injection a) 132KV SS Points Banswada b) 33 KV SS Damarancha

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 218

SOLAR RFS BID DOCUMENT

c) 33 KV SS Maddelcheru d) 33 KV SS Shanthapoor e) 33 KV SS Chillargi f) 33 KV SS Birkur g) 33 KV SS Mirzapur h) 33 KV SS Konapur i) 33 KV SS Ibrahimpet

Location - 132 KV SS Dharmora 2x16 32 5 150 (Gutta LI scheme) --

Injection Dharmora(Gutta a) 132KV SS Points LI Scheme)

Location - 132 KV SS C.H.Kondur (Gutta LI 2x16 32 5 151 scheme)

Injection C.H.Kondur(Gutta a) 132KV SS Points LI Scheme)

Location - 132 KV SS Bikanoor 2x16 32 5 -- 152 Injection a) 132KV SS Biknoor Points b) 33 KV SS Baswapoor c) 33 KV SS Peddamallareddy d) 33 KV SS Kachapoor e) 33 KV SS Isannapaly f) 33 KV SS Thippapur g) 33 KV SS Talamadla

Location - 132 KV SS Reddypet 2x16 32 5 153 Injection a) 132KV SS Reddypet Points b) 33 KV SS Shasodopur c) 33 KV SS Ramreddy

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 219

SOLAR RFS BID DOCUMENT

d) 33 KV SS Adloor ADILABAD Location - 154 132 KV SS Adilabad 2x31.5 63 5 Injection Points a) 132KV SS Adilabad b) 33 KV SS Bukthapur c) 33 KV SS Rampur d) 33 KV SS G.S.Nagar e) 33 KV SS Kailasnagar f) 33 KV SS Thamsi g) 33 KV SS Talamadugu h) 33 KV SS Arli i) 33 KV SS Ponnari j) 33 KV SS Jainath k) 33 KV SS Bhoraj l) 33 KV SS Sathnala m) 33 KV SS Bela n) 33 KV SS Dasnapur

Location - 132 KV SS Bellampally 1x15+1x16 31 5 -- 155 Injection a) 132KV SS Bellampally Points b) 33 KV SS Andugulpet c) 33 KV SS Kondapoor d) 33 KV SS Nennel e) 33 KV SS Bellampally (T) f) 33 KV SS Rebbana g) 33 KV SS Thandoor h) 33 KV SS Kannepally i) 33 KV SS Ginnedari j) 33 KV SS Thiryani k) 33 KV SS Asifabad l) 33 KV SS Ippal Navegoam

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 220

SOLAR RFS BID DOCUMENT

m) 33 KV SS Wankidi n) 33 KV SS Kerameri o) 33 KV SS Jankapur p) 33 KV SS Rechini q) 33 KV SS Vankulam Shivalayam/Bella r) 33 KV SS mpaly Town

Location - 132 KV SS Mancherial 1x31.5+1x16 47.5 5 -- 156 Injection a) 132KV SS Mancherial Points b) 33 KV SS ACC c) 33 KV SS Ramnagar d) 33 KV SS Jaipoor e) 33 KV SS Kundaram f) 33 KV SS Naspoor g) 33 KV SS Hazipoor h) 33 KV SS Ryali Gadpoor i) 33 KV SS RKP j) 33 KV SS Gudipet k) 33 KV SS Awadam l) 33 KV SS RK 6 Huts

Location - 132 KV SS Sirpurkagaznagar 2x16 32 5 157 a) 132KV SS Sirpurkagaznagar b) 33 KV SS Kagaz nagar (t) c) 33 KV SS Nazrool nagar d) 33 KV SS jambuga e) 33 KV SS Sirpur(t) f) 33 KV SS Kowtala g) 33 KV SS Ravindranagar h) 33 KV SS Rebbena(B) i) 33 KV SS Beejjur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 221

SOLAR RFS BID DOCUMENT

j) 33 KV SS Elkapally

k) 33 KV SS Dahegam

Location - 132 KV SS Bhainsa 2x31.5 63 5 -- 158 a) 132KV SS BHAINSA b) 33 KV SS DEGAON c) 33 KV SS WANALPAD d) 33 KV SS LOHESRA e) 33 KV SS PIPREE f) 33 KV SS ABDULLAPUR g) 33 KV SS MANMAD h) 33 KV SS KALLUR i) 33 KV SS KUNTALA j) 33 KV SS Gollamada k) 33 KV SS KUBEER l) 33 KV SS Sonari m) 33 KV SS Mudhole n) 33 KV SS EDBID o) 33 KV SS BRAHMAN GOAN p) 33 KV SS THANOOR q) 33 KV SS Beltharoda

Location - 132 KV SS Luxettipeta 2x16 32 5 159 -- a) 132KV SS Luxettipeta b) 33 KV SS Suraram c) 33 KV SS Jannaram d) 33 KV SS Dandepally e) 33 KV SS Velganoor f) 33 KV SS Venkatraopet g) 33 KV SS Kawal h) 33 KV SS Thapalpur

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 222

SOLAR RFS BID DOCUMENT

Location - 132 KV SS Ichoda 2x16 32 5 160 -- a) 132KV SS Ichoda b) 33 KV SS Barampur c) 33 KV SS Echoda d) 33 KV SS Bazarhathnoor e) 33 KV SS Pochera (Boath) f) 33 KV SS Sonala g) 33 KV SS Neradigonda h) 33 KV SS Utnoor i) 33 KV SS Pulimadugu j) 33 KV SS Narnoor k) 33 KV SS Lokari l) 33 KV SS Jainoor m) 33 KV SS Sirpur U n) 33 KV SS Indervelly o) 33 KV SS Dasnapur (Ivelly) p) 33 KV SS Gudihathnoor q) 33 KV SS Seethagondi

Location - 132 KV SS Chennur 2x16 32 5 -- 161 a) 132KV SS Chennur b) 33 KV SS Kotapally c) 33 KV SS Neelwai d) 33 KV SS Bheemaram e) 33 KV SS Devula Wada f) 33 KV SS Chennor g) 33 KV SS Kommera

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 223

SOLAR RFS BID DOCUMENT

Format 6.13 – Format for Contract Performance Bank Guarantee

(To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution.)

In consideration of the ------[Insert name of the Bidder] (hereinafter referred to as selected Solar Power Developer') submitting the response to RfS inter alia for selection of the project of the capacity of ______MW, at …………[Insert name of the place], for supply of power there from on long term basis, in response to the RfS dated ………….issued by APTRANSCO/DISCOM and APTRANSCO/DISCOM considering such response to the RfS of ………[insert the name of the selected Solar Power Developer] (which expression shall unless repugnant to the context or meaning thereof include its executers, administrators, successors and assignees) and selecting the Solar Power Project of the Developer and issuing Letter of Intent No ------to (Insert Name of selected Solar Power Developer) as per terms of RfS and the same having been accepted by the selected SPD resulting in a Power Purchase Agreement (PPA) to be entered into, for purchase of Power [from selected Solar Power Developer or a Project Company, M/s ------{a Special Purpose Vehicle (SPV) formed for this purpose}, if applicable ]. As per the terms of the RfS, the [insert name & address of bank] hereby agrees unequivocally, irrevocably and unconditionally to pay to APTRANSCO/DISCOM at [Insert Name of the Place from the address of the APTRANSCO/DISCOM] forthwith on demand in writing from APTRANSCO/DISCOM or any Officer authorised by it in this behalf, any amount up to and not exceeding Rupees------[Total Value] only, on behalf of M/s [Insert name of the selected Solar Power Developer / Project Company ]

This guarantee shall be valid and binding on this Bank up to and including and shall not be terminable by notice or any change in the constitution of the Bank or the term of contract or by any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any extension of time or variations or alternations made, given, or agreed with or without our knowledge or consent, by or between parties to the respective agreement.

Our liability under this Guarantee is restricted to Rs. (Rs. only) ------. Our Guarantee shall remain in force until _[Insert date] APTRANSCO/DISCOM shall be entitled to invoke this Guarantee till [Insert date]

The Guarantor Bank hereby agrees and acknowledges that the APTRANSCO/DISCOM shall

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 224

SOLAR RFS BID DOCUMENT

have a right to invoke this BANK GUARANTEE in part or in full, as it may deem fit.

The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the written demand by APTRANSCO/DISCOM, made in any format, raised at the above mentioned address of the Guarantor Bank, in order to make the said payment to APTRANSCO/DISCOM.

The Guarantor Bank shall make payment hereunder on first demand without restriction or conditions and notwithstanding any objection by ------[Insert name of the selected Solar Power Developer / Project Company as applicable] and/or any other person. The Guarantor Bank shall not require APTRANSCO/DISCOM to justify the invocation of this BANK GUARANTEE, nor shall the Guarantor Bank have any recourse against APTRANSCO/DISCOM in respect of any payment made hereunder

This BANK GUARANTEE shall be interpreted in accordance with the laws of India and the courts at Andhra Pradesh shall have exclusive jurisdiction.

The Guarantor Bank represents that this BANK GUARANTEE has been established in such form and with such content that it is fully enforceable in accordance with its terms as against the Guarantor Bank in the manner provided herein.

This BANK GUARANTEE shall not be affected in any manner by reason of merger, amalgamation, restructuring or any other change in the constitution of the Guarantor Bank.

This BANK GUARANTEE shall be a primary obligation of the Guarantor Bank and accordingly APTRANSCO/DISCOM shall not be obliged before enforcing this BANK GUARANTEE to take any action in any court or arbitral proceedings against the selected Solar Power Developer / Project Company, to make any claim against or any demand on the selected Solar Power Developer / Project Company or to give any notice to the selected Solar Power Developer / Project Company or to enforce any security held by APTRANSCO/DISCOM or to exercise, levy or enforce any distress, diligence or other process against the selected Solar Power Developer / Project Company .

The Guarantor Bank acknowledges that this BANK GUARANTEE is not personal to APTRANSCO/DISCOM and may be assigned, in whole or in part, (whether absolutely or by way of security) by APTRANSCO/DISCOM to any entity to whom APTRANSCO/DISCOM is entitled to assign its rights and obligations under the PPA.

Notwithstanding anything-contained hereinabove, our liability under this Guarantee is

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 225

SOLAR RFS BID DOCUMENT

restricted to Rs. (Rs. only) and it shall remain in force until with an additional claim period of thirty (30) days thereafter. We are liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only if APTRANSCO/DISCOM serves upon us a written claim or demand.

Signature

Name

Power of Attorney No. For

[Insert Name of the Bank]

Banker's Stamp and Full Address.

Dated this day of , 20 Witness: 1. ……………………………………. Signature Name and Address 2. …………………………………..

Signature Name and Address

Notes:

The Stamp Paper should be in the name of the Executing Bank. The Bank Guarantee shall be executed by any of the Bank from the List of Banks enclosed.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 226

SOLAR RFS BID DOCUMENT

Format 6.14 – Format for Earnest Money Deposit (EMD)

(To be on non-judicial stamp paper of appropriate value as per Stamp Act relevant to place of execution.)

In consideration of the ------[Insert name of the Bidder] (hereinafter referred to as selected Solar Power Developer') submitting the response to RfS inter alia for selection of the project of the capacity of ______MW, at …………[Insert name of the place], for supply of power there from on long term basis, in response to the RfS dated ………….issued by APTRANSCO and APTRANSCO considering such response to the RfS of ………[insert the name of the selected Solar Power Developer] (which expression shall unless repugnant to the context or meaning thereof include its executers, administrators, successors and assignees) and selecting the Solar Power Project of the Developer and issuing Letter of Intent No ------to (Insert Name of selected Solar Power Developer) as per terms of RfS and the same having been accepted by the selected SPD resulting in a Power Purchase Agreement (PPA) to be entered into, for purchase of Power [from selected Solar Power Developer or a Project Company, As per the terms of the RfS, the [insert name & address of bank] hereby agrees unequivocally, irrevocably and unconditionally to pay to APTRANSCO at [Insert Name of the Place from the address of the APTRANSCO] forthwith on demand in writing from APTRANSCO or any Officer authorised by it in this behalf, any amount up to and not exceeding Rupees------[Total Value] only, on behalf of M/s [Insert name of the selected Solar Power Developer / Project Company]

This guarantee shall be valid and binding on this Bank up to and including and shall not be terminable by notice or any change in the constitution of the Bank or the term of contract or by any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any extension of time or variations or alternations made, given, or agreed with or without our knowledge or consent, by or between parties to the respective agreement.

Our liability under this Guarantee is restricted to Rs. (Rs. only). Our Guarantee shall remain in force until _[Insert date] APTRANSCO shall be entitled to invoke this Guarantee till [Insert date]

The Guarantor Bank hereby agrees and acknowledges that the APTRANSCO shall have a right to invoke this BANK GUARANTEE in part or in full, as it may deem fit.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 227

SOLAR RFS BID DOCUMENT

The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the written demand by APTRANSCO, made in any format, raised at the above mentioned address of the Guarantor Bank, in order to make the said payment to APTRANSCO

The Guarantor Bank shall make payment hereunder on first demand without restriction or conditions and notwithstanding any objection by ------[Insert name of the selected Solar Power Developer / Project Company as applicable] and/or any other person. The Guarantor Bank shall not require APTRANSCO to justify the invocation of this BANK GUARANTEE, nor shall the Guarantor Bank have any recourse against APTRANSCO in respect of any payment made hereunder

This BANK GUARANTEE shall be interpreted in accordance with the laws of India and the courts at Andhra Pradesh shall have exclusive jurisdiction.

The Guarantor Bank represents that this BANK GUARANTEE has been established in such form and with such content that it is fully enforceable in accordance with its terms as against the Guarantor Bank in the manner provided herein.

This BANK GUARANTEE shall not be affected in any manner by reason of merger, amalgamation, restructuring or any other change in the constitution of the Guarantor Bank.

This BANK GUARANTEE shall be a primary obligation of the Guarantor Bank and accordingly APTRANSCO shall not be obliged before enforcing this BANK GUARANTEE to take any action in any court or arbitral proceedings against the selected Solar Power Developer / Project Company, to make any claim against or any demand on the selected Solar Power Developer / Project Company or to give any notice to the selected Solar Power Developer / Project Company or to enforce any security held by APTRANSCO or to exercise, levy or enforce any distress, diligence or other process against the selected Solar Power Developer / Project Company .

The Guarantor Bank acknowledges that this BANK GUARANTEE is not personal to APTRANSCO and may be assigned, in whole or in part, (whether absolutely or by way of security) by APTRANSCO to any entity to whom APTRANSCO is entitled to assign its rights and obligations under the PPA.

Notwithstanding anything-contained hereinabove, our liability under this Guarantee is restricted to Rs. (Rs. only) and it shall remain in force

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 228

SOLAR RFS BID DOCUMENT

until with an additional claim period of thirty (30) days thereafter. We are liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only if APTRANSCO serves upon us a written claim or demand.

Signature

Name

Power of Attorney No. For

[Insert Name of the Bank]

Banker's Stamp and Full Address.

Dated this day of , 20 Witness: 1. ……………………………………. Signature Name and Address 2. …………………………………..

Signature Name and Address

Notes:

The Stamp Paper should be in the name of the Executing Bank. The EMD shall be executed by any of the Bank from the List of Banks enclosed.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 229

SOLAR RFS BID DOCUMENT

Appendix – A CHECK LIST FOR BANK GUARANTEES/DDs Sl.No. Details of checks YES/NO. a) Bid Processing fee Rs. 2 Lakhs in the form of DD or by online payment through RTGS . b) Is the EMD in the form of BG. C) Whether date, purpose of purchase of stamp paper and name of the purchaser are indicated on the back of Stamp paper under the Signature of Stamp vendor? (The date of purchase of stamp paper should be not later than the date of execution of BG and the stamp paper should be purchased either in the name of the executing Bank or the party on whose behalf the BG has been issued. Also the Stamp Paper should not be older than six months from the date of execution of BG). d) In case of BGs from Banks abroad, has the BG been executed on Letter Head of the Bank endorsed by SBI, India. e) Has the executing Officer of BG indicated his name, designation and Power of Attorney No./Signing Power no. on the BG? f) Is each page of BG duly signed / initialed by executants and whether stamp of Bank is affixed thereon? Whether the last page is signed with full particulars including two witnesses under seal of Bank as required in the prescribed proforma? g) Does the Bank Guarantees compare verbatim with the Proforma prescribed in the Bid Documents? h) Are the factual details such as Bid Document No. / Specification No., / LoI No. (if applicable) / Amount of BG and Validity of BG correctly mentioned in the BG i) Whether overwriting/cutting if any on the BG have been properly authenticated under signature & seal of executant? j) Whether the BG has been issued by a Bank in line with the provisions of Bidding documents? k) In case BG has been issued by a Bank other than those specified in Bidding Document, is the BG confirmed by a Bank in India acceptable as per Bidding documents?

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 230

SOLAR RFS BID DOCUMENT

Annexure1 Technical Qualification requirement in case of Solar Project

The following are some of the technical measures required to ensure quality of the PV modules used in grid connected Solar Power Projects.

1. PV Module Qualification

1.1 The PV modules used in the grid connected Solar Power Projects must qualify to the latest edition of any of the following IEC PV module qualification test or equivalent BIS standards.

Crystalline Silicon Solar Cell Modules IEC 61215

Thin Film Modules IEC 61646

Concentrator PV modules IEC 62108

1.2 In addition, PV modules must qualify to IEC 61730 for safety qualification testing. For the PV modules to be used in a highly corrosive atmosphere throughout their lifetime, they must qualify to IEC 61701. 2 Solar Thermal Qualification 2.1 Only new plant & machinery to be used. 2.2 Any of the Concentrated Solar Power (CSP) technology, such as, Parabolic Trough Collectors, Solar Dish Stirling (or any other prime mover), Linear Fresnel Reflector, Central Tower with heliostats, or their any other combination could be used.

3. Authorized Test Centers

The Solar plant equipment must be tested and approved by one of the IEC/ Accredited authorized test centers as per norms. In addition a PV module qualification test certificate as per IEC standard, issued by Solar Energy Centre, MNRE, New Delhi will also be valid.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 231

SOLAR RFS BID DOCUMENT

4. Warranty

The mechanical structures, electrical works and overall workmanship of the grid solar power plants must be warranted for a minimum of 5 years.

The plant equipment used for solar Power generation in grid connected solar power plants must be warranted for output wattage, which should not be less than 90% at the end of 10 years and 75% at the end of 20 years.

5. Identification and Traceability

Each equipment used in any Solar power Project must use a RF identification tag (RFID). The following information must be mentioned in the RFID used on each module (This can be inside or outside the laminate, but must be able to withstand state harsh environmental conditions.)

(i) Name of the manufacturer of each equipment. (ii) Month and year of the manufacture (separately for solar cells and module) of each apparatus. (iii) Country of origin (separately for solar cells and module). (iv) I-V curve for the module and generator. (v) Wattage, Im, Vm and FF for the module for the installed equipment. (vi) Unique Serial No and Model No of the module. (vii) Date and year of obtaining qualification certificate from appropriate authority as per Indian/Global standards. (viii) Name of the test lab issuing IEC/qualification certificate. (ix) Other relevant information on traceability of solar cells and module as per ISO 9000.

All grid connected Solar Power Projects must install necessary equipment to continuously measure solar radiation, ambient temperature, and other weather parameters and simultaneously measure the generation of DC power as w ell as AC power generated from the plant besides measuring Electrical Parameters. It is also required that suitable SCADA system with facilities for remote monitoring must be installed. They will be required to provide remote access to the above data to SLDCas well as submit the same through a monthly report for the entire duration of Power Purchase Agreement.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 232

SOLAR RFS BID DOCUMENT

Annexure 2 List of Banks

A. SBI AND ASSOCIATES 1. State Bank of India 2. State Bank of Bikaner & Jaipur 3. State Bank of Hyderabad 4. State Bank of Indore 5. State Bank of Mysore 6. State Bank of Patiala 7. State Bank of Travancore B. NATIONALISED BANKS 1. Allahabad Bank 2. Andhra Bank 3. Bank of India 4. Bank of Maharashtra 5. Canara Bank 6. Central Bank of India 7. Corporation Bank 8. Dena Bank 9. Indian Bank 10. Indian Overseas Bank 11. Oriental Bank of Commerce 12. Punjab National Bank 13. Punjab & Sind Bank 14. Syndicate Bank of India 15. Union Bank of India 16. United Bank of India 17. UCO Bank 18. Vijaya Bank 19. Bank of Baroda C. SCHEDULED FOREIGN BANKS 1. Bank of America N.A. 2. Bank of Tokyo Mitsubishi UFJ Ltd. 3. BNP Paribas 4. Citi Bank N.A. 5. Deutsche Bank A.G 6. The Hongkong and Shanghai Banking Corp. Ltd. 7. Standard Charted Bank 8. Societe General 9. Barclays Bank 10. ABN Amro Bank N.V. 11. Bank of Nova Scotia 12. Development Bank of Singapore(DBS, Bank Ltd.)

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 233

SOLAR RFS BID DOCUMENT

Annexure 3 Checklist of Documents to be submitted: a. Demand Draft/Receipt of cash payment made towards cost of the RfS. b. RfS document duly signed and stamped on every page. c. Covering Letter as per Format 6.1 d. Power of Attorney/Board Resolution as per Format 6.2 e. Earnest Money Deposit (EMD) in the form of Demand Draft in Format 6.14 f. Processing fee in the form of Demand Draft g. Submission of bid document and all other relevant documents in English language only. h. Board Resolution as per Format 6.4 i. Consortium Agreement as per Format 6.5 j. Financial Requirements criteria as per Format 6.6 k. Technical Criteria as per Format 6.7 l. Letter from Developer confirming connectivity as per Format 6.8 m. Disclosure Statement as per Format 6.9 n. Technological Tie Up as per Format 6.10 o. Checklist of Bank Guarantee as per Appendix-A p. Data Sheet as per Format 6.11 q. Tariff Bid as per Format 6.12 r. Calculation of Net worth s. Memorandum and Articles of Association t. Certificate of Incorporation u. Annual audited accounts for the financial year 2011-12 and also for relevant years as per RfS. All financial documents submitted along with the RfS must be signed on all pages by the Chartered Accountant. v. Shareholding pattern indicating the controlling shareholding certified by chartered accountant. w. Shareholding pattern statement of the Foreign Company, duly certified by competent authority. x. Proof of listing in the Stock Exchange if a public limited company. y. Any other document mentioned in the RfS or PPA.

NOTE:

All the above items in the check list are to be submitted as per the requirements under the RfS. Response to RfS that are incomplete, which do not substantially meet the requirements prescribed in this RfS, will be liable for rejection by APTRANSCO.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 234

SOLAR RFS BID DOCUMENT

Annexure-B A. Charges to be paid by the bidder

a) Processing fee of Rs. 2 Lakh per location at the time of submission of RfS (Non-refundable) to APPCC/DISCOM.

b) Bid security: EMD in the form of BG as follows: Rs 2 lakhs/MW BG in favor of Chief Engineer/IPC/APPCC/APTRANSCO,for Validity period of 90 days from the date of bid submission and claim period of one more month over and above validity period.

Insufficient Bid submitted by the bidders will be rejected without any prior notice.

B. Charges to be paid by the Developer/Successful Bidder

a) Contract performance Bank Guarantee (if applicable) as specified in Clause 3.17. b) Performance Bank Guarantee as specified in Clause 3.17.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 235

SOLAR RFS BID DOCUMENT

ANNEXURE –C (for RTGS)

RTGS Particulars

Sl.No. Particulars

State Bank of Hyderabad, Gunfoundry Branch, Abids 1 Bank's name and branch name Hyderabad.

2 Bank address Gunfoundry Branch, Abids, Hyderabad.

3 Name of City Hyderabad.

4 Bank Telephone Number 23387334/23387837 (F)/23387551 (F)

5 Bank IFSC code for NEFT SBHY0020066

6 Bank IFSC code for RTGS SBHY0020066

7 Bank MICR code 50000401900049011

8 Beneficiary name AP Power Distribution companies pool account

9 Beneficiaries Bank Account No. 52117479223

10 Type of account current account

off 23369000, Extn. 3663, Fx-23395370, Mobile- 11 Telephone No. of Beneficiary 9440816306

Note for bidder: Bidder has to ensure that the address of the bidder is correctly reflected in the RTGS transaction for technical bid evaluation.

Bidders declaration form: ______Bidder has to ensure the payment of processing fee through RTGS by submitting the relevant details i.e., they have paid the processing fee through transaction number______date:______for an amount of Rs.______from______Bank, ______Branch. The same is required to be uploaded along with the other required documents/Formats, failing which the bid is liable for rejection.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 236

SOLAR RFS BID DOCUMENT

Power Purchase Agreement

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 237

SOLAR RFS BID DOCUMENT

Draft PPA

POWER PURCHASE AGREEMENT BETWEEN ______POWER DISTRIBUTION COMPANY OF ANDHRA PRADESH LIMITED AND M/s. ______

NCE SOLAR PPA No.______

1. This Power Purchase Agreement ( “Agreement”) entered into this ____ day of ______between ______Power Distribution Company of Andhra Pradesh Limited (DISCOM), incorporated by the Government of Andhra Pradesh in accordance with the Andhra Pradesh Electricity Reform Act 1998 (Act No.30 of 1998), under the provisions of Companies Act, 1956, having its office at ______Andhra Pradesh, India, hereinafter referred to as the “DISCOM” (which expression shall, unless repugnant to the context or meaning thereof, include its successors and assigns) as first party, and ______, having registered office at ______hereinafter referred to as the “Solar Power Developer” (which expression shall, unless repugnant to the context or meaning thereof, include its successors and assigns) as second party; 2. WHEREAS, the Solar Power Developer is setting up the Solar Power Project of ____MW capacity at ______(Village/Mandal) ______District, Andhra Pradesh (hereafter called the Project,) with a proposal of ______MW for Sale to DISCOM as detailed in Schedule 1 attached herewith. 3. WHEREAS, APTRANSCO/DISCOM has no obligation to recommend any department to grant permissions /sanctions for the Solar Power Project. The Solar Power Developer shall obtain permissions/sanctions from Govt authorities, if any required for establishing the project.

4. And where as Solar Power Developer desires to sell entire solar energy from the Contracted Capacity to DISCOM in accordance with the Policy announced by GoAP vide G.O. Ms. No.46, dated: 27.11.2012.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 238

SOLAR RFS BID DOCUMENT

5. WHEREAS, the Solar Power Developer shall achieve Commercial Operation Date within 12 months from the date of signing of this Agreement, default of which, the Agreement is liable for termination as provided in Clause 10.5.

The PPA will continue to be in force for a period of 20 years from the Date of Commercial Operation (COD) subject to the approval of Andhra Pradesh Electricity Regulatory Commission (“APERC”).

6. WHEREAS, it has been agreed that the Project will be designed, engineered and constructed and operated by or on behalf of the Solar Power Developer or its successors with reasonable diligence subject to all applicable Indian laws, rules, regulations and orders having the force of law;

7. Whereas, the Project proposed at ______(Village/Mandal), ______(District) will be connected to ______(insert 132/33 kV or 33/11 kV) grid substation for easy power evacuation within the time frame stipulated in this Agreement. The injection of power from the Project to the grid is to be limited to the already technically approved capacity. 8. This Agreement is enforceable subject to approval of APERC as per Section 86 of Electricity Act 2003; 9. The terms and conditions of this Agreement are subject to the provisions of the Act and also subject to relevant regulations, if any, issued by the APERC from time to time. 10. NOW THEREFORE, in consideration of the foregoing premises and their mutual covenants herein, and for other valuable consideration, the receipt and sufficiency of which are acknowledged, the parties hereto, intending to be legally bound hereby agree as follows: 11. The Solar Power Developer shall deploy commercially established technologies for generation of Solar Power. 12. The Solar Power Developer shall not be eligible for obtaining RECs, as per prevailing regulations issued by CERC and APERC, for energy generated from this Project and supplied to DISCOMs.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 239

SOLAR RFS BID DOCUMENT

ARTICLE 1 DEFINITIONS Unless the context otherwise expressed in this Agreement, the following terms shall have the meanings set forth herein below. Defined terms of singular number shall include the plural and vice-versa.

“Act” shall mean the Electricity Act, 2003 and include any modifications, amendments and substitution from time to time;

“Agreement” shall mean this Power Purchase Agreement in accordance with Government policy vide G.O. Ms. No.46, dated:27.11.2012 through competitive bidding route, including the articles, schedules, amendments, modifications and supplements made in writing by the parties from time to time.

“APTRANSCO” shall mean Transmission Corporation of Andhra Pradesh Limited, incorporated under the Company Act 1956.

“Performance Bank Guarantee (BG)” shall mean any bank guarantee (BG) furnished by the developer to APTRANSCO/DISCOM, to assure timely and satisfactory completion of a Project by a developer as described in the RfS.

“Billing Date” shall mean the fifth (5th) Working day after the Meter Reading Date.

“Billing Month” shall mean the period commencing from 25th of the calendar month and ending on the 24th of the next calendar month.

“Capacity Utilization factor” (“CUF”) shall have the same meaning as provided by APERC from time to time. Till such time, it shall have the same meaning as provided in CERC (Terms and Conditions for the Tariff determination from Renewable Energy Sources) Regulations, 2012 and as amended from time to time.

“CERC” shall mean Central Electricity Regulatory Commission formed under Section 76 of the Electricity Act 2003.

“Commercial Operation Date”/ “Date of Commercial Operation” (“COD”) shall mean, with respect to each Generating unit, the date on which such Generating unit is declared by the Solar Power Developer to be operational, provided that the Solar Power

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 240

SOLAR RFS BID DOCUMENT

Developer shall not declare a Generating unit to be operational until such Generating unit has met the conditions of the Clause 3.9.

“Consultation Period” shall mean the period of sixty (60) days or such other longer period as the parties may agree, commencing from the date of issuance of a Solar Power Developer Preliminary Default Notice or DISCOM Preliminary Default Notice as provided in Article 10 of this Agreement, for consultation between the parties to mitigate the consequence of the relevant event having regard to all the circumstances;

“Contract Performance Bank Guarantee” (“CPBG”) shall refer to the bank guarantee to be produced by successful bidder to the concerned distribution licensees on the difference of L1 Tariff and Committee decided benchmark price to the tune of amount of rupees equivalent to the energy that would be generated for 3 [three] years at CUF (capacity utilization factor) of 25% from the plant if the technology used is Solar PV and 25% CUF for STP (Solar Thermal plant) provided to the L1 Tariff is lesser than the benchmark price.

“Change in Law” shall mean any change in the, provision of electricity law in force, regulations, directions, notifications issued by the competent authorities and GoI/GoAP from time to time.

"Contracted Capacity" shall mean ……[Insert capacity] MW contracted with DISCOM for supply by the Solar Power Developer to DISCOM at the Interconnection Point from the Project.

“Delivered Energy” shall mean, with respect to any Billing Month, the kilo watt hours (kWh) of electrical energy generated by the Project and delivered to the DISCOM at the Interconnection Point, as measured by both energy meters at the Interconnection Point during that Billing Month at the designated substation of APTRANSCO/DISCOM.

Explanation 1: For the purpose of clarification, Delivered Energy, excludes all energy consumed in the Project, by the main plant and equipment, lighting and other loads of the Project from the energy generated and as recorded by energy meter at Interconnection Point.

Explanation 2: The Delivered Energy in a Billing Month shall be limited to the energy calculated based on the Contracted Capacity multiplied with number of hours and

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 241

SOLAR RFS BID DOCUMENT

fraction thereof the Project is in operation during that Billing Month. In case, energy will be procured at L1 Tariff up to 25% CUF for this location, beyond the same, the energy will be purchased at a flat rate of Rs 3.00 / commercial (kWh) unit (without escalation) for the entire agreement period.

“Due Date of Payment” shall mean the date on which the amount payable by the DISCOM to the Solar Power Developer hereunder for Delivered Energy, if any, supplied during a Billing Month becomes due for payment, which date shall be thirty (30) days from the Meter Reading Date provided the bill is received by DISCOM within 5 working days from Meter Reading Date, and in the case of any supplemental or other bill or claim, if any, the Due Date of Payment shall be thirty (30) days from the date of the presentation of such bill or claim to the designated officer of the DISCOM. If the last date of payment falls on a holiday, the next working day shall be considered as last date.

“Financial Year” shall mean, with respect to the initial Financial Year, the period beginning on the Commercial Operation Date and ending at 12.00 midnight on the following March 31. Each successive Financial Year shall begin on April 1 and end on the following March 31, except that the final Financial Year shall end on the date of expiry of the term or on termination of this Agreement as per the provisions of Clauses 9.2, 10.4.4 and 10.5 whichever is earlier.

“Financing Agreement” shall mean the agreement pursuant to which the Solar Power Developer has sought financing for the Project including the loan agreements, security documents, notes, indentures, security agreements, letters of credit and other documents, as may be amended, modified, or replaced from time to time, but without in anyway increasing the liabilities of APTRANSCO/ DISCOM;

“Grid Code” shall mean the Indian Electricity Grid Code issued by CERC vide notification No. L-1/18/2010-CERC, New Delhi, 28-04-2010 including any amendments and modifications thereto and/ or AP Grid Code, as amended from time to time.

“Installed Capacity” shall mean the name plate capacity of all the Units of the Project.

“Interconnection Facilities” shall mean all the equipment and facilities, including, but not limited to, all metering facilities, switchgear, substation facilities, transmission lines and related infrastructure, to be installed at the Voltage of Delivery at the Solar

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 242

SOLAR RFS BID DOCUMENT

Power Developer's expense from time to time throughout the Term of the Agreement, necessary to enable the DISCOM to economically, reliably and safely receive Delivered Energy from the Project in accordance with the terms of this Agreement. The Solar Power Developer has to bear entire expenditure of Interconnection Facilities for power evacuation as per the sanctioned estimate by the field officers.

“Interconnection Point” shall mean the point or points where the Project and the grid system of APTRANSCO/ DISCOM are interconnected at the grid substation of APTRANSCO/DISCOM. The metering for the Project will be provided at the interconnection point as per Clause 4.1.

“Interconnection Substation” shall mean the substation where the Project and the APTRANSCO/ DISCOM grid system are interconnected.

“Metering Code” shall mean Central Electricity Authority (“CEA”) (Installation and Operation of Meters) Regulations, 2006 , as amended from time to time.

“Meter Reading Date” shall mean the 25th (twenty fifth) day of each calendar month, at 00:00 hours, at the Interconnection Point.

“Metering Point” shall mean points where metering shall be provided for Project and shall be as follows:

(i) Both meters (main & check) provided at the Interconnection Point for purposes of recording of Delivered Energy of the Project;

(ii) Additionally, a standby meter shall be provided as per CEA norms on the dedicated feeder at grid Substation.

(iii) Metering point shall include three separate sets of 0.2s class accuracy ABT meters as specified in Clause 4.1, main meter, check and standby meter installed by the Solar Power Developer and all meters sealed by the DISCOM, having facilities to record both export and import of electricity to / from the grid.

“Project” shall mean the solar power generation facility of Installed Capacity of ………..[Insert capacity ] MW, located at ……………. [Insert name of the place] in …. [Insert name of the District and State];

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 243

SOLAR RFS BID DOCUMENT

Which includes all units and auxiliaries such as water supply, treatment or storage facilities; bay/s for transmission system in the switchyard, and all the other assets, buildings/structures, equipments, plant and machinery, facilities and related assets required for the efficient and economic operation of the power generation facility;

whether completed or at any stage of development and construction or intended to be developed and constructed for the purpose of supply of power as per this Agreement;

“Prudent Utility Practices” shall mean those practices, methods, techniques and standards, that are generally accepted for use in electric utility industries taking into account conditions in India, and commonly used in prudent electric utility engineering and operations to design, engineer, construct, test, operate and maintain equipment lawfully, safely, efficiently and economically as applicable to power stations of the size, service and type of the Project, and that generally conform to the manufacturers' operation and maintenance guidelines.

“RfS” shall mean the document to request for selection of solar power projects for purchase of solar energy by DISCOMs, issued by Transmission Corporation of Andhra Pradesh Limited floated in accordance with the Policy issued by GoAP vide G.O. Ms No.46, dated: 27.11.2012

“Scheduled COD” shall mean 12 months from the date of signing of this Agreement.

“SLDC” shall mean the State Load Dispatch Center as notified by the State Government under the provisions of the Electricity Act 2003.

“Solar Power” shall mean power generated from the SPV or STP.

“Solar Power Project” shall mean either an SPV or STP Project.

“Solar Photovoltaic Project” or “Solar PV” or “SPV” shall mean the solar photovoltaic power project that uses sunlight for conversion into electricity and that is being set up by the Solar Power Developer to provide Solar Power to DISCOM as per the terms and conditions of this Agreement.

“Solar Thermal Project” or “STP” shall mean the solar thermal power project that uses sunlight through Concentrated Solar Power Technology (based on either line

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 244

SOLAR RFS BID DOCUMENT

focus or point focus principle) for conversion into heat/steam which can be used for producing electricity.

“System Emergency” means a condition affecting the APTRANSCO/ DISCOM electrical system including grid which threatens the safe and reliable operation of such system or which is likely to result in the disruption of safe, adequate and continuous electric supply by the APTRANSCO/ DISCOM, or which endangers life or property, which condition is affected or aggravated by the continued delivery of Delivered Energy from the Project.

“Solar Power Developer” shall mean a company registered under Indian companies Act, a partnership firm registered under partnership Act or a society registered under A.P. society Registration Act.

“Tariff” shall have the same meaning as provided for in Clause 2.2 of this Agreement.

“Term of the Agreement” shall have the same meaning as provided for in Article 7 of this Agreement

“Unit”, when used in relation to the solar generating equipment, shall mean the set of solar panels multiplied by their name plate capacity in MW in case of Solar PV Project and set of parabolic troughs, turbo plant and connected equipment along with related auxiliary equipment in case of Solar Thermal Project and facilities forming part of the Project and when used in relation to electrical energy, means Kilo Watt Hour (kWh).

“Voltage of Delivery” shall mean the voltage at which the electrical energy generated by the Project is required to be delivered to the APTRANSCO/DISCOM grid substation at the Interconnection Point. Any modifications or procedures or changes in arranging Interconnection Facilities for power evacuation rest with APTRANSCO and DISCOM.

All other words and expressions used herein and not defined herein but defined in AP Electricity Reform Act, 1998 and the Electricity Act, 2003 and rules and Regulations made there under shall have the meanings respectively assigned to them in the said laws, as amended from time to time.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 245

SOLAR RFS BID DOCUMENT

ARTICLE 2 PURCHASE OF DELIVERED ENERGY AND TARIFF

2.1 All the Delivered Energy, as mentioned in Schedule 1, at the Interconnection Point for sale to DISCOM will be purchased at the Tariff provided for in Clause 2.2 from and after the Date of Commercial Operation of the Project and limited to capacity of project only and title to Delivered Energy purchased shall pass from the Solar Power Developer to the DISCOM at the Interconnection Point.

2.2 The DISCOM shall pay a Tariff of Rs. _____ / Unit (“Tariff”) arrived through competitive bidding for this particular location based on the bidding guidelines issued and RfS floated in accordance with the Policy issued by GoAP vide G.O. Ms No.46, dated: 27.11.2012.

2.3 The Tariff payable by the DISCOM will be inclusive of all taxes, duties and levies, to be borne by the Solar Power Developer. 2.4 All future increase in taxes, duties and levies on energy generated will have to be borne by the Solar Power Developer.

2.5 DISCOM, at any time during a contract year will purchase electricity at the Tariff from the Solar Power Developer up to the CUF of 25%, beyond the said quantum, the electricity will be purchased at a flat rate of Rs 3.00 / Unit for the entire agreement period.

2.6 The Solar Power Developer, at any time during validity of this Agreement, shall not add any extra solar modules/equipment more than the Contracted Capacity.

2.7 The solar Developer is entitled to draw the power for its auxiliary consumption the limit of which is specified in schedule-1 from DISCOM. The energy supplied by the DISCOM to the Solar Power Developer through a bilateral arrangement, to maintain the Auxiliaries of the power plant in situations of non-generation of power, in any billing month shall be adjusted from the delivered energy, as indicated below:

Net off Energy= Deliveed energy by the developer at interconnection point- Energy drawl from DISCOM for auxiliaries.

Explanation: The Solar plants during the plant shut down/non-generation periods shall draw the energy from DISCOM only for the essential loads not exceeding auxiliary consumption.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 246

SOLAR RFS BID DOCUMENT

ARTICLE 3 INTERCONNECTION FACILITIES, SYNCHRONIZATION, COMMISSIONING AND COMMERCIAL OPERATIONS

3.1 Upon receipt of a requisition from the Solar Power Developer, APTRANSCO/ DISCOM will prepare an estimate for arranging Interconnection Facilities for power evacuation at the Voltage of Delivery. The Solar Power Developer has to bear the entire cost of the Interconnection Facilities as per the sanctioned estimate.

3.2 APTRANSCO and DISCOM may also permit the Solar Power Developer to execute the Interconnection Facilities for power evacuation as per the sanctioned estimate at its discretion duly collecting the supervision charges as per procedure in vogue.

3.3 The Solar Power Developer shall own, operate and maintain Interconnection Facilities from Project to grid sub-station from time to time and necessary expenditure shall have to be borne by the Solar Power Developer. The maintenance work at the grid sub-station and connected bay and equipment has to be done in coordination with the APTRANSCO and DISCOM authorities. If APTRANSCO/DISCOM carryout the O&M work, the power producer shall pay such expenses to APTRANSCO/DISCOM as applicable.

3.4 Any modifications or procedures or changes in arranging Interconnection Facilities for power evacuations rest with APTRANSCO and DISCOM.

3.5 DISCOM reserves the right to add any additional loads on the feeder without detriment to the existing generator /solar plants on the same feeder.

3.6 The Solar Power Developer shall be responsible to operate the Project as envisaged under this Agreement & to provide appropriate facility/ instrumentation/ metering arrangement as per Clause 4.1.

3.7 The Solar Power Developer shall deploy components/ equipment for the STP/SPV complying with approved/ minimum technical standards as per International Electrotechnical Commission (“IEC”) & Bureau of Indian Standards (“BIS”) or

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 247

SOLAR RFS BID DOCUMENT

technical standards that are as specified by Ministry of New and Renewable Energy (“MNRE”) as amended from time to time at the cost of the Solar Power Developer.

3.8 Any modifications or procedures or changes in arranging Interconnection Facilities for power evacuation shall be at the discretion of APTRANSCO and DISCOM.

3.9 Acceptance/Performance Test Prior to synchronization of the Project as per Clause 3.11, the Solar Power Developer shall be required to get the Project certified for the requisite acceptance/performance test as may be laid down by CEA/ APERC/APTRANSCO or an agency identified by APTRANSCO/DISCOM to carry out testing and certification for the Solar Power Projects.

3.10 Verification by APTRANSCO/DISCOM 3.10.1 The Solar Power Developer shall be further required to provide entry to the site of the Project free of all encumbrances at all times during the Term of the Agreement to APTRANSCO/ DISCOM for inspection and verification of the works being carried out by the Solar Power Developer at the site of the Project.

3.10.2 The APTRANSCO/DISCOM may verify the construction works/operation of the Project being carried out by the Solar Power Developer and if it is found that the construction works/operation of the Project is not as per the Prudent Utility Practices, it may seek clarifications from Solar Power Developer or require the works to be stopped or to comply with the instructions of such third party.

3.11 Synchronization, Commissioning and Commercial Operation 3.11.1 The Solar Power Developer shall give the concerned SLDC and DISCOM at least sixty (60) days advance of preliminary written notice and at least thirty (30) days advance of final written notice, of the date on which it intends to synchronize the Project to the grid system.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 248

SOLAR RFS BID DOCUMENT

3.11.2 The Project may be synchronized by the Solar Power Developer to the grid system when it meets all the connection conditions prescribed in applicable Grid Code then in effect and otherwise meets all other Indian legal requirements for synchronization to the grid system.

3.11.3 The synchronization equipment shall be installed by the Solar Power Developer at its generation facility of the Project at its own cost. The Solar Power Developer shall synchronize its system with the Grid System only after the approval of synchronization scheme is granted by the head of the concerned sub-station/grid system and checking/verification is made by the concerned authorities of the grid system.

3.11.4 The Solar Power Developer shall immediately after synchronization/ tripping of generator, inform the sub-station of the grid system to which the Project is electrically connected in accordance with applicable Grid Code.

3.11.5 The Solar Power Developer shall commission the Project within twelve (12) Months of the date of signing of this Agreement, and delayed commissioning of the same is subject to the penalties and incentives stated in Clause 3.12 and Clause 10.5.

3.12 Incentives for early commissioning The Solar Power Developer will be paid an incentive by DISCOM for early commissioning. The incentive will be paid as follows: iv. Commissioning between 30 days and 59 days before Scheduled COD: Rs 1 lakh/MW of capacity commissioned. v. Commissioning between 60 days and 89 days before Scheduled COD: Rs 2 lakh/MW of capacity commissioned. vi. Commissioning before 90 days of the Scheduled COD: Rs 3 lakh/MW of capacity commissioned.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 249

SOLAR RFS BID DOCUMENT

ARTICLE 4 METERING AND PROTECTION

4.1 The Solar Power Developer shall install main meter, check meter of static type 0.2 class accuracy of ABT Meters at the Interconnection Point. Also Solar Power Developer shall install stand by meter of same accuracy as per norms fixed by CEA/APERC/APTRANSCO. The main meter, check meter and stand by meter will each consist of a pair of export and import parameters with facility for recording meter readings using meter recording instrument. For the purpose of uniformity, the Solar Power Developer shall follow metering specifications as developed by the DISCOM from time to time and as per Metering Code. The Solar Power Developer shall be responsible to enable remote monitoring of generation (providing of AMR modules to the billing meters by Solar Power Developer).

4.2 All of the meters required to be installed pursuant to Clause 4.1 above shall be jointly inspected and sealed on behalf of both parties and shall not be interfered with, tested or checked except in the presence of representatives of both parties and as per Metering Code.

4.3 The meter readings from the main meters will form the basis of billing. If any of the meters required to be installed pursuant to Clause 4.1 above are found to be registering inaccurately the affected meter will be immediately be replaced.

4.4 Where the half yearly meter check indicates an error in one of the main meter/meters beyond the limits for such meter but no such error is indicated in the corresponding check meter/meters, billing for the month will be done on the basis of the reading on the check meter/meters and the main meter will be replaced immediately. If both the main and check meters indicate an error beyond the limits, billing for the month will be reconciled on the basis of the reading on the standby meter/meters, and the main and check meters will be replaced immediately.

4.5 If during the half yearly test checks, all the main meters and the corresponding check meters and standby meters are found to be beyond permissible limits of error, all the meters shall be immediately replaced and the correction applied to the

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 250

SOLAR RFS BID DOCUMENT

consumption registered by the main meter to arrive at the correct Delivered Energy for billing purposes for the period of one month up to the time of such test check, computation of Deliv ered Energy for the period thereafter till the next monthly meter reading shall be as per the replaced main meter.

4.6 Corrections in Delivered Energy billing, whenever necessary, shall be applicable to the period between the previous monthly meter reading and the date and time of the test calibration in the current month when the error is observed and this correction shall be for the full value of the absolute error. For the purpose of determining the correction to be applied to any meter registering inaccurately, the meter shall be tested under conditions simulating 100, 50, 20 and 10 percent load at unity power factor and 0.5 power factor. Of these eight values, the error at the load and power factor nearest the average monthly load served at the Interconnection Point during the applicable period shall be taken as the error to be applied for correction.

4.7 If all the main, check and standby meters fail to record or if all/ any of the PT fuses are blown out, then the energy will be computed on a mutually agreeable basis for that period of defect.

4.8 The main, check and standby meters shall be tested and calibrated once in a financial year utilizing a standard meter of 0.02 class accuracy testing meter (“Standard Meter”). The Standard Meter shall be calibrated once in every year at the approved Laboratory by Government of India / Government of Andhra Pradesh, as per Terms and Conditions of supply. The testing of meters shall be carried out as per T.O.O (CE/Comml/APTRANSCO) Rt.No.537, dated.23.03.2010 (which is available in APTRANSCO Website) issued by APTRANSCO scrupulously.

4.9 All main, check and stand by meter tests shall be jointly conducted by the authorized representatives of both the parties and the results and correction so arrived at mutually will be applicable and binding on both the parties.

4.10 On the Meter Reading Date of each month, meter readings shall be taken (and an acknowledgement thereof signed) by the authorized representatives of both parties.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 251

SOLAR RFS BID DOCUMENT

4.11 Within six (6) months, following the execution of this Agreement, the Solar Power Developer and the APTRANSCO/DISCOM shall mutually agree to technical and performance specifications (including, but not limited to, the metering configuration for the Project) concerning the design and operation of the facilities required to be installed by the Solar Power Developer in order for the Solar Power Developer to operate in parallel with the grid. Thereafter, any change in such specifications shall be subject to mutual agreement of the parties.

4.12 The Project shall be operated and maintained in accordance with good and generally accepted fraudulent utility standards with respect to synchronizing, voltage, frequency and reactive power control.

4.13 Voltage regulation shall be such as to enable continued paralleling and synchronization with the network voltage at the point of interconnection.

4.14 The equipment of the Solar Power Developer shall be designed for fluctuations in the frequency within limits of -5% and +3% of the standard frequency of 50 cycles per second.

4.15 The Solar Power Developer shall ensure that the power factor of the power delivered to the DISCOM is maintained at or above the Minimum Power Factor as per Tariff Notification, or otherwise pay Surcharge as per Tariff Notification in force.

4.16 Any change in rupturing capacity of switch-gear, settings of the relays, etc., shall be subject to approval of the APTRANSCO/DISCOM.

4.17 As the Solar Project's plant may carry fault currents that may occur on the grid, the Solar Power Developer shall provide adequate switchgear protection against such faults. The APTRANSCO/DISCOM is not responsible for damage, if any, caused to the Project’s plant and allied equipment during parallel operation of the plant with the grid.

4.18 The Solar Power Developer shall make bonafied effort to operate the Project in such a manner so as to avoid fluctuations and disturbances to the APTRANSCO / DISCOM network due to parallel operation with the network.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 252

SOLAR RFS BID DOCUMENT

4.19 The Solar Power Developer shall control and operate the Project as per Prudent Utility Practices. The APTRANSCO/DISCOM shall only be entitled to request the Solar Power Developer to reduce electric power and energy deliveries from the Project during a System Emergency, and then only to the extent that in the APTRANSCO/ DISCOM’s reasonable judgment such a reduction will alleviate the emergency. The DISCOM shall give the Solar Power Developer as much advance notice of such a reduction as is practicable under the circumstances and shall use all reasonable efforts to remedy the circumstance causing the reduction as soon as possible. Any reduction required of the Solar Power Developer hereunder shall be implemented in a manner consistent with safe operating procedures. 4.20 SLDC may instruct the Solar plant to back down generation on consideration of grid safety and security or safety of any equipment or personnel is endangered and solar plant shall comply with the same. For this, the Solar Power Developer shall provide Data Acquisition System (“DAS”) facility in compatible to SLDC Supervisory Control and Data Acquisition (“SCADA”) system in consultation with SLDC for transfer of online information to concerned SLDC as per the clause No. 5.2.U of APERC Grid Code and IEGC 2010 & APERC Grid Code.

(i) SLDC may direct the Solar Power Developer to curtail its VAR /injection incase the security of grid or safety of any equipment or personnel is endangered. (ii) During the Project start-up, the Solar Power Developer shall ensure that the reactive power drawl (inrush currents in case of induction plants) shall not affect the grid performance. 4.21 The Solar Power Developer shall ensure the connectivity standards applicable to the solar generating stations as per the Central Electricity Authority (CEA) Regulations and its amendments thereto are adhered to.

4.22 The Project proponent will install necessary current limiting devices such as thyristors etc, if required. The project proponent shall provide protection system in compliance to grid code requirement for short circuit level, neutral grounding, current unbalance, limiting of harmonics, fault- clearing time etc. A generating unit may be synchronized to the state grid system, when the project proponent has obtained permission for synchronization after meeting system requirements and such generating unit complies with Prudent Utility Practices.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 253

SOLAR RFS BID DOCUMENT

ARTICLE 5 BILLING AND PAYMENT

5.1 For the Delivered Energy purchased, Solar Power Developer shall furnish a bill to the DISCOM calculated at the Tariff provided for in Article 2, in such form as may be mutually agreed between the DISCOM and the Solar Power Developer, for the billing month on or before the 5th working day following the Meter Reading Date.

5.2 The DISCOM shall be entitled to get a rebate of 1% of the total amount billed in any billing month for payments made before the Due Date of Payment. Any payment made beyond the Due Date of Payment, DISCOM shall pay interest at prevailing SBI bank rate and in case this rate is reduced, such reduced rate is applicable from the date of reduction.

5.3 The DISCOM shall pay the bill on monthly basis as per Clause 5.1, by opening a one month revolving Letter of Credit in favour of Solar Power Developer.

5.4 Letter of Credit: Not later than 30 days prior to the Scheduled COD of the Generating Unit, DISCOM shall cause to be in effect an irrevocable revolving Letter of Credit issued in favour of Solar Power Developer by a Scheduled Bank (the “Letter of Credit”). Each Letter of Credit shall

(a) on the date it is issued, have a term of one month;

(b) be payable upon the execution and presentation by an officer of Solar Power Developer of a sight draft to the issuer of such Letter of Credit supported by a meter reading statement accepted and signed by both parties or a certification from Solar Power Developer that the DISCOM failed to sign the meter reading statements within five days of the Meter Reading Date or that a supplemental bill has been issued and remains unpaid until the Due Date of Payment;

(c) In the absence any dispute regarding the claim provide that Solar Power Developer shall have the right to draw upon such Letter of Credit notwithstanding any failure by the DISCOM to reimburse the issuer thereof for any draw made under; and TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 254

SOLAR RFS BID DOCUMENT

(d) not less than 7 days prior to the expiration of any Letter of Credit, the DISCOM shall provide a new or replacement Letter of Credit. Each monthly bill or supplemental bill shall be presented at the said Scheduled Bank for payment under the Letter of Credit and shall become payable there under. The opening charges for Letter of Credit and Letter of Credit negotiation charges will be borne by the beneficiary Solar Power Developer.

(e) Letter of Credit should not be invoked for any disputed bill amount.

5.5 Direct Payment: Notwithstanding the fact that a Letter of Credit has been opened, in the event that through the actions of the DISCOM, Solar Power Developer is not able to make a draw upon the Letter of Credit for the full amount of any bill, Solar Power Developer shall have the right to require the DISCOM to make direct payment of any bill by cheque or otherwise on or before the Due Date of Payment by delivering to the DISCOM on or prior to the Due Date of Payment of such bill a notice requiring payment in the foregoing manner. Without prejudice to the right of Solar Power Developer to draw upon the Letter of Credit if payment is not received in full, the DISCOM shall have the right to make direct payment by cheque or otherwise of any bill such that within 30 days after the date of its presentation to the designated officer of the DISCOM, Solar Power Developer shall receive payment in full for such bill. When either such direct payment is made, Solar Power Developer shall not present the same bill to the Scheduled Bank for payment against the Letter of Credit.

5.6 Billing disputes: The DISCOM shall pay the bills of Solar Power Developer promptly subject to the Clauses 5.1 and 5.2.

The DISCOM shall notify Solar Power Developer in respect of any disallowed amount on account of any dispute as to all or any portion of the bill. Solar Power Developer shall immediately take up issue with all relevant information with DISCOM which shall be rectified by the DISCOM, if found satisfactory. Otherwise notify its (DISCOM’s) rejection of the disputed claim within reasonable time with reasons therefore. The dispute may also be decided by mutual agreement. If the resolution of any dispute requires the DISCOM to reimburse Solar Power Developer, the amount to be reimbursed shall bear interest at prevailing SBI bank rate (Prime Lending Rate) TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 255

SOLAR RFS BID DOCUMENT

and in case this rate is reduced, such reduced rate is applicable from the date of reduction from the date of disallowance to the date of reimbursement. 5.7 All payments by the DISCOM to Solar Power Developer hereunder shall be made to such address as may be designated by Solar Power Developer to the DISCOM in writing from time to time. 5.8 Notwithstanding anything stated in this Article, the dispute of correctness or otherwise of the applicable Tariff, shall not be considered as billing dispute. Further in the event, the Solar Power Developer is found due of any amount to the DISCOM either under this agreement or under any other transaction, the DISCOM/first party is entitled to recover the said due amount by adjusting from the bill amount payable to the Solar Power Developer .

Address : M/s. ______

Telephone : ______

Fax : ______

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 256

SOLAR RFS BID DOCUMENT

ARTICLE 6 UNDERTAKING

6.1 The Solar Power Developer shall be responsible:

(i) for proper maintenance of the Project in accordance with established Prudent Utility Practices.

(ii) for operation, maintenance, overhaul of the plant, equipment, works, switch yard and transmission lines and equipment up to the Interconnection Point of the Project in coordination with the APTRANSCO/DISCOM officials.

(iii) to furnish the generation and maintenance schedules every year, during peak and non-peak season.

(iv) for making all payments on account of any taxes, cess, duties or levies imposed by any government or competent statutory authority on the land, equipment, material or works of the Project or on the energy generated or consumed by the Project or the Solar Power Developer or on the income or assets of the Solar Power Developer.

(v) for obtaining necessary approvals, permits or licences for operation of the Project and sale of energy to DISCOM there from under the provision of the relevant laws.

(vi) to comply with the provisions of the Grid Code. Notwithstanding any provision in this Agreement, the Solar Power Developer shall comply with the state Grid Code, dispatch practices, performance standard, protection & safety as required as per the rules & regulations in force as applicable from time to time in the State of AP.

(vii) for achieving Commercial Operation Date within 12 months from the date of signing of the Agreement.

(viii) for seeking approval of APTRANSCO and DISCOM in respect of Interconnection Facilities with grid substation and synchronization of the Project with grid.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 257

SOLAR RFS BID DOCUMENT

(ix) to install new machinery/modules in the plant.

(x) The Solar Power Developer shall not dismantle and take away Project machinery and Interconnection Facilities during the Term of the Agreement.

(xi) To share Clean Development Mechanism (“CDM”) benefit with DISCOM as provided in CERC (Terms and Conditions for the Tariff determination from Renewable Energy Sources) Regulations, 2012, and as amended from time to time, as indicated below:

(1) The proceeds of carbon credit from approved CDM Project shall be shared between Solar Power Developer and DISCOM in the following manner, namely

a) 100% of the gross proceeds on account of CDM benefit to be retained by the Solar Power Developer in the first year after the date of commercial operation of the generating station;

b) In the second year, the share of the beneficiaries shall be 10% which shall be progressively increased by 10% every year till it reaches 50%, where after the proceeds shall be shared in equal proportion, by the Solar Power Developer and the DISCOM.

6.2 The DISCOM agrees:

(i) to make all reasonable efforts for making arrangements for evacuation of power from the Project to be completed prior to the COD of the Project subject to Article 3.

(ii) for purchase of Delivered Energy from the Project as per Clause 2.2.

(iii) to co-ordinate with APTRANSCO and guide the Solar Power Developer in obtaining approval for the interconnection facilities where the interconnection is at 33 kV or above voltages, for synchronization, commercial operation, regular operation etc., as required by the Solar Power Developer.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 258

SOLAR RFS BID DOCUMENT

ARTICLE 7 DURATION OF AGREEMENT

This Agreement is subject to para (5) of the Preamble and shall be effective upon its execution and delivery thereof between parties hereto and shall continue in force from the Commercial Operation Date (COD) and until the 20th anniversary that is for a period of twenty years from the Commercial Operation Date (COD) or any mutually agreed time period from the date of Commercial Operation (COD) subject to the approval of APERC (“Term of the Agreement”). This Agreement may be renewed for such further period of time and on such terms and conditions as may be mutually agreed upon by the parties, 90 days prior to the expiry of the said period, subject to the consent of the APERC. Any and all incentives/conditions envisaged in the Articles of this Agreement are subject to modification from time to time as per the directions of APERC. It is agreed that they are bound by the competitive least Tariff that may be consented by APERC, at the request of either or both the parties.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 259

SOLAR RFS BID DOCUMENT

ARTICLE 8 NOTICES

8.1 Except as otherwise expressly provided in this Agreement, all notices or other communications which are required or permitted hereunder shall be in writing and sufficient if delivered personally or sent by registered or certified mail, telecopy, telex or telegram addressed as follows:

If to the Solar Power Developer:

Attention : Mr. [Insert details of Solar Power Developer] : M/s. [Insert details of Solar Power Developer] Telephone : [Insert details of Solar Power Developer] Fax : [Insert details of Solar Power Developer]

If to the DISCOM: Attention : [Insert details of DISCOM] Fax No. : [Insert details of DISCOM] Telephone No. : [Insert details of DISCOM]

8.2 All notices or communications given by telecopy, telex or telegram shall be confirmed by depositing a copy of the same in the post office in an envelope properly addressed to the appropriate party for delivery by registered or certified mail. All notices shall be deemed delivered upon receipt, including notices given by telecopy, telex or telegram regardless of the date the confirmation of such notice is received.

8.3 Any party, may by written notice, change the address and/or addresses to which such notices and communications to it are to be delivered or mailed.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 260

SOLAR RFS BID DOCUMENT

ARTICLE 9

FORCE MAJEURE 9.1 Definition of Force Majeure: (a) “Force Majeure” shall mean any event or circumstance or combination of events or circumstances that materially and adversely affects the performance by either party (the “Affected Party”) of its obligations pursuant to the terms of this Agreement (including by preventing, hindering or delaying such performance), but only if and to the extent that such events and circumstances are not within the Affected Party’s reasonable control and were not reasonably foreseeable and the effects of which the Affected Party could not have prevented by Prudent Utility Practices or, in the case of construction activities, by the exercise of reasonable skill and care. Any events or circumstances meeting the description of Force Majeure which have the same effect upon the performance of any of the Solar Power Project setup in accordance with solar policy announced by GoAP under competitive bidding route and which therefore materially and adversely affect the ability of the Project or, as the case may be, the DISCOM to perform its obligations hereunder shall constitute Force Majeure with respect to the Solar Power Developer or the DISCOM, respectively.

(b) Force Majeure circumstances and events shall include the following events to the extent that they or their consequences satisfy the above requirements.

i. Non Political Events such as acts of GOD including but not limited to any storm, flood, Drought, Lightning, Earthquake or other natural, fire, accident, equipment failure, explosion, strikes, labour difficulties, epidemic, plague or quarantine, air crash, shipwreck, train wrecks or failure (“Non Political Events”).

ii. Indirect Political Events such as acts of war sabotage, terrorism or act of public enemy, blockades, embargoes, civil disturbance, revolution or radioactive contamination (“Indirect Political Events”).

iii. Direct Political Events such as any Government Agencies’ or the DISCOM’s unlawful or discriminatory delay, modification, denial or refusal to grant or

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 261

SOLAR RFS BID DOCUMENT

renew, or any revocation of any required permit or Change in Law (Direct Political Events).

9.2 In the event of a delay in COD due to:

a) Force Majeure Events affecting the Solar Power Developer; or

b) any DISCOM Event of Default, the COD and the date of expiry of the Agreement shall be deferred, subject to a limit of 12 months from the Scheduled COD, for a reasonable period but not less than ‘day for day’ basis, to permit the Solar Power Developer or DISCOM through the use of due diligence, to overcome the effects of the Force Majeure events affecting the Solar Power Developer or DISCOM, or till such time such event of default is rectified by DISCOM.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 262

SOLAR RFS BID DOCUMENT

ARTICLE 10

EVENTS OF DEFAULT AND TERMINATION

10.1 Solar Power Developer Event of Default

10.1.1 The occurrence and continuation of any of the following events, unless any such event occurs as a result of a Force Majeure event or a breach by DISCOM of its obligations under this Agreement, shall constitute a Solar Power Developer Event of Default (“Solar Power Developer Event of Default”):

(i) if (a) the Solar Power Developer assigns, mortgages or charges or purports to assign, mortgage or charge any of its assets or rights related to the Project in contravention of the provisions of this Agreement; or (b) the Solar Power Developer transfers or novates any of its rights and/ or obligations under this Agreement, in a manner contrary to the provisions of this Agreement; except where such transfer

• is in pursuance of a law; and does not affect the ability of the transferee to perform, and such transferee has the financial capability to perform, its obligations under this Agreement or

• is to a transferee who assumes such obligations under this Agreement and the Agreement remains effective with respect to the transferee;

(ii) if (a) the Solar Power Developer becomes voluntarily or involuntarily the subject of any bankruptcy or insolvency or winding up proceedings and such proceedings remain uncontested for a period of thirty (30) days, or (b) any winding up or bankruptcy or insolvency order is passed against the Solar Power Developer, or (c) the Solar Power Developer goes into liquidation or dissolution or has a receiver or any similar officer appointed over all or substantially all of its assets or official liquidator is appointed to manage its affairs, pursuant to law,

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 263

SOLAR RFS BID DOCUMENT

Provided that a dissolution or liquidation of the Solar Power Developer will not be a Solar Power Developer Event of Default if such dissolution or liquidation is for the purpose of a merger, consolidation or reorganization and where the resulting company retains creditworthiness similar to the Solar Power Developer and expressly assumes all obligations of the Solar Power Developer under this Agreement and is in a position to perform them; or

(iii) the Solar Power Developer repudiates this Agreement and does not rectify such breach within a period of thirty (30) days from a notice from DISCOM in this regard; or

(iv) except where due to any DISCOM’s failure to comply with its material obligations, the Solar Power Developer is in breach of any of its material obligations pursuant to this Agreement, and such material breach is not rectified by the Solar Power Developer within thirty (30) days of receipt of first notice in this regard given by DISCOM.

(v) the Solar Power Developer delays the commissioning of the Project by more than 4 months from the Scheduled COD, in which case the procedures of Clause 10.5 shall be followed.

(vi) occurrence of any other event which is specified in this Agreement to be a material breach/ default of the Solar Power Developer.

10.2 DISCOM Event of Default

10.2.1 The occurrence and the continuation of any of the following events, unless any such event occurs as a result of a Force Majeure event or a breach by the Solar Power Developer of its obligations under this Agreement, shall constitute the Event of Default on the part of defaulting DISCOM (“DISCOM Event of Default”):

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 264

SOLAR RFS BID DOCUMENT

(i) DISCOM fails to pay (with respect to payments due to the Solar Power Developer according to Article 5), for a period of ninety (90) days after the Due Date of Payment and the Solar Power Developer is unable to recover the amount outstanding to the Solar Power Developer through the Letter of Credit,

(ii) DISCOM repudiates this Agreement and does not rectify such breach even within a period of thirty (30) days from a notice from the Solar Power Developer in this regard;

or

(iii) except where due to any Solar Power Developer’s failure to comply with its obligations, DISCOM is in material breach of any of its obligations pursuant to this Agreement, and such material breach is not rectified by DISCOM within thirty (30) days of receipt of notice in this regard from the Solar Power Developer to DISCOM; or

(iv) if :-

• DISCOM becomes voluntarily or involuntarily the subject of any bankruptcy or insolvency or winding up proceedings and such proceedings remain uncontested for a period of thirty (30) days, or

• any winding up or bankruptcy or insolvency order is passed against DISCOM, or

• DISCOM goes into liquidation or dissolution or a receiver or any similar officer is appointed over all or substantially all of its assets or official liquidator is appointed to manage its affairs, pursuant to law,

Provided that it shall not constitute a DISCOM Event of Default, where such dissolution or liquidation of DISCOM or DISCOM is for the purpose of a merger, consolidation or reorganization and where the resulting entity has the financial standing to perform its obligations under this Agreement and has creditworthiness similar to DISCOM and expressly assumes all obligations of DISCOM and is in a position to perform them;

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 265

SOLAR RFS BID DOCUMENT

or;

(v) If DISCOM is subject to any of the above defaults and DISCOM does not designate another DISCOM for purchase of Solar Power.

(vi) occurrence of any other event which is specified in this Agreement to be a material breach or default of DISCOM.

10.3 Procedure for cases of Solar Power Developer Event of Default

10.3.1 Upon the occurrence and continuation of any Solar Power Developer Event of Default under Clause 10.1, DISCOM shall have the right to deliver to the Solar Power Developer, with a copy to the representative of the lenders to the Solar Power Developer with whom the Solar Power Developer has executed the Financing Agreements, a notice stating its intention to terminate this Agreement (“DISCOM Preliminary Default Notice”), which shall specify in reasonable detail, the circumstances giving rise to the issue of such notice.

10.3.2 Within a period of seven (7) days following the expiry of the Consultation Period unless the parties shall have otherwise agreed to the contrary or the Solar Power Developer Event of Default giving rise to the Consultation Period shall have ceased to exist or shall have been remedied, DISCOM may terminate this Agreement by giving a written Termination Notice of thirty (30) days to the Solar Power Developer.

10.3.3 Subject to the terms of this Agreement, upon occurrence of a Solar Power Developer Event of Default under this Agreement, the lenders may exercise their rights, if any, under Financing Agreements, to seek substitution of the Solar Power Developer by a selectee for the residual period of the Agreement, for the purpose of securing the payments of the total debt amount from the Solar Power Developer and performing the obligations of the Solar Power Developer.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 266

SOLAR RFS BID DOCUMENT

Provided that any substitution under this Agreement can only be made with the condition that the selectee meets the eligibility requirements of RfS issued by DISCOM.

10.3.4 The lenders may seek to exercise right of substitution under Clause 10.3.3 by an amendment or novation of the Agreement in favour of the selectee. The Solar Power Developer shall cooperate with the lenders to carry out such substitution and shall have the duty and obligation to continue to operate the Project in accordance with this Agreement till such time as the substitution is finalized.

10.4 Procedure for cases of DISCOM Event of Default

10.4.1 Upon the occurrence and continuation of any DISCOM Event of Default specified in Clause 10.2 the Solar Power Developer shall have the right to deliver to DISCOM, a Solar Power Developer Preliminary Default Notice, which notice shall specify in reasonable detail the circumstances giving rise to its issue.

10.4.2 Following the issue of a Solar Power Developer Preliminary Default Notice, the Consultation Period of sixty (60) days or such longer period as the parties may agree, shall apply and it shall be the responsibility of the parties to discuss as to what steps shall be taken with a view to mitigate the consequences of the relevant DISCOM Event of Default having regard to all the circumstances.

10.4.3 During the Consultation Period, the parties shall continue to perform their respective obligations under this Agreement.

10.4.4 After a period of seven (7) days following the expiry of the Consultation Period and unless the parties otherwise agreed to the contrary or DISCOM Event of Default giving rise to the Consultation Period shall have ceased to exist or shall have been remedied, the Solar Power Developer shall be free to sell the Contracted Capacity to any third party of the Solar Power Developer’s choice.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 267

SOLAR RFS BID DOCUMENT

Provided further that at the end of three (3) months period from the period mentioned in this Clause 10.4.4, this Agreement may be terminated by the Solar

Power Developer.

10.5 Penalties in case of Delayed Commissioning Under normal circumstances the Project has to be commissioned within 12 months from the date of signing of this Agreement. In case of failing to achieve this milestone, DISCOM shall encash the Bank Guarantee in the following manner:

a) Delay up to one month from Scheduled COD: 2 lakhs/MW of capacity not commissioned. b) Delay of more than one month up to two months from Scheduled COD: 3 lakhs/MW of capacity not commissioned. c) Delay of more than two months up to four months from Scheduled COD: 5 lakhs/MW of capacity not commissioned. d) Delay of more than 4 months: i. In case of part commissioning, the Agreement shall be amended to reflect the capacity that has been commissioned. ii. Else, the Agreement stands terminated for unfulfilled obligation. For all other cases of Solar Power Developer Event of Default, procedure as provided in Clause 10.3 shall be applicable.

CPBG will be returned on COD. If commissioning does not happen within 15 months of signing this Agreement, the CPBG will be encashed.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 268

SOLAR RFS BID DOCUMENT

ARTICLE 11

DISPUTE RESOLUTION

11.1 Each party shall designate in writing to the other party a representative who shall be authorized to resolve any dispute arising under this Agreement in an equitable manner.

11.2 Following notice by one party to the other setting out the particulars of the dispute, if the designated representatives are unable to resolve a dispute under this Agreement within 15 days, such dispute shall be referred by such representatives to a senior officer designated by the Solar Power Developer and a senior officer designated by the DISCOM, respectively, who shall attempt to resolve the dispute within a further period of 15 days.

11.3 The parties hereto agree to use their best efforts to attempt to resolve all disputes arising hereunder promptly, equitably and in good faith and further agree to provide each other with reasonable access during normal business hours to any and all non- privileged records, information and data pertaining to any such dispute.

11.4 Failing resolution of the dispute in terms of the above provisions or even otherwise, any party may approach the APERC to resolve the dispute in terms of Section 86 (1) (f) of Electricity Act, 2003.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 269

SOLAR RFS BID DOCUMENT

ARTICLE 12

SPECIAL PROVISIONS

12.1 The waiver of any breach or failure to enforce any of the terms, covenants or conditions of this Agreement shall not in any way affect, limit, modify or waive the future enforcement of such terms, covenants or conditions.

12.2 No oral or written modification of this Agreement either before or after its execution shall be of any force or effect unless such modification is in writing and signed by the duly authorized representatives of the Solar Power Developer and the APTRANSCO/DISCOM, subject to the condition that any further modification of the Agreement shall be done only with the prior approval of APERC. However, the amendments to the Agreement as per the respective orders of APERC from time to time shall be carried out. All the conditions mentioned in the Agreement are with the consent of APERC.

12.3 However, in respect of power evacuation, the voltage levels for interfacing with grid will be as per Voltage of Delivery. The cost of Interconnection Facilities has to be borne by the Solar Power Developer as per Article 3.

12.4 The invalidity or unenforceability for any reason of any provision of this Agreement shall not prejudice or affect the validity or enforceability of any other provision of this Agreement.

12.5 The failure of any party to insist in one or more instances upon the strict performance of any of the provisions of this Agreement or to take advantage of any of its rights hereunder shall not be construed as a waiver of any such provisions or relinquishment of any such rights but the same shall continue in full force and effect.

12.6 Unless the context otherwise requires, every arrangement, procedure or any other matter which is, under any of the provisions of this Agreement, required to be mutually agreed upon between the parties, shall be concluded by a written Agreement between the parties not later than the date specified in the concerned clause of this Agreement, subject to the consent of the APERC.

12.7 This Agreement, including Schedule 1 attached hereto, constitute the entire agreement between the parties with respect to the subject matter hereof, and there are no oral or written understandings, representations or commitments of any kind, express or implied, not set forth herein.

12.8 The headings contained herein are included solely for the convenience of the parties and are not to be used as a basis for interpreting the various sections of this Agreement.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 270

SOLAR RFS BID DOCUMENT

12.9 The parties each agree to act in good faith in implementing the terms and conditions of this Agreement and in carrying out their respective obligations hereunder.

12.10 In the event of the merger or re-organization of DISCOM, if the resulting entity is able to perform DISCOM’s obligations hereunder in no less a manner than DISCOM, the resulting entity shall take the right and responsibility for performance of DISCOM’s obligations.

12.11 In the event of the merger or re-organization of Solar Power Developer if the resulting entity is able to perform Solar Power Developer’s obligations hereunder in no less a manner than Solar Power Developer, the resulting entity shall take the right and responsibility for performance of Solar Power Developer’s obligations.

12.12 Assignment and Financing: Neither party shall assign this Agreement or any portion thereof to any third party without the prior written consent of the other party which consent shall not be unreasonably withheld.

IN WITNESS WHEREOF, the Solar Power Developer and the DISCOM have caused this Agreement to be executed as on the date and the year first set forth above.

For and behalf of

______POWER DISTRIBUTION COMPANY

OF ANDHRA PRADESH LIMITED

WITNESS

1. By:

2. Its:

For and behalf of

M/s. WITNESS 1. By: 2. Its:

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 271

SOLAR RFS BID DOCUMENT

SCHEDULE 1

Particulars of the Project

(referred to in the Preamble to the Agreement)

NAME OF THE PROJECT LOCATION 33/11 kV TYPE OF PROJECT CAPACITY OF THE AND ADDRESS /EHT SUBSTATION (IF PROJECT (MW) APPLICABLE) SUBSTATION Solar Photo Voltaic/ M/s. Solar Thermal

* Out of ______MW, _____ is for Auxiliary Consumption and ______MW is for export to grid for sale to DISCOM.

*Note: Auxiliary Consumption of 0.1% is for for Solar PV and 10% is for Solar Thermal

SCHEDULE 2

Attach copy of Solar Power Policy announced by GoAP by competitive bidding route vide G.O.Ms No. 46 dated 27.11.2012.

SCHEDULE 3 Attach sanction copies of Solar Power plant, if any, from government authorities.

TRANSMISSION CORPORATION OF ANDHRA PRADESH LIMITED Page 272

Clarifications to the bidders for the queries on the “MODEL RFS BID DOCUMENT” for grid connected solar power projects issued by APTransco

Issue Bidder Queries Response

No of bids that a Can any company send in single RFS The bidder can bid for any company can for more than one station? number of locations. participate in/Max What is the maximum No. of The bidder should submit a capacity that can be applications by a company? different bid for each location. bid But, the bidder cannot submit more than one bid for a particular location. What is the maximum capacity that The maximum capacity for a can be bid by a bidder? bidder shall be limited to the capacities specified for each location. The „Maximum Cumulative Capacity that any bidder can bid across locations should not exceed 200 MW

Bidder Selection Methodology of L1 computation. The lowest quoted tariff for each location shall be considered as L1 for that particular location. Other bids in that location shall not be considered.

A single tariff for the entire agreement period should be quoted by the project developer and no escalation shall be given.

Bidders should not be asked to match L1 will be the successful bidder the L1 price but power contracted at for the location. the quoted tariff

No other bidders in that location will be considered

1 | P a g e

Will the tariff be modified later The tariff will not change over the entire agreement period

Processing When will the EMD of successful/ EMD will be returned to all Fee/EMD unsuccessful bidders be returned? unsuccessful bidders within 15 days of issue of LOI. For all successful bidders, EMD will be adjusted against the Performance Bank Guarantee What is the EMD Amount? What is EMD format will be enclosed in the format for EMD BG? the modified RfS

When should the processing fee be The project developer shall submit paid? Is the processing fee applicable non refundable processing fee of to each bid or each bidder? Rs. 2 Lakh along with RfS for each bid.

The processing fee will have to be paid separately for each bid.

Performance Bank When should the performance bank The Bank Guarantee of Rs. 10 Guarantee to be guarantee be submitted by the bidder? Lakh /MW has to be submitted at replaced with the time of signing of PPA. Three ‘Bank Guarantee’ separate BG's shall be submitted in the amounts of Rs. 2, 3 and 5 lakh /MW.

The bank guarantee is to ensure timely completion of the project. When should the contract CPBG has to be submitted before performance bank guarantee (CPBG) the LOI issue date. be submitted by the bidder? When is CPBG not required? If difference in price is less than 5%, then CPBG is not required.

The CPBG is to safeguard APTransco against any non- realistic bids.

2 | P a g e

When will the CPBG be encashed or CPBG will be returned on the date returned? of commissioning.

It will be encashed if the plant is not commissioned within 15 months from the signing of PPA

Should the bidder then submit Yes. The bidder has to submit multiple BG's for various locations or multiple bids for multiple one BG amounting to the total locations. The bidder also has to requirement? What about the submit multiple BG's and separate processing fee processing fee for each bid.

Benchmark Price Mechanism and time schedule Benchmark price shall be decided associated with determination of after opening the bids. This price Benchmark Price - When shall the will be determined by the committee. This will be uniform benchmark price be announced? across all the locations. Payment Security Payment Security Mechanism has not One month revolving Letter of Mechanism been included in the RfS Bid Credit Document.

Technology Can the SPD change PV technology Yes - Change of technology is after signing PPA? allowed subject to CUF ceiling for only solar related technology - after signing the PPA

Local Content Mandate? No such provision exists

Are trackers allowed? Yes The PLF of 25% for solar PV with trackers

3 | P a g e

CUF A ceiling CUF of 25% shall be considered for PV modules.

A ceiling CUF of 25% CUF shall be considered for Solar Thermal.

For the energy generation within the ceiling CUF, the tariff finalized for a location shall be payable. For any energy generation over and above the ceiling CUF, a flat tariff of Rs 3 per unit for the entire period of the agreement irrespective of the location shall be payable.

Shareholding Change in shareholding pattern? Yes.

Can 4 companies form a consortium Yes. It is for bidders to decide with 25% stake each and in such case about the lead member. who will be considered as lead member?

4 | P a g e

Penalty The Damages towards delay in Damages are on the capacity not commissioning is for the Total commissioned Capacity or the Capacity not . <1 month : Rs 2 lakh/MW of capacity not commissioned commissioned. . >1 month and <2 months : Rs 3 lakh/MW of capacity not commissioned . >2 month and <4 month: Rs 5 lakh/MW of capacity not commissioned . >4 months : . In case of part commissioning, the PPA shall be amended to reflect the capacity that has been commissioned . Else, the PPA stands terminated for unfulfilled obligation What is the penalty in case of less No penalties for under generation than 80% of expected generation

In case of shortfall in supply due If shortfall in supply of electricity is to grid unavailability, the due to grid unavailability, developer developer will not be penalized should not be penalized

Performance In page no 12, regarding COD it is Standard procedures of COD shall Acceptance mentioned performance acceptance be followed tests, will you declare what are those tests, who had to do, what are the related standard clause?

Plant Who will issue the Plant Concerned SE/CE Commissioning Commissioning Certificate

5 | P a g e

PV based power plant should be PV Plant should be commissioned commissioned within 6 months of within 12 months of signing the signing PPA which is too aggressive PPA.

However, there will be incentives provided for early commissioning. The incentive to be paid is as follows:

. 9 to 10 months : Rs 3 lakh/MW of capacity commissioned . 10 to 11 months : Rs 2 lakh/MW of capacity commissioned . 11 to 12 months : Rs 1 lakh/MW of capacity commissioned Plant commissioning proof to be Notice for readiness of the plant submitted to DISCOMS, for commissioning shall be given APTRANSCO one month before the at least one month before the Commissioning date COD.

PPA Draft PPA to be provided along with Yes. A copy of draft PPA shall be invitation for RfS provided along with invitation for submission of RfS

Is the PPA for 25 years irrevocable? Yes, PPA holds good for entire agreement period. The agreement period will be for 20 years.

After termination of PPA, can the No mid-course termination of developer still be connected to the PPA is allowed. However, on grid and sell power on a merchant expiration of PPA, the First right basis of refusal of the power shall remain with Discoms

Land and Water Water Requirement not asked for Responsibility of water lies with the developer.

6 | P a g e

When should details of land No land details are required to be ownership be provided submitted.

Financial Criteria Ambiguity prevails regarding the The company is required to submission of audited financial submit annual audited accounts records is for the last 4 years or 1 for the last four financial years (or year. if the period of existence of the Company is less than four Years, then starting from the year of incorporation) indicating the year which should be considered for evaluation along with a net worth certificate from a Chartered Accountant

Evacuation and Shall developer bear the cost related Yes. The bidder shall bear all Connectivity to transmission, evacuation etc responsibilities and costs associated with transmission, evacuation, right of way, bay extensions etc.

Financial Closure Too optimistic to expect financial Financial closure within 180 days closure within 60 days of signing from the date of signing of PPA PPA

Timelines RfS states technical and financial bid Technical bid will be opened first would be opened on the same day but and the financial bids will be financial bids of only shortlisted opened subsequently for the bidders would be opened successful technical bids

What is the date of bid submission 30 days from the modified RfS date Miscellaneous Payment to bidder in case grid Maximum care will be taken by network is unavailable to accept the APTRANSCO for availability of power transmission network. Since APTRANSCO is not levying any penalty for under-generation, no penalty shall be paid by APTRANSCO in case of non availability of grid network.

7 | P a g e

Allocation in case of two bidders Bidders shall both be awarded the quoting same price, both L1 project subject to maximum capacity per location.

In case the maximum capacity at the location is exceeded, then the prorated capacity shall be awarded in the ratio of offered capacity by the bidders. Taxes, Duties, Cess, Accelerated It is the bidder‟s responsibility to Depreciation and other Special account for all incentives/costs Incentives/Costs granted to renewable energy projects.

Connectivity at the 11 KV level is No.List of substations has been allowed? provided and connection is only allowed to substations in the list

Can a bid be made for locations other No than those specified?

Does the bidder pay for the No connectivity application processing fee also?

Is the project capacity mentioned an The capacity is considered as AC AC capacity or DC capacity? capacity

What are the statutory clearances List of necessary clearances required to be obtained by the bidder? should be obtained and responsibility lies with the Developer.

Is the interconnection point at Busbar substation the bus bar or C&R panel?

Is the developer allowed to take a No. separate auxiliary power connection for the project?

8 | P a g e

Why is number of responses limited The bid criteria will applicable to only for a “Company” and not for all bidders. Please refer modified “firm/society/association”? Does this RFS mean that a firm/society/association can submit alternate bids in the same location? Can one person float a company and a firm and bid in the name of company and firm for the same location? Wouldn‟t that be alternate bids for same location and violate the spirit?

If for suppose at a substation if before Both are independent schemes and the bidding process, if there is a will not be linked with each other. private developer who is setting up a This bidding process is meant for power plant on the rec mechanism, selection of developers for setting who would be given the first up solar capacity under the PPA preference to inject the power in to route under competitive bidding the grid, is it going to be the route with APDiscoms for each successful bidder or the private location developer on the rec route.

What if separation of State happens It will be accordingly addressed after PPA then in the PPA

The capacity mentioned to generate Installed Capacity solar power as per annexure - A is it installed capacity or solar power generated capacity which is about 20% PLF on installed capacity.

9 | P a g e

It has been understood that at a given Processing fee will not be substation, even if I am the lowest refunded. bidder, my bid price is higher than the bench mark figure I have to go with the bench mark figure or have to quit. In this case will I be refunded my BG and application fees as I was the lowest bidder in this scenario but was not happy with the bench mark figure. Yes I understand that if multiple bidders are there then I would be automatically refunded the amount but here what if I am the only bidder at that substation?

As per Section 2, under the definition Procedures of COD will be of COD, it is stated that “Solar Power applicable. Producer shall not declare a generating unit to be operationalize until such generating unit has completed its performance acceptance test as per standard prescribed”. What is the standard since it has not been prescribed anywhere?

As per clause 3.5-C, The bidder is Evidence of one year completion required to undertake to furnish of successful operation in India evidence of meeting commercially will have to be provided. established solar PV technology. What sort of evidence required in this?

10 | P a g e

The Rajasthan Electricity Regulatory This is an order issued by the Commission (RERC) had tried to RERC. APDiscoms will file with bring in regulations for RE based APERC Power Projects for competitive bidding. The Commission backed out on this front as it was in conflict with the provisions of Electricity Act, 2003, Section 63 which is as given below. You may have a look at the RERC website for the order issued by the RERC on this issue.

What would be the legal status of the The benchmark tariffs to be Committee who will decide the tariffs determined by the committee will for awards as only the Commission be used only for comparison of has the right to award the tariff as per competitiveness of the tariffs regulations. Even, the Government received in the bid process does not have the authority to determine the tariff as per Electricity Act, 2003. So, how come tariffs decided by the Committee will be accepted as it does not have any legal authority or the legal sanctity.

Does capacity limit at a substation This limit is the maximum refer to Transformer Capacity of injectable capacity of the “Proposed Anticipated Generation”? particular sub station as per system studies.

What are the provisions for This will be as per the PPA Compensation/Termination in case of Force Majeure?

11 | P a g e

In sub-clause (b) it is mentioned that The SPD has to pay all relevant the Developer has to do O&M of charges according to procedures power evacuation line also. Does this of APTRANSCO/ DISCOM mean that if a developer chooses to build the transmission line on his own then he need not pay any supervision charges? In our limited knowledge we understand that supervision charges are collected as certain % of capital cost because once the line is built the line is handed over to concerned licensee and the O&M is then taken care of licensee. Please clarify if our understanding is incorrect.

12 | P a g e

GOVERNMENT OF ANDHRA PRADESH ABSTRACT

Energy Department - Purchase of solar power by DISCOMs Policy- orders – Issued.

ENERGY (RES-A1) DEPARTMENT

G.O.Ms. No. 46 Dt.27-11-2012. Read the following.

1. G.O.Ms. No. 39, Energy (RES-A1) Department, Dt. 26-09-2012. 2. G.O. Rt. No.1663, G.A (Cabinet) Deptt, dt 16-04-2012. *******

ORDER:

State Government have issued policy guidelines vide G.O 1st read above for production of Solar Power by Private developers for captive use and sale to third party within the state and also for sale of Solar Power to DISCOMs at pooled cost. However, there was no provision for sale of solar power to DISCOMs at regulated price.

2. Group of Ministers was constituted vide G.O 2nd read above to suggest ways to encourage the generation of Power through non- Conventional sources including Solar in view of the prevailing power deficit in the State. Group of Ministers after detailed deliberations has recommended various actions and one of the recommendations regarding encouraging generation of solar power is purchase of solar power by APDISCOMs from the developers at a price to be determined through a process of competitive bidding. Group of Ministers also recommended that State should plan for setting up of 2000 MW of solar power plants under this route with a condition that 1000 MW plants will be set up before June, 2013. DISCOMs would list out industries who are willing to purchase solar power at the rate decided through the process of competitive bidding. However, incase all the procured solar power is not utilized by the willing industries, the State Government would bear the financial burden arising out of purchase of such solar power.

3. Government after careful examination of the recommendations of the Group of Ministers order as follows:

(i) DISCOMs will ensure that 1,000 MW of Solar Power Plants is set up before June,2013. (ii) DISCOMs shall select Solar Power developers through the process of competitive bidding. (iii) DISCOMs should include the cost of Solar Power in their filing with APERC. To the extent not covered by tariff the extra cost to be recovered through sale to the industries at the rate at which it is procured. (iv) DISCOMs will prepare the list of industries willing to purchase such solar power at the rate arrived through process of competitive bidding. State Government will finance the differential cost over and above the rate fixed by APERC (or pooled cost till the rate is decided by APERC) for the purchase of solar power by DISCOMs over and above power not purchased by the Industries.

Cntd. P.2

-2-

4. CMD, APTRANSCO will conduct bidding process duly notifying 132/33/11 KV sub-station near which developers can develop their solar power unit to facilitate easy evacuation. Solar developers would be required to offer their bids and quantum of power proposed to be sold to the DISCOMs at the notified locations.

5. CMD, APTRANSCO will develop bidding document for selection of developers through the process of competitive bidding. The bidding document should contain provision to check non- serious bidding or frivolous bids. The bidding time should be appropriately decided to ensure wider participation and there shall be a pre- bid conference to hear the points or difficulties of potential bidders for addressing them in a suitable manner before final bid is received.

6. Chairman, APPCC, CMD, APTRANSCO are requested to take necessary action accordingly.

7. This issues with the concurrence of Finance Department vide their U.O.No 213/PF.I/2012: dt. 24-11-2012.

(BY ORDER AND IN THE NAME OF THE GOVERNOR OF ANDHRA PRADESH)

MRUTUNJAY SAHOO PRINCIPAL SECRETARY TO GOVERNMENT

To

The C&MD AP TRANSCO, Hyderabad. The C&MD of All DISCOMs The VC&MD, NREDCAP. The MD. AP GENCO The Secretary to APERC The PFS/ PFS(IF)/PFS(R& E)

Copy to: P.S to Secretary to Hon’ble C.M. P.S to Hon’ble Minister for Finance. P.S to Principal Secretary to Government, Energy. P.A to Special Secretary to Government, Energy. S.F/SC ( C.No.4244/RES-A1/2012)

// FORWARDED: BY ORDER//

SECTION OFFICER